oral argument not yet scheduled - the … · oral argument not yet scheduled no. 17 ... have...
TRANSCRIPT
ORAL ARGUMENT NOT YET SCHEDULED
No. 17-5132, 17-5161, 17-5174, and 17-5175 (Consolidated)
UNITED STATES COURT OF APPEALS
FOR THE DISTRICT OF COLUMBIA CIRCUIT
JOHN M. FITZGERALD, ET AL.,
Plaintiffs-Appellees/Cross-Appellants,
v.
FEDERAL TRANSIT ADMINISTRATION, ET AL.,
Defendants-Appellants/Cross-Appellees,
STATE OF MARYLAND,
Intervenor Defendant-Appellant/Cross-Appellee.
On Appeal from the United States District Court
for the District of Columbia
Case No. 1:14-cv-01471 (Hon. Richard J. Leon)
AMICUS CURIAE BRIEF OF AMERICAN ROAD & TRANSPORTATION
BUILDERS ASSOCIATION IN SUPPORT OF DEFENDANTS-
APPELLANTS FOR REVERSAL OF DISTRICT COURT
James M. Auslander (counsel of record) Nick Goldstein, Esq.
Gus B. Bauman American Road & Transportation
BEVERIDGE AND DIAMOND, P.C. Builders Association
1350 I Street, N.W., Suite 700 250 E Street, S.W., Suite 900
Washington, DC 20005-3311 Washington, DC 20024
(202) 789-6009 (202) 683-1005
[email protected] [email protected]
Attorneys for Amicus Curiae American Road
& Transportation Builders Association
Dated: August 23, 2017
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 1 of 26
(Page 1 of Total)
- ii -
CIRCUIT RULE 28(A)(1) CERTIFICATE AS TO PARTIES, RULINGS,
AND RELATED CASES
Parties and Amici: Except for the American Road & Transportation
Builders Association (“ARTBA”), all parties, intervenors, and amici appearing
before the district court and in this court are listed in the opening brief for
Defendants-Appellants Federal Transit Administration (“FTA”), et al.
Rulings under Review: References to the rulings at issue appear in the
opening brief for Defendants-Appellants FTA, et al.
Related Cases: This consolidated case is on appeal from the United States
District Court for the District of Columbia, No. 14-1471 (RJL), Friends of the
Capital Crescent Trail, et al. v. Federal Transit Administration, et al. This case has
not previously been before this Court. Counsel is not aware of any related cases
involving substantially the same parties and the same or similar issues pending
before this Court or any other court.
Dated: August 23, 2017 /s/ James M. Auslander
James M. Auslander
BEVERIDGE & DIAMOND, P.C.
Attorney for Amicus Curiae ARTBA
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 2 of 26
(Page 2 of Total)
- iii -
WRITTEN REPRESENTATION OF CONSENT
ARTBA represents that all parties have consented to the filing of this brief
by ARTBA as amicus curiae. ARTBA further certifies that no party’s counsel
authored this brief in whole or in part; no party or party’s counsel contributed
money intended to fund preparing or submitting the brief; and no person other than
ARTBA and its members contributed money intended to fund preparing or
submitting the brief.
Dated: August 23, 2017 /s/ James M. Auslander
James M. Auslander
BEVERIDGE & DIAMOND, P.C.
Attorney for Amicus Curiae ARTBA
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 3 of 26
(Page 3 of Total)
- iv -
CORPORATE DISCLOSURE STATEMENT
Pursuant to Rule 26.1 of the Federal Rules of Appellate Procedure, and
Circuit Rule 26.1, amicus curiae ARBTA states (a) that it is a District of Columbia
nonprofit trade organization that represents the collective interests of the U.S.
transportation construction industry before the national executive, legislative, and
judicial branches of government; (b) that it is an umbrella group for more than
7,500 members from all sectors and modes of the transportation construction
industry (including without limitation roads, public transit, airports, ports, and
waterways); and (c) that it has no parent corporations and that no publicly held
company owns any stock in it.
Dated: August 23, 2017 /s/ James M. Auslander
James M. Auslander
BEVERIDGE & DIAMOND, P.C.
Attorney for Amicus Curiae ARTBA
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 4 of 26
(Page 4 of Total)
- v -
CERTIFICATE IN SUPPORT OF SEPARATE BRIEF
Pursuant to D.C. Circuit Rule 29(d), undersigned counsel certifies that a
separate brief is necessary. All of the Defendants-Appellants in this case are
federal and state governmental entities, and the amici curiae in the district court
below were local government entities. Amicus curiae ARTBA represents the
private transportation construction industry and its unique interests in timely,
orderly, and efficient project development. By providing industry perspective and
experience to place the district court’s decisions on appeal into their appropriate
broader context, ARTBA is well situated to assist this Court in rendering its
decision.
Dated: August 23, 2017 /s/ James M. Auslander
James M. Auslander
BEVERIDGE & DIAMOND, P.C.
Attorney for Amicus Curiae ARTBA
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 5 of 26
(Page 5 of Total)
- vi -
TABLE OF CONTENTS
CIRCUIT RULE 28(A)(1) CERTIFICATE AS TO PARTIES, RULINGS,
AND RELATED CASES ......................................................................................... II
WRITTEN REPRESENTATION OF CONSENT .................................................. III
CORPORATE DISCLOSURE STATEMENT ...................................................... IV
CERTIFICATE IN SUPPORT OF SEPARATE BRIEF ......................................... V
TABLE OF AUTHORITIES ................................................................................. VII
GLOSSARY OF ACRONYMS AND ABBREVIATIONS................................. VIII
STATEMENT OF INTEREST ............................................................................... IX
STATEMENT OF ISSUES PRESENTED................................................................ 1
SUMMARY OF ARGUMENT ................................................................................. 1
ARGUMENT ............................................................................................................. 3
I. The District Court’s Opinion on Public Transit Ridership Does Not
Implicate NEPA. .............................................................................................. 3
II. The Ruling Below Would Deter and Obstruct Critical Transportation
Projects............................................................................................................. 8
CONCLUSION ........................................................................................................ 14
CERTIFICATE OF COMPLIANCE OF BRIEF .................................................... 16
CERTIFICATE OF SERVICE ................................................................................ 17
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 6 of 26
(Page 6 of Total)
- vii -
TABLE OF AUTHORITIES
CASES
Grunewald v. Jarvis,
776 F.3d 893 (D.C. Cir. 2015)............................................................................... 6
Metro. Edison Co. v. People Against Nuclear Energy,
460 U.S. 766 (1983) ..........................................................................................6, 8
Nat’l Comm. for the New River v. FERC,
373 F.3d 1323 (D.C. Cir. 2004)............................................................................. 7
Statutory Authorities
42 U.S.C. § 4332(2)(C) .............................................................................................. 4
Rules and Regulations
23 C.F.R. § 771.130(a)(2) .......................................................................................... 4
23 C.F.R. § 771.130(c) ............................................................................................... 5
40 C.F.R. § 1502.9(c)(1)(ii) ....................................................................................... 4
40 C.F.R. § 1508.11 ................................................................................................... 4
40 C.F.R. § 1508.14 ...................................................................................................6
Other Authority
Exec. Order No. 13807, Establishing Discipline and
Accountability in the Environmental Review and
Permitting Process for Infrastructure, § 2(f) (Aug. 15, 2017) .................................... 9
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 7 of 26
(Page 7 of Total)
- viii -
GLOSSARY OF ACRONYMS AND ABBREVIATIONS
Pursuant to D.C. Circuit Rule 28(a)(3), the following is a glossary of
acronyms and abbreviations used in this brief.
ARTBA American Road & Transportation Builders Association
EIS Environmental Impact Statement
FTA Federal Transit Administration
JA Joint Appendix
NEPA National Environmental Policy Act
P3 Public-Private Partnership
SEIS Supplemental Environmental Impact Statement
WMATA Washington Metropolitan Area Transit Authority
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 8 of 26
(Page 8 of Total)
- ix -
STATEMENT OF INTEREST
This matter involves a challenge to a public-private partnership (“P3”)
transit project by and in the State of Maryland known as the Purple Line. ARTBA
regularly participates in litigation that impacts transportation projects. ARTBA
supports the Purple Line and similar P3 and non-P3 transportation projects.
Founded in 1902, ARTBA’s membership includes private and public sector
members that are involved in the planning, designing, construction and
maintenance of the nation’s roadways, bridges, ports, airports, and transit systems.
The transportation construction industry generates more than $380 billion annually
in U.S. economic activity and sustains more than 3.3 million American jobs.
ARTBA maintains ongoing and thorough involvement in federal legislative,
policy, regulatory, and legal developments relating to transportation infrastructure
development and investment. This includes P3s in transportation, with which
ARTBA has a long history. ARTBA’s P3 Division dates back nearly 30 years and
includes prominent concessionaires, planning and design firms, contractors,
financial entities, and other parties in the P3 field.
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 9 of 26
(Page 9 of Total)
STATEMENT OF ISSUES PRESENTED
ARTBA adopts the statement of issues set forth in the opening brief of
Defendants-Appellants FTA, et al.
SUMMARY OF ARGUMENT
This case involves a non-environmental policy disagreement masquerading
as a National Environmental Policy Act (“NEPA”) claim against a critical State of
Maryland transit project known as the Purple Line. Appellees in Chevy Chase,
Maryland dislike the project and challenged a federal approval for it. The district
court held, correctly, that “[t]he law only requires that defendants take a ‘hard
look’ at the project’s environmental impacts during the NEPA process, and it is
clear to me that they did so.” Joint Appendix (“JA”) 935. The district court denied
all of Appellees’ environmental claims under NEPA and other statutes.
That dismissal should have fully disposed of Appellees’ NEPA claim. The
district court further acknowledged that it “may not substitute its judgment for that
of [the] agency.” JA822-823. But then it did the opposite. Though finding no
issue with the government’s environmental analysis, the district court questioned
the wisdom and cost-effectiveness of the light-rail Purple Line based solely on
perceived safety and ridership concerns with Metrorail, a heavy-rail system that
does not include the Purple Line. In essence, the district court asked whether the
Purple Line would carry enough people to be worth its cost in that court’s view.
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 10 of 26
(Page 10 of Total)
- 2 -
The district court then styled its policy reservations as a novel NEPA violation.
But the project’s merit has nothing to do with NEPA’s assessment of
environmental impacts. Whether Purple Line light-rail cars carry 100 riders or 50
riders has no bearing on the physical footprint of the project. NEPA cannot be
used to justify on ridership grounds the blocking of a contracted critical
infrastructure project that received a federal approval after, as the district court
concedes, exhaustive environmental study under NEPA.
The Purple Line, a project 29 years in the making, is one of the first P3
transit projects in the nation. It has painstakingly complied with NEPA and other
applicable federal, State, and local laws and duly adopted plans. It has
overwhelming support by the general public of Montgomery and Prince George’s
Counties. Construction is finally imminent. Yet, the district court’s lengthy delays
and unprecedented application of NEPA imperil the whole project. Only this
Court can apply NEPA correctly so that this long-needed, fully vetted, P3
transitway may be fully realized and open its light-rail train doors to all in 2022.
The import of the ruling below is not limited to Maryland’s Purple Line.
Unless reversed, this precedent also will have adverse consequences for complex
transportation and related infrastructure projects across the country. Allowing a
court – at the culmination of years of environmental reviews and planning – to
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 11 of 26
(Page 11 of Total)
- 3 -
superimpose its own views on whether a given project is good policy or cost-
effective is not only wholly inappropriate legally but also would create significant
uncertainty for ARTBA and its members by threatening carefully planned project
funding, schedules, and construction. Particularly for P3s, the district court’s
holding injects new delay and litigation risks, thereby stifling the growth of this
key financing mechanism to leverage and combine governmental and private
dollars and responsibilities to meet the nation’s exigent transportation needs. The
district court’s grant of partial summary judgment to Appellees should be reversed.
ARGUMENT
I. THE DISTRICT COURT’S OPINION ON PUBLIC TRANSIT
RIDERSHIP DOES NOT IMPLICATE NEPA.
The proceedings below largely focused on whether the government’s NEPA
review for the Purple Line already had adequately considered information on
Metrorail’s own ridership and safety, or must be supplemented to do so. But the
Court need not reach that question because those subjects are beyond the scope of
required NEPA review. NEPA calls for a hard look at the environmental impacts
of a federal agency action, and the district court unequivocally has held – twice –
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 12 of 26
(Page 12 of Total)
- 4 -
that the government did that here.1 In short, nothing remains under NEPA that
could warrant more agency studies and unnecessary delays that place the entire
Purple Line project at funding risk (thereby serving Appellees’ ultimate goal of
killing the project through added delay and cost).
The district court acknowledged that under NEPA, “[t]he Court’s obligation
is simply to determine that the agency has taken a hard look at the project and has
adequately considered and disclosed the environmental impact of its actions.”
JA934 (internal citation omitted). That is because the National Environmental
Policy Act requires, for major federal actions “significantly affecting the quality of
the human environment,” preparation of an Environmental Impact Statement
(“EIS”), detailing “the environmental impact of the proposed action” (emphases
added). 42 U.S.C. § 4332(2)(C); 40 C.F.R. § 1508.11. Similarly, a Supplemental
EIS (“SEIS”) is triggered by new information “relevant to environmental
concerns” and that “would result in significant environmental impacts not
evaluated in the EIS” (emphases added). 40 C.F.R. § 1502.9(c)(1)(ii); 23 C.F.R.
§ 771.130(a)(2). Moreover, “environmental studies” may be performed to
1 The district court properly dismissed Appellees’ environmental claims for the
reasons stated in the district court’s opinions dated June 9, 2017, and July 31,
2017, and in the opening appellate briefs by the federal government and by the
State of Maryland. As amicus, ARTBA will not repeat those arguments here.
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 13 of 26
(Page 13 of Total)
- 5 -
determine if a Supplemental EIS is necessary. 23 C.F.R. § 771.130(c) (emphasis
added).
As it detailed in two opinions, the district court is “convinced” that the
government adequately considered all environmental impacts.2 Appellees’ NEPA
claims thus fail. Nonetheless, the district court went on to speculate that Metrorail
ridership might collapse, and then faulted the government for not supplementing its
EIS to address how the Purple Line’s own ridership might be affected in turn.
But the Washington Metropolitan Area Transit Authority’s (“WMATA”)
Metrorail ridership and safety do not trigger an SEIS for Maryland’s Purple Line
transitway. The opinions below fail to identify any potential environmental
impacts related to the Metrorail information. The district court, citing to no
pertinent legal authority, assumes that such a Metrorail ridership “impact” or
“effect” requires a “hard look,” but nowhere explains its flawed premise that this is
a NEPA issue in the first place.3 It is not.
2 JA935 (“I am convinced that the FTA reasonably considered and [sic] the
project’s possible alternatives and has carefully considered the environmental
impacts of the project.”); JA1017 (“defendants had, in my judgment, taken a ‘hard
look’ at the Purple Line’s environmental impacts during the NEPA process”).
3 E.g., JA819-820 (district court describing “overarching issue” as “the necessity
of an SEIS addressing the potential impact of WMATA’s ridership and safety
issues”).
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 14 of 26
(Page 14 of Total)
- 6 -
Ridership and other economic concerns do not trigger NEPA where, as here,
they are unrelated to environmental impacts. The regulatory definition of “human
environment” relevant under NEPA declares that “economic or social effects are
not intended by themselves to require preparation of an environmental impact
statement.” 40 C.F.R. § 1508.14. An ongoing EIS discusses economic or social
effects when “natural or physical environmental effects are interrelated.” Id.
Consistently, the Supreme Court and this Court have made clear that NEPA
“does not require the agency to assess every impact or effect of its proposed action,
but only the impact or effect on the environment” – specifically “the physical
environment.” Metro. Edison Co. v. People Against Nuclear Energy, 460 U.S.
766, 772 (1983) (emphasis in original).4 “If a harm does not have a sufficiently
close connection to the physical environment, NEPA does not apply.” Id. at 778
(“psychological health and community well-being of residents of the surrounding
area” was not within proper scope of NEPA review for nuclear power plant
permit); Grunewald v. Jarvis, 776 F.3d 893, 907 (D.C. Cir. 2015) (agency need not
consider psychological harm in NEPA review for plan to cull deer in Rock Creek
Park). Likewise, an SEIS is warranted only when “new information provides a
4 Highlighting its error, the district court relied upon the lower ruling in that case
that was reversed by the Supreme Court. JA0667, n.2.
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 15 of 26
(Page 15 of Total)
- 7 -
seriously different picture of the environmental landscape.” Nat’l Comm. for the
New River v. FERC, 373 F.3d 1323, 1330 (D.C. Cir. 2004) (emphasis in original)
(no SEIS required for natural gas pipeline approval).
The district court invoked this SEIS standard but then ignored “of the
environmental landscape.” JA824. There is not even an allegation in this case that
any “effect” the district court believed the government failed to consider would
interrelate with the physical environment. Indeed, the footprint of the Purple
Line’s light-rail tracks, stations, and other physical elements are wholly
independent of how many people ultimately ride in each car. What is more,
Defendants-Appellants here went above and beyond NEPA’s requirements and
responded to the district court by performing an assessment of different Metrorail
scenarios, which found no meaningful impact on Purple Line operations because
the project would not physically change at all.5
At base, the district court openly queried whether Purple Line ridership
justifies its cost per passenger, including to taxpayers. This is not and cannot be
grounds for a NEPA violation. Moreover, this plainly exceeds the district court’s
5 If Metrorail safety and ridership were within the scope of NEPA (which they are
not), ARTBA concurs with the federal government and State opening appellate
briefs that Appellees did, in fact, sufficiently consider such information in the
record and appropriately declined to prepare an SEIS.
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 16 of 26
(Page 16 of Total)
- 8 -
own articulation of its limited standard of review. It is not a court’s role to second-
guess the economic projections of expert agencies, the policy views of officials at
the local, State, and federal levels, and widespread public support in the two
Maryland counties where the project is located. See Metro. Edison, 460 U.S. at
777 (“Neither the language nor the history of NEPA suggest that it was intended to
give citizens a general opportunity to air their policy objections to proposed federal
actions. The political process, and not NEPA, provides the appropriate forum in
which to air policy disagreements.”). The district court erred in not dismissing
Appellees’ NEPA claim in toto, and this Court should reverse that ruling.
II. THE RULING BELOW WOULD DETER AND OBSTRUCT
CRITICAL TRANSPORTATION PROJECTS.
As evidenced by this amicus brief on behalf of the broader transportation
construction industry, this case is being watched not only by those with a direct
stake in the Purple Line. The precedent created by the district court’s ruling also
would dim the prospects for pending and future critical transportation projects. If
plaintiffs or courts can upend the culmination of the onerous NEPA process for
economic or policy reasons having nothing to do with the environment, the ensuing
uncertainty and delay would discourage public and private investment needed to
rebuild and improve the country’s transportation infrastructure. These concerns
are particularly heightened for P3s, which are central to modern infrastructure
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 17 of 26
(Page 17 of Total)
- 9 -
financing and development.
It is a well-known fact that the United States’ transportation system,
including transit, is in disrepair and in desperate need of substantial upgrades. In
the 2016 campaign, both Republicans and Democrats championed a renewed focus
and targeted investment in infrastructure. The current Administration, like others
before it, has undertaken multiple efforts to improve the timeliness of the
environmental review process. Most recently, an August 15, 2017 Executive
Order declared a national policy “to conduct environmental reviews and
authorization processes in a coordinated, consistent, predictable, and timely
manner in order to give public and private investors the confidence necessary to
make funding decisions for new infrastructure projects,” including transit and other
modes of surface transportation.6
ARTBA and its members are on the front lines delivering transportation
projects. More recently, P3s have gained increasing prominence in successfully
leveraging combined public and private resources to implement these needed
6 Exec. Order No. 13807, Establishing Discipline and Accountability in the
Environmental Review and Permitting Process for Infrastructure,
§ 2(f)) (Aug. 15, 2017), https://www.whitehouse.gov/the-press-
office/2017/08/15/presidential-executive-order-establishing-discipline-and-
accountability.
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 18 of 26
(Page 18 of Total)
- 10 -
transit systems, roads, bridges, and other projects. ARTBA’s P3 Division dates
back nearly 30 years and includes prominent concessionaires, planning and design
firms, contractors, financial entities, and other parties in the P3 field.
While there are several types of P3s that vary in scope, their core feature is
the sharing of responsibility and risk between the public (State or local) project
sponsor and private entities in some or all of designing, building, financing,
operating, and maintaining the project. P3s rely on legislative authorization by the
individual States. Between 1989 and 2011, 24 states and the District of Columbia
have used a P3 process to achieve at least 96 transportation projects worth a total
$54.3 billion.7 In the past three and a half years, 37 surface transportation-related
P3 projects were brought to financial close in the U.S., totaling $31.55 billion in
investment.8
The Purple Line is one of the first P3 transit projects in the nation, and the
first in the State of Maryland. Maryland enacted comprehensive amendments to its
7 William Reinhardt, The Role of Private Investment in Meeting U.S.
Transportation Infrastructure Needs, Transp. Dev. Found., at 8 (May 2011),
http://www.pwfinance.net/document/research_reports/0%20artba.pdf (“Reinhardt
Report”) (executive summary attached in Addendum).
8 Public Works Financing, International Major Projects Database (2017) (excerpts
attached in Addendum).
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 19 of 26
(Page 19 of Total)
- 11 -
P3 legislation in 2013.9 The Purple Line is among seven transit projects that have
come to financial close since 2014, totaling $9.57 billion.10
Other transit P3
projects across the country are currently in the planning pipeline.
Any P3 entails a lengthy, complex, and arduous process.11
First, P3 project
sponsors (often State, regional, or local transportation agencies) must build
significant community, political, and legislative support for their efforts. Then,
careful consideration and negotiation must go into the planning, permitting,
procurement, design, building, financing, operation, and maintenance for the multi-
decade anticipated life of a P3 project, as well as the corresponding allocation of
responsibility and risk among the parties to a P3. To ensure integrity, the public
sponsor for a project typically must conduct a lengthy, transparent, and competitive
solicitation before selecting a P3 project development team. Other complicating
factors for a P3 agreement include, but are not limited to, the terms of financing
(debt or equity), availability and means of public financing or credit assistance,
tolling (existence and rates), project duration, public sponsor buyback options,
9 H.D. 560, 443
rd Sess. (Md. 2013).
10 Public Works Financing, International Major Projects Database (2017) (excerpts
attached in Addendum).
11 See, generally, Reinhardt Report (more fully describing obstacles for
establishing and implementing a P3).
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 20 of 26
(Page 20 of Total)
- 12 -
taxation, and performance monitoring.
The key import of all these moving parts is that P3s take enormous time, and
effort, and thus certainty is paramount. The Purple Line, for example, took
approximately two years from inception of the Maryland P3 process until selection
of a P3 development team. The P3 selection process, and the parallel NEPA
review, yield project schedules that must be met to control total costs and the
timing of those costs.
The lower court’s decisions on appeal by the United States and Maryland,
however, are anathema to this needed certainty. Instead, they inject new risks into
the 47-year-old NEPA process, whereby fully conducting all required
environmental reviews would no longer be sufficient. Rather, apart from any
environmental issue, a court reviewing the claims of any project opponent, at any
time, could proffer a different economic or political decision than the expert local,
regional, State, or federal agency proponent of the project, and remand for more
“NEPA review.”
Even if the end product of a remand should later satisfy a court, the costs of
such project delay can be substantial, even fatal. For example, interest rates may
change, rendering the same project more costly than before it was litigated.
Intervening elections could result in newly-elected officeholders who want to
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 21 of 26
(Page 21 of Total)
- 13 -
assess the project anew from their own unique perspective. In the interim,
continued or increasing transportation congestion in the region awaiting the new
project could result in increased travel times, wasted fuel, and foregone
opportunities for economic development. For P3 and non-P3 projects, a single
month of delay can increase project costs by 1.5% for a project costing $28.5-
$85.2 million.12
The Purple Line construction cost is more than $2 billion. In one
recent study of P3s, delays in obtaining government approvals or adverse changes
in the law were among the most significant factors in increasing project costs.13
The district court here has already occasioned significant delays and costs,
and if its unprecedented ruling is upheld, it would do the same for other planned
transit projects. An even more uncertain NEPA process will render P3s less
attractive to potential private partners. Ultimately, in Maryland and other states,
the rogue application of NEPA could result in hesitancy to undertake complex,
12
Curtis Beaty et al., Assessing the Costs Attributed to Project Delay During
Project Pre-Construction Stages, Rep. No. FHWA/TX-15/0-6806-FY 15 WR#3,
Tex. A&M Univ., at 2 (Mar. 2016),
https://static.tti.tamu.edu/tti.tamu.edu/documents/0-6806-FY15-WR3.pdf (excerpts
attached in Addendum).
13 Hemanta Doloi, Understanding Impacts of Time and Cost Related Construction
Risks on Operational Performance of PPP Projects, Int’l Journal of Strategic Prop.
Mgmt., vol. 16, no. 3, Sept. 2012, at 316, 325 (analyzing and weighting relative
risk factors on cost of P3 projects in Australia) (excerpts attached in Addendum).
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 22 of 26
(Page 22 of Total)
- 14 -
transformative transportation projects – whether through a P3 process or otherwise
– when the nation’s need for these long-planned projects is urgent. The lower
court’s opinions ordering an SEIS and vacating the Record of Decision are
incompatible both with the law and with the continued strength of P3s as a viable
alternative in the delivery of transportation improvement projects.
CONCLUSION
The public and private parties engaged in Maryland’s Purple Line have
expended many years, millions of dollars, and enormous energy into a legislated
P3 that serves as a model for financing, building, and operating future transit
projects nationwide. The desperately needed Purple Line is being challenged by a
parochial few in Chevy Chase, the location of just one of the Purple Line’s 21
stations knitting together communities along 16 miles between Bethesda and New
Carrollton. That obstruction and delay have been sustained by lower court rulings
that completely misconstrue NEPA’s fundamental purpose and requirements. For
the reasons set forth herein, ARTBA submits that the district court’s order of
partial summary judgment for Plaintiffs-Appellees should be reversed.
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 23 of 26
(Page 23 of Total)
- 15 -
Dated: August 23, 2017 Respectfully submitted,
/s/ James M. Auslander
James M. Auslander
Gus B. Bauman
BEVERIDGE & DIAMOND, P.C.
Attorneys for Amicus Curiae ARTBA
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 24 of 26
(Page 24 of Total)
- 16 -
CERTIFICATE OF COMPLIANCE OF BRIEF
I certify, pursuant to Fed. R. App. P. Rule 29(a)(4), that the foregoing brief
amicus curiae brief, complies with the type-volume limitation of Fed. R. App. P.
Rule 32(a)(7)(B) because, excluding the parts of the document exempted by Fed.
R. App. P. 32(f) and Circuit Rule 32(e)(1), this document contains 2,776 words, as
computed by Microsoft Word. This document complies with the typeface
requirements of Fed. R. App. P. 32(a)(5) and the type-style requirements of Fed. R.
App. P. 32(a)(6) because this document has been prepared in a proportionally
spaced typeface of Times New Roman, 14 points.
Dated: August 23, 2017 /s/ James M. Auslander
James M. Auslander
BEVERIDGE & DIAMOND, P.C.
Attorney for Amicus Curiae ARTBA
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 25 of 26
(Page 25 of Total)
- 17 -
CERTIFICATE OF SERVICE
I hereby certify that, on this 23rd day of August, 2017, the foregoing Amicus
Curiae Brief of American Road & Transportation Builders Association was served
(1) electronically through the Court’s CM/ECF system with the Court and all
registered counsel, and (2) hardcopy via hand delivery (original and eight copies)
with the Court.
Dated: August 23, 2017 /s/ James M. Auslander
James M. Auslander
BEVERIDGE & DIAMOND, P.C.
Attorney for Amicus Curiae ARTBA
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 26 of 26
(Page 26 of Total)
USCA Form 44March 2017 (REVISED)
v.
ENTRY OF APPEARANCE
Party Information(List each represented party individually - Use an additional blank sheet as necessary)
The Clerk shall enter my appearance as
Counsel Information
Notes: This form must be submitted by a member of the Bar of the U.S. Court of Appeals for the D.C. Circuit.Names of non-member attorneys listed above will not be entered on the court's docket. Applications foradmission are available on the court's web site at http://www.cadc.uscourts.gov/.
Case Caption:
Case No:
Appellant(s)/Petitioner(s) Appellee(s)/Respondent(s) Amicus CuriaeIntervenor(s)
Lead Counsel:
Email:
2nd Counsel:
3rd Counsel:
Firm Name:
Firm Address:
Direct Phone: ( ) Fax: ( )
Email:Direct Phone: ( ) Fax: ( )
Email:Direct Phone: ( ) Fax: ( )
Email:Firm Phone: ( ) Fax: ( )
UNITED STATES COURT OF APPEALS
DISTRICT OF COLUMBIA CIRCUIT333 Constitution Avenue, NWWashington, DC 20001-2866
Phone: 202-216-7000 | Facsimile: 202-219-8530
Retained Pro Bono Gov't counselAppointed (CJA/FPD)
for the below:
Fitzgerald, et al.
Federal Transit Administration, et al.
17-5132
American Road & Transportation
Builders Association
James M. Auslander, Bar No. 974898
Gus B. Bauman, Bar No. 234401
Beveridge & Diamond, P.C.
1350 I Street, N.W., Suite 700, Washington, D. C. 20005-3311
202 789-6009 202 789-6190
- -
789-6013 [email protected] 202 789-6190
789-6190202 789-6000 202
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 1 of 1
(Page 27 of Total)
STATUTORY, REGULATORY AND OTHER AUTHORITIES ADDENDUM
TABLE OF CONTENTS
42 U.S.C. § 4332 ......................................................................................................... A1
23 C.F.R. § 771.130 .................................................................................................... A4
40 C.F.R. § 1502.9 ....................................................................................................... A6
40 C.F.R. § 1508.11 ..................................................................................................... A8
40 C.F.R. § 1508.14 ..................................................................................................... A9
Exec. Order No. 13807, Establishing Discipline and
Accountability in the Environmental Review and
Permitting Process for Infrastructure (Aug. 15, 2017) ................................................ A10
Curtis Beaty et al., Assessing the Costs Attributed to
Project Delay During Project Pre-Construction Stages,
Rep. No. FHWA/TX-15/0-6806-FY 15 WR#3,
Tex. A&M Univ., (Mar. 2016) (excerpts) ................................................................... A20
Hemanta Doloi, Understanding Impacts of Time and
Cost Related Construction Risks on Operational Performance of
PPP Projects, Int’l Journal of Strategic Prop. Mgmt.,
vol. 16, no. 3, Sept. 2012. Pp. 316-337 (excerpts) ..................................................... A23
William Reinhardt, The Role of Private Investment in
Meeting U.S. Transportation Infrastructure Needs,
Transp. Dev. Found. (May 2011) (executive summary) ............................................. A25
Public Works Financing,
International Major Projects Database (2017) (excerpts) ............................................ A32
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 1 of 43
(Page 28 of Total)
§ 4332. Cooperation of agencies; reports; availability of..., 42 USCA § 4332
© 2017 Thomson Reuters. No claim to original U.S. Government Works. 1
United States Code AnnotatedTitle 42. The Public Health and Welfare
Chapter 55. National Environmental Policy (Refs & Annos)Subchapter I. Policies and Goals (Refs & Annos)
42 U.S.C.A. § 4332
§ 4332. Cooperation of agencies; reports; availability of information;recommendations; international and national coordination of efforts
Currentness
The Congress authorizes and directs that, to the fullest extent possible: (1) the policies, regulations, and public laws ofthe United States shall be interpreted and administered in accordance with the policies set forth in this chapter, and (2)all agencies of the Federal Government shall--
(A) utilize a systematic, interdisciplinary approach which will insure the integrated use of the natural and socialsciences and the environmental design arts in planning and in decisionmaking which may have an impact on man'senvironment;
(B) identify and develop methods and procedures, in consultation with the Council on Environmental Qualityestablished by subchapter II of this chapter, which will insure that presently unquantified environmental amenities andvalues may be given appropriate consideration in decisionmaking along with economic and technical considerations;
(C) include in every recommendation or report on proposals for legislation and other major Federal actionssignificantly affecting the quality of the human environment, a detailed statement by the responsible official on--
(i) the environmental impact of the proposed action,
(ii) any adverse environmental effects which cannot be avoided should the proposal be implemented,
(iii) alternatives to the proposed action,
(iv) the relationship between local short-term uses of man's environment and the maintenance and enhancement oflong-term productivity, and
(v) any irreversible and irretrievable commitments of resources which would be involved in the proposed actionshould it be implemented.
Prior to making any detailed statement, the responsible Federal official shall consult with and obtain the commentsof any Federal agency which has jurisdiction by law or special expertise with respect to any environmental impactinvolved. Copies of such statement and the comments and views of the appropriate Federal, State, and local agencies,
A1
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 2 of 43
(Page 29 of Total)
§ 4332. Cooperation of agencies; reports; availability of..., 42 USCA § 4332
© 2017 Thomson Reuters. No claim to original U.S. Government Works. 2
which are authorized to develop and enforce environmental standards, shall be made available to the President, theCouncil on Environmental Quality and to the public as provided by section 552 of Title 5, and shall accompany theproposal through the existing agency review processes;
(D) Any detailed statement required under subparagraph (C) after January 1, 1970, for any major Federal actionfunded under a program of grants to States shall not be deemed to be legally insufficient solely by reason of havingbeen prepared by a State agency or official, if:
(i) the State agency or official has statewide jurisdiction and has the responsibility for such action,
(ii) the responsible Federal official furnishes guidance and participates in such preparation,
(iii) the responsible Federal official independently evaluates such statement prior to its approval and adoption, and
(iv) after January 1, 1976, the responsible Federal official provides early notification to, and solicits the views of,any other State or any Federal land management entity of any action or any alternative thereto which may havesignificant impacts upon such State or affected Federal land management entity and, if there is any disagreementon such impacts, prepares a written assessment of such impacts and views for incorporation into such detailedstatement.
The procedures in this subparagraph shall not relieve the Federal official of his responsibilities for the scope,objectivity, and content of the entire statement or of any other responsibility under this chapter; and further, thissubparagraph does not affect the legal sufficiency of statements prepared by State agencies with less than statewide
jurisdiction. 1
(E) study, develop, and describe appropriate alternatives to recommended courses of action in any proposal whichinvolves unresolved conflicts concerning alternative uses of available resources;
(F) recognize the worldwide and long-range character of environmental problems and, where consistent with theforeign policy of the United States, lend appropriate support to initiatives, resolutions, and programs designedto maximize international cooperation in anticipating and preventing a decline in the quality of mankind's worldenvironment;
(G) make available to States, counties, municipalities, institutions, and individuals, advice and information useful inrestoring, maintaining, and enhancing the quality of the environment;
(H) initiate and utilize ecological information in the planning and development of resource-oriented projects; and
(I) assist the Council on Environmental Quality established by subchapter II of this chapter.
CREDIT(S)(Pub.L. 91-190, Title I, § 102, Jan. 1, 1970, 83 Stat. 853; Pub.L. 94-83, Aug. 9, 1975, 89 Stat. 424.)
A2
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 3 of 43
(Page 30 of Total)
§ 4332. Cooperation of agencies; reports; availability of..., 42 USCA § 4332
© 2017 Thomson Reuters. No claim to original U.S. Government Works. 3
Footnotes1 So in original. The period probably should be a semicolon.
42 U.S.C.A. § 4332, 42 USCA § 4332Current through P.L. 115-45. Title 26 current through 115-52.
End of Document © 2017 Thomson Reuters. No claim to original U.S. Government Works.
A3
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 4 of 43
(Page 31 of Total)
§ 771.130 Supplemental environmental impact statements., 23 C.F.R. § 771.130
© 2017 Thomson Reuters. No claim to original U.S. Government Works. 1
Code of Federal RegulationsTitle 23. Highways
Chapter I. Federal Highway Administration, Department of TransportationSubchapter H. Right–of–Way and Environment
Part 771. Environmental Impact and Related Procedures (Refs & Annos)
23 C.F.R. § 771.130
§ 771.130 Supplemental environmental impact statements.
Effective: April 23, 2009Currentness
(a) A draft EIS, final EIS, or supplemental EIS may be supplemented at any time. An EIS shall be supplemented wheneverthe Administration determines that:
(1) Changes to the proposed action would result in significant environmental impacts that were not evaluated inthe EIS; or
(2) New information or circumstances relevant to environmental concerns and bearing on the proposed action orits impacts would result in significant environmental impacts not evaluated in the EIS.
(b) However, a supplemental EIS will not be necessary where:
(1) The changes to the proposed action, new information, or new circumstances result in a lessening of adverseenvironmental impacts evaluated in the EIS without causing other environmental impacts that are significant andwere not evaluated in the EIS; or
(2) The Administration decides to approve an alternative fully evaluated in an approved final EIS but not identifiedas the preferred alternative. In such a case, a revised ROD shall be prepared and circulated in accordance with §771.127(b).
(c) Where the Administration is uncertain of the significance of the new impacts, the applicant will develop appropriateenvironmental studies or, if the Administration deems appropriate, an EA to assess the impacts of the changes, newinformation, or new circumstances. If, based upon the studies, the Administration determines that a supplemental EISis not necessary, the Administration shall so indicate in the project file.
(d) A supplement is to be developed using the same process and format (i.e., draft EIS, final EIS, and ROD) as an originalEIS, except that scoping is not required.
(e) A supplemental draft EIS may be necessary for major new fixed guideway capital projects proposed for FTA fundingif there is a substantial change in the level of detail on project impacts during project planning and development. The
A4
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 5 of 43
(Page 32 of Total)
§ 771.130 Supplemental environmental impact statements., 23 C.F.R. § 771.130
© 2017 Thomson Reuters. No claim to original U.S. Government Works. 2
supplement will address site-specific impacts and refined cost estimates that have been developed since the original draftEIS.
(f) In some cases, a supplemental EIS may be required to address issues of limited scope, such as the extent of proposedmitigation or the evaluation of location or design variations for a limited portion of the overall project. Where this is thecase, the preparation of a supplemental EIS shall not necessarily:
(1) Prevent the granting of new approvals;
(2) Require the withdrawal of previous approvals; or
(3) Require the suspension of project activities; for any activity not directly affected by the supplement. If the changesin question are of such magnitude to require a reassessment of the entire action, or more than a limited portionof the overall action, the Administration shall suspend any activities which would have an adverse environmentalimpact or limit the choice of reasonable alternatives, until the supplemental EIS is completed.
Credits[70 FR 24470, May 9, 2005; 74 FR 12530, March 24, 2009]
SOURCE: 52 FR 32660, Aug. 28, 1987; 62 FR 6873, Feb. 14, 1997; 74 FR 12527, March 24, 2009; 78 FR 11602, Feb.19, 2013; 79 FR 2118, Jan. 13, 2014; 79 FR 60115, Oct. 6, 2014; 81 FR 34164, May 27, 2016; 81 FR 34274, May 31,2016, unless otherwise noted.
AUTHORITY: 42 U.S.C. 4321 et seq.; 23 U.S.C. 106, 109, 128, 138, 139, 315, 325, 326, and 327; 49 U.S.C. 303; 40 CFRparts 1500–1508; 49 CFR 1.81, 1.85, and 1.91; Pub.L. 109–59, 119 Stat. 1144, Sections 6002 and 6010; Pub.L. 112–141,126 Stat. 405, Sections 1315, 1316, 1317, 1318, and 1319; Pub.L. 114–94, 129 Stat. 1312, Sections 1314 and 1315.
Notes of Decisions (41)
Current through August 17, 2017; 82 FR 39274.
End of Document © 2017 Thomson Reuters. No claim to original U.S. Government Works.
A5
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 6 of 43
(Page 33 of Total)
§ 1502.9 Draft, final, and supplemental statements., 40 C.F.R. § 1502.9
© 2017 Thomson Reuters. No claim to original U.S. Government Works. 1
Code of Federal RegulationsTitle 40. Protection of Environment
Chapter V. Council on Environmental QualityPart 1502. Environmental Impact Statement (Refs & Annos)
40 C.F.R. § 1502.9
§ 1502.9 Draft, final, and supplemental statements.
Currentness
Except for proposals for legislation as provided in § 1506.8 environmental impact statements shall be prepared in twostages and may be supplemented.
(a) Draft environmental impact statements shall be prepared in accordance with the scope decided upon in the scopingprocess. The lead agency shall work with the cooperating agencies and shall obtain comments as required in part 1503of this chapter. The draft statement must fulfill and satisfy to the fullest extent possible the requirements established forfinal statements in section 102(2)(C) of the Act. If a draft statement is so inadequate as to preclude meaningful analysis,the agency shall prepare and circulate a revised draft of the appropriate portion. The agency shall make every effort todisclose and discuss at appropriate points in the draft statement all major points of view on the environmental impactsof the alternatives including the proposed action.
(b) Final environmental impact statements shall respond to comments as required in part 1503 of this chapter. Theagency shall discuss at appropriate points in the final statement any responsible opposing view which was not adequatelydiscussed in the draft statement and shall indicate the agency's response to the issues raised.
(c) Agencies:
(1) Shall prepare supplements to either draft or final environmental impact statements if:
(i) The agency makes substantial changes in the proposed action that are relevant to environmental concerns; or
(ii) There are significant new circumstances or information relevant to environmental concerns and bearing on theproposed action or its impacts.
(2) May also prepare supplements when the agency determines that the purposes of the Act will be furthered bydoing so.
(3) Shall adopt procedures for introducing a supplement into its formal administrative record, if such a record exists.
A6
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 7 of 43
(Page 34 of Total)
§ 1502.9 Draft, final, and supplemental statements., 40 C.F.R. § 1502.9
© 2017 Thomson Reuters. No claim to original U.S. Government Works. 2
(4) Shall prepare, circulate, and file a supplement to a statement in the same fashion (exclusive of scoping) as a draftand final statement unless alternative procedures are approved by the Council.
SOURCE: 43 FR 55994, Nov. 29, 1978, unless otherwise noted.
AUTHORITY: NEPA, the Environmental Quality Improvement Act of 1970, as amended (42 U.S.C. 4371 et seq.),Sec. 309 of the Clean Air Act, as amended (42 U.S.C. 7609), and Executive Order 11514 (Mar. 5, 1970, as amended byExecutive Order 11991, May 24, 1977).
Notes of Decisions (603)
Current through August 17, 2017; 82 FR 39274.
End of Document © 2017 Thomson Reuters. No claim to original U.S. Government Works.
A7
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 8 of 43
(Page 35 of Total)
§ 1508.11 Environmental impact statement., 40 C.F.R. § 1508.11
© 2017 Thomson Reuters. No claim to original U.S. Government Works. 1
Code of Federal RegulationsTitle 40. Protection of Environment
Chapter V. Council on Environmental QualityPart 1508. Terminology and Index (Refs & Annos)
40 C.F.R. § 1508.11
§ 1508.11 Environmental impact statement.
Currentness
Environmental impact statement means a detailed written statement as required by section 102(2)(C) of the Act.
SOURCE: 43 FR 56003, Nov. 29, 1978, unless otherwise noted.
AUTHORITY: NEPA, the Environmental Quality Improvement Act of 1970, as amended (42 U.S.C. 4371 et seq.),sec. 309 of the Clean Air Act, as amended (42 U.S.C. 7609), and Executive Order 11514 (Mar. 5, 1970, as amended byExecutive Order 11991, May 24, 1977).
Notes of Decisions (6)
Current through August 17, 2017; 82 FR 39274.
End of Document © 2017 Thomson Reuters. No claim to original U.S. Government Works.
A8
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 9 of 43
(Page 36 of Total)
§ 1508.14 Human environment., 40 C.F.R. § 1508.14
© 2017 Thomson Reuters. No claim to original U.S. Government Works. 1
Code of Federal RegulationsTitle 40. Protection of Environment
Chapter V. Council on Environmental QualityPart 1508. Terminology and Index (Refs & Annos)
40 C.F.R. § 1508.14
§ 1508.14 Human environment.
Currentness
Human environment shall be interpreted comprehensively to include the natural and physical environment and therelationship of people with that environment. (See the definition of “effects” (§ 1508.8).) This means that economic orsocial effects are not intended by themselves to require preparation of an environmental impact statement. When anenvironmental impact statement is prepared and economic or social and natural or physical environmental effects areinterrelated, then the environmental impact statement will discuss all of these effects on the human environment.
SOURCE: 43 FR 56003, Nov. 29, 1978, unless otherwise noted.
AUTHORITY: NEPA, the Environmental Quality Improvement Act of 1970, as amended (42 U.S.C. 4371 et seq.),sec. 309 of the Clean Air Act, as amended (42 U.S.C. 7609), and Executive Order 11514 (Mar. 5, 1970, as amended byExecutive Order 11991, May 24, 1977).
Notes of Decisions (31)
Current through August 17, 2017; 82 FR 39274.
End of Document © 2017 Thomson Reuters. No claim to original U.S. Government Works.
A9
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 10 of 43
(Page 37 of Total)
From the Press Office
Speeches & Remarks
Press Briefings
Statements & Releases
Nominations & Appointments
Presidential Actions
Executive Orders
Presidential Memoranda
Proclamations
Legislation
Disclosures
For Immediate Release August 15, 2017
The White House
Office of the Press Secretary
Presidential Executive Order on
Establishing Discipline and
Accountability in the Environmental
Review and Permitting Process for
Infrastructure
EXECUTIVE ORDER
- - - - - - -
the WHITE HOUSE PRESIDENT DONALD J. TRUMP
Page 1 of 10Presidential Executive Order on Establishing Discipline and Accountability in the Environmental Revie...
8/23/2017https://www.whitehouse.gov/the-press-office/2017/08/15/presidential-executive-order-establishing-discipl...
A10
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 11 of 43
(Page 38 of Total)
ESTABLISHING DISCIPLINE AND ACCOUNTABILITY IN THE ENVIRONMENTAL REVIEW AND
PERMITTING PROCESS FOR INFRASTRUCTURE PROJECTS
By the authority vested in me as President by the Constitution and the laws of the United States
of America, and in order to ensure that the Federal environmental review and permitting
process for infrastructure projects is coordinated, predictable, and transparent, it is hereby
ordered as follows:
Section 1. Purpose. America needs increased infrastructure investment to strengthen our
economy, enhance our competitiveness in world trade, create jobs and increase wages for our
workers, and reduce the costs of goods and services for our families. The poor condition of
America's infrastructure has been estimated to cost a typical American household thousands of
dollars each year. Inefficiencies in current infrastructure project decisions, including
management of environmental reviews and permit decisions or authorizations, have delayed
infrastructure investments, increased project costs, and blocked the American people from
enjoying improved infrastructure that would benefit our economy, society, and environment.
More efficient and effective Federal infrastructure decisions can transform our economy, so the
Federal Government, as a whole, must change the way it processes environmental reviews and
authorization decisions.
Sec. 2. Policy. It is the policy of the Federal Government to:
(a) safeguard our communities and maintain a healthy environment;
(b) ensure that Federal authorities make informed decisions concerning the environmental
impacts of infrastructure projects;
(c) develop infrastructure in an environmentally sensitive manner;
(d) provide transparency and accountability to the public regarding environmental review and
authorization decisions;
(e) be good stewards of public funds, including those used to develop infrastructure projects,
and avoid duplicative and wasteful processes;
(f) conduct environmental reviews and authorization processes in a coordinated, consistent,
predictable, and timely manner in order to give public and private investors the confidence
necessary to make funding decisions for new infrastructure projects;
(g) speak with a coordinated voice when conducting environmental reviews and making
authorization decisions; and
(h) make timely decisions with the goal of completing all Federal environmental reviews and
authorization decisions for major infrastructure projects within 2 years.
Page 2 of 10Presidential Executive Order on Establishing Discipline and Accountability in the Environmental Revie...
8/23/2017https://www.whitehouse.gov/the-press-office/2017/08/15/presidential-executive-order-establishing-discipl...
A11
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 12 of 43
(Page 39 of Total)
Sec. 3. Definitions. The terms of this order shall be applied consistently with those defined
under 42 U.S.C. 4370m and implementing guidance to the maximum extent possible. The
following definitions shall specifically apply:
(a) "Authorization" means any license, permit, approval, finding, determination, or other
administrative decision issued by a Federal department or agency (agency) that is required or
authorized under Federal law in order to site, construct, reconstruct, or commence operations
of an infrastructure project, including any authorization under 42 U.S.C. 4370m(3).
(b) "CAP Goals" means Federal Government Priority Goals established by the Government
Performance and Results Act (GPRA) Modernization Act of 2010, Public Law 111-352, 124 Stat.
3866, and commonly referred to as Cross-Agency Priority (CAP) Goals.
(c) "Federal Permitting Improvement Steering Council" or "FPISC" means the entity
established under 42 U.S.C. 4370m-1.
(d) "Infrastructure project" means a project to develop the public and private physical assets
that are designed to provide or support services to the general public in the following sectors:
surface transportation, including roadways, bridges, railroads, and transit; aviation; ports,
including navigational channels; water resources projects; energy production and generation,
including from fossil, renewable, nuclear, and hydro sources; electricity transmission;
broadband internet; pipelines; stormwater and sewer infrastructure; drinking water
infrastructure; and other sectors as may be determined by the FPISC.
(e) "Major infrastructure project" means an infrastructure project for which multiple
authorizations by Federal agencies will be required to proceed with construction, the lead
Federal agency has determined that it will prepare an environmental impact statement (EIS)
under the National Environmental Policy Act (NEPA), 42 U.S.C. 4321 et seq., and the project
sponsor has identified the reasonable availability of funds sufficient to complete the project.
(f) "Permitting timetable" means an environmental review and authorization schedule, or other
equivalent schedule, for a project or group of projects that identifies milestones -- including
intermediate and final completion dates for action by each agency on any Federal
environmental review or authorization required for a project or group of projects -- that is
prepared by the lead Federal agency in consultation with all cooperating and participating
agencies.
Sec. 4. Agency Performance Accountability. Federal agencies should follow transparent and
coordinated processes for conducting environmental reviews and making authorization
decisions. These processes must include early and open coordination among Federal, State,
tribal, and local agencies and early engagement with the public. Holding Federal agencies
accountable for their progress on implementing the policy set forth in section 2 of this order
should, among other things, produce measurably better environmental outcomes with respect
to infrastructure development.
Page 3 of 10Presidential Executive Order on Establishing Discipline and Accountability in the Environmental Revie...
8/23/2017https://www.whitehouse.gov/the-press-office/2017/08/15/presidential-executive-order-establishing-discipl...
A12
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 13 of 43
(Page 40 of Total)
(a) Performance Priority Goals.
(i) CAP Goal. A CAP Goal is a Federal tool for accelerating progress in priority areas that
require active collaboration among multiple agencies to overcome organizational
barriers and to achieve better performance than one agency could achieve on its own.
Within 180 days of the date of this order, the Director of the Office of Management and
Budget (OMB), in consultation with the FPISC, shall establish a CAP Goal on Infrastructure
Permitting Modernization so that, where permitted by law:
(A) Federal environmental reviews and authorization processes for infrastructure
projects are consistent, coordinated, and predictable; and
(B) the time for the Federal Government's processing of environmental reviews and
authorization decisions for new major infrastructure projects should be reduced to
not more than an average of approximately 2 years, measured from the date of the
publication of a notice of intent to prepare an environmental impact statement or
other benchmark deemed appropriate by the Director of OMB.
(ii) Agency Goals. All Federal agencies with environmental review, authorization, or
consultation responsibilities for infrastructure projects shall modify their Strategic Plans
and Annual Performance Plans under the GPRA Modernization Act of 2010 to include
agency performance goals related to the completion of environmental reviews and
authorizations for infrastructure projects consistent with the new CAP Goal on
Infrastructure Permitting Modernization. The agencies shall integrate the achievement of
these performance goals into appropriate agency personnel performance plans, such as
those of the agency Chief Environmental Review and Permitting Officers (CERPOs) or
other appropriate officials, consistent with guidance to be provided by OMB, in
consultation with the Office of Personnel Management. Progress on these goals shall be
reviewed and analyzed by agency leadership, pursuant to the GPRA Modernization Act of
2010.
(b) Accountability. Within 180 days of the establishment of the CAP Goal on Infrastructure
Permitting Modernization, as described in subsection (a) of this section, or such longer period
of time as determined by the Director of OMB, OMB, in consultation with the FPISC, shall issue
guidance for establishing a performance accountability system to facilitate achievement of the
CAP Goal.
(i) Tracking of Major Infrastructure Projects. The performance accountability system
shall track each major infrastructure project. The performance accountability system
shall include, at a minimum, assessments of the agency's performance with respect to
each of the following areas, as applicable:
(A) whether major infrastructure projects are processed using the "One Federal
Decision" mechanism, as described in subsection 5(b) of this order;
Page 4 of 10Presidential Executive Order on Establishing Discipline and Accountability in the Environmental Revie...
8/23/2017https://www.whitehouse.gov/the-press-office/2017/08/15/presidential-executive-order-establishing-discipl...
A13
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 14 of 43
(Page 41 of Total)
(B) whether major infrastructure projects have a permitting timetable;
(C) whether major infrastructure projects follow an effective process that
automatically elevates instances in which permitting timetable milestones are
missed or extended, or are anticipated to be missed or extended, to appropriate
senior agency officials;
(D) whether agencies are meeting the established milestones in the permitting
timetable;
(E) the time it takes to complete the processing of environmental reviews and
authorizations for each major infrastructure project; and
(F) the costs of the environmental reviews and authorizations for each major
infrastructure project.
(ii) Scoring. The accountability system shall include a scoring mechanism that shall
follow, at a minimum, the following procedures:
(A) agencies will submit information to OMB, consistent with existing reporting
mechanisms to the maximum extent possible, on the assessment areas described in
subsection (b)(i) of this section;
(B) at least once per quarter, OMB will produce a scorecard of agency performance
and overall progress toward achieving CAP Goal targets;
(C) where an agency's inability to meet a permitting timetable milestone results in
a significant delay of the project timeline, after consulting with the project sponsor
and relevant agencies, agencies will submit (based on OMB guidance) an estimate
of the delay's costs to the project; and
(D) the Director of OMB will consider each agency's performance during budget
formulation and determine whether appropriate penalties, including those
authorized at 23 U.S.C. 139(h)(7) and 33 U.S.C. 2348(h)(5), must or should be
imposed, to the extent required or permitted by law, for those that significantly fail
to meet a permitting timetable milestone or in other situations deemed appropriate
by the Director of OMB after considering the causes of any poor performance.
(iii) Best Practices. Agencies shall implement the techniques and strategies the FPISC
annually identifies as best practices pursuant to 42 U.S.C. 4370m-1(c)(2)(B), as
appropriate. The performance accountability system shall track and score agencies on
the incorporation and implementation of appropriate best practices for all infrastructure
projects, including the implementation of such best practices at an agency's field level.
Page 5 of 10Presidential Executive Order on Establishing Discipline and Accountability in the Environmental Revie...
8/23/2017https://www.whitehouse.gov/the-press-office/2017/08/15/presidential-executive-order-establishing-discipl...
A14
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 15 of 43
(Page 42 of Total)
Sec. 5. Process Enhancements. In furtherance of the policy described in section 2 of this order,
Federal agencies shall follow a more unified environmental review and authorization process.
(a) Processing of Major Infrastructure Projects. In processing environmental reviews and
authorizations for major infrastructure projects, Federal agencies shall:
(i) use "One Federal Decision" described in subsection (b) of this section;
(ii) develop and follow a permitting timetable, which shall be reviewed and updated at
least quarterly by the lead Federal agency in consultation with Federal cooperating and
participating agencies; and
(iii) follow an effective process that automatically elevates instances where a permitting
timetable milestone is missed or extended, or is anticipated to be missed or extended, to
appropriate senior agency officials of the lead Federal agency and the cooperating and
participating Federal agency or agencies to which the milestone applies.
(b) One Federal Decision.
(i) Each major infrastructure project shall have a lead Federal agency, which shall be
responsible for navigating the project through the Federal environmental review and
authorization process, including the identification of a primary Federal point of contact at
each Federal agency. All Federal cooperating and participating agencies shall identify
points of contact for each project, cooperate with the lead Federal agency point of
contact, and respond to all reasonable requests for information from the lead Federal
agency in a timely manner.
(ii) With respect to the applicability of NEPA to a major infrastructure project, the Federal
lead, cooperating, and participating agencies for each major infrastructure project shall
all record any individual agency decision in one Record of Decision (ROD), which shall be
coordinated by the lead Federal agency unless the project sponsor requests that agencies
issue separate NEPA documents, the NEPA obligations of a cooperating or participating
agency have already been satisfied, or the lead Federal agency determines that a single
ROD would not best promote completion of the project's environmental review and
authorization process. The Federal lead, cooperating, and participating agencies shall all
agree to a permitting timetable that includes the completion dates for the ROD and the
federally required authorizations for the project.
(iii) All Federal authorization decisions for the construction of a major infrastructure
project shall be completed within 90 days of the issuance of a ROD by the lead Federal
agency, provided that the final EIS includes an adequate level of detail to inform agency
decisions pursuant to their specific statutory authority and requirements. The lead
Federal agency may extend the 90-day deadline if the lead Federal agency determines
that Federal law prohibits the agency from issuing its approval or permit within the 90-
Page 6 of 10Presidential Executive Order on Establishing Discipline and Accountability in the Environmental Revie...
8/23/2017https://www.whitehouse.gov/the-press-office/2017/08/15/presidential-executive-order-establishing-discipl...
A15
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 16 of 43
(Page 43 of Total)
day period, the project sponsor requests that the permit or approval follow a different
timeline, or the lead Federal agency determines that an extension would better promote
completion of the project's environmental review and authorization process.
(iv) The Council on Environmental Quality (CEQ) and OMB shall develop the framework
for implementing One Federal Decision, in consultation with the FPISC.
(A) The framework should be consistent with the model processes established
under 42 U.S.C. 4370m-2, 23 U.S.C. 139, 33 U.S.C. 2348, the 2015 "Red
Book" (officially entitled "Synchronizing Environmental Reviews for Transportation
and Other Infrastructure Projects"), and CEQ guidance on efficient and timely
environmental reviews under NEPA.
(B) The framework shall also include guidance on the development of permitting
timetables by the lead Federal agencies, in collaboration with Federal cooperating
and participating agencies. Permitting timetables shall identify estimated
intermediate and final completion dates for all environmental reviews and
authorizations that are reasonably anticipated as being needed for a project,
including the process for granting extensions of any established dates. The
guidance shall specify that lead Federal agencies need not include the estimated
intermediate and final completion dates of any such reviews or authorizations until
the design of a project has sufficiently advanced so that they can be developed. In
such cases, the guidance shall instruct lead Federal agencies to estimate when the
project's design will be advanced enough to determine such dates. The timelines
shall account for any federally required decisions or permits that are assumed by, or
delegated to, State, tribal, or local agencies and the extent to which any approval or
permit to be issued by a Federal agency is dependent upon the issuance of such a
decision or permit.
(C) CEQ and OMB shall also develop guidance for applying One Federal Decision
whenever the lead agency is a State, tribal, or local agency exercising an
assignment or delegation of an agency's NEPA responsibilities.
(c) Dashboard. All projects subject to 23 U.S.C. 139 and "covered projects" under 42 U.S.C.
4370m shall be tracked on the Dashboard established under 42 U.S.C. 4370m-2(b). Other
projects or classes of projects subject to special environmental review and authorization
streamlining processes similar to those referenced in this subsection may also be tracked on
the Dashboard at the discretion of the FPISC Executive Director. The dates for milestones of all
projects tracked on the Dashboard shall be updated monthly, or on another appropriate
timeline as may be determined by the FPISC Executive Director.
(d) Executive Order 13766. For purposes of implementing Executive Order 13766 of January 24,
2017 (Expediting Environmental Reviews and Approvals for High Priority Infrastructure
Page 7 of 10Presidential Executive Order on Establishing Discipline and Accountability in the Environmental Revie...
8/23/2017https://www.whitehouse.gov/the-press-office/2017/08/15/presidential-executive-order-establishing-discipl...
A16
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 17 of 43
(Page 44 of Total)
Projects), all infrastructure projects that meet the criteria for, and are subject to, 23 U.S.C. 139,
33 U.S.C. 2348, or 42 U.S.C. 4370m–4370m-12 shall qualify as high priority projects under
Executive Order 13766. Other projects or classes of projects subject to special environmental
review and authorization streamlining processes, similar to those referenced in this subsection
as may be determined by the FPISC Executive Director in consultation with OMB and CEQ, shall
also qualify as high priority infrastructure projects under Executive Order 13766. The CEQ
Chairman's responsibilities under sections 2 and 3 of Executive Order 13766 shall be satisfied by
referring the project to the FPISC Executive Director, the Secretary of Transportation, or the
Assistant Secretary of the Army for Civil Works, as appropriate.
(e) Council on Environmental Quality.
(i) Directives. Within 30 days of the date of this order, the CEQ shall develop an initial list
of actions it will take to enhance and modernize the Federal environmental review and
authorization process. Such actions should include issuing such regulations, guidance,
and directives as CEQ may deem necessary to:
(A) ensure optimal interagency coordination of environmental review and
authorization decisions, including by providing for an expanded role and authorities
for lead agencies, more clearly defined responsibilities for cooperating and
participating agencies, and Government-wide applicability of NEPA decisions and
analyses;
(B) ensure that environmental reviews and authorization decisions involving
multiple agencies are conducted in a manner that is concurrent, synchronized,
timely, and efficient;
(C) provide for agency use, to the maximum extent permitted by law, of
environmental studies, analysis, and decisions conducted in support of earlier
Federal, State, tribal, or local environmental reviews or authorization decisions; and
(D) ensure that agencies apply NEPA in a manner that reduces unnecessary burdens
and delays as much as possible, including by using CEQ's authority to interpret
NEPA to simplify and accelerate the NEPA review process.
(ii) Dispute Resolution. Except where dispute resolution processes are otherwise
provided for in law, including under 42 U.S.C. 4370m-2, or by Executive Order or other
Presidential directive, upon request of a lead Federal agency, cooperating agency, or
participating agency, CEQ may mediate interagency disputes arising between Federal
agencies concerning Federal environmental review or authorization decisions for any
infrastructure project pertaining to any environmental law, regulation, order or policy,
and shall facilitate resolution of any conflicting positions of the relevant agencies.
Page 8 of 10Presidential Executive Order on Establishing Discipline and Accountability in the Environmental Revie...
8/23/2017https://www.whitehouse.gov/the-press-office/2017/08/15/presidential-executive-order-establishing-discipl...
A17
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 18 of 43
(Page 45 of Total)
(iii) Agency Procedures. CEQ shall form and lead an interagency working group,
consisting of the Director of OMB, agency CERPOs, and such other representatives of
agencies as CEQ deems appropriate. The working group shall review the NEPA
implementing regulations and other environmental review and authorization processing
policies of agencies that are members of the FPISC to identify impediments to efficient
and effective environmental reviews and authorizations for infrastructure projects. The
working group shall also identify those agencies that require an action plan to address
identified impediments. Based on this review, agencies shall develop action plans that
set forth the actions they will take and timelines for completing those actions, and they
shall submit those action plans to CEQ and OMB for comment. Each agency's action plan
shall, at a minimum, establish procedures for a regular review and update of categorical
exclusions, where appropriate.
(f) Federal Permitting Improvement Steering Council.
(i) Organizational Support. Unless otherwise determined by the Director of OMB, the
General Services Administration (GSA) shall provide necessary administrative and
organizational support to the FPISC, including personnel, procurement, and budget
support. The GSA Administrator, or the head of another agency designated by the
Director of OMB, may delegate any authority to the FPISC Executive Director necessary for
the operation and administration of the FPISC and the Office of the Executive Director,
and the Executive Director may redelegate these authorities, as appropriate.
(ii) Additional Duties. In addition to the duties and responsibilities charged to the FPISC
Executive Director under 42 U.S.C. 4370m–4370m-12 and this order, the FPISC Executive
Director may, upon request of a FPISC member agency or a project sponsor, work with the
lead agency or any cooperating and participating agencies to facilitate the environmental
review and authorization process for any infrastructure project regardless of whether the
project is a "covered project" under 42 U.S.C. 4370m, including by resolving disputes and
promoting early coordination. The FPISC Executive Director, the Director of OMB, or the
Chairman of CEQ may establish any appropriate policies or procedures concerning the
FPISC Executive Director's facilitation of the environmental review and authorization
process under this subsection. Agencies must cooperate with the FPISC Executive
Director with respect to the implementation of these additional duties.
(g) Energy Corridors. The Departments of the Interior and Agriculture, as appropriate, shall be
the lead agencies for facilitating the identification and designation of energy right-of-way
corridors on Federal lands for Government-wide expedited environmental review for the
development of energy infrastructure projects.
(h) The Department of the Interior shall provide to OMB a strategy and recommendations for a
multi-agency reorganization effort that would further the aims of this order. OMB, in
consultation with the Department of the Interior, shall coordinate with the heads of other
Page 9 of 10Presidential Executive Order on Establishing Discipline and Accountability in the Environmental Revie...
8/23/2017https://www.whitehouse.gov/the-press-office/2017/08/15/presidential-executive-order-establishing-discipl...
A18
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 19 of 43
(Page 46 of Total)
agencies affected to incorporate the strategy, as appropriate, into the comprehensive
reorganization plan developed under Executive Order 13781 of March 13, 2017 (Comprehensive
Plan for Reorganizing the Executive Branch).
Sec. 6. Executive Order 13690 of January 30, 2015 (Establishing a Federal Flood Risk
Management Standard and a Process for Further Soliciting and Considering Stakeholder Input),
is revoked.
Sec. 7. General Provisions. (a) Nothing in this order shall be construed to impair or otherwise
affect:
(i) the authority granted by law to an executive department, agency, or the head thereof;
or
(ii) the functions of the Director of the Office of Management and Budget relating to
budgetary, administrative, or legislative proposals.
(b) This order shall be implemented consistent with applicable law and subject to the
availability of appropriations.
(c) This order is not intended to, and does not, create any right or benefit, substantive or
procedural, enforceable at law or in equity by any party against the United States, its
departments, agencies, or entities, its officers, employees, or agents, or any other person.
DONALD J. TRUMP
THE WHITE HOUSE,
August 15, 2017.
HOME BRIEFING ROOM ISSUES THE ADMINISTRATION PARTICIPATE 1600 PENN
USA.gov Privacy Policy Copyright Policy
Page 10 of 10Presidential Executive Order on Establishing Discipline and Accountability in the Environmental Revi...
8/23/2017https://www.whitehouse.gov/the-press-office/2017/08/15/presidential-executive-order-establishing-discipl...
A19
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 20 of 43
(Page 47 of Total)
ASSESSING THE COSTS ATTRIBUTED TO PROJECT DELAY DURING PROJECT PRE-CONSTRUCTION STAGES
by
Curtis Beaty, P.E. Associate Research Engineer
Texas A&M Transportation Institute
David Ellis, Ph.D. Research Scientist
Texas A&M Transportation Institute
Brianne Glover Associate Transportation Researcher Texas A&M Transportation Institute
and
Bill Stockton, Ph.D., P.E.
Executive Associate Agency Director Texas A&M Transportation Institute
Report 0-6806-FY15 WR#3 Project 0-6806-TTI
Project Title: TxDOT Administration Research
Performed in cooperation with the Texas Department of Transportation
and the Federal Highway Administration
Published: March 2016
TEXAS A&M TRANSPORTATION INSTITUTE College Station, Texas 77843-3135
A20
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 21 of 43
(Page 48 of Total)
1
EXECUTIVE SUMMARY
All departments of transportation face delays on highway projects. They often have anecdotal accounts of the significant financial impact that the delay of a highway project had on project costs, local businesses, commuters, and other users of the highway. But in many cases hard data on the financial impact are lacking. This project for the Texas Department of Transportation (TxDOT) developed a simple but sound methodology for estimating the cost of delaying most types of highway projects. In 2011, the Texas A&M Transportation Institute (TTI) performed a study examining the cost associated with delays during the construction phase (i.e., post letting) of highway projects. This project considered the cost of delays during the pre-construction phases of project development: planning and scoping, preliminary engineering, final design, and letting.
The project draws on two main resources to produce reliable estimates of impacts:
• Existing data from projects originally scheduled to let between January 2012 and March 2014 and reported in TxDOT’s Design Construction Information System, SiteManager™, and Primavera™.
• Methodologies developed for other applications that can be applied to estimating the cost of project delay.
DELAY DURING PROJECT PHASES
Delay can occur in any phase in the project:
• Planning/scoping phase: Delay can be significant when litigation is initiated. • Development phase: Permitting (environmental, fish and wildlife, railroad, etc.), right-of-
way acquisition, and utility agreements can be significant causes of delay. • Contracting phase: Generally, this phase has less incidence of delay but can still have
issues. • Construction phase: This phase has numerous opportunities for delay and is often the
delay most visible to the public.
Project delay almost always has some costs associated with it, but not all project delay is a waste of time and public money. In some instances, the reason for the delay is to make an improvement in the design or construction of the project that will ultimately deliver better value to the public. At the same time, delays during the pre-construction phases of project development can be introduced due to poor project management activities (e.g., failing to publicly advertise a project’s bid request the required numbers of days before the bidding deadline) that can have minor direct costs but with more significant indirect costs to commuters and businesses.
ESTIMATION MODEL
This project developed a simplified model that incorporates 17 user-controlled variables and produces estimates of the effect of project delay on personal and commercial travel and the cost to the general economy. While the methodology is simple, there is no rule of thumb because
A21
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 22 of 43
(Page 49 of Total)
2
project delay costs depend on several variables, primarily location, traffic, construction costs, travel speeds, fuel prices, construction prices, and the change in prices as influenced by the general economy.
Three projects of varying size were used as examples:
• The small project illustrates delay to a $10.6 million, reconstruction of four-lane roadway project in a rural setting. The project’s 6-month delay produced an additional cost of $570,000, or a cost of $87,000 for every month of delay.
• The medium project illustrates delay to a $28.5 million, widening of a semi-rural highway project. The project’s 2-month delay produced an additional cost of $870,000, or a cost of over $420,000 for every month of delay.
• The large project illustrates delay to an $85.2 million freeway reconstruction in a large metro area. The project’s 3-month delay produced an additional cost of $4 million, or a cost of $1.3 million for every month of delay.
A22
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 23 of 43
(Page 50 of Total)
RoutledgeTaylor &FrancisCroup
Edinburgh NapierlUNIVERSITY
INTERNATIONAL JOURNAL OF STRATEGIC PROPERTY MANAGEMENTISSN 1648-715X print / ISSN 1648-9179 online
2012 Volume 16(3): 316-337doi:10.3846/1648715X.2012.688774
UNDERSTANDING IMPACTS OF TIME AND COST RELATEDCONSTRUCTION RISKS ON OPERATIONAL PERFORMANCEOF PPP PROJECTS
Hemanta DOLOIFaculty of Architecture, Building and Planning, The University of Melbourne, Victoria 3010,AustraliaE-mail: [email protected]
Received 17 November 2011; accepted 21 February 2012
ABSTRACT. The risk attributes in construction project is one of the widely published topics,yet there is no or little investigation whether or not risks associated with construction phasepropagate over operational phase. As operation phase of the PPP projects is significantlylong compared to the construction phase, understanding the impact of time and cost relatedconstruction risks over operation phase is quite important. In this research, risk attributesassociated with the PPP procurement method have been identified across three dimensions,time, cost and operational performance. A questionnaire survey was used for collecting datain seven major PPP projects in Australia. Based on standard statistical methods and factoranalysis, a number of key risk factors infiuencing time, cost and operational performancehave been extracted. The research revealed that site conditions and design complexity is oneof the most critical risk attribute infiuencing time performance in projects. Similarly, marketdynamics is the most critical attribute infiuencing both construction cost and operational per-formance in PPP projects. Based on regression modeling, partner's dispute was found to be agood determinant of time and cost performance. Technical obsolescence has significant impactson the operational performance of PPP projects. It was revealed that the design complexity,financial structure and government policy are the three main common factors affecting risksacross time, cost and operational performance in PPP projects. It is anticipated that the find-ings wül impact the construction firms for improving the front-end risk management capabil-ity for efficient positioning within the competitive business environment.
KEYWORDS: Construction risks; Operational risks; Puhlic-private-partnerships; Factoranalysis; Multiple regression
1. INTRODUCTION
Risk management is a topic area that in-terests most industry sectors and particularlyin the construction industry. However, tradi-tional risk management framework applied inconstruction industry predominately focuseson management of risks over constructionphase. In fact, the current risk management
processes are significantly inadequate in man-aging risks associated with issues such asselection of procurement routes, contractualarrangements, management of stakeholders,organisational complexity and operationalperformance and de-investment decisions (PM-BOK, 2008). A contemporary risk managementframework must be able to deal with everyincreasing complexity with bigger stakes and
Copyright © 2012 Vilnius Gedirainas Technical University (VGTU) Press Technikahttp://www.tandfonllne.comyTSPM
A23
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 24 of 43
(Page 51 of Total)
Understanding Impacts of Time and Cost Related Construction Risks on Operational... 325
the PPP project. Lack of cooperation from thegovernment with factor loading of 0.853 is oneof the most significant attributes in this fac-tor. Misinterpretation of contract (with factorloading of 0.850) in construction phase exertscost performance in overall projects. Failure/delay in obtaining permit/approval due to bu-reaucracy in government organizations (withfactor loading of 0.716) is found to be crucial
in PPP project. Partner's dispute was found tohave significant impact (with a factor loadingof 0.577). Failure or delay in material deliveryscored 0.507 for the project. Due to involve-ment of a multitude of stakeholders in the PPPprocess, a measure of real time communication(factor loading of 0.476) between stakeholdersshould impact positively on overall cost out-comes in projects.
Table 2. Rotated factor loadings of eight key risk factors influencing project cost performance
Variahles Factor loading Varianceexplained
Factor 1: Planning and design5. Change in scope 0.8664. Defects in design 0.8351. Changes in output specification 0.5692. Innovative design 0.54311. Delay in operation 0.538
Factor 2: Communications23. Lack of cooperation of the government 0.85330. Misinterpretation of contract 0.85032. Fedlure/delay in ohtaining permit/approval 0.71629. Partner's disputes 0.5779. Failure/delay in material delivery 0.50726. Lack of communication hetween stakeholders 0.476
Factor 3; Site conditions38. Commercial rights due to development in vicinity 0.87141. Site contamination 0.85837. Adverse changes in tax 0.61442. Force Majeure 0.520
Factor 4: Market dynamics36. Adverse changes in interest rates 0.88335. Financial failure of private consortium 0.85621. Unanticipated inflation 0.71633. Unavailahility of financing 0.674
Factor 5: Construction risk6. ConstructahiHty 0.87028. Destructive industrial action 0.8408. Unforeseen site condition 0.7747. Failure/delay in site acquisition 0.753
Factor 6: PoUcy, legislation & regulation17. Unanticipated economic downturn 0.11918. Increased competition 0.11224. Misunderstanding the role of stakeholders 0.74331. Adverse changes in law, pohcy or regulations 0.722
22.65%
18.05%
14.05%
11.60%
8.85%
7.65%
Total variance explained = 82.85%
A24
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 25 of 43
(Page 52 of Total)
The Ro I e of P rivate I nvestm e nt i nMeeting U.S. TransportationInfrastructure Needs
• What We've Learned from Two Decades' F~cperience withTransportation Public-Private Partnerships (P3s) in theUnited States
• Recommendations for Increasing Private Investmentin Transportation Projects Going Forward
By William Reinhardt, 23-year P3 observer, publisher and editor of"Public Works Financing" newsletter
American Ao3d & Tra~spoitation Bai/dersAssociation
TransparfationDevelopmentFoundation
May 2011
A25
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 26 of 43
(Page 53 of Total)
Executive Summary
Over the past 22 years, the Congress and the federal government have proactively supported development
and implementation of public-private partnerships to finance and build transportation projects in many
significant ways. These include:
• A statutory framework that allows the use of federal funds on P3 projects;
• Two pilot programs. The first, from the 1998 federal surface transportation authorization law, the
"Transportation Equity Act for the 21St Century" (TEA-21), permits toll finance to reconstruct three
existing Interstates. The second, from the 2005 law, the "Safe, Accountable, Flexible, Efficient
Transportation Equity Act: A Legacy for Users" (SAFETEA-LU), permits toll finance to pay for three
new Interstates;
• Encouraging the establishment of state infrastructure banks (SIBS);
• Providing substantive assistance from the Federal Highway Administration's (FHWA) Office of
I nnovative Program Delivery;
• FHWA's "Special Experimental Project"(SEP-15) program to promote new P3 approaches to
project delivery;
• Private activity bonds (PABs); and the
• The "Transportation Infrastructure Finance &Innovation Act" (TIFIA) federal credit assistance
program.
Since 1989:
Using a broad definition that includes design-build as P3 projects, the data show:
• 24 states and the District of Columbia have used a P3 process to help finance and build at least 96
transportation protects worth a total $54.3 billion. The implementing states include: Alaska,
Alabama, Arizona, California, Colorado, Florida, Illinois, Indiana, Maryland, Massachusetts,
Minnesota, Missouri, Nevada, New Jersey, New Mexico, New York, North Carolina, Oregon, Rhode
Island, South Carolina, Texas, Utah, Virginia and Washington.
o Sixty-five percent of these projects occurred in just eight states—Florida (10), California (11),
Texas (18), Colorado (9), Virginia (7), Minnesota (2), North Carolina (2), and South Carolina
~3)•
o One-third of these project starts occurred in one of four years-2009 (10), 2002 (8), 1998 (8)
and 2000 (7).
• 26 states have not initiated a P3 transportation protect. These include: Arkansas, Connecticut,
Delaware, Georgia, Hawaii, Idaho, Iowa, Kansas, Kentucky, Louisiana, Maine, Michigan, Mississippi,
Tlie Role of Private Investment in Meeting U.S. Transportation Infrastructure Needs Page 7
A26
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 27 of 43
(Page 54 of Total)
Montana, Nebraska, New Hampshire, North Dakota, Ohio, Oklahoma, Pennsylvania, South Dakota,Tennessee, Vermont, West Virginia, Wisconsin and Wyoming.
• Over the past 10 years, 2001 through 2010, on average, five states started a transportation P3protect each year.
• Of the $54.3 billion in transportation P3 contracts let over the past 22 years, almost 75 percent ofthe contract value is accounted for by eight states—Texas ($9.57 billion, 17.6 percent), California($6.02 billion, 11.1 percent), Florida ($5.63 billion, 10.4 percent), Colorado ($4.85 billion, 9 percent),
I ndiana ($3.85 billion, 7.1 percent), Virginia ($3.88 billion, 7.1 percent), Utah ($3.66 billion, 6.7percent), and New Jersey ($3.35 billion, 6.2 percent).
• 79 of the transportation P3 projects, worth $31.5 billion, have been either Design-Build (DB),Design-Build-Finance (DBF),'or Design-Build-Operate-Maintain (DBOM) contracts.
• 11 of the transportation P3 proj.ects, worth $12.4 billion, have included a P3 financing component,been Design-Build-Finance-Operate-Maintain (DBFOM) contracts, or straight concessions involvingtraffic forecasting risk.
• Over the period, there have been four transportation asset privatizations with total up-frontpayments to government valued at $6.9 billion. These include the:
o Indiana Toll Road (Indiana Finance Authority) in 2006—a 75-year (ease for $3.85 billion;
o Chicago Skyway (City of Chicago) in 2005—a 99-year lease for $1.83 billion;
o Pocahontas Parkway (Virginia Department of Transportation) in 2006—a 99-year lease for$611 million; and the
o Northwest Parkway (Colorado, Northwest Parkway Authority) in 2007—a 99-year lease for$603 million.
• The P3 market share of total U.S. capital investment in hi~hways by all levels of government since2008 is about 2 percent.
• A number of large P3 contracts have been signed since 2008 and, together, these account for about11 percent of total national capital investment in new highway capacity in 2011. These new projectsare mostly express lanes that can be tolled, built next to existing freeways in heavily congestedurban areas.
Going Forward...
Many states have adopted alternative delivery contracting approaches that capture some of the benefits ofPas but do not entail private finance. As the data show, there is room for substantial growth in thedevelopment of new capacity through privately financed concessions.
However, given (a) the nation's enormous, unmet transportation infrastructure needs, (b) almost two-decades of proactive federal policy and legislative advocacy for implementation of P3 transportationprojects, (c) the financial challenges facing all levels of government, and (d) the claimed "$100 billion to $400billion in private funds available for P3 projects," several questions must be asked at this juncture:
The Role of Private Investment in Meeting U.S. Transportation Infrastructure Needs Page 8
A27
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 28 of 43
(Page 55 of Total)
• Why have there been so relatively few privately financed P3 transportation projects in the United
States over the ►ast 22 years? Whv haven't there been many more?
• Why have only five states—California, Florida, Georgia, Texas and Virginia—developed the capabilityto execute complex P3 transactions involving private finance?
• What is a realistic forecast for P3 projects in the future?
Obviously, there are some impediments to widespread use of P3 approaches for meeting transportationinfrastructure needs.
Experience is showing, for example, that Pas are likely not feasible replacements for the 80-90 percent oftotal public capital investment each year that is directed to transportation infrastructure repair,rehabilitation and reconstruction.
Potential investors are also not looking to participate in smaller, less expensive new construction projects or
routine maintenance where governments and their traditional contracting partners deliver a high level ofservice.
It is also true that most of the profitable toll road corridors in America have already been developed and arebeing operated by independent toll authorities or states.
Tolling the Interstate system in order to pay for its reconstruction has been proposed as a major newbusiness opportunity for P3 developers. But the political barriers to tolling in.~eneral and to tolling existingfreeways in specific are formidable, especially among states.
It has become clear that the following reasons go a long way toward explaining why the P3 share of theoverall U.S. transportation infrastructure construction market has been fairly limited over the past twodecades and will likely remain so in the decades ahead:
• P3s do not provide "new" or "free" money for building transportation projects.
Public sector investment in transportation projects and infrastructure is made in the public interest as acore~function of government. The investment is funded through government-levied taxes and user fees,or through public borrowing—debt which must be repaid with interest with public funds generated byfuture tax or fee collections.
The private sector must meet the same public interest test and also find projects that provide anadequate return on investment—a profit.
Pas do not provide project funding, they provide project financing—borrowed money that must bereimbursed, at a profit, to the lender. Therefore, P3 projects must include a reliable revenue stream,which, as has been demonstrated over the past two decades' experience, is generally accomplishedthrough tolling.
While technology has made toll collection far more efficient and opened the door to "variable pricing" ofinfrastructure use based on demand, the fact remains that the decision whether or not to allow thecollection of tolls from the public is a decision that must be made by elected officials. And the decisionto initiate tolls—or increase existing toll rates—is no less a political decision than whether or not to raise
The Role of Private Investment in Meeting U.S. Transportation Infrastructure Needs Page 9
A28
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 29 of 43
(Page 56 of Total)
the motor fuels excise to pay for transportation infrastructure. As is the case with the gas tax, many riskaverse politicians are not interested in having to make a decision to levy tolls.
Ultimately, public-purpose infrastructure must be paid for by some combination of users and taxpayers.I nnovative financing models can access new sources of borrowing and allow leveraging of public funds.But they don't create new funding sources per se.
Pas are a financing solution chasing a funding problem.
• U.S. tax policy is a hurdle for Pas.
The U.S. public finance industry very efficiently employs long-dated, tax-exempt debt to meet a largepart of the capital-raising needs of governments and non-profit authorities. When compared tothe interest rates on the taxable debt used in Pas, there'is acost-of-capital advantage'of 1% to 2%conferred on state and local borrowers by federal tax rules. Some of that advantage can be offset whenF3s access special federal financing instruments that help to level the playing field.
To compete with the low cost of public borrowing, P3 projects as a class must be tightly managed tocontrol expenses, meet schedules and deliver life-cycle cost savings. Having to meet those demands inevery project ultimately may be one of the greatest benefits of adding Pas to the Americantransportation infrastructure toolbox.
• P3s are often the preferred option for delivery of large, complex projects that add newcapacity in heavily-travelled corridors or reconstruct deteriorating existing capacity on theInterstate Highway System.
With the need to generate a return on investment a prerequisite for bringing private investors into atransportation project, Pas are best suited for lame protects with a high probability for strong revenuegeneration over many years.
Unfortunately, despite the staggering cost of traffic congestion to the U.S. economy and quality of life,the federal government does not have a national strategic business plan for building additionaltransportation infrastructure capacity in all modes—or for even performing necessary reconstruction ofexisting capacity on the Interstate Highway System. Nor do many of the states.
A new national initiative to build multi-modal "Critical Commerce Corridors" with dedicated truck lanesand connections to major airports, waterways, ports and rail hubs, for example, would lend itself quitewell to the P3 model.
To the contrary, however, much federal and state transportation, environmental and fiscal policydiscourages investments. in new transportation capacity. Thus the "market" for P3-like projects in theU.S. is, unfortunately. constrained.
Perhaps two to four new P3 projects per year in the U.S. would be a reasonable assumption for thefuture.
• While relatively few non-highway transportation Pas have been undertaken in the U.S. thusfar, the P3 model has been used successfully to finance Denver's Eagle P3 rail project- andcould play a larger role in the financing of other transit and rail infrastructure projects.
The Role of Private Investment in Meeting U.S. Transportation Infrastructure Needs Page 10
A29
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 30 of 43
(Page 57 of Total)
Pas can never be the "centerpiece" or even a major element of federal transportation
programs. Proactive state actions are needed.
While the federal government can encourage private investment in transportation infrastructure
through favorable tax treatments, supplementary loans and the easing of restrictions on tolling existing
federally-funded assets, P3 transportation projects must be contracted with state and local governments
or authorities.
Pas are a state or local, not federal, decision. That is why when Congress writes the next federal surface
transportation authorization, it would be a mistake to depend on private sector investment for meeting
most of the nation's surface transportation capital needs.
My recommendations for increasing private investment in needed U.S.
transportation infrastructure:
Authorize the USDOT to Develop a "National Strategic Transportation Business Plan"—
Authdrize in the next federal surface transportation law the development of a multi-modal "National
Strategic Transportation Development Business Plan" aimed at achieving national goals and leading to
necessary expansion of existing system capacity in all modes and the expensive reconstruction necessary
to maintain existing capacity on the aging, original Interstate Highway System.
Enhance TIFIA and PAB tools—There are important transportation projects being planned now that
will be able to arrange financing and start construction with support from existing federal programs. The
amount of funding for the U.S. Department of Transportation's (USDOT) "Transportation Infrastructure
Finance &Innovation Act". (TIFIA) should be substantially increased and the volume capon tax-exempt
"Private Activity Bonds" (PAB) should be removed. Decisions about which projects receive support
should be made on based solely on project merits and economic benefits. Both tools serve to reduce the
cost of capital in P3 financings and, thus, lower the tolls users must pay or the amount of availability-
based payments from legislatures.
Attract Pension Funds—Congress should embrace a form of private "Build America Bonds" (BAB),
indexed bonds, or other debt instruments that would attract critically needed investment from
insurance companies and public-employee and union pension funds.
4. Educate Governors, State Legislators and the Public—P3s should be included in every state's
transportation financing toolbox for use on appropriate projects and to provide much-needed
supplemental dollars. The first step in this process is educating legislators and encouraging them to
enact comprehensive P3 authorization laws. (This is currently a joint project of ARTBA and the National
Conference of State Legislatures). Once in place, state DOTS should be encouraged to thoroughly
consider the application of P3 techniques to all appropriate projects. Collectively, the transportation
community must also do a much betterjob of educating the public on the true costs of providing and
maintaining a safe and efficient transportation network.
5. Further Ease Federal Restrictions on State Tolling of the Interstate Highway System—It has
been clearly demonstrated over the past two decades that the P3 approach can quickly deliver the high-
cost, new capacity highway projects that are needed in many parts of the nation to meet current and
The Role of Private [nvestmeiit in Meeting U.S. Transportation Infrastructure Needs Page 11
A30
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 31 of 43
(Page 58 of Total)
future mobility demands. Similarly, Pas are also well-suited to the expensive task facing all states ofreconstructing and improving their existing—and aging—Interstate highway capacity.
It is also clear, however, that Pas require a new and consistent revenue stream to retire project debt andprovide a fair return on investment to the private sector partners who help front the project's cost andassume the costs of operation and maintenance. Tolis imposed on a facility's users are a provenmechanism for providing that revenue stream.
Current federal law has four tolling and pricing "pilot programs" that allow a limited number of statesthe opportunity to impose tolls on their Interstate mileage for specific purposes: the "Express LaneDemonstration Program," the "Value Pricing Pilot Program," the "Interstate System Reconstruction &Rehabilitation Pilot Program," and the "Interstate System Construction Toll Pilot Program."
These programs should be made permanent and available to all states with the only restriction beingthat resulting revenue raised from users be exclusively dedicated to financing the reconstruction andimprovement of the state's Interstate mileage and/or the addition of new Interstate capacity.
Conclusions
The United States has a comprehensive and relatively mature transportation infrastructure network in place.As a result, aUaut 85 percent o~ the tota~ public capital investrnefit in the nation's transportation system inrecent years is directed toward maintaining and repairing it, not constructing new facilities or addingcapacity to existing ones.
Two decades of experience have shown that private investment is attracted to large, complex and expensivetransportation projects that add new capacity to the U.S. system and can be supported by a new revenuestream, usually tolling. Thus, the overall market share for P3 projects in the overall U.S. transportationconstruction market has been—and likely will remain—fairly small, less than five percent per year.
The value of this contribution, however, should not be underestimated. For, absent sisnificant increases inpublic funding, Pas will likely be the primary model for building new highway capacity in heavily congestedurban areas in the decades ahead.
Given the economic and social toll caused by traffic congestion in the U.S. and the enormous unmet demandfor new hi~hwav capacity to facilitate freight movement in an increasingly competitive international market,P3~rolects should be a~gressively encouraged and supported.
The Role of Private Investment in Meeting U.S. Transportation Infrastructure Needs Page 12
A31
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 32 of 43
(Page 59 of Total)
Back to your search
Printer Friendly
Country equals United States and Financial Close equals 2014 and Project Type equals Motorway = 5 projects | 5 closed -- $1,462m project cost
= back to top
[x] = construction underway or completed
[o] = proposed
Name
(click for
detail)
Project
Description
Public
Sponsors
+Advisors
Developer
+Advisors Builders +Operators
Financiers
+Advisors
Project
Status
Financial Close:
Cost (current US$):
Contract Type:
[x] Motorway:
Indiana, I-69,
Section 5 Upgrade
United States
DBFOM 35yrs
upgrade 21
miles of existing SR 37 (section 5
of I-69 upgrade
project, between Bloomingt. . .
Indiana
Finance
Authority (IFA) /
Indiana
Department of Tran... .
I-69
Development
Partners: Roadis (PSP
Investments)
(100%) -... .
$325 db cost.
Construction:
Corsan-Corviam Construccion, S.A... .
Equity:
$40.4m
PABs: $243.8m
(Citigroup ...
.
Under
construction.
8/16 Isolux files for
bankruptcy
in Madrid and New
York. 5/16
PSP Inve... .
Close: 07/14
Cost (Construction): US$370m
Contract Type: DBFOM_________________ .
[x] Motorway: Massachusetts,
I-90 All
Electronic Tolling System
United States
Install all-electronic tolling
system for
Massachusetts Turnpike and
Sumner/Callahan
and Ted William.
. .
Massachusetts DOT (Mass
DOT)
.
N/A . Raytheon/SPS New England/Liddell
Brothers CDM Smith
(design)... .
N/A . 8/14 award and NTP.
8/13 LOI....
.
Close: 08/14
Cost (Construction):
US$130m
Contract Type: DB
_________________ .
[x] Motorway: New York,
Kosciuszko
Bridge, Brooklyn-
Queens, New
York City
United States
Two bridges (each one way)
to replace 76-
year-old 6-lane bridge that
connects
Brooklyn and Queens. C. . .
New York State DOT
.
N/A . Skanska/Kiewit/ECCO II HNTB (design)... .
N/A . 6/14 NTP.... .
Close: 06/14
Cost (Construction):
US$555m
Contract Type: DB
_________________ .
[x] Motorway:
North Carolina,
US 220/NC 68 Connector,
I-73 and
Taxiway Bridge
United States
New 9.4-mile,
four-lane
interstate highway with
two
interchanges, and bridges over
Reedy Fork
Creek,. . .
North Carolina
DOT
.
N/A . Flatiron/Blythe RK&K
(design)... .
N/A . 7/14 NTP
and
construction start.... .
Close: 07/14
Cost (Construction): US$176m
Contract Type: DB_________________ .
[x] Motorway: South
Carolina,
I-85/385 Interchange
Improvements,
Greenville
United States
Reconfigure the interchange at
I-85 and I-385
in Greenville, SC. Replace
existing loop
ramps with di. . .
South Carolina DOT
.
N/A . Flatiron/Zachry (DB)... .
N/A . Under construction.
10/14 start.
1/14 RFP.... .
Close: 10/14
Cost (Construction):
US$231m
Contract Type: DB
_________________ .
Page 1 of 1Survey
8/22/2017http://50.79.187.201:8081/4DACTION/Web_QExec
A32
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 33 of 43
(Page 60 of Total)
Back to your search
Printer Friendly
Country equals United States and Financial Close equals 2014 and Project Type equals Toll Motorway = 5 projects | 5 closed -- $5,166m project cost
= back to top
[x] = construction underway or completed
[o] = proposed
Name
(click for
detail)
Project
Description
Public
Sponsors
+Advisors
Developer
+Advisors
Builders
+Operators
Financiers
+Advisors
Project
Status
Financial Close:
Cost (current US$):
Contract Type:
[x] Toll Motorway:
Colorado,
FasTracks, US 36 Express
Lanes/ BRT,
phase 2, Denver-
Boulder
United States
50yr DBFOM
with revenue
risk for the 6-mile second
and final
segment of US 36 Express
lanes project..
. .
Colorado High
Performance
Transportation Enterprise
(HPTE) /... .
Plenary Roads
Denver: The
Plenary Group (100%)
Goldman
Sac... .
Ames
Construction/
Granite jv (db) HDR (design +
engineering... .
Equity:
$20.6m. Debt:
total debt = $101m... .
Complete.
3/16 tolling
start. 1/16 complete
and open.
3/14 construction
start; est.
comple... .
Close: 3/14
Cost (Project NPV): US$200m
Contract Type: DBFOM_________________ .
[x] Toll Motorway:
Florida, I-4
Ultimate Improvements,
Orlando,
Orange and
Seminole Counties
United States
40yr
availability pay
contract to widen 21.1
miles of I-4
through
Orlando to three general
purpose l. . .
Florida DOT
(Dist. 5)
URS Corp. (t&r)
Nossaman
(legal) KP... .
I-4 Mobility
Partners:
Skanska (50%)/ John
Laing
Investments...
.
Skanska USA
Civil (40%)
-Granite (30%)-Lane (30%)
(DB) HDR/Ja... .
Milestone
payments
account for about 70%... .
Under
construction.
2/15 construction
start;
expected
completion 2021.
9.4.14
commercial a... .
Close: 09/14
Cost (Project): US$2877m
Contract Type: DBFOM
_________________ .
[x] Toll Motorway:
Texas, Loop
375 Border Highway West
Extension, El
Paso
United States
DB greenfield
bypass of I-10
forming a 9-mile-long
2x2 tolled
(5.6mi tolled) loop west of
downtown E. .
.
Texas DOT
(TxDOT)/
Camino Real Regional
Mobility
Authority (... .
N/A . JD Abrams/
Kiewit
Infrastructure South... .
N/A . Under
construction.
8/22/14 commercial
close;
construction start early
2015;
completion
es... .
Close: 04/14
Cost (Construction): US$525m
Contract Type: DB_________________ .
[x] Toll Motorway: Texas,
Midtown
Express (SH 183 Managed
Lanes), Dallas-
Fort Worth
United States
DB with corporate gap
financing of
$250 million and 25yr
O&M/handback
priced at $172m
secured by
Kie. . .
Texas Department of
Transportation
(TxDOT)/ Central Texas
RM... .
SouthGate Mobility
Partners:
Kiewit Development
Co. and Kie...
.
DB: KIewit Southern/Parsons
Transportation/
Austin Bridge/ P... .
5yr x $50m balance sheet
gap financing
b... .
Under construction.
11/20/14
commercial close. 5/14
preferred
bidder and award;
constructi...
.
Close: 11/14
Cost (Project):
US$1415m
Contract Type: DBOM
_________________ .
[x] Toll Motorway:
Texas, SH 71 Express
Project, Austin
United States
Develop,
design and construct
improvements
along SH 71 from
Presidential
Blvd. to east of SH 130 in .
. .
Texas DOT
(TxDOT)Mayer Brown
(legal) .
N/A . McCarthy
Building Companies... .
funds from
state and federal
governments...
.
6/14
contract awarded;
construction
to start in fall and be
completed
late 2016.... .
Close: 06/14
Cost (Construction):
US$149m
Contract Type: DB
_________________ .
Page 1 of 1Survey
8/22/2017http://50.79.187.201:8081/4DACTION/Web_QExec
A33
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 34 of 43
(Page 61 of Total)
Back to your search
Printer Friendly
Country equals United States and Project Type equals Rail and Financial Close equals 2014 = 3 projects | 3 closed -- $4,671m project cost
= back to top
[x] = construction underway or completed
[o] = proposed
Name
(click for
detail)
Project
Description
Public
Sponsors
+Advisors
Developer
+Advisors
Builders
+Operators
Financiers
+Advisors Project Status
Financial Close:
Cost (current US$):
Contract Type:
[x] Rail:
California,
Los Angeles Regional
Connector
Transit Corridor
United States
1.9-mile
underground
transit link between the
Metro Gold
Line, Metro Blue Line and
Expo light rail
t. . .
Los Angeles
County
Metropolitan Transportation
Authority (Me...
.
N/A . Skanska/Traylor
Brothers ... .
Metro grant:
$160m US
DOT construction
g... .
Under
construction.
9/14 constructon
start. 4/14
NTP. 2/14 $670m
construction
grant signed... .
Close: 04/14
Cost (Construction): US$918m
Contract Type: DB_________________ .
[x] Rail:
Florida, All
Aboard Florida,
Miami-
Orlando
High Speed Rail
United States
High-speed
passenger rail
system in 240-mile corridor
between
Orlando and
Miami, with stops in Ft. L. .
.
Florida DOT
(FDOT)
.
Under
construction.
Unsolicited proposal
from: All
Aboard Fl... .
Siemens (train
operator) Archer
Western (upgrade 66
miles of... .
Bank of
America
Merrill Lynch 10/15
seek... .
Under
construction.
5/16 Tri Rail link to All
Aboard
Florida's Miami
Station approved by
s... .
Close: 11/14
Cost (Project): US$3500m
Contract Type: BOO
_________________ .
[x] Rail:
Virginia,
Dulles Corridor
Metrorail
(Silver Line)
Project,
pkg. B, Rail
Yard
United
States
DB a rail yard
and
maintenance facility at
Dulles
International Airport as third
phase of Silver
Lin. . .
Metropolitan
Washington
Airports Authority
(MWAA)/
Washingto... .
N/A . Hensel/Phelps... . N/A . 8/14 award.
2/14 shortlist;
award expected in
June.... .
Close: 08/14
Cost (Construction): US$253m
Contract Type: DB_________________ .
Page 1 of 1Survey
8/22/2017http://50.79.187.201:8081/4DACTION/Web_QExec
A34
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 35 of 43
(Page 62 of Total)
Back to your search
Printer Friendly
Country equals United States and Financial Close equals 2015 and Project Type equals Motorway = 10 projects | 10 closed -- $3,766m project cost
= back to top
[x] = construction underway or completed
[o] = proposed
Name
(click for
detail) Project Description
Public Sponsors
+Advisors
Developer
+Advisors
Builders
+Operators Financiers +Advisors Project Status
Financial Close:
Cost (current US$):
Contract Type:
[x] Motorway:
Georgia, I-85
Express Lanes, Gainesville
United States
Add 10 miles of one
additional express lane
northbound and southbound on I-85
from Old Peachtree Roa.
. .
Georgia DOT
.
N/A . CW Matthews
(DB)... .
N/A . 7/15 award.... . Close: 07/15
Cost (Construction): US$140m
Contract Type: DB_________________ .
[x] Motorway:
Michigan,
Detroit Freeway
Lighting,
Detroit
United States
15yr contract including
2yrs construction to
replace 15,000 lights in Detroit metro region
freeways . . .
Michigan DOT
(MDOT)
.
Freeway Lighting
Partners (FLP): Star
America Infrastructure... .
DB cost: $40m.
Aldridge Electric
(DB) Parsons Brinckerhoff (... .
debt: Allianz Life
Insurance
(Blackrock)... .
Operational.
8/24/15
financial and commercial
close. 5/14 four
shortlisted. 3/14 RFQ. 7/13... .
Close: 08/15
Cost (Project): US$90m
Contract Type: DBFOM_________________ .
[x] Motorway:
Nevada,
Project Neon, I-15 Widening,
Las Vegas
(DB)
United States
A 3.7-mile-long
widening of I-15
between Sahara Avenue and the “Spaghetti
Bowl” interchange in
downt. . .
Nevada DOT
.
N/A . Kiewit
Infrastructure
West... .
N/A . 12/15 award.
10/15 preferred
bidder.... .
Close: 12/15
Cost: US$559m
Contract Type: DB
_________________ .
[x] Motorway:
Ohio, Southern Ohio Veterans
Memorial
Highway
(Portsmouth Bypass), SR
823
United States
DBFOM of a 16-mile
greenfield limited-access, four-lane divided
highway bypassing 26
miles of local . . .
Ohio Department of
Transportation (ODOT)
Ernst & Young (f...
.
Portsmouth
Gateway Group: ACS Infrastructure
Development, In... .
DB $430m
Dragados USA (Grupo ACS)
(50%), Beaver
Construction... .
equity: $49m. TIFIA
loan: $208m; 1.27% (... .
Under
construction. 4/7/15 financial
close; expected
completion
2019. 3/31/15 TIFIA agreem...
.
Close: 04/15
Cost (Project):
US$557m
Contract Type: DBFOM_________________ .
[x] Motorway:
Pennsylvania,
Rapid Bridge Replacement
Project
United States
Availability-pay DBFM
bundling of 558
structurally deficient bridges to be rebuilt
under a single 3y. . .
Pennsylvania DOT
(PennDOT)
KPMG (fa & overall strategic a... .
Plenary Walsh
Keystone Partners:
Plenary Group (80%)/ The Wa... .
Walsh
(60%)/Granite
Construction (40%) ($899m DB) HDR
Engine... .
Mobilizatiton/milestone
payments: $225m ... .
Under
construction.
6/15 construction
start. 3/18/15
financial close; est.completion
12/17... .
Close: 03/15
Cost (Construction): US$899m
Contract Type: DBFM_________________ .
[x] Motorway:
Texas, US 181
Harbor Bridge Replacement,
Corpus Christi
United States
Project is to replace
I-mile Harbor Bridge
carrying U.S. 181 over the Corpus Christi, TX
ship channe. . .
Texas DOT
(TxDOT)
Nossaman (legal) HNTB (technical) .
CIBC World Markets
Corp (financial)
Chadbourne & Parke (le... .
$829m DB cost.
Flatiron
(50%)/Dragados (Grupo ACS) (50%)
(DB... .
N/A . Under
construction.
8/16 groundbreaking;
five yrs.
construction. 9/28/15 CDA
signed. 4/30/...
.
Close: 09/15
Cost (Construction): US$898m
Contract Type: DBM_________________ .
[x] Motorway: Virginia, I-64
Capacity
Improvements,
Seg. 1, Newport News
United States
Widen 21 miles of I-64 between Jefferson Ave.
and Yorktown Rd. in
Newport News. This
$122m project i. . .
Virgnia DOT.
N/A . Shirley Contracting (DB) Dewberry
(design)... .
N/A . Under construction.
9/15 NTP;
construction
start; est. completion
Dec.2017.... .
Close: 09/15
Cost (Construction):
US$122m
Contract Type: DB
_________________ .
Name
(click for
detail) Project Description
Public
Sponsors+Advisors Developer+Advisors Builders+Operators Financiers+Advisors Project Status
Financial Close:
Cost(current US$):
Contract Type:
[x] Motorway:
Virginia, Route
29 Solutions, three projects,
Charlotteville
United States
Improve north-south
corridor on Rt. 29 in
Charlottesville/Albemarle County region. Three
projects (o. . .
Virginia DOT
.
N/A . Lane/Corman (DB)
RK&K (Richmond)
(design)... .
N/A . 3/15 start. 1/15
preferred
bidder.... .
Close: 03/15
Cost (Construction): US$117m
Contract Type: DB
_________________ .
[x] N/A . N/A .
Page 1 of 2Survey
8/22/2017http://50.79.187.201:8081/4DACTION/Web_QExec
A35
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 36 of 43
(Page 63 of Total)
Motorway: West Virginia,
Corridor H
United States
DBF a 7.5-mile, 4-lane section of US Route 48,
from Kerens in Randolph
County to the US 219
Connecto. . .
West Virginia DOT (WVDOT)
.
Kokosing Construction/ El
Robinson
Engineering ... .
11/15 preferred bidder;
expected
completion Fall
2019.... .
Close: 11/15
Cost: US$210m
Contract Type: DBF_________________ .
[x] Motorway:
West Virginia,
US 35 Completion
United States
Complete remaining
14.6-mile grade and
drainage project on US 35. Upon completion,
entire length of . . .
West Virginia DOT
(WVDOT)
.
Bizzack
Construction ... .
N/A . Gap financing provided
by Bizzack Constr... .
10/15
construction
start. 6/15 award;
expected
completion October 2018....
.
Close: 10/15
Cost (Construction): US$174m
Contract Type: DBF_________________ .
Page 2 of 2Survey
8/22/2017http://50.79.187.201:8081/4DACTION/Web_QExec
A36
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 37 of 43
(Page 64 of Total)
Back to your search
Printer Friendly
Country equals United States and Financial Close equals 2015 and Project Type equals Toll Motorway = 4 projects | 4 closed -- $6,804m project cost
= back to top
[x] = construction underway or completed
[o] = proposed
Name
(click for
detail)
Project
Description
Public
Sponsors
+Advisors
Developer
+Advisors
Builders
+Operators
Financiers
+Advisors
Project
Status
Financial Close:
Cost (current US$):
Contract Type:
[x] Toll Motorway:
Indiana,
Indiana Toll Road (ITR)
(2015)
United States
Sale of ITR
Concession Co.
(ITRCC) to IFM Investors for
$5.725b. IFM
will take over the 66yrs
remain. . .
Indiana
Finance
Authority (IFA)
.
2016: ITR
Concession Co.:
IFM Investors (IFM Gobal
Infrastr... .
Roy
Jorgenson
(O&M)... .
equity: $3.2bn
(57% of
purchase price) d... .
Operating.
6/16
CalPERS and Allstate
(insurance)
Corp. have each
purchased
stakes in IFM. ... .
Close: 05/15
Cost: US$5275m
Contract Type:
concession_________________ .
[x] Toll Motorway:
North Carolina,
I-77 HOT Lanes,
Charlotte
United States
50yr DBFOM
with toll
revenue risk to widen and
convert 26-mile
section of I-77,
north of I-85 interc. . .
North
Carolina
DOT (NCDOT)
KPMG
(financial)
Ray Strategie...
.
Cintra
Infraestructuras,
S.A. (Ferrovial) / John Laing
($25m... .
DB--Ferrovial
Agroman,
financial responsible
party with FA
(... .
equity: $249.8m
(Cintra/Aberdeen
Global ... .
Under
construction.
6/16 NC legislature
votes to
cancel
project; but Senate
refuses to
con... .
Close: 05/15
Cost (Project): US$648m
Contract Type: DBFOM
_________________ .
[x] Toll Motorway: Texas,
Bergstrom
Expressway, Austin
United States
4yr DB contract for design and
reconstruction
of 8 miles of US 183 from US
290 in Austin to
SH 71 ne. . .
Central Texas
Regional
Mobility Authority
.
N/A . Colorado River
Constructors:
Balfour Beatty/Fluor
$581 (DB)...
.
N/A . 6/15 award; expected
construction
start 2016.... .
Close: 06/15
Cost (Construction):
US$581m
Contract Type: DB
_________________ .
[x] Toll Motorway:
Texas, SH 360, Fort
Worth/Arlington
United States
Design and
build 9.7 miles of
improvements
to SH 360 in Fort
Worth/Arlington
including 2x2 toll lane. . .
Texas
DOT/North Texas
Tollway
Authority (NTTA)/
North
Centra... .
N/A . Lane/Abrams
(DBM) AECOM
(design)... .
N/A . 5/15
agreement signed;
construction
start late 2015, est.
completion
fall 2017.... .
Close: 05/15
Cost: US$300m
Contract Type: DB_________________ .
Page 1 of 1Survey
8/22/2017http://50.79.187.201:8081/4DACTION/Web_QExec
A37
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 38 of 43
(Page 65 of Total)
Back to your search
Printer Friendly
Country equals United States and Project Type equals Rail and Financial Close equals 2015 = 2 projects | 2 closed -- $1,374m project cost
= back to top
[x] = construction underway or completed
[o] = proposed
Name
(click for
detail)
Project
Description
Public
Sponsors
+Advisors
Developer
+Advisors
Builders
+Operators
Financiers
+Advisors Project Status
Financial Close:
Cost (current US$):
Contract Type:
[x] Rail:
California,
High Speed Rail,
construction
packages 2-3, Fresno-Kern
County
United
States
DB high-speed
rail civil works
for 60-mile segment from
the terminus of
Construction Package 1 at E.
. .
California High
Speed Rail
Authority (CHSRA)
Arcadis (pro... .
N/A . Dragados (Grupo
ACS)-Flatiron
(Hochtief-Grupo ACS)/Shimmick ... .
N/A . Under
construction.
6/15 award. 12/14 preferred
bidder. 9/14
proposals due. 4/14 RFP.
2/14... .
Close: 06/15
Cost (Construction): US$1234m
Contract Type: DB_________________ .
[x] Rail: Colorado,
FasTracks, Southeast Rail
Extension,
Denver
United
States
Add 2.3 miles
to the Southeast Rail
Line under the
FasTracks
Program in Denver from
Lincoln to
Ridge. . .
Regional
Transportation District
(Denver) (RTD)
.
N/A . Balfour Beatty Infra.
Inc. Parsons Brinckerhoff
(design)... .
N/A . 6/15 NTP; est.
completion 2019. 2/15
RFP.... .
Close: 06/15
Cost (Construction):
US$140m
Contract Type: DB_________________ .
Page 1 of 1Survey
8/22/2017http://50.79.187.201:8081/4DACTION/Web_QExec
A38
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 39 of 43
(Page 66 of Total)
Back to your search
Printer Friendly
Country equals United States and Financial Close equals 2016 and Project Type equals Motorway = 2 projects | 2 closed -- $1,038m project cost
= back to top
[x] = construction underway or completed
[o] = proposed
Name
(click for
detail)
Project
Description
Public
Sponsors
+Advisors
Developer
+Advisors
Builders
+Operators
Financiers
+Advisors Project Status
Financial Close:
Cost (current US$):
Contract Type:
[x] Motorway:
Arizona, Loop
202 South Mountain
Freeway,
Phoenix
United States
Greenfield 22-
mile, 8-lane
(4x4) untolled freeway around
the southern and
western sides of Phoenix, . . .
Arizona DOT/
Maricopa
Association of Governments
HDR (des... .
... . Connect 202
Partners: Fluor
Enterprises/ Granite
Constructio... .
Federal-aid
funds state
highway funds, l... .
2/26/16 award;
agreement
finalized; to open 2019. 1/16
preferred
bidder. 11/15 proposals s... .
Close: 2/16
Cost (Construction): US$916m
Contract Type: DBM_________________ .
[x] Motorway:
Washington, I-5 Freeway
and SR 16,
Tacoma
United States
Reconstruct both
lanes of I-5 at its interchange with
WA SR 16 in
Tacoma. Includes
construction of
H. . .
Washington
State DOT.
N/A . Skanska... . N/A . 9/16
construction start. ... .
Close: 09/16
Cost (Construction):
US$122m
Contract Type: DB
_________________ .
Page 1 of 1Survey
8/22/2017http://50.79.187.201:8081/4DACTION/Web_QExec
A39
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 40 of 43
(Page 67 of Total)
Back to your search
Printer Friendly
Country equals United States and Financial Close equals 2016 and Project Type equals Toll Motorway = 3 projects | 3 closed -- $1,845m project cost
= back to top
[x] = construction underway or completed
[o] = proposed
Name
(click for detail)
Project
Description
Public
Sponsors
+Advisors
Developer
+Advisors
Builders
+Operators
Financiers
+Advisors Project Status
Financial Close:
Cost (current US$):
Contract Type:
[x] Toll Motorway:
Colorado, C-470
Express Lanes, Segment 1,
Denver
United States
A 27-mile tolled
managed lanes
project in the south and west
quadrants of the
Denver metro area, run. . .
Colorado
DOT/ HPTE
Louis Berger
Group .
N/A . Flatiron/Aecom
segment 1 DB
cost: Guaranteed
Maximum Price,
... .
The project
is funded
by $110.6 million ... .
Under
construction.
11/16 construction
start;
est.completion spring 2019.
4/16 award.
9/15... .
Close: 11/16
Cost (Project): US$318m
Contract Type: DB_________________ .
[x] Toll Motorway: Georgia,
I-285/SR 400
Improvements, Atlanta
United States
2014 plan: improvements
to 16.5km of
I-285/SR 400 interchange
area in metro
Atlanta. Two
projects to. . .
Georgia DOT
(GDOT)/
State Road and
Tollway
Authority
(SRTA)<... .
... . $458m DB cost. $800 project
cost. North
Perimeter Contractor... .
debt: $458m
(max) tax-
exempt bank debt;
... .
4/11/16 NTP. 4/8/16 financial
close;
completion est. 2020. 2/8/16
commercial
close. 12/10/...
.
Close: 04/16
Cost (Construction):
US$458m
Contract Type: DBF
_________________ .
[x] Toll Motorway:
Texas, SH 288
Toll Lanes, Houston, Harris
County
United States
52yr (including
3.4yrs
construction) DBFOM toll
revenue-risk
concession for 2x2 toll lanes in
existi. . .
Texas DOT
(TxDOT)
Mayer Brown
(legal)
KPMG (financial)
Ja... .
Blueridge
Transportation
Group (BTG): ACS
Infrastructure
Dev... .
construction
cost est.:
$800m. Dragados
(Grupo ACS)
(30%)/ P... .
equity:
$375m
debt: $646m:
TIFIA
$357m... .
Under
construction.
5/9/16 financial close. 3/5/2016
commercial
close. 2/15 award. 1/14
RF... .
Close: 05/16
Cost (Project): US$1069m
Contract Type: DBFOM_________________ .
Page 1 of 1Survey
8/22/2017http://50.79.187.201:8081/4DACTION/Web_QExec
A40
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 41 of 43
(Page 68 of Total)
Back to your search
Printer Friendly
Country equals United States and Financial Close equals 2016 and Project Type equals Rail = 2 projects | 2 closed -- $3,525m project cost
= back to top
[x] = construction underway or completed
[o] = proposed
Name
(click for
detail)
Project
Description
Public Sponsors
+Advisors
Developer
+Advisors
Builders
+Operators
Financiers
+Advisors Project Status
Financial Close:
Cost (current US$):
Contract Type:
[x] Rail:
Hawaii,
Airport Guideway
and
Stations, Honolulu
United States
Construction of
5.2 miles of new
elevated guideway
between Aloha
Stadium to the Middle Street
Transi. . .
Honolulu
Authority for
Rapid Transportation
.
N/A . Granite
Construction
Co./ Shimmick Construction
Co./ Traylor... .
N/A . 9/16 award;
construction to
begin spring 2017 and be
completed by
2021.... .
Close: 09/16
Cost (Construction): US$875m
Contract Type: DB_________________ .
[x] Rail:
Maryland,
Purple Line LRT,
Bethesda-
New
Carrollton
United
States
36yr DBFOM
$149m/yr
availability pay P3 (30yr O&M)
for greenfield,
stand-alone
16.2-mile light rail . . .
Maryland DOT
(MDOT)/
Maryland Transit Administration
(MTA).
Purple Line
Transit
Partners LLC: Fluor
Enterprises
(70%)/Me... .
db cost $2 bn
Fluor/Lane
(Salini Impregilo)
(30%)/Traylor
(d... .
• Progress
Payments:
$860m • Revenue
S... .
In pre-
construction.
8/16 US District judge stays
construction
start pending
another rider... .
Close: 06/16
Cost (Project): US$2650m
Contract Type: DBFOM
_________________ .
Page 1 of 1Survey
8/22/2017http://50.79.187.201:8081/4DACTION/Web_QExec
A41
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 42 of 43
(Page 69 of Total)
Back to your search
Printer Friendly
Country equals United States and Financial Close equals 2017 and Project Type equals Toll Motorway = 1 projects | 1 closed -- $1,900m project cost
= back to top
[x] = construction underway or completed
[o] = proposed
Name
(click for
detail)
Project
Description
Public
Sponsors
+Advisors
Developer
+Advisors
Builders
+Operators
Financiers
+Advisors Project Status
Financial Close:
Cost (current US$):
Contract Type:
[x] Toll Motorway:
California,
I-405 Improvement
Project, Orange
County
United States
Design-build
one general-
purpose lane in each direction
from Euclid
Street to I-605 in Orange
County. . .
Orange County
Transportation
Authority (OCTA)
Nossaman .
... . OC 405 Partners:
OHL USA/Astaldi.
$1.2 billion construction ... .
$1.25
billion of
local sales tax
funds. ... .
In procurement.
2/17 contract
executed. 3/16 RFP; responses
due 8.31.16.
11/15 shortlist. ... .
Close: 02/17
Cost (Project): US$1900m
Contract Type: DB_________________ .
Page 1 of 1Survey
8/22/2017http://50.79.187.201:8081/4DACTION/Web_QExec
A42
USCA Case #17-5132 Document #1689991 Filed: 08/23/2017 Page 43 of 43
(Page 70 of Total)