sow detroit courtroom 219 · the purpose of this statement of work (sow) is to provide the district...

31
Page 1 of 4 STATEMENT OF WORK (SOW) Detroit Courtroom 219 - Courtroom Technology Upgrade BACKGROUND INFORMATION The U.S. District Court Michigan Eastern District has been upgrading the AV technology in its courtrooms for several years. The AV installations generally follow once a courtrooms infrastructure has been upgraded to include floor boxes and data paths. We have installed systems in Detroit and in each in our divisional courthouses in Ann Arbor, Bay City, Flint and Port Huron. Detroit courtroom 219 will be receiving infrastructure upgrades and we will be installing the AV equipment described in this SOW and Attachments A & B. OBJECTIVE The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system, sound system, installation and programming. The Court would normally conduct a walkthrough of the courtroom. Due to the ongoing pandemic access to the court is limited at the present time. We are hoping to obtain quotes without a walkthrough. SCOPE OF WORK The Courtroom 219 will be undergoing infrastructure construction that will include adding floor boxes for the lectern, attorney table and witness location. Construction is tentatively scheduled to start in early in 2021. This AV installation will be coordinated with the completion of the construction. Attachment A is an equipment list the court has been installing in our AV upgrades the past two years. This list includes equipment that our Administrative Office (AO) AV contractors have recommended. The court is requiring that Attachment A be completed along with your quotes. This will ease the courts burden when comparing quotes. It is understood that model numbers change and equipment purchased a year ago may no longer be available. Equivalent equipment can be quoted and any additional equipment required should be added to Attachment A by AV vendor. Attachment B shows the courts requirement and what functions are required at each courtroom location. Construction drawings and courtroom pictures will be included with RFQ/SOW submission. All contractor trash must be removed from the building by the contractor and disposed of by the contractor. The courts trash dumpsters and recycling services cannot be utilized by the AV contractor. Contractor will be responsible for cleanup and removal of all trash from the court containers that the contractor places in the court’s containers.

Upload: others

Post on 06-Aug-2020

0 views

Category:

Documents


0 download

TRANSCRIPT

Page 1: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

Page 1 of 4

STATEMENT OF WORK (SOW) Detroit Courtroom 219 - Courtroom Technology Upgrade

BACKGROUND INFORMATION

The U.S. District Court – Michigan Eastern District has been upgrading the AV technology in its

courtrooms for several years. The AV installations generally follow once a courtrooms infrastructure has

been upgraded to include floor boxes and data paths. We have installed systems in Detroit and in each

in our divisional courthouses in Ann Arbor, Bay City, Flint and Port Huron. Detroit courtroom 219 will be

receiving infrastructure upgrades and we will be installing the AV equipment described in this SOW and

Attachments A & B.

OBJECTIVE

The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading

the courtroom technology equipment, control system, sound system, installation and programming. The

Court would normally conduct a walkthrough of the courtroom. Due to the ongoing pandemic access to

the court is limited at the present time. We are hoping to obtain quotes without a walkthrough.

SCOPE OF WORK

The Courtroom 219 will be undergoing infrastructure construction that will include adding floor boxes for the lectern, attorney table and witness location. Construction is tentatively scheduled to start in early in 2021. This AV installation will be coordinated with the completion of the construction.

Attachment A is an equipment list the court has been installing in our AV upgrades the past two years. This list includes equipment that our Administrative Office (AO) AV contractors have recommended. The court is requiring that Attachment A be completed along with your quotes. This will ease the courts burden when comparing quotes. It is understood that model numbers change and equipment purchased a year ago may no longer be available. Equivalent equipment can be quoted and any additional equipment required should be added to Attachment A by AV vendor.

Attachment B shows the courts requirement and what functions are required at each courtroom location.

Construction drawings and courtroom pictures will be included with RFQ/SOW submission.

All contractor trash must be removed from the building by the contractor and disposed of by the contractor. The courts trash dumpsters and recycling services cannot be utilized by the AV contractor. Contractor will be responsible for cleanup and removal of all trash from the court containers that the contractor places in the court’s containers.

Page 2: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

Page 2 of 4

SECURITY REQUIRMENTS

The contractor shall provide competent personnel to perform services under this contract. Work shall be

performed in accordance with the best commercial practices, without unnecessary delays or interference

with the Court’s mission or functions. The Contracting Officer (CO) and the Contracting Officer’s

Technical Representative (COTR) reserves the right to judge the adequacy of the services provided, and

may require the contractor to replace the support resource(s), if deemed inadequate. Formal U.S.

Marshal Service security clearances are required prior to the start of any work. Personnel contracted by

the Courthouse to provide services covered under this contract will be subjected to security background

checks and U.S. Marshal daily inspections when entering the Courthouse. The contractor shall be

responsible for completing a contractor clearance document for the contractor’s employees performing

said services. Upon completion, the document should be returned via email to the Contracting Officer,

Bill Truskowski, at [email protected]. This document enables the Court to

complete a background check on the worker(s) provided by the contractor. The document MUST be

completed prior to the contract work start date. Under no circumstances shall any court data and/or

property be taken or removed from the court.

DOCUMENTATION REQUIREMENTS

The Contracting Officer (CO) will issue the winning bidder a purchase order based on the Statement of

Work and all attachments. The Court’s purchase order will be the ONLY governing document for the

procurement of goods and services from the contractor. The contractor shall be responsible for providing

an invoice billed to the Court with net 30 day payment terms. The Court does not pay for services prior

to them being rendered. Upon receipt of the invoice by the Court, and verification that work has been

completed by the Court’s Technical Representative, payment will be rendered to the contractor for the

specified amount.

CONTRACT CLAUSES

Once the Award has been made, the Court reserves the right to cancel the contract with the contractor

for failure to complete the work as specified in this agreement. The person(s) assigned by the contractor

to perform the specified work shall not be deemed a U.S. District Court Employee, but shall be an

employee of the contractor. The contractor warrants that its employees are adequately covered by

workers compensation insurance and that it assumes total responsibility to pay all applicable federal,

state and local withholding taxes and unemployment taxes, as well as social security, state disability

insurance and all other payroll charges. The contract further warrants that the person(s) performing the

work are certified and knowledgeable enough complete the work as specified in the statement of work.

Other pertinent information will be provided to the contractor upon acceptance of the winning bid

proposal. This information will include the following: 1) exact start and end time of daily work hours, 2)

miscellaneous information (example: driving directions, and parking information).

Page 3: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

Page 3 of 4

CONTRACT MANAGEMENT

The administration of this contract will require coordination between the contracting officer, the COTR,

and the contractor. The individuals cited below will be the court’s primary points of contact during the

performance period. In no event shall any understanding or agreement, modification, change order, or

other matter in deviation from the terms of this contract between the contractor and a person other than

the contracting officer be effective or binding upon the Court. All such actions must be formalized by a

proper contractual document and signed by all parties.

CONTRACTING OFFICER: All administration of this contract will be affected by the contracting

officer:

Bill Truskowski – Procurement Officer

United States District Court

231 West Lafayette Blvd – Room 827

Detroit, MI 48226

Phone: 313-234-5362

Fax: 313-202-5843

Email: [email protected]

Written communications shall make reference to the contract title and shall be mailed to the above

address. The contracting officer is authorized to certify invoices for payment in accordance with

the terms of this contract.

CONTRACTING OFFICER TECHNICAL REPRESENTATIVE (COTR):

The COTR for this contract is:

Jay Theisen – Systems Manager United States District Court 231 West Lafayette Blvd. Detroit, MI 48226 Phone: 313-234-2618 Email: [email protected]

Upon award, the COTR will be responsible for coordinating the installation and performance of services

with regards to this contract. However, the COTR shall not be authorized to change any terms and

conditions of the resultant contract, including, but not limited to, price.

Responsibilities of the COTR include:

1. Monitoring the performance of the contractor’s employee(s) under the contract to ensure

compliance with the contract requirements.

2. Ensuring that changes in work under the contract are not initiated before written

authorization or modification is issues by the contracting officer.

3. Providing interpretation of the meaning of project specifications.

4. Accepting the contractor’s equipment and services.

Page 4: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

Page 4 of 4

LIMITED USE OF DATA

Performance of this contract may require the contractor’s employee(s) to access and use data and

information proprietary to the government, which is of such a nature that its dissemination or use, other

than in performance of this contract, would be adverse to the interest of the government and/or others.

The contractor and/or contactor personnel shall not divulge or release data or information developed or

obtained in performance of this contract. The contractor and its employees shall not use, disclose, or

reproduce proprietary data other than as required in the performance of this contract.

PLACE OF PERFORMANCE

Delivery of equipment/services reflected on this contract shall be performed at the U.S. District Court,

231 W. Lafayette Blvd, Detroit, MI 48226. Work will be performed during hours that do not impact the

activities of the Court or adjacent courtrooms. Performance may take place during normal work hours

(8:00 am to 5:00 pm). However, installation must be restricted to dates that will not interfere with the

Judge’s schedule. Dates will be provided to the contractor upon successful award of contract.

TYPE OF CONTRACT

This contract shall be awarded on a Technically Sound/Best Price and Past Performance Basis.

The awarding of this contract is subject to the availability of funds and approval from our Chief Judge.

Winning contractor must be available for construction and millwork contractor to review and discuss any

and all AV equipment needs for the modification and construction of floor boxes, data runs to rack,

witness box, lectern and attorney tables.

PROPOSAL DUE DATE

Proposals are due no later than Friday August 14, 2020 @5:00 PM. Offers will be subject to FAR

52.214-7, “Late Submissions, Modifications, and Withdrawal of Bids”.

Submit a copy of the proposal via email to:

Bill Truskowski – Contracting Officer

United States District Court

231 West Lafayette Blvd

Detroit, MI 48226

Phone: 313-234-5362

Email: [email protected]

Page 5: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

Item Bid Title Bid ID Bid Amount1 Audio & Control Systems Base Bid $0.002 Video & Control Systems Base Bid $0.00

$0.00

U.S. District Court - Michiagn Eastern District - Detroit Courtroom 219Attachment A Pricing SheetBidder:

GRAND TOTAL

Courtroom Name

Detroit Courtroom 219

Date:

Page 6: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

Attachment A - Audio - Detroit Courtroom 219AUDIO/CONTROLITEM MAKE MODEL QTY OFFERED MAKE OFFERED MODEL OFF. QTY UNIT PRICE TOTAL PRICEMicrophone, w/ 18" gooseneck, Cardioid capsule, integral desk stand and Switch

Shure MX418D/C 8$0.00

Microphone, w/ 18" gooseneck, cardioid capsule, integral XLR connector, Shock-mount and Switch (for lectern)

Shure MX418S/C 1

$0.00Microphone, Boundary (sidebar Judge) Shure MX391/O 1 $0.00Dual Wireless Microphone Receiver, Diversity, UHF, Digital, Frequency Agile, w/ Rack Mount Kit

Shure ULXD4D 1

$0.00Handheld Transmitter for Wireless Microphone System, w/ Condenser Cardioid Element

Shure ULXD2/SM86 1

$0.00BodypackTransmitter for Wireless Microphone System, w/ Lavaliere Condenser Cardioid Element

Shure ULX1/MX183 1

$0.00Remote Antennas For Wireless Mic System, Half Wave

Shure UA820X 2$0.00

Digital Signal Processor, Fixed I/O, 12 AEC In x 8 Out, w/ VOIP Telephone Interface

Biamp TesiraForte AVB VI 2$0.00

Digital Signal Processor, 4 Out, AVB Enabled Biamp Tesira EX-OUT 3$0.00

USB From Biamp to Reporter for electronic recording

Open 1$0.00

AVB Network Switch, Ethernet, PoE, Managed, 10/100/1000, 24-port, with AVB Option Enabled

Extreme Networks Summit X430 w/ AVB Option

1

$0.00USB 2.0 Extender over Cat 5 (for CRD to Counsel Digital Signature System)

Gefen EXT-USB2.0-LR 1$0.00

Interpreter's Control Panel w/ Approx. 15' Cord Terminated with 7-Pin XLR Connectors

Quantum 1952 w/ Cord 1

$0.00Playback Switch Quantum 2540 1 $0.00

Page 7: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

ITEM MAKE MODEL QTY OFFERED MAKE OFFERED MODEL OFF. QTY UNIT PRICE TOTAL PRICEHeadphone Amplifier Radio Design Labs ST-SH2 7 $0.00Headphone, Under Chin Bosch LBB 3441 1 $0.00Headphone Volume Control, In-line Koss VC-20 1 $0.00Self-Powered Desk Speaker, Black (for judge) Open 1

$0.00Peaker Bar, Black (for witness) Open 1 $0.00Power Amplifier, 4 Channel, 200 W/ Channel QSC CX204V 1

$0.00Speaker for jury box - with grill black?. Atlas Sound - for Jury

BoxFA138T87 6

$0.00Headphone/Microphone Combo Sennheiser HMD 26-II-600-8 2 $0.00Emitter Panel w/ Mounting Bracket - MUST BE POE

Sennheiser SZI1029 2$0.00

Modulator, Dual Channel Sennheiser SI 1015 1 $0.00Receivers, w/ Batteries Sennheiser HDI 830 / BA 300 8 $0.00Receivers, w/ Batteries Sennheiser RI 830-S / BA 300 2 $0.00Induction Neck Loop Sennheiser EZT 3011 4 $0.00Charger, 10-Position Sennheiser L 300-10-NT 2 $0.00IR Bodypack Receiver, two wideband frequencies

Sennheiser USEKI830ADA 2$0.00

Network Switch, Ethernet, PoE, Managed, 10/100/1000, 24-port (for main rack)

Cisco SG350-28MP 1$0.00

24 port patch panel IT to confirm CAT Jacks Open 2$0.00

Uninterruptible Power Supply, Rack Mountable, 1650 Watt capacity

TBD Open 1$0.00

Transient Voltage Surge Supp., 15A, Rack mount

Tripp Lite IBAR12-15ULTRA 1$0.00

Power Relay, 15A Lowell RPC-1-15A-CD 1 $0.00Credenza Equipment Rack - Color TBD Middle Atlantic C5 - 3 Bay 1 $0.00Patch Cables Misc Various Models $0.00Power Supplies and Transformers Various Models $0.00Misc Adaptors / Adaptor Cables Various Models $0.00Cable - Audio, CAT6 etc. Various Models $0.00

Page 8: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

ITEM MAKE MODEL QTY OFFERED MAKE OFFERED MODEL OFF. QTY UNIT PRICE TOTAL PRICEAudiol System Programming, Complete Programming of Entire Audio System. 2/XPanel Web Control Functionality.

1

$0.00Include Costs For an Authorized Representative of the Installation Contractor to Attend a Pre-installation Meeting Prior to Commencement of Construction at a Time Convenient to the Court.

1

$0.00Install cabling for Chambers speakers 1 $0.00EQUIPMENT SUB TOTAL $0.00LABOR SUB TOTAL $0.00GRAND TOTAL $0.00

Page 9: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

Attachment A - Video - Detroit Courtroom 219VIDEO/CONTROLITEM MAKE MODEL QTY OFFERED MAKE OFFERED MODEL OFF. QTY UNIT PRICE TOTAL PRICEDigital Matrix Switcher and Distribution System, 16 x 16, HDMI 1.3 Compatible, HDCP2 Compliant, w/ EDID Management and Key Management - Card Frame

Crestron DM-MD16X16 1

$0.00Digital Matrix Switcher, Twisted Pair Input Card, HDMI 1.3 Compatible, HDCP2 Compliant, EDID Management, and Key Management

Crestron DMC-4K-C-HDCP2 6

$0.00Digital Matrix Switcher, HDMI Input Card, HDMI 1.3 Compatible, HDCP2 Compliant, EDID Management, and Key Management

Crestron DMC-4K-HD-HDCP2 4

$0.00Digital Matrix Switcher, Twisted Pair Output Card, 2-Channel, HDMI 1.3 Compatible, HDCP2 Compliant, EDID Management, and Key Management

Crestron DMC-4K-CO-HD-HDCP2

5

$0.00Digital Matrix Switcher, HDMI Output Card, 2-Channel, HDMI 1.3 Compatible, HDCP2 Compliant, EDID Management, and Key Management

Crestron DMC-4K-HDO 2

$0.00Multi-format Twisted Pair Transmitter, Connection Panel Format, w/ Digital Video Input, Analog Video Input, HDMI 1.3 Compatible, HDCP2 Compliant, EDID Management, and Key Management, w/ Power Supply and Cover Plate, Architect/Court to Select Color, w/ Mud Rings

Crestron DM-TX-200-C-2G-B-T w/ 2G Decora Faceplate

1

$0.00

Page 10: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

ITEM MAKE MODEL QTY OFFERED MAKE OFFERED MODEL OFF. QTY UNIT PRICE TOTAL PRICEMulti-format Twisted Pair Transmitter, Furniture Mount Format,, w/ Digital Video Input, Analog Video Input, HDMI 1.3 Compatible, HDCP2 Compliant, EDID Management, and Key Management, w/ Power Supply (includes one spare)

Crestron DM-TX-4K-302-C 5

$0.00HDMI Twisted Pair Receiver, HDMI 1.3 Compatible, HDCP2 Compliant, EDID Management, and Key Management, w/ Built-in Scaler, Power Supply (includes one spare)

Crestron DM-RMC-4K-SCALER-C

9

$0.00Touch Panel, Wired, 10", Tilt, Wide Screen, 16:10, 1280 x 800, w/ Table Top Mount, Power Supply

Crestron TSW-1060 / TSW-1060-TTK-B-S

2

$0.00Main Control System, Integrated Controller, 8 - IR/Serial, 8 - Digital IO, 8 - Relays, 6 - Two way RS-232/485, 3 - Expansion Slots w/ Master Ethernet Card and Power Supply

Crestron Pro 3 w/ C2ENET-1, Power Supply, and Memory

1

$0.00CODEC, High Definition, w/ Natural Presenter Package, 1080p Premium Resolution Option

Cisco Current Standard SX80 Which is discontinued

1

$0.00VTC Camera Vaddio RoboSHOT 20 UHD 2 $0.00HDBaseT Receiver for VTC camera Vaddio OneLINK HDMI 2 $0.00 Marshall CV502 VTC small format camera, HDSDI to HDMI converter for Marshall camera - for Judge

Marshal CV502 1

$0.00Graphics Processor, 4 Window, w/ Individual Scalers & Digital Video Inputs

ExtronMGP 464 PRO DI

1$0.00

Projector Open TBD 1 $0.00DaLite Ascender Screen Electrol 133" 1 SUPPLIED BY CONSTRUCTION CONTRACTORMonitor, 22", 16:9, 1080p, LED Lit (includes one spare)

Open Open 7$0.00

Page 11: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

ITEM MAKE MODEL QTY OFFERED MAKE OFFERED MODEL OFF. QTY UNIT PRICE TOTAL PRICEMonitor Mount - Low Profile Desk Stand, Select VESA Bolt Pattern to Match Specified Monitor (includes one spare)

ErgoMart SL102 Limbo 4

$0.00Monitor Mount -for Witness Box Chief Kontour K1W120B 1 $0.00Flit-Top Table Box with control, Cable Organizer Kits, Cable Pass-Through Brackets, Blank Modules and Power Modules, Black

Crestron FT-TS600-B w/ FTA-PWR-102

2

$0.00Cable Retractors for Flip-Top Table Box (one set of retractors per box)

Crestron CBLR2-AUDIO / CBLR2-VGA / CBLR2-HD

2

$0.00Custom Floor Box Plates - Attorney Tables, Lectern, Witness, Judge, Reporter & Clerk - Layout to be Approved By Court.

Open 7

$0.00Patch Cables, Various Models 1 $0.00Power Supplies and Transformers Various Models 1 $0.00Adaptors / Adaptor Cables, Various Models 1 $0.00Control System Programming, Complete Programming of Entire Control System.

1$0.00

Engineering, Design & Labor 1 $0.00Freight 1 $0.00EQUIPMENT SUB TOTAL $0.00LABOR SUB TOTAL $0.00GRAND TOTAL $0.00

Page 12: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

Page 1 of 3

ATTACHMENT B Courtroom 219 - Courtroom Technology Upgrade

The U.S. District Court – Michigan Eastern District’s standard for courtroom AV equipment has been to use Crestron, Biamp and Extron. Equivalent equipment can be quoted and will be considered. Equivalent equipment quotes must be submitted with documentation and specifications on how the equipment conforms to existing installs and programming.

• Award winning contractor for this project must be able to attend construction meetings as necessary to coordinate installation and to provide requirements to construction contractor.

• Spare AUDIO cable to be pulled to each floor box location and judge and clerks bench and witness box.

• Spare CAT cable to be pulled to each floor box location and judge and clerks bench.

• Pull string to be pulled to each floor box location and judge and clerks bench from rack.

• System to be thoroughly tested and vetted by AV contractor before handoff to court.

• Court to receive ALL source code and must approve ALL programming code

• Presentation (PPS or equivalent) with updated images and instruction that can be provided to chambers to give to attorney's for operational purposes.

• An Xpanel.exe of the control panel needs to be provided by contractor.

• Sign off on courtroom completion by COTR. RACK:

• Credenza Rack – 27” 3 Bay – Color TBD

• Rack mounted UPS.

• 1 each - 24 Port Switch

• 2 each - 24 port patch panel or 1 each - 48 port patch panel. Video Conference Equipment Requirements:

• 1 each – Codec SX80 or equivalent

• 2 each – Vaddio Camera or equivalent. One to cover Witness. One to cover lectern and attorney tables.

• 1 each – Marshall small format camera or equivalent. To cover judge. To be mounted on top of viewing monitor.

• Codec as source on judge and clerk control only.

• Video source routing to window processor.

• Video Layout: Single Window, Dual Window, Triple Window and Quad Window

• VTC Controls: Only for Judge and Clerk panels. Address book and manual dialing. Camera presets. Projector for Jury Viewing:

• 1 each – Projector

• 1 each - Dalite Ascending Projection Screen supplied by construction contractor. See attached spec sheet

Page 13: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

Page 2 of 3

Attorney Tables - Prosecution:

• 1 each – 22” Monitor

• 1 each - DM201c input or equivalent to be mounted under each attorney table

• 1 each - Crestron Fliptop Touchscreen Control with Electrical Power, HDMI, VGA & Audio Retractors

• 2 each – XLR Microphone jacks. In floor box. To be programmed as Prosecution1&2

• 2 each – Shure 18” Gooseneck microphones or equivalent

Attorney Tables - Defense:

• 1 each – 22” Monitor

• 1 each - DM201c input or equivalent to be mounted under each attorney table

• 1 each - Crestron Fliptop Touchscreen Control with Electrical Power, HDMI, VGA & Audio Retractors

• 2 each – XLR Microphone jacks. In floor box. To be programmed as Prosecution1&2

• 2 each – Shure 18” Gooseneck microphones or equivalent

• 1 each – USB to Clerks bench for electronic signature

• 1 each – 7 Pin XLR Connection for interpreter control – Quantum 1952

Judge Bench:

• 1 each - Crestron 10” Tabletop Touch Panel or Equivalent

• 22" Monitor for viewing

• Audio out line with mini connector – for use with a speaker at the judge’s bench

• XLR Microphone jack

• Shure 18” Gooseneck microphones or equivalent

• Shure boundary microphone or equivalent

• Marshall camera to be mounted on top of viewing monitor for VTC Clerk Bench:

• 1 each - 22" monitor for viewing

• 1 each – Crestron DM201c input or Equivalent

• 1 each - XLR Microphone jack

• 1 each – Shure 18” Gooseneck microphones or equivalent

• 1 each – USB to Defense table for electronic signature Court Reporter:

• 1 each - Crestron 10” Tabletop Touch Panel or Equivalent (may move to clerk or be shared)

• 1 each - 22" monitor for viewing

• 1 each – USB Audio Wiring for digital recordings (4 line recording program)

• 1 each – Headphone Amp

• 1 each – Audio line for Headphone amp.

• 1 each – Audio line for laptop recording Lectern/Podium:

• 1 each - DM200 input (or equivalent to fit in floor box)

• 1 each - Spare CAT5 cable pulled

• 1 each - XLR Microphone jack

• 1 each – Shure 18” Shock Mounted or equivalent

Page 14: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

Page 3 of 3

Witness Box:

• 1 each – 22” Monitor with Chief Kontour K1W120B or Equivalent

• 1 each – Crestron DM201c or Equivalent

• 1 each - XLR Microphone jack

• 1 each – Shure 18” Gooseneck microphones or equivalent

• 1 each – Speaker Bar

• 1 each – 7 Pin XLR Connection for interpreter control – Quantum 1952

• Jury Box:

• 6 each – Speakers for white noise

• Will utilize wireless microphone for jury selection Gallery Display:

• 2 each – Wiring for Portable TV’s. One on each side if accessible.

• 2 each - Crestron Scaler/Receiver or Equivalent and wiring for portable TV on cart

Page 15: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

SUGGESTED SPECIFICATIONS: projection screen(s), (H) x (W), electrically operated 120 volt (60 Hz) not more than 2.4 amp. Fabric to be flame retardant and mildew resistant fiberglass with black masking borders standard. To be mounted on rigid steel roller. Screen to be raised vertically by two spring loaded aluminum arms. Shall have specially designed motor mounted inside the roller, to be three wire with ground, quick reversal type, oiled for life, with automatic thermal overload cutout, integral gears, capacitor and an electric brake to prevent coasting. To have preset but adjustable limit switches to automatically stop picture surface

in the “up” and “down” position. Case to be made of 3⁄4" wood and finished with a black primer coat, ready to accept final finish by others. Top of case and lid to be covered with black laminate. Safety features to include a lid switch to reverse and stop the screen from rising if the lid does not open. Screen to be operated by low voltage control unit, momentary contact rocker switch, and inputs for optional infrared or radio frequency remote control. To be listed by Underwriters’ Laboratories.

SPECIFICATION DATA

HDTV (16:9) Format Dimensions

Viewing Area (H x W) Nominal DiagonalA – Overall

Length of Case B – Extended Height C – Leader Height Approx. Ship. Wt.In. Cm In. Cm In. Cm In. Cm In. Cm Lbs. Kg

52" x 92" 132 x 234 106" 269 130" 330 86" 218 15" 38 480 217.7

58" x 104" 147 x 264 119" 302 130" 330 92" 234 15" 38 485 220.0

65" x 116" 165 x 295 133" 338 134" 340 99" 251 15" 38 500 226.8

78" x 139" 198 x 353 159" 404 158" 401 112" 284 15" 38 600 272.2

Video (NTSC 4:3) Format Dimensions

Viewing Area (H x W) Nominal DiagonalA – Overall

Length of Case B – Extended Height C – Leader Height Approx. Ship. Wt.In. Cm In. Cm In. Cm In. Cm In. Cm Lbs. Kg

60" x 80" 152 x 203 100" 254 130" 330 94" 239 15" 38 485 220.0

69" x 92" 175 x 234 120" 305 130" 330 100" 254 12" 30 490 222.3

87" x 116" 221 x 295 150" 381 158" 401 117" 297 11" 28 585 265.4

105" x 140" 267 x 356 180" 457 178" 452 139" 353 15" 38 654 296.7

120" x 160" 305 x 406 200" 508 178" 452 146" 371 6" 15 660 299.4

Ascender® Electrol®Automatic Electric Projection Screen Model

PRODUCT NOTES

• Matte White: Seamless in all standard sizes.

• Video Spectra 1.5: Available in sizes where both

dimensions do not exceed 8'.

• Overall case length dimensions +/- 1/4".

• 12" clearance required from back of screen housing for

clearance of extension arms.

WHEN ORDERING, MARK APPROPRIATE SELECTIONS:

1. Select size from charts on the other side.

2. Select viewing surface (All Da-Lite surfaces are GREENGUARD GOLD Certified.):

Matte White Video Spectra 1.5

3. Optional accessories:

No borders (Black masking

borders standard).

Wireless Remote Control.

Radio Frequency Remote

Radio Frequency Range

Extender available.

Infrared Remote.

Key Locking Cover Plate

for LVC Switch.

220 Volt (50 Hz) Motor.

White box and door (black standard).

Scott Goodsell
Highlight
Scott Goodsell
Typewritten Text
x
Scott Goodsell
Typewritten Text
x
Scott Goodsell
Typewritten Text
x
Page 16: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

Project Name:

Architect:

Contractor: Phone:

Reseller: Phone:

Audience Side

Back View Side View

7/8" Diameter Opening For Electrical Fittings

C

Front View

B

Fabric Width +2"

A

3⁄4"113/8"

141/2"

161/8"

PRODUCT VIEWS

A BRAND OF MILESTONE AV TECHNOLOGIES

www.milestone.com

P 800.622.3737 / 574.267.8101

F 877.325.4832 / 574.267.7804

E [email protected]

In British Columbia, Milestone AV Technologies ULC carries on business as MAVT Milestone AV Technologies ULC.

©2017 Milestone AV Technologies. DL–0209 (Rev. 1) 04.17. Da-Lite is a registered trademarks of Milestone AV Technologies. All other brand names or marks are used for identification purposes and are trademarks of their respective owners. All patents are protected under existing designations. Other patents pending.

Page 17: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,
Page 18: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,
Page 19: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,
Page 20: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,
Page 21: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,
Page 22: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,
Page 23: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

UPUP

DNDN

Page 24: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

UPUP

DNDN

Page 25: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,
Page 26: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,
Page 27: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,
Page 28: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,
Page 29: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,
Page 30: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

DATE SIGNED: 04-27-2020

Page 31: SOW Detroit Courtroom 219 · The purpose of this Statement of Work (SOW) is to provide the District Court with proposals on upgrading the courtroom technology equipment, control system,

DATE SIGNED: 04-27-2020