misapplication of fidic red book 1987
TRANSCRIPT
-
7/29/2019 Misapplication of FIDIC Red Book 1987
1/9
Welcome to DRBF ConferenceWelcome to DRBF Conference
Eng. Dr. Kamal Adnan Malas
Some misapplications of FIDIC Red BookSome misapplications of FIDIC Red Book 19871987
-
7/29/2019 Misapplication of FIDIC Red Book 1987
2/9
Some misapplications of FIDIC Red BookSome misapplications of FIDIC Red Book 19871987
5-2 Priority of contract documents
Extending the Completion date
Handing Over Certificate
44-1
48-1
Variations
Claims
Funny Arbitration Clause67
51-1
53-2
-
7/29/2019 Misapplication of FIDIC Red Book 1987
3/9
The Engineer cancelled the Priority of Documents Clause.
The Result:
Some misapplications of FIDIC Red BookSome misapplications of FIDIC Red Book 19871987
5-2 Priority of Contract Documents
In case of contradiction between the documents (which is
common practice). And after that the dispute is to be
resolved through Arbitration.
Then the result in the Arbitration is unknown due to the factthat the Arbitrator is not bound with any condition
regarding the priority of documents.
-
7/29/2019 Misapplication of FIDIC Red Book 1987
4/9
The Engineer ignores the contractor requests, and did not
give any decision regarding time for completion.
The Engineer gives variations order with out considering any
Extension Of Time (EOT)44-1
Some misapplications of FIDIC Red BookSome misapplications of FIDIC Red Book 19871987
extension of time leaving that till the end of the project?
The Result:
In case of termination of contract then may be the result is
not as per the engineer and (the employer) thoughts. theymissed the chance to agree with the contractor about Its request
for EOT.
-
7/29/2019 Misapplication of FIDIC Red Book 1987
5/9
The Engineer refuses to sign the handing over certificate, in-
spite that he signed the Municipality completion certificate.
After signing the Municipality certificate the Engineer giver
new variation orders to the contractor, and refuses to sign the
Some misapplications of FIDIC Red BookSome misapplications of FIDIC Red Book 19871987
Handing over certificate48-1
handing over certificate before the executing of these newvariations.
The Engineer issued the handing over certificate with out
informing the contractor.
The Engineer continue issuing snag lists and always mention
that the work is not done even if he has letter from thecontractor informing the engineer tat the snag list work is done.
The Result:
Many disputes between the employer and the contractor which
lead to big losses ( always the employer pay the price of the
Engineer bad decision)
-
7/29/2019 Misapplication of FIDIC Red Book 1987
6/9
The Engineer cancel the maximum variation limit ( %25 )
and leave it o en ( He thinks that he could increase the
Some misapplications of FIDIC Red BookSome misapplications of FIDIC Red Book 19871987
Variations51-1
variation in this way )
The Result:
In civil Law countries ( The employer ) looses his right to order
the contractor to execute variations with the same break down
prices of the contract.
-
7/29/2019 Misapplication of FIDIC Red Book 1987
7/9
Some misapplications of FIDIC Red BookSome misapplications of FIDIC Red Book 19871987
Claims52-1
The Engineer refuse to give decision about the claims, and
postponed them till the end of the Project. The Engineer refuse to give decision about the claims, andpostponed them till the end of the Project.
-
7/29/2019 Misapplication of FIDIC Red Book 1987
8/9
Examples:
All disputes will be resolved through Arbitration, and after
completing the Arbitration procedures then recourse to courts.
Funny arbitration clauses67
Some misapplications of FIDIC Red BookSome misapplications of FIDIC Red Book 19871987
The Engineer is the sole Arbitrator and his decisions are finaland binding.
-
7/29/2019 Misapplication of FIDIC Red Book 1987
9/9
Thank
Some misapplications of FIDIC Red BookSome misapplications of FIDIC Red Book 19871987
Eng. Dr. Kamal Adnan Malas