U.N.MEHTA INSTITUTE OF CARDIOLOGY & RESEARCH CENTRE, CIVIL HOSPITAL CAMPUS, ASARWA,
AHMEDABAD - 380016
TENDER DOCUMENT
OF
LAUNDRY WORK
DECEMBER - 2010
1
U.N.MEHTA INSTITUTE OF CARDIOLOGY & RESEARCH CENTRE
DECEMBER - 2010
BID DOCUMENT
CONDITION OF CONTRACT TECHNICAL SPECIFICATION
BILL OF QUANTITIES
FOR
LAUNDRY WORK
Issue to : Document to be download from web site https://unmicrc.nprocure.com or www.unmicrc.org Bidder’s Name : Bidder's Address : Date of Issue : 23.12.2010 Form of Receipt of Tender Fee : D.D. of any Nationalized bank / HDFC Bank / ICICI Bank / Axis Bank
2
U.N.MEHTA INSTITUTE OF CARDIOLOGY & RESEARCH CENTRE
DECEMBER - 2010
LAUNDRY WORK
TABLE OF CONTENTS
SECTION-I
1. Notice Inviting Tender…………………………………………………………………… 03 2. Prequalification criteria………………………………………………………………….. 04 3. Preamble, Scope of the work…………………………………………………………… 05 4. Procedure for submitting the Tender…………………………………………………. 06 5. Tender Form…………………………………………………………………………….. 09 6. Articles of Agreement…………………………………………………………………… 10 7. General Terms and Conditions……………………………………………………….. 14 8. Annexure – 1 “Specifications”…………………………………………………………. 15 9. Annexure – 2 “Earnest Money Deposit”……………………………………………… 16 10. Annexure – 3 “Income Tax Return & PAN Number”………………………………… 17 11. Annexure – 4 “Undertaking”…………………………………………………………… 18 12. Physical aspects………………………………………………………………………… 19 SECTION II 13. Special Conditions……………………………………………………………………… 20 SECTION III 14. B.O.Q. …………………………………………………………………………………... 24
3
SECTION-I
U.N.MEHTA INSTITUTE OF CARDIOLOGY & RESEARCH CENTRE
LAUNDRY WORK
NOTICE INVITING TENDER 1 Tender in the prescribed form is hereby invited on behalf of The Director, U.N. Mehta
Institute of Cardiology & Research Centre for LAUNDRY WORK OF HOSPITAL of the U.N. Mehta Institute of Cardiology & Research Centre at Civil Hospital Campus, Asarwa, Ahmedabad - 380016. The estimated value of the daily turnover of tender is Rs. 5000/- & yearly estimated value of tender is Rs. 17.5 lacs (Rupees Seventeen lacs & Fifty thousand only).
2. Tender documents may be downloaded from the site https://unmicrc.nprocure.com or
www.unmicrc.org. on 23.12.2010 onwards. Tender fee Rs.1000/- (Rupees One Thousand only) (non refundable) paid in the form of Demand Draft drawn on a Nationalized bank / HDFC Bank / ICICI Bank/ Axis Bank payable at Ahmedabad, in favour of The Director, U.N. Mehta Institute of Cardiology & Research Centre.
3. The required physical submission of the documents should be submitted in sealed cover
with Name of the work and Name of the Bidder written on the envelops will be received at the office of the Director, U. N. Mehta Institute of Cardiology & Research Centre on or before 11.01.2011 up to 1:30 pm
4. Contractor fulfilling pre-qualification criteria of the tender can fill up Tender online on or
before 10.01.2011 up to 6:00 pm. 5. The tender shall be accompanied by EMD amounting to Rs. 25,000/- (Rupees Twenty Five
Thousand only) in the form of Demand Draft drawn on a D.D. of Nationalized bank / HDFC Bank / ICICI Bank/ Axis Bank payable at Ahmedabad in favour of The Director,
U. N. Mehta Institute of Cardiology & Research Centre on 11.01.2011 at the Institute before opening of the tender i.e. 1:30 pm.
Any Physical submission not accompanied by the requisite EMD is liable to be rejected.
It is understood that EMD will not bear any interest and shall be returned to all
unsuccessful bidders after the award of the work to the successful bidder. The EMD will stand forfeited in the event of the contractor whose tender is accepted and fails to execute the contract when called upon to do so.
6. The EMD of successful bidder will be converted is security deposit after signing the
contract agreement. 7. The tender bid shall be valid for 90 days from the date of submission of the tender.
4
PREQUALIFICATION CRITERIA 1. Contractors are requested to submit the details about their organisation, their technical
experience, their spare capacity and their competency and suitable evidence of their financial standing. Contractors shall be liable for rejection due to any false or incomplete information furnished.
INITIAL CRITERIA FOR ELIGIBILITY FOR PRE-QUALIFICATION
I. The Bidder should have the site area within 30 kms. from UNMICRC.
II. The Bidder should have minimum five year Experience of this type of work.
III. The Bidder must have experience and work completion Certificate for LAUNDRY WORK in organizations like Big Govt. Hospital, Corporate Hospitals, Multi/Super Speciality Hospital, Western RLY., Semi Government and Local Self Government Body etc…
IV. The Bidder should have Average Annual turn over of more than Rs. 20 Lac. for the last
three financial year ending 2009-10. CA certificate with copy of balance sheets should be enclosed.
V. UNMICRC shall give to preference who is certified by Gujarat Pollution Control Board.
VI. The Bidder Should have any one financial year Bill / Purchase Order of Rs. 4 lac from one
firm.
5
U. N. MEHTA INSTITUTE OF CARDIOLOGY & RESEARCH CENTRE
LAUNDRY WORK
PREAMBLE & SCOPE OF WORK
1. PREAMBLE
1.1 It is proposed to provide LAUNDRY WORK of the U. N. Mehta Institute of
Cardiology & Research Centre, Civil Hospital Campus, Asarwa, Ahmedabad 380 016
1.2 The contractor should work with high efficiency.
2. SCOPE OF WORK - Contractor will have to wash dry all Clothes by Automatic Laundry Machine.
- Ironing of Linen will be as requirement mentioned in BOQ.
- Big clothes: Bad sheet, Draping sheet, OT Sheet, Woollen Blanket, Cotton Blanket,
Big Curtain, Gown, Apron, Screen Curtain, Mattress cover etc.
- Medium clothes: Draw sheet, Pillow, Pillow Cover, Shirt, Pent, Medium Curtain, Dirty
Clothes Bag, Operation / isolation towel, White Turkish Towel, Hall Towel, Squire
cousin cover, Ring towel, PPI Cap, Trey cover, Cautry Cover, etc.
- Small Clothes: White Napkin, Green Napkin, Mops, Cap, Mask, Duster pieces,
Triangular, Side pieces, Shaft cover etc.
- The wash linen with soap, washing detergent powder, emulsifier, Industrial salt,
Hydrogen peroxide, Hydrofluoric acid (H.F.) Borax, Liq. Ammonia, Sofener, Oxalic Acid,
Tinopol, Soda ash Bleaching Reagent and other required chemical.
6
U.N.MEHTA INSTITUTE OF CARDIOLOGY & RESEARCH CENTRE
LAUNDRY WORK
PROCEDURES FOR SUBMITTING TENDERS
A) EARNEST MONEY TENDER FEE
Should be submitted on 11.01.2011before 1:30 p.m. in a separate, sealed envelope at the Institute’s Office marked with the wordings “EARNEST MONEY & TENDER FEE” at U. N. Mehta Institute of Cardiology & Research Centre, Civil Hospital Campus, Asarwa, Ahmedabad 380 016.
B) Technical Bid (TB) TECHNICAL BID should be submitted ON LINE as per details asked on website. Copies of supporting documents can be attached in scanned format online while Physical Original submission's verification is must and to be carried out on 11.01.2011before 1:30 p.m. before opening of Tender at U. N. Mehta Institute of Cardiology & Research Centre, Civil Hospital Campus, Asarwa, Ahmedabad 380 016. a) prequalification information b) All the technical Documents like, Performance
Certificates, Copy of Income Tax Return of last three years along with Annual account, Profit & Loss account, Balance sheet etc. duly stamped and signed by the bidder.
C) Price Bid (PB) PRICE BID should be given ON LINE as per details asked on web site.
1) Please note that NO PRICES SHALL BE INDICATED in the Earnest money Bid or the Technical Bid, otherwise the Bid will be rejected outright without any further correspondence.
2) All physically submitted documents like Original Earnest Money Bid, as above must be
kept in single sealed cover marked with name of the Bidder and Name and Address of the Bidder.
3) If the Earnest money Bid does not comply the requirement, it shall be rejected and
Technical & Price bid shall not be opened. 4) If the Technical bid does not comply the requirement, it shall be rejected and the Price bid
shall not be opened.
7
A) Technical Bid:
Details of various documents- Attested copy (to Physical & to scan copy) Sr. No.
(1)
Details
(2)
Applicable or Not
Applicable
(3)
Number
(4)
Date
(5)
Issuing Authority
(6) 1 Shops &
Establishment Registration Certificate
2 PAN Card
3 Professional Tax Registration Number
4 Service Tax
5 Gujarat Pollution Control Board Certificate
Date........................................ Sign..................................................
Place........................................ Name ...............................................
Designation.......................................
Company seal...................................
8
B) PRICE BID
a. Price Bid to be submitted Online. C) Procedure for evaluation of Bid
a. This is three cover bid system. b. The physical submission of cover one and two (tender fee & EMD) will be checked and
verified (Technical + Pre qualification). The successful bidder’s, cover 3 will be opened.
c. The Bid Committee will evaluate the bids and may visit the Site of work. The Technical
Committee will approve / recommend the Qualified Bidders.
d. The Price Bid will be opened of only Technically Qualified Bidders and the Contract will be awarded to the bidder which has the lowest bid total in aggregate.
D) Criteria for Qualification in Inspection Stage Inspection Stage :-
Sr. No. Equipment Minimum Total Capacity
1 Washing Machine 100 kg. 2 Hydro Extractor 50 kg. 3 Drying Tumbler 70 kg.4 Sluice Machine 25 kg.
1. Bidder Should have adequate Capacity of Boiler for hot water, Calendaring Machine /
Flatbed press and Hot press. 2. Well established good quality of work. 3. Present available inventory. 4. Details of machines like manufacturing year, present availabilities, conditions of machines. 5. Details of establishment. 6. Present manpower and other resources. - The above Assessment will be for fulfilling the quantity and Technical Specifications of
Cardiac Hospital LAUNDRY WORK provided elsewhere in the contract. - The cost for carrying out Inspection will be paid by the Contractor.
9
U. N. MEHTA INSTITUTE OF CARDIOLOGY & RESEARCH CENTRE
LAUNDRY WORK
TENDER FORM
(ON BIDDER’S LETTER HEAD) To, The Director, U. N. Mehta Institute of Cardiology & Research Centre Civil Hospital Campus, Asarwa, Ahmedabad 380 016. I/We have read and examined the following documents relating to Cardiac Hospital Laundry Work for U. N. Mehta Institute of Cardiology & Research Centre, Ahmedabad 380 016 Gujarat.
a) Notice Inviting Tender b) Instruction to the Bidder c) Technical Specifications d) Bill of Quantities
I/We hereby submit the tender for the execution of the works referred to in the aforesaid documents upon the terms and conditions contained or referred to therein and in accordance in all respects with the type of work and other relevant details at the rates contained in the Bill of quantities and within the period of completion as stipulated in the Appendix. A sum of Rs. _______/- (Rupees ____________ Only ) is hereby forwarded in shape of D.D. of Nationalized Bank / HDFC Bank / ICICI Bank/ Axis Bank Draft No.___________ dated __________ drawn on _______________________ from ___— __ bank favouring _________________________________________ as EMD. If I/We fail to keep the tender open for a period of 90 days validity after opening the tender(s), or make any modifications in terms and conditions of the tender which are not acceptable to the Owner, I/We agree that the Owner shall without prejudice to any other right or remedy, be at liberty to forfeit the said 'EMD' absolutely. Should the tender be accepted, I/We hereby agree to abide by and fulfill the terms, conditions and provisions of the aforesaid documents. If, after the tender is accepted, I/We fail to commence the execution of the works as provided in the conditions, I/We agree that the Owner shall, without prejudice to any of their right or remedy, be at liberty to forfeit the said 'EMD' absolutely.
Signature_____________________
in the Capacity of ______________
duly authorized to sign the tender on
behalf of _____________________
(in block letters)
Witness_________________ Date_____________
Date____________________ Address_________________
Address_________________ _____________________________
________________________ Telephone No._________________
________________________ Fax No._______________________
10
U.N.MEHTA INSTITUTE OF CARDIOLOGY & RESEARCH CENTER
ARTICLES OF AGREEMENT ARTICLES OF AGREEMENT made at Ahmedabad, on this _____________ day of ______ 2010 between
M/s. UN Mehta Institute of Cardiology & Research Centre, (hereinafter referred to as ‘The Owners’ which
expression shall include his heirs, executors, administrators, and assignees) of the ONE PART.
AND
M/s. ___________________________., (hereinafter referred to as ‘The Contractor’ which express in shall
include his heirs, executors, administrators and assigns) of the other part.
Whereas the owner is desirous of getting executed the Services of proposed of UNMICRC which is
described as Hospital LAUNDRY WORK.
WHEREAS THE Contractor has expressed his desire by Applying in Advertised E Tender to provide
Laundry Work to UNMICRC, Ahmedabad under this Agreement .The Contractor has represented that they
have the necessary experience and expertise, infrastructure , manpower , training facilities for providing
compressive Laundry Work and they possess financial capability to deliver Laundry and related Work as
may be assigned to them from time to time by the institute.
NOW IT IS HEREBY AGREED AS FOLLOWS:
1. The Owner shall pay the Contractor the said Contract Amount or such other sum as shall become
payable at the times and in the manner hereinafter specified in the said Conditions.
2. The said Conditions and appendices there to shall be read and construed as forming part of this
Agreement, and the parties hereto shall respectively abide by and submit themselves to the
Conditions and perform the Agreement on their part respectively in said Conditions contained.
1. This contract comprises the following documents which are annexed.
- List of Work Planning with Mobilization of Sources Annexure-1
- List of Hierarchy of documents to this agreement shall be as under:
a Contract Agreement
b Letter of Intent dated ____________.
c Pre award Minutes of Meeting dated _____________.
d Addendum & Clarification to the Bidder to original tender
d General Conditions of tender Document.
11
- Original Tender Document as per (n)procure upload Volume-1
a Notice Inviting Tender
b Original Tender Document as per (n)procure upload
- Appendix, Addendum to Original Tender Document Volume-2
- Pre-bid Minutes of Meeting & Clarification
- Addendum to e-Tender
- Bidder’s Complete submission
- Pre award Minutes of Meeting dated ___________.
- Letter of Intent
All the said documents shall be read and construed together as forming part of this contract, and the
parties hereto will respectfully abide by this submit themselves to the conditions and stipulations and
perform the contract on their parts respectively.
6 The contractor hereby agrees to comply all the laws which may be applicable.
7 Any and all disputes or differences arising out of or in connection with this contract and not
amendable to amicable settlement shall be referred to arbitrator or panel arbitrators in accordance
with Indian Arbitration Act. Place of Arbitration shall be at Ahmedabad. One of the arbitrator shall be
appointed by the Director, UNMICRC, and other arbitrator by the Contractor, and both arbitrators will
finalize the third Arbitrator.
8 Time is essence of contract. Work is to be completed as per the time schedule mentioned in the
Letter of Intent bearing No. Cardio:_________ dated :______2010.
9 Contract labour requirement and duties as per chart which annexed herewith and marked Annexure
“B” will form part of this Agreement .The Contractor is required to follow the same in consonance
with the SOPs formed for this Work.
10 The Contractor shall pay wages to their contract labourers rendering Laundry Work at the rates
applicable under Minimum Wages Act.
11 The Contractor would be liable for wages, Service Tax, Service Charge, EPF & ESI contribution,
Workman Compensation, Gratuity and Other Benefits as per other Act/Laws applicable to the
Contract Labours.
12 TDS will be deducted from the bill amount as per the Income Tax Act.,1961.
13 The Contractor shall be responsible for all the acts done by the personnel / contract labourers
engaged by the Contractor’s personnel and contract labourers in the premises of UNMICRC,
Ahmedabad.
14 Payment will be release 15 days after receipt of necessary documents of completion of satisfactory
works by contractor.
12
15 If the Linen is not returned with washing, drying and ironing within 24 hours from its receipt even
during rains, Rs. 500/- (Rupees Five Hundred only) will be deducted from the monthly bill of the
bidder. 16 All the parts of this contract have been read and fully understood by the undersigned.
IN WITNESS, WHEREOF the official Seal of U. N. Mehta Institute of Cardiology & Research Centre, is
thereto affixed and signed on its behalf by its Director, and the Contractor has/have signed this Agreement
on the dates respectively mentioned against their signatures in the presence of the following witnesses:
In the Presence of:
____________________ ________________________
Signature and stamp of Signature and stamp of
The Owner The Contractor
Signed by the said (name) Signed by the said (name)
Witness: _____________ Witness: _________________
(Signature) (Signature)
Name: _________________ Name: ___________________
Address: _______________ Address: _________________
_______________________ _________________________
Occupation: ____________ Occupation: _______________
13
APPENDIX 'A'
Completion Certificate of Work done by the Bidder.
(to Physical & Contract scan copy)
Sr.
(1)
Nature of work
(2)
Name of the Institution / Hospital /
Organization
(3)
Contract Period
from... to …
(4)
Total Amount of Contract
(5)
Remarks
(6) 1
2
3
4
5
6
14
General Terms & Conditions: I. i) Tender document shall be downloaded from the web site & duly filled in and signed
with full validity as per Tender Enquiry, failing which Tenders will be liable to be rejected.
ii) Covering letter should clearly indicate the list of enclosures.
i. It shall be presumed that the Terms & Conditions mentioned in the Tender have
been duly accepted by bidder in the case he submits the Tender. The Bidder shall have no right to modify / alter / amend / delete any Terms / Conditions mentioned in Tender document.
ii. Each page of the Tender should be signed by the bidder with the seal of his firm while physically submitting tender in a sealed cover.
iii. Telegraphic / Telex / Fax and Letter Head quotations, and physical quotations / tenders are not acceptable and will be rejected.
iv. The owner has the right to reject, withdraw / revoke / cancel whole or any part of Tender / or at any stage without assigning any reason.
v. No correspondence shall be entertained after opening of the Tenders. II. Earnest Money Deposit (EMD-Refundable), as per Annexure-2
Tender Fees as mentioned on the page 3 of the tender document mentioned in Notice Inviting Tender (Non Refundable).
III. Each Tender must be accompanied by a Demand Draft/Pay Order for EMD payable at
Ahmedabad in the name of The Director, U. N. Mehta Institute of Cardiology & Research Centre for Rs. 25,000/- (Twenty Five Thousand only), duly discharged.
IV. The DD shall be payable by the contractor as the Earnest Money Deposit. V. No interest shall be payable by the owner on the Earnest Money Deposit. It is understood that EMD will not bear any interest and shall be returned to all
unsuccessful bidders after the award of the work to the successful bidder. The EMD of successful bidder will be converted is security deposit after signing the
contract agreement. VI. The EMD is liable to be forfeited if the Bidder withdraws or awards or impairs or regret the
Bid in any respect within the period of validity of this offer. VII. Income Tax Return (As per Annexure-3) VIII. The Bidder must attach a scanned image of last three Income tax return (ITR) and PAN
number, Issued in the name of the firm, along with Technical bid. Failure to submit the same shall render invalid automatically. Govt. of India / State Government Undertaking is exempted from submitting the Income Tax Return. The Original Document shall be presented for verification on 11.01.2011 before 1:30 p.m. along with EMD.
15
ANNEXURE – 1
SPECIFICATIONS Tender Item No.____________________ Due for opening on:_______________ Details of the equipment & machinery to be used in washing and ironing (pressing) cloths:
16
ANNEXURE – 2
EARNEST MONEY DEPOSIT Tender No.________________ Due for opening on:_________
As required by this Tender Enquiry (T/E No.____) is being submitted in the form of Demand Draft
to The Director, U. N. Mehta Institute of Cardiology & Research Centre and duly discharged in his
favour, in advance.
Detail of Demand Draft attached:
D.D. No.______________ Dated____________________ Drawn on Bank _________________________________________ Amount : Rs. ____________/- (Rupees _____________________________________ only)
Signature of the Bidder Name & Address with stamp
17
ANNEXURE – 3
INCOME TAX RETURN & PAN NUMBER Tender No.________________ Due for opening on:_________
IT Return & PAN number, as required by this Tender Enquiry (T/E. No.___________________) is
being submit along with this tender.
Details of Last 3 years IT Return & PAN number attached.
Signature of the Bidder Name & Address with Stamp
18
ANNEXURE – 4
UNDERTAKING
UNDERTAKING (To be signed on a Rs. 50/- stamp paper attested by notary)
We have carefully read the terms and conditions & have satisfied ourselves of the
meaning implied therein and after fully understanding all the implication of these terms
and conditions, we agree with them without any reservation, and undertake to abide by it
fully and unconditionally. We understand that in the event of any declarations and
contents being false or untrue the contract is liable to be terminated & black – listed.
Date........................................ Sign..................................................
Place........................................ Name ...............................................
Designation………………….......
Company seal.................................
19
U. N. MEHTA INSTITUTE OF CARDIOLOGY & RESEARCH CENTRE
LAUNDRY WORK
PHYSICAL ASPECTS OF TENDER
1 Nature of Work WASHING OF HOSPITAL CLOTHESOF U.N.MEHTA INSTITUTE OF CARDIOLOGY & RESEARCH CENTRE, CIVIL HOSPITAL CAMPUS, ASARVA , AHMEDABAD 380 016.
2 Type of Tender Rate Contract
3 Issue Date of Tender Document
Date: 23.12.2010 Web site: https://.unmicrc.nprocure.com, www.unmicrc.org
4 Tender Submission date, time Tender fee
Date: 10.01.2011 Time: Latest by 6:00 pm. (18:00 hrs) Rs. 1000/- (One Thousand Only) in the form of demand draft
payable at Ahmedabad Drawn in favour of The Director, U. N. Mehta Institute of Cardiology & Research Centre On 11.01.2011 before 1:30 pm at U N Mehta Institute of Cardiology & Research Centre, Civil Hospital Campus, Asarwa, Ahmedabad 380 016.
5 Earnest Money Deposit Rs. 25,000/- (Rupees Twenty Five Thousand only) in the form of demand draft payable at Ahmedabad Drawn in favour of The Director, U.N.Mehta institute of Cardiology & Research centre On 11.01.2011 before 1:30 pm at U N Mehta Institute of Cardiology & Research Centre, Civil Hospital Campus, Asarwa, Ahmedabad 380 016.
6 Completion Period ONE Year 7 Pre-bid meeting Date: 29.12.2010
Time: 11:00 am Place: Office of The Director, U.N.Mehta Institute of Cardiology & Research Centre, Ahmedabad 380 016. All Queries to be submitted in writing 3 days before the meeting.
8 Payments Payment release 15 days after receipt of necessary documents of completion of satisfactory works done by contractor.
9 Validity of Rates 12 Months
20
Special Terms & Conditions
1. Daily number of different size of cloth to be washed & pressed approximately is as
under. Big cloth 475, Medium cloth 250, small cloth 100 and press for big & medium
cloth. You are required to give rates for each type of cloth for wash & press. On this
basis daily charges towards washing & pressing will be calculated and party quoting
lowest (L1) will be awarded the contract. This break-up of number of cloth to be
washes & pressed daily is an approximate estimate.
2. The actual number may increase or decrease and accordingly bill is to be raised on
number of Linen actually washed & pressed.
3. The bidder has to quote for all the items mentioned in Bill of Quantities. If the bidder
fails to fill up the full Bill of Quantities, the tender of the same bidder is liable to be
rejected.
4. Collection of Dirty Linen from various wards and returning of dry / pressed Linen back
to respective wards will be the responsibility of the bidder.
5. Washed / pressed linen should be returned within 24 hrs. Late delivery is liable for
penalty.
6. The LAUNDRY WORK will be provided even on the Sundays/ Public Holidays and
during the emergency.
7. The bidders interested in the LAUNDRY WORK will have to wash and dry the cloths
with automatic LAUNDRY WORK machine.
8. The bidders / agencies having certificate of Gujarat Pollution Control Board will be
given preference.
9. The Prices filled in the Price Bid will be inclusive of the transportation from the
respective wards, wash, drying of the linen, ironing of Linen and return it to respective
wards with applicable taxes/ levies/ duties etc…
10. No increase in the price will be given in form of taxes / levies / duties increase in
wages, material rate etc…
11. The bidder should use branded raw materials during the LAUNDRY WORK process of
the linen. U N Mehta Institute of Cardiology and Research Centre reserves the right to
Accept/Reject the material to be used in the process of Laundry work.
12. If any Linen from the Institute will be returned in the torn/burnt manner OR if the Linen
is lost during the transport or washing will be the responsibility of the bidder and the
21
original price of the damaged OR lost material will be deducted from the monthly bill of
the bidder.
13. No Acidic liquid should be used for the LAUNDRY WORK of Clothes.
14. If the Linen is not properly washed OR ironed it will be returned back and it has to be
rewashed OR Re-ironed by the bidder. No extra charges will be paid for this purpose.
15. The bidder cannot transfer this contract to some one else OR even cannot appoint the
Sub Contractor for the Laundry Work.
16. The contract will be valid for One year.
17. The Director of the Institute reserves the right to terminate the contract at any stage
without any pre notification and on Immediate basis.
18. The bidder has to submit the monthly bill in two copies (Original & Duplicate)
addressing to the Director, U. N. Mehta Institute of Cardiology & Research Centre.
19. Penalty Clause: If the Linen is not returned with washing, drying and ironing within 24
hours from its receipt even during rains, Rs. 500/- (Rupees Five Hundred only) will be
deducted from the monthly bill of the bidder.
20. The Director UNMICRC Reserve the right for the implementation of penalty clause.
21. The Director of the Institute may extend the contract subject to same terms and
conditions, if found necessary, for a period of six month to which the contractor will
have to abide by. However, the extension for a period of more than six month can be
granted on mutual agreement by both parties.
22. The legal jurisdiction for any dispute will be Ahmedabad only.
23. If any dispute arises out of the transaction in any manner that shall be resolved by the
sole arbitration which shall be appointed by the Director, UNMICRC and in case such
person is not acceptable to the supplier, Director-UNMICRC shall be the final and sole
arbitrator who shall undertake the exercise of arbitration to resolve the dispute and
such award as may be given by Director-UNMICRC shall be final and binding on both
the parties.
24. In case if L1 fails to provide satisfactory services, the Director, U. N. Mehta Institute of
Cardiology & Research Centre reserves the right to terminate the contract to give the
same to L2.
25. In such case the security deposit of the terminated contractor is liable to be forfitted.
22
26. The contractor would be engaged purely on temporary and trial basis for a period of
three months to observe the working of the system by the contractor and if within the
said period, the work is not found satisfactory, the contract would be discontinued
automatically on the expiry of the said period.
27. The UNMICRC will have right to deduct Income Tax of TDS as applicable form time to
time.
28. The Contractor would be liable for wages, Service Tax, Service Charge, EPF & ESI
contribution, Workman Compensation, Gratuity and Other Benefits as per other
Act/Laws applicable to the Contract Labours. Contractor will have to provide prescribed
uniform & I-card to each staff. The Institute may refuse the entry of any personnel /
contract labour of contractor without proper uniform & I card.
29. The decisions, opinion, direction, certificate (except for payment) with respect to all or
any of the matters under relevant clause (which are herein referred to as the excepted
matters) shall be final and conclusive and binding on the parties hereto and shall be
without appeal. Any other decision, opinion, direction, certificate or valuation of the
Client or any refusal of the Authority to give any of the same, shall be subject to the
right of arbitration and review under clause 34 hereof in the same way in all respects
(including the provision as to opening the reference) as if it were a decision of the
Client.
All disputes and differences of any kind whatever arising out of or in connection with
the Contractor the carrying out of the works (whether during the progress of the works
of after their completion and whether before or after the determination abandon or
breach of the contract) shall be referred to and settled by the Client who shall state his
decision in writing. Such decision may be in the form of a final certificate or otherwise.
The decision of the Client with respect to any of the excepted matters shall be final and
without appeal as stated in relevant clause. But if either the Client or the Contractor be
dissatisfied with the decision of the Authority on a matter, question or dispute of any
kind (except any of the excepted matters)or as to the withholding by the Authority of
any certificate to which the Contractor may claim to be entitled, then in any such case
either party(the Client or the Contractor) may within 28 days after receiving notice of
such decision give a written notice to the other party through the Authority requiring
that matters in dispute be arbitrated upon. Such written notice shall specify the matters
which are in dispute or difference of which such written notice has been given and no
other shall be and is hereby referred to the arbitration and final decision of an arbitrator
to be agreed upon and appointed by both the parties or, in case of disagreements as
23
to the appointment of a single arbitrator, to the appointment of two arbitrators, one to
be appointed by each party, which arbitrators shall, before taking upon themselves the
burden or reference, appoint an Umpire. The venue for such arbitration shall be at
Ahmedabad.
The Arbitrator or Arbitrators, as the case may be, shall have power to open up, review
and revise any certificate, opinion decision requisition or notice, save in regard to the
excepted matters in dispute which shall be submitted to arbitration and of which notice
shall have been given as aforesaid.
The Arbitrator or Arbitrators, as the case may be, shall make his or their award within
one year (or such further extended time as may be decided by him or them as the case
may be with the consent of the parties) from the date of entering on the reference. In
case, during the arbitration proceedings, the parties mutually settle, compromise or
compound their dispute or difference, the reference to arbitration and the appointment
of the Arbitrator or Arbitrators, as the case may be, shall be deemed to have been
revoked and the arbitration proceedings shall stand withdrawn or terminated, with
effect from the date on which the parties file a joint memorandum of settlement thereof,
with the Arbitrator or the Arbitrators, as the case may be.
Upon every or any such reference, the cost of, incidental to the reference and award respectively, shall be in the
discretion of the Arbitrator or Arbitrators, as the case may be who may determine the amount thereof, or direct the
same to be taxed as between attorney and Client or as between party and party and shall direct by whom and to
whom and in what matter the same shall be borne and paid. This submission shall be deemed to be a submission to
arbitration within the meaning of the Indian Arbitration Act, 10 or any statutory modification thereof. The Award
of the Arbitrator or Arbitrators, as the case may be, shall be final and binding on the parties. It is agreed that the
Contractor shall not delay the carrying out of the works by reason of any such matter, question or dispute being
referred to arbitration, but shall proceed with the works with all diligence and shall, until the decision of the
Arbitrator or Arbitrators, as the case may be, is given, abide by the decision of the Authority and no award of the
Arbitrator or Arbitrators, as the case may be, shall relieve the Contractor of his obligation to adhere strictly to the
Authority 's instructions with regard to the actual carrying out of the works. The Client or the Contractor hereby
also agree that arbitration under this clause shall be a condition precedent to any right of action under the contract.
24
BILL OF QUANTITY
Sr. No. Items Approx.
Daily Qty. Rate of each
cloth Total Daily
cost Rs. 1 Big clothes: Bad sheet, Draping
sheet, OT Sheet, Woollen Blanket, Cotton Blanket, Big Curtain, Gown, Apron, Screen Curtain, Mattress cover etc.
475 Nos.
2 Medium clothes: Draw sheet, Pillow, Pillow Cover, Shirt, Pent, Medium Curtain, Dirty Clothes Bag, Operation / isolation towel, White Turkish Towel, Hall Towel, Squire cousin cover, Ring towel, PPI Cap, Trey cover, Cautry Cover, etc.
250 Nos.
3 Small Clothes: White Napkin, Green Napkin, Mops, Cap, Mask, Duster pieces, Triangular, Side pieces, Shaft cover etc.
100 Nos.
4 Only Press rate – Big Clothes: Bad sheet Big Curtain, Apron, Gown Screen Curtain, Mattress cover etc.
350 Nos.
5 Only Press rate – Medium Clothes: Draw sheet Pillow Cover, Shirt, Pent, Medium Curtain, Squire cousin cover
170 Nos.
Total daily wash / press amount:
Date........................................ Sign............................................................
Place........................................ Name..........................................................
Designation………......………….................
Company seal............................................