road safety barrier system works - tasman council · tenders are invited from suitably qualified...
TRANSCRIPT
Road Safety Barrier System Tasman Municipality 01/2016 Page 1
Request for Tender
Road Safety Barrier System Works
Various Locations, Tasman Municipality
Contract 02-2016
Closes: 17-8-2016 at 4.00pm. Tasman Council Offices, 1713 Main
Road Nubeena, Tasmania 7184
Road Safety Barrier System Tender 02/2016 Page 2
Contents
Contents
Project Requirements 4
Conditions of Tendering 4
1. Nature of Tender 4
2. Scope of Tender 4
3. Tender Documents 5
4. Addenda 5
5. Discrepancies, Errors and Omissions in Tender Documents 5
6. Submission of Tender 5
7. Lodgement of Tenders 6
8. Conforming Tender 6
9. Alternative Tender 7
10. Prerequisites to Acceptance 7
11. Rise and Fall 7
12. Inspection of Site 7
13. Notices of Tenderer 7
!Unexpected End of Formula
15. Validity Period 7
16. Acceptance of Tender 8
17. Tender Deposit 8
Scope of Works 8
18. Design and constructions requirements 8
19. The Works 9
20. Hold Points 10
Site Conditions 10
Tender Form 11
Schedules 12
Appendices
Road Safety Barrier System Tender 02/2016 Page 3
Appendix B – Location Plan
Appendix C – Council Policies that also relate to Contractors
Appendices D – State Growth W Beam Barrier Check List
Road Safety Barrier System Tender 02/2016 Page 4
Project Requirements
Tenders are invited from suitably qualified guard rail installation companies to
submit a tender to undertake works as specified in the Scope of Works and the
accompanying documentation.
Conditions of Tendering
1. Nature of Tender
Tenders shall be lodged as a lump sum and the price should be consistent with the basis of
payment as stated in the Conditions of Contract, General Specification and Project Specific
Specification.
2. Scope of Tender
The tender shall be for the whole of the works unless otherwise stated in the General Conditions
of the contract AS4902-2000, Annexure Part A. (Appendix A)
This Standard is available from Standards Australia at http://www.standards.com.au
The works shall be carried out in accordance with the Department of State Growth standard
specifications for Road Safety Barrier Systems R61 as applicable. The Department of State Growth
specifications (DSG) can be found on the DSG website, namely:
DSG General Specifications
http://www.transport.tas.gov.au/road/contractor/specifications/general
DSG G1 General Provision (DIER) – review for conflict with AS4902
http://www.transport.tas.gov.au/__data/assets/pdf_file/0010/109657/G1_General_Provisio
ns_July_2014.pdf
• Environmental Management (DIER Standard Specs G10)
• Product Quality Compliance (Inspection and Test Plan – WA plan in AS4902)
• WH&S/Risk Management Plan
• Traffic Management
• Public contact
• Maintenance procedures for defects liability period (suggest deliver prior to Date of
Practical Completion)
• Emergency Management (DIER R101)
DSG Roadworks Specifications
http://www.transport.tas.gov.au/road/contractor/specifications/roadworks
Road Safety Barrier System Tender 02/2016 Page 5
3. Tender Documents
The tender document referred to herein shall mean the Drawings, Specifications, Conditions
of Contact, Conditions of Tendering, Tender Form, Schedule of Quantities and other
documents issued to Tenderers by the Principal or his/her representative, and upon which
tenders for the contact shall be based.
4. Addenda
No amendment to the tender documents shall be recognised unless in the form of a written
addendum issued by the Principal or his representative.
5. Discrepancies, Errors and Omissions in Tender Documents
If the Tenderer finds any discrepancy, error or omission in the tender documents, notify the
Principal in writing on or before the closing date for tenders.
6. Submission of Tender
Form of Tender
Submit the tender upon the Form of Tender provided, duly completed and signed by the
Tenderer or as authorised representative.
Accompanying Documents
The following documents are to be submitted with the tender:
• Form of Tender and schedules completed and signed by the Tenderer
• Insurance Certificates of Currency
• Quality Management System certification
• Environmental Management System certification
• WHS Management System certification
• A program scheduling the various activities from the Date of Acceptance of Tender
through to issue of the Final Certificate.
• Relevant qualifications and experience of key staff that the Contractor will use to
deliver this Contact.
• Proposed systems for risk management including workplace health and safety, quality
of product and environmental management.
• A statement of the current capability and capacity to deliver the contract on time.
• Any supporting documentation which the Tenderer considers relevant to the Tender.
• Information to support the selection criteria of the Tender assessment.
• Safe Work Method Statements for all works
• White Card (or interstate equivalent) for workers to be used.
• Traffic management plans
The Tenderer shall not alter or add to any tender document except as required by these
Conditions of Tendering.
Road Safety Barrier System Tender 02/2016 Page 6
Selection Criteria
Tender selection criteria have been developed in line with the Tasman Council’s Code of
Tenders and Contracts aim of achieving value for money. The selection of the successful
Tender will be based on the following criteria:-
• Price and rates
• Workplace health and safety management plan
• Proposed systems for risk management including WHS, EMS and Quality control
• Experience of the construction company and any sub-contractors and consultants
• Experience and qualifications of key personnel
Name and Address
The Tender shall state:
• If the Tenderer is a person, the full given names, surname and address of the
Tenderer.
• If the Tenderer is a firm, the names in full of each member of the firm and address of
the firm.
• If the Tenderer is a company, the name of the company, the ABN and the address of
the registered office of the company
7. Lodgement of Tenders
Tenders must be contained in a sealed envelope and clearly marked:-
“TENDER – Road Safety Barrier Systems, Various Locations Tasman Municipality”
Tenders must be deposited in the Tender Box at the Tasman Council Offices, 1713 Main Road,
Nubeena, Tasmania 7184 prior to the closing time.
Late tenders or tenders received by facsimile or electronic mail will not be accepted.
8. Conforming Tender
A conforming tender is defined as follows:-
• It is submitted on time
• It is lodged at the nominated place
• All required schedules are completed except in the case of alternative tender a
separate schedule prepared by the Tenderer must be completed.
• Documents are properly signed
• It complies with the tender conditions
• There are no commercial and contractual qualifications to the tender
A non-conforming tender is one, which does not satisfy the above requirements and it
may be rejected.
Road Safety Barrier System Tender 02/2016 Page 7
9. Alternative Tender
An alternative tender is one, which complies with the above conditions for a conforming
tender but does not comply with the specific scope of work. However it complies with the
intent, and meets the objective or the desired outcome of the tender.
To be eligible for consideration, the alternative tender must contain all the technical
information, costs and should identify all the proposed deviations from the tender
documents. The alternative tender will only be considered if it is suitable and acceptable for
the proposed work.
It is not a requirement to submit a conforming tender with the alternative tender.
10. Prerequisites to Acceptance
The Principal may, before any tender is accepted, require a Tenderer to submit any or all of the
following:-
• Proof of his/her resources and ability to carry out the works
• An estimated monthly cash flow
• Details of the method of construction to be used
• Proof of sound financial capacity.
The tenderer shall submit this information within the specified time as required by the Principal.
11. Rise and Fall
The rise and fall adjustments to compensate for variations in labour, material and other costs
will be provided in the specifications if the contract period exceeds one year.
12. Inspection of Site
The Tenderer is required to inspect the sites, and make allowance for those site conditions in
his offered unit rates and/or lump sum prices.
13. Notices of Tenderer
The Tenderer shall acknowledge with the tender the receipt of each notice issued by the
Principal or his/her representative.
14. Completion Time
The time for completion of the works is stated in the Annexure, Part A to the General Conditions
of Contract, AS4902-2000. The Tenderer may submit different tender prices for different
completion times.
Tenderers are to make due and proper allowances for down time caused by wet weather,
storm flows, material availability and other natural delays that may occur during the
construction period.
15. Validity Period
Tender prices of rates shall remain valid for a period of 120 days from the date of closing of
tenders.
Road Safety Barrier System Tender 02/2016 Page 8
16. Acceptance of Tender
The Principal shall not be bound to accept the lowest or any tender. The Principal will not be
responsible for or pay for expenses or losses which may be incurred by any tenderer in the
preparation of the tender.
Any tender which does not comply in every respect with the requirements of the tender
documents may be rejected.
No tender shall be deemed to have been accepted until the successful Tenderer has received
a letter of acceptance of the tender from the Principal.
On acceptance of the tender the Contractor and the Principal shall execute a formal
instrument of agreement as required by the General Conditions of Contact AS4902-2000.
Until a formal instrument of agreement is executive by the parties, documents evidencing the
parties’ consensus shall constitute the contract.
17. Tender Deposit
A tender deposit is not required.
Scope of Works This contract is for the construction of Road Safety Barrier Systems at six sites in the Tasman
Municipality. The sites are shown on the attached location map (Appendix B).
18. Design and construction requirements
• Removal of the existing barrier systems is to be done by the tenderer as part of this tender.
• W-Beam Safety Barrier as approved by the State Growth Specification R61 and AS3845
• All rail shall be 4 metre lengths
• Proprietary Semi Rigid Systems to be as per the Department of State Growth R61
• All material supplied to site must come with a NATA certificate to meet Australian Standards
and be subject to the hold points/checklist in Appendix C.
• The Council reserve the right to withhold payment if site inspections by the Council conclude
that materials do not meet specification. Any cost associated with removal and or re-
installation will be the responsibility of the Head Contractor.
• Attention is drawn to the fact the contractor will be required to work in accordance with the
DSG “General Specifications” and “Roadworks Specifications”.
• A traffic management plan prepared by a suitably qualified person is to be approved by
Councils superintendent prior to any works commencing.
• The Contract will include the General Specifications prepared by the Department of
Infrastructure, Energy and Resources which can be found at
http://www.transport.tas.gov.au/road/specifications
• Practical Completion will include the works being completed to the satisfaction of the
Superintendent.
Road Safety Barrier System Tender 02/2016 Page 9
• After the completion of installation, the contractor shall supply documentation to certify that
works have been completed in accordance with the AS/NZ 3845:1999.
• Gating & non gating end treatment Terminals
• Non-Gating Terminal shall be as approved by the Department of State Growth R61
and installation shall be as per R61 design guidelines ie includes hazard free zone
etc. Proprietary Energy Absorbing Terminals shall be as per Department of State
Growths R61 but (due to site conditions eg Drive way entrances etc) must have the
point of need (PON) at the terminal starting from the very first post at the impact
head. Total barrier LON shall be determined inclusive of LON as per standard
VicRoads drawing SD3545
• All lengths shown in the schedule are for LON. The tenderer is to include the cost of the
terminal and any additional guard rail to the PON in their tender.
19. The Works
The works are to include:-
• Prior to the commencement of any works on site the Contractor shall undertake site
investigation and prepare a Contract Management Plan in accordance with the
Department of Infrastructure Energy and Resources (DIER) General specification G2 –
Contract Management Plan to the satisfaction of the Superintendent. The Contract
Management Plan is to address all aspects of this specification including:
o Detailed program of works
o Environmental management
o Product quality compliance
o Workplace health and safety
o Traffic management
o Public contact
o Maintenance during defects liability period
o Emergency management
• Site preparation including:-
o Establishing site offices and storage area and fencing with a suitable security
fence to prevent access by the public and stock.
o Relocation of services where required
o Traffic management
o Environmental protection works
• Construction of the works to the detailed design including:-
o Excavation
o Asset construction
o Relocation and management of services
o Traffic management
o Inspection and testing
Road Safety Barrier System Tender 02/2016 Page 10
o Environmental management
• Site meetings with the Superintendent on a regular basis. During peak construction
activity the frequency of these meetings may be increased at the discretion of the
Superintendent. The Contractor is to prepare minutes of site meetings and forward
to the Superintendent within three working days of the meeting.
• Project management of the Contract including, management of sub-contractors,
preparation of all programs and schedules, site meeting minutes and delivery of the
Contract Management Plan.
• Maintenance and inspection during the Defects Liability Period.
20. Hold Points
The Contract shall have Hold Points per State Growth Standard Roadworks Specifications R61.
Site Conditions It is the Contractors’ responsibility to undertake site investigations to determine conditions that may
affect both the design and the construction of the works.
Road Safety Barrier System Tender 02/2016 Page 11
Tender Form
CONSTRUCTION OF ROAD SAFETY BARRIER SYSTEMS FOR VARIOUS LOCATIONS
IN THE TASMAN MUNICIPALITY
CONTRACT 02/2016
TENDER FORM
Name of Person, form or Company tendering
Company ABN
Address of Tenderer
Contact Phone Number
Contact Fax Number
Contact E-mail Address
Hereby tender(s) to perform the work for Description of the Works Contract 02/2016: Installation of Road Safety
Barrier Systems
List of Documents In accordance with the following documents:
• Request for Tender Contract 02/2016
documents
Insert Tender Lump Sum Price For the Lump Sum of
…………………………………………………………………..
$ ……………………………………………………………….
Amount Exclusive of GST
If the Tenderer is a firm, the full name of the
firm’s representative
Insert date
Dated (day) of
(month)2016
Signature of Tenderer
Road Safety Barrier System Tender 02/2016 Page 12
Schedules
INSTALLATION OF ROAD SAFETY BARRIER SYSTEMS-VARIOUS LOCATIONS TASMAN
MUNICIPALITY
This Schedule of Works sets out the items of work required under the contract.
Each item in the schedule shall be all inclusive of design, materials, labour, plant, project and
incidentals necessary to complete the specific item.
Any item or part of the works not specifically mentioned shall be allowed for within the items in this
schedule as considered relevant by the tenderer to allow for the intended execution of the contract
in accordance with the contact documents.
This schedule sets out the items of work required under the contract.
SITE DESCRIPTION LENGTHS NOMINATED ARE A GUIDE ONLY. ACTUAL
LENGTHS MUST BE OBTAINED FROM VISITING EACH SITE AND
REFERENCING R61 AND VIC ROADS SD 3545
AMOUNT
(Excl. GST)
AMOUNT
(Incl. GST)
1 Nubeena Road 755 metres west of Marsh Road junction. Remove
existing signage and wire rope and post fence. Install approx. 174
metres of w-beam barrier system, 3 non-gating terminals, 1 BCTA.
Site ready now.
2 Saltwater River Road crossing Noxes Creek, CH 3,270. Remove
existing barrier system. Install approx. 74 metres of w-beam
barrier system with 4 non-gating terminals. Reuse approximately
54 metres existing w-beam.
Site ready March 2017.
3 Saltwater River Road crossing Garnetts Creek, CH 8,970. Install 4 /
10 metre BCTA’s. Site ready now.
4 Safety Cove Road crossing Ferks Creek, CH 4,400. Remove existing
barrier system. Install w-beam safety barrier in accordance with
attached plan (Appendix D). Site ready now.
5 Gwandalan Road, 70 metres west of Slopen Main Drive Crossing
Norfolk Bay Creek. Install approx. 80 metres of w-beam safety
barrier with 4 non-gating terminals. Site ready now.
6 Nubeena Road 415 metres east of Marsh Road junction. Add 4 / 10
metre BCTA’s to existing w-beam safety barrier. Site ready now.
TOTALS
Unit rate per metre of W-Beam if extra is required =
Road Safety Barrier System Tender 02/2016 Page 13
This Schedule of Rates will be used to assess variations to the contract sum. The rates shall be
inclusive of mark up for profit and attendance:
Item Unit Rate
(Excl GST)
Rate
(Incl GST)
Project Manager Hour
Professional Engineer Hour
Site Supervisor Hour
Tradesperson Hour
Labourer Hour
5-7t excavator Hour
Backhoe Hour
10y truck Hour
Add additional plant if required.
Tenderer’s Signature: Date:
Road Safety Barrier System Tender 02/2016 Page 14
Appendices
Appendix A – AS4902-2000 General Conditions of Contract for Design and
Construct Annexure Part A
ANNEXURE to the Australian Standard General
Conditions of Contract for Design and Construct PART A
This Annexure shall be completed and issued as part of the tender documents and, subject to any
amendments to be incorporated into the Contract, is to be attached to the General Conditions of
Contract and shall be read as part of the Contract.
Item
1 Principal
(clause 1)
Tasman Council
ACN ………………………….. ABN 63 590 070 717
2 Principal’s address 1713 Main Road
Nubeena Tas 7184
Phone: 6250 9200 Fax: 6250 9220
3 Contractor
(clause 1)
………………………………………………………………………………………………
………………………………………………………………………………………………
ACN …………………………………… ABN ………………………………………..
4 Contractor’s address
………………………………………………………………………………………………
………………………………………………………………………………………………
Phone: ………………………………. Fax: ………………………………………..
5 Superintendent
(clause 1)
………………………………………………………………………………………………
………………………………………………………………………………………………
6 Superintendent’s address
………………………………………………………………………………………………
………………………………………………………………………………………………
71 (a) Date for practical completion
(clause 1)
OR
(b) Period of time for practical
completion (clause 1)
Site’s 1,3,4,5,6 by Friday 2 December 2016
Site 2 when available. Approximately March 2017.
…………………………………………………………………………………………
1 If applicable, delete and instead complete equivalent item in the separable portions section of the Annexure
Part A
Road Safety Barrier System Tender 02/2016 Page 15
8 (c) Governing law (clause 1(h)) …………………………………………………………………………………………………
If nothing stated, that of the jurisdiction where the site is located
9 (a) Currency (clause 1(g)
(b) Place for payments (Clause
1(g))
(c) Place of business of banks
(clause 1(d))
…………………………………………………………………………………………………
If nothing stated, that of the jurisdiction where the site is located
…………………………………………………………………………………………………
If nothing stated, The Principal’s address
…………………………………………………………………………………………………
If nothing stated, the place nearest to where the site is located
10 The Principal’s project
requirements are described in the
following documents (clause 1)
1. Preliminary design (if included in Item 11)
2. Project requirements for Contract No. 01/2014
3. …………………………………………………………………………………..
4. …………………………………………………………………………………..
5. …………………………………………………………………………………..
11 Preliminary design (clause 1) A preliminary design is not included in the Principal’s
requirements.
12 Quantities in schedule of rates,
limits of accuracy (subclause 2.5)
Upper limit ………………………………………………………………………
Lower limit ……………………………………………………………………….
13 Provisional sum, percentage for
profit and attendance (clause 3)
……………………………………… %
142 Contractor’s security
(a) Form (clause 5)
(b) Amount of maximum
percentage of contract sum
(clause 5)
(c) If retention moneys,
percentage of each progress
certificate (clause 5 and
subclause 37.2)
(d) Time for provision (except for
retention moneys) (clause 5)
(e) Additional security for unfixed
plant and materials (subclauses
5.4 and 37.3)
(f) Contractor’s security upon
certificate of practical
completion is reduced by
(subclause 5.4)
Retention ……………………………………………………………………………
…………………………………………………………………………………………….
………………….. %, until the limit in Item 14(b)
If nothing stated, 10%, until the limit in Item 14(b)
Within …………………. Days after date of acceptance of tender
If nothing stated, 28 days
All items with a value of more than $5,000.00
……………………………………………………………. $ ……………………….
………………………..% of amount held
If nothing stated, 50% of amount held
153 Principal’s security
(a) Form (clause 5)
(b) Amount or maximum
percentage of contract sum
(clause 5)
(c) Time for provision (clause 5)
(d) Principal’s security upon
certificate of practical
Nil
Nil
If nothing stated, nil
Within NA days after date of acceptance of tender
If nothing stated, 28 days
Nil % of amount held
If nothing stated, 50% of amount held
2 If applicable, delete and instead complete equivalent item in the separable portions section of the Annexure
Part A 3 If applicable, delete and instead complete equivalent item in the separable portions section of the Annexure
Part A
Road Safety Barrier System Tender 02/2016 Page 16
completion is reduce by
(subclause 5.4)
16 Principal-supplied documents
(subclause 8.2)
Documents No. of copies
1. Principal’s project requirements Electronic
2. Geotechnical Report Electronic
3. ……………………………………………… …………………….
4. ……………………………………………… …………………….
5. ……………………………………………… …………………….
If nothing stated 5 copies
17 Documents, numbers of copies,
and the times or stages at which
they are to be supplied by the
Contractor (subclause 8.3)
Documents
1. Contract Management Plan
2. Preliminary Design
3. Detailed Design
4. Engineers report
5. Engineers maintenance report
No. of copies Time/stage
Electronic 2 weeks from date of acceptance
Electronic 4 weeks from date of acceptance
Electronic 8 weeks from date of acceptance
Electronic Prior to date of Practical Completion
Electronic 52 weeks from Practical Completion
18 Time for Superintendent’s direction
about documents (subclause 8.3)
……………………….days
If nothing stated, 14 days
19 Subcontracting
(subclause 9.2)
Work by consultants Work by others
………………………………………… All subcontract work with an
anticipated value of more
than 10% of the contract sum
………………………………………… …………………………………………..
………………………………………… …………………………………………..
………………………………………… …………………………………………..
………………………………………… …………………………………………..
20 Novation (subclause 9.4) Subcontractor or selected Work by others
Subcontractor, as the case All subcontract work with an
anticipated value of more
than 10% of the contract sum
………………………………………… …………………………………………..
………………………………………… …………………………………………..
………………………………………… …………………………………………..
………………………………………… …………………………………………..
21 Intellectual property rights granted
to the Principal, the Alternative
applying (subclause 10.2)
……………………………………………………………………………………………
If nothing stated, Alternative 1 applies
22 Legislative requirements
(a) Those excepted (subclause
11.1)
(b) Identified WUC (subclause
11.2(a)(iii))
Nil
…………………………………………………………………………………………..
Any WUC with a value of more than 10% of the contract sum
…………………………………………………………………………………………..
23 Insurance of the Works (Clause
16A)
(a) Alternative applying
…………………………………………………………………………………………..
Road Safety Barrier System Tender 02/2016 Page 17
If Alternative 1 applies
(b) Provision for demolition and
removal of debris
(c) Provision for consultants fees
and Principal’s consultants fees
(d) Value of materials or things to
be supplied by the Principal
(e) Additional amount or
percentage
If nothing stated, Alternative 1 applies
NA
……………………………………………….. $ ………………………………….
OR
………………………………………..% of the contract sum
NA
……………………………………………….. $ ………………………………….
OR
………………………………………..% of the contract sum
NA
……………………………………………….. $ ………………………………….
NA
……………………………………………….. $ ………………………………….
OR
………………………………………..% of the total of (a) to (d) in clause 16A
24 Professional indemnity insurance
(clause 16B and subclause 9.2(d))
(a) Levels of cover of Contractor’s
professional indemnity
insurance shall be not less than
(b) Period for which Contractor’s
professional indemnity
insurance shall be maintained
after issue of the final
certificate
(c) Categories of consultants and
levels of cover of consultants
professional indemnity
insurance
(d) Period for which each
consultant’s professional
indemnity insurance shall be
maintained after issue of the
final certificate
…………………………………………………………………………………………
…………………………………………………. $ …………………………………
If nothing stated, $5,000,000
…………………………………………………………………………………………
If nothing stated, 6 years
Category Levels of Cover
Consulting Engineers $...........................
Surveyors $...........................
Geologists $...........................
…………………………………………………………………. $............................
If nothing stated, $1,000,000
………………………………………………………………………………………….
If nothing stated, 6 years
25 Public liability insurance (clause 17)
(a) Alternative applying
If Alternative 1 applies
(b) Amount per occurrence shall
be not less than
………………………………………………………………………………………….
If nothing stated, Alternative 1 applies
………………………………………………………………………………………….
…………………………………………. $20,000,000
If nothing stated, $10,000,000
26 (a) Time for giving access
(subclause 24.1)
(b) Time for giving possession
(subclause 24.1)
Within ………………… days of date of acceptance of tender
If nothing stated, 14 days
Within……………….. days of date of acceptance of tender
If nothing stated, 14 days
27 The information, materials,
documents or instructions and the
times by, or periods within which
they are to be given to the
Contractor (clause 32)
Documents or instructions Times/Periods
1. ……………………………………………… ………………………….
2. ……………………………………………… ………………………….
3. ……………………………………………… ………………………….
4. ……………………………………………… ………………………….
5. ……………………………………………… ………………………….
28 Qualifying causes of delay, causes
of delay for which EOTs will not be
The first three days of inclement weather in each calendar month
up to and including the date of Practical Completion
Road Safety Barrier System Tender 02/2016 Page 18
granted (paragraph (b)(iii) of clause
1 and subclause 34.3)
………………………………………………………………………………………………..
………………………………………………………………………………………………..
294 Liquidated damages, rate
(subclause 34.7)
Based on a seven day week the rate shall be $110.00 per day
305 Bonus for early practical
completion (subclause 34.8)
(a) Rate
(b) Limit
………………………………………………………………………………………………..
………………………………………….. per day $ ……………………..per day
………………………………………………………………………………………………..
.………………………………………………………….$ ……………………………….
OR
………………………………………….. % of contract sum
If nothing stated, there is no waiver
316 Other compensable causes
(paragraph (b) of clause 1 and
subclause 34.9)
…………………………………………………………………………………………….
…………………………………………………………………………………………….
…………………………………………………………………………………………….
…………………………………………………………………………………………….
32 Defects Liability period (clause 35) …………………………………………………………………………………………….
If nothing stated, 12 months
33 Progress Claims (subclause 37.1)
(a) Times for progress claims
OR
(b) Stages of WUC for progress
claims
…………………………………………….. day of each month for WUC done
to the second last day of that month
………………………………………………………………………………………………
………………………………………………………………………………………………
………………………………………………………………………………………………
………………………………………………………………………………………………
34 Unfixed plant and materials for
which payment claims may be
made (subclause 37.3)
………………………………………………………………………………………………
………………………………………………………………………………………………
………………………………………………………………………………………………
35 Interest rate on overdue payments
(subclause 37.5)
5% per annum
If nothing stated, 18% per annum
36 (a) Time for Principal to rectify
inadequate access (subclause
39.7(a)(iii))
………………………………. Days
If nothing stated, 14 days
4 If applicable, delete and instead complete equivalent item in the separable portions section of the Annexure
Part A.
5 If applicable, delete and instead complete equivalent item in the separable portions section of the Annexure
Part A 6 If applicable, delete and instead complete equivalent item in the separable portions section of the Annexure
Part A
Road Safety Barrier System Tender 02/2016 Page 19
(b) Time for Principal to rectify
inadequate possession
(subclause 39.7(a)(iv)
………………………………. Days
If nothing stated, 14 days
37 Arbitration (subclause 42.3)
(a) Person to nominate an
arbitrator
(b) Rules for arbitration
(c) Appointing Authority
under UNCITRAL
Arbitration Rules
…………………………………………………………………………………………….
…………………………………………………………………………………………….
…………………………………………………………………………………………….
If no-one stated, the President of the Institute of Arbitrators &
Mediators Australia
…………………………………………………………………………………………….
…………………………………………………………………………………………….
…………………………………………………………………………………………….
If nothing stated:
(a) Rules 5-18 of the Rules of The Institute of Arbitrators &
Mediators Australia for the Conduct of Commercial
Arbitrations;
…………………………………………………………………………………………….
…………………………………………………………………………………………….
…………………………………………………………………………………………….
(b) If one or more of the parties are nationals of and
habitually resident in, incorporated in, or where the
central management and control is exercised in,
different countries as between the parties, then the
UNCITRAL Arbitration Rules shall apply and the
appointing authority shall be the person provided in Item
37(c)
…………………………………………………………………………………………….
If no-one stated, the President of the Institute of Arbitrators &
Mediators Australia.
map
© COPYRIGHT AND DISCLAIMER . Map data is compiled from a variety of sources and hence its accuracy is variable. If you wish to make decisions based on this data you should consult with the relevant authorities. Apart from any use permitted under the Copyright Act 1968, no part of the report may be copied without the permission of the General Manager, Land Tasmania, Department of Primary Industries, Parks, Water and Environment, GPO Box 44 Hobart 7001.
www.thelist.tas.gov.au
Site 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's Creek
Generated at: 12:09 on 21-June-2016 User: [email protected] 1Page: 1 of
www.thelist.tas.gov.au
map
© COPYRIGHT AND DISCLAIMER . Map data is compiled from a variety of sources and hence its accuracy is variable. If you wish to make decisions based on this data you should consult with the relevant authorities. Apart from any use permitted under the Copyright Act 1968, no part of the report may be copied without the permission of the General Manager, Land Tasmania, Department of Primary Industries, Parks, Water and Environment, GPO Box 44 Hobart 7001.
www.thelist.tas.gov.au
Site 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's Creek
Site 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks Creek
Site 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes Creek
Generated at: 13:31 on 21-June-2016 User: [email protected] 1Page: 1 of
www.thelist.tas.gov.au
map
© COPYRIGHT AND DISCLAIMER . Map data is compiled from a variety of sources and hence its accuracy is variable. If you wish to make decisions based on this data you should consult with the relevant authorities. Apart from any use permitted under the Copyright Act 1968, no part of the report may be copied without the permission of the General Manager, Land Tasmania, Department of Primary Industries, Parks, Water and Environment, GPO Box 44 Hobart 7001.
www.thelist.tas.gov.au
Site 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's Creek
Site 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks Creek
Site 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes Creek
Site 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts Creak
Generated at: 13:35 on 21-June-2016 User: [email protected] 1Page: 1 of
www.thelist.tas.gov.au
map
© COPYRIGHT AND DISCLAIMER . Map data is compiled from a variety of sources and hence its accuracy is variable. If you wish to make decisions based on this data you should consult with the relevant authorities. Apart from any use permitted under the Copyright Act 1968, no part of the report may be copied without the permission of the General Manager, Land Tasmania, Department of Primary Industries, Parks, Water and Environment, GPO Box 44 Hobart 7001.
www.thelist.tas.gov.au
Site 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's Creek
Site 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks Creek
Generated at: 13:23 on 21-June-2016 User: [email protected] 1Page: 1 of
www.thelist.tas.gov.au
map
© COPYRIGHT AND DISCLAIMER . Map data is compiled from a variety of sources and hence its accuracy is variable. If you wish to make decisions based on this data you should consult with the relevant authorities. Apart from any use permitted under the Copyright Act 1968, no part of the report may be copied without the permission of the General Manager, Land Tasmania, Department of Primary Industries, Parks, Water and Environment, GPO Box 44 Hobart 7001.
www.thelist.tas.gov.au
Site 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's CreekSite 1. Kennedy's Creek
Site 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks Creek
Site 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes Creek
Site 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts Creak
Site 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay Creek
Generated at: 13:37 on 21-June-2016 User: [email protected] 1Page: 1 of
www.thelist.tas.gov.au
map
© COPYRIGHT AND DISCLAIMER . Map data is compiled from a variety of sources and hence its accuracy is variable. If you wish to make decisions based on this data you should consult with the relevant authorities. Apart from any use permitted under the Copyright Act 1968, no part of the report may be copied without the permission of the General Manager, Land Tasmania, Department of Primary Industries, Parks, Water and Environment, GPO Box 44 Hobart 7001.
www.thelist.tas.gov.au
Site 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks CreekSite 4. Ferks Creek
Site 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes CreekSite 2. Noxes Creek
Site 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts CreakSite 3 Garnetts Creak
Site 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay CreekSite 5 Norfolk Bay Creek
Site 6 Kennedy's Creek TributarySite 6 Kennedy's Creek TributarySite 6 Kennedy's Creek TributarySite 6 Kennedy's Creek TributarySite 6 Kennedy's Creek TributarySite 6 Kennedy's Creek TributarySite 6 Kennedy's Creek TributarySite 6 Kennedy's Creek TributarySite 6 Kennedy's Creek TributarySite 6 Kennedy's Creek TributarySite 6 Kennedy's Creek TributarySite 6 Kennedy's Creek TributarySite 6 Kennedy's Creek Tributary
Generated at: 16:00 on 21-June-2016 User: [email protected] 1Page: 1 of
www.thelist.tas.gov.au
Department of State Growth, Tasmania Roadworks Specification
Checklist for W-beam Profile Barrier Panels
Item Yes No W-beam rail & guardrail posts have the following identification marks:
Name of Manufacturer (not Supplier)
Date of manufacture or batch number
Steel grade and base metal thickness
Material test certificates to be submitted to superintendent
Steel material test certificates by a NATA accredited Australian laboratory site
Steel Test Certificate to show w-beam steel meets the requirements of AS/NZS 1594 Grade HA350 as follows:
Minimum yield strength is 350MPa
Minimum tensile strength is 430MPa
Minimum elongation in 80mm is 16%
Mill camber tolerance on2500mm length 10.0mm maximum
Mill tolerance on strip width +2.5mm, - 0.0mm
Base metal thickness is 2.7mm 9-0.10mm; + 0.21mm) measure with digital calipers
Steel Test Certificate to show guardrail post steel meets the requirements of AS/NZS 1594 Grade HA250 as follows:
Minimum yield strength is 250MPa
Minimum tensile strength is 430MPa
Base metal thickness is 6.0mm ± 0.27mm – measure with digital calipers
Galvanising is in accordance with AS/NZS 4680 and complies with the following:
Coating to be smooth and adherent
Free from stains and surface imperfections
Uniform colour
If damaged galvanising to be repaired using one of two methods: 1. Regalvanising 2. Painting with a minimum two coat of zinc rich inorganic paint in
accordance with AS/NZS3750.9 and one coat of aluminium paint
Name of manufacturer
Grade of steel and BMT
(Base metal thickness) before galvanising
Batch number
Example of correct stamping for a standard post
Contract Number: - Date: - Contractor: -
Example of correct stamping for standard W-beam
Name of manufacturer
Grade of steel and BMT
(Base metal thickness) before galvanising
Batch number
Example of NATA certified laboratory material certificate