republic of kenya county government of …...1.1 the county government of uasin gishu invites sealed...
TRANSCRIPT
1
REPUBLIC OF KENYA
COUNTY GOVERNMENT OF UASIN GISHU
TENDER DOCUMENT FOR ROAD INFRASTRUCTURE WORKS
IN ELDORET MUNICIPALITY
TENDER NO: CGU/PP&UD/KUSP/003/2018-2019
FOR
CONSTRUCTION OF STORM WATER DRAINAGE FROM KPLC YARD-WEST
MARKET WETLAND THROUGH ARAP KITONGO & FARMERS STREET, ELDORET
BEAUTIFICATION (GREENING) OF ACK-MTRH, 64 STREET-A104&CBD
CONSTRUCTION OF HIGH MASTS AT KIPKAREN, ASIS &NGOMONGO;FRONTAGE
IMPROVEMENT FROM ITEN ROAD(C51) TO MULIRO STREET ALONG A104 PLUS
DRAINAGE WORKS
COUNTY SECRETARY, CHIEF OFFICER,
COUNTY GOVERNMENT OF UASIN GISHU, PHYSICAL PLANNING & URBAN DEVELOPMENT,
P.O. BOX 40 – 30100, THE COUNTY GOVERNMENT OF UASIN GISHU,
ELDORET. P.O. BOX 40 – 30100, ELDORET.
CLOSING DATE: 8TH
FEBRUARY, 2019 AT 10:30AM
2
TABLE OF CONTENT
Contents INVITATION FOR TENDER ............................................................................................................................ 4
DATE: 22ND
JANUARY, 2019 .......................................................................................................................... 4
SECTION II - INSTRUCTIONS TO TENDERERS ............................................................................ 5
APPENDIX TO INSTRUCTIONS TO TENDERERS ............................................................................. 24
FINANCIAL CRITERIA .............................................................................................................................. 27
SECTION III: CONDITIONS OF CONTRACT, PART I – GENERAL CONDITIONS .................... 28
SECTION IV: CONDITIONS OF CONTRACT PART II ........................................................................ 29
(CONDITIONS OF PARTICULAR APPLICATION) ................................................................................ 29
SECTION IV: CONDITIONS OF CONTRACT PART II – CONDITIONS OF .................................. 31
PARTICULAR APPLICATION ..................................................................................................................... 31
SECTION VI: DRAWINGS .......................................................................................................................... 61
SECTION VII – BILLS OF QUANTITIES ................................................................................................ 74
SECTION VIII – STANDARD FORMS ..................................................................................................... 79
3
INTRODUCTION
1.1 This standard tender document for procurement of works has been prepared for use by procuring entities in Kenya in the procurement of works (i.e. Roads, Bridges, Airports and Dams).
1.2 The following guidelines should be observed when using the document:-
(a) Specific details should be furnished in the tender notice and in the special conditions of contract (where applicable). The tender document issued to tenderers should not have blank spaces or options.
(b) The instructions to tenderers and the General Conditions of Contract should remain unchanged. Any necessary amendments to these parts should be made through Appendix to instructions to tenderers and special conditions of contract respectively.
1.3 (a) Information contained in the invitation to tender shall conform to the data and information in the tender documents to enable prospective tenderers to decide whether or not to participate in the tender and shall indicate any important tender requirements
(b) The invitation to tender shall be as an advertisement in accordance with the regulations or a letter of invitation addressed to tenderers who have been prequalified following a request for prequalification.
1.4 This document is based on PART 1 of the latest Edition of the International Federation of Consulting Engineers (Federation Internationale des Ingenieurs Con Seils – FIDIC) General Conditions of Contract for works of Civil Engineering.
1.5 The cover of the tender document should be modified to include -:
i. Tender number.
ii. Tender name. iii. Name of procuring entity. iv. Delete name and address of PPOA.
4
SECTION I
INVITATION FOR TENDER
DATE: 22ND
JANUARY, 2019
TENDER NO: CGU/PP&UD/KUSP/003/2018-2019
TENDER NAME: PROPOSED BEAUTIFICATION, HIGH MASTS AND DRAINAGE
WORKS
1.1 The County Government of Uasin Gishu invites sealed tenders from eligible candidates for Proposed Beautification, High Masts and Drainage Works -Uasin Gishu
County. 1.2 Interested eligible candidates may obtain further information from and inspect
the tender documents at Supply chain Management Offices, Town Hall Room 19 during normal office working hours.
1.3 A complete set of tender documents may be obtained by interested
candidates free of charge from the county website: www.uasingishu.go.ke or IFMIS Supplier Portal: http://supplier.treasury.go.ke OR procurement portal
1.4 Prices quoted should be net inclusive of all taxes, and delivery costs, must be
in Kenya Shillings and shall remain valid for ( 120 ) days from the closing date of the tender.
1.5 Completed tender documents are to be uploaded in to the IFMIS Suppliers
Portal (http://supplier.treasury.go.ke) so as to be received on or before Thursday, 8th 2019) at 10:30am.
1.6 Preliminary and Technical bid Documents shall be opened immediately after
the closing date online and the suppliers shall receive notification on the opening date of commercial bids which shall be projected at the county chambers –Town Hall. Bidders or their representative may attended the commercial opening.
CHIEF OFFICER LANDS AND HOUSING
UASIN GISHU COUNTY
5
SECTION II - INSTRUCTIONS TO TENDERERS
TABLE OF CLAUSES
CLAUSE NUMBERS PAGE
DESCRIPTION
GENERAL
1. Definitions ………………………………………………… 6
2. Eligibility and Qualification Requirements ……….. 6 3. Cost of Tendering ……………………………………….. 7 4. Site Visit ………………………………………………….. 8
TENDER DOCUMENT
5. Tender Documents …………………………………….. 8 6. Clarification of Tender Documents ………………… 9
7. Ammendment of Tender Documents ……………… 9
PREPARATION OF TENDER
8. Language of Tender …………………………………… 10 9. Documents Comprising the Tender ……………….. 10 10. Tender Prices …………………………………………… 10
11. Currencies of Tender and Payment ……………….. 11
12. Tender Validity ………………………………………….12 13. Tender Surety ………………………………………….. 12
14. No Alternative Offers ………………………………….. 13
15. Pre-tender meeting …………………………………….. 13
16. Format and Signing of Tenders ………………………… 14
SUBMISSION OF TENDERS
17. Sealing and Marking of Tenders …………………… 14
18. Deadline and Submission of Tenders ……………. 15
19. Modification and Withdrawal of Tenders ………… 15
TENDER OPENING AND EVALUATION
20. Tender Opening ……………………………………… 16
21. Process to be Confidential ………………………… 16 22. Clarification of Tenders ……………………………. 17
6
4
PAGE
23. Determination of Responsiveness …………………………………… 17
24. Correction of Errors …………………………………………………….. 18 25. Conversion to Single Currency ……………………………………….. 18
26. Evaluation and Comparison of Tenders …………………………….. 19
AWARD OF CONTRACT
27. Award Criteria ……………………………………………………………… 20 28. Notification of Award …………………………………………………….. 20 29. Performance Guarantee …………………………………………………. 21 30. Advance Payment …………………………………………………………. 21
Appendix to Instructions to Tenderers ………………………………. 21
7
SECTION II - INSTRUCTION TO TENDERERS
Note: The tenderer must comply with the following conditions and instructions and failure to do so is liable to result in rejection of the tender.
GENERAL
1. Definitions
(a) “Tenderer” means any persons, partnership firm or company submitting a sum or sums in the Bills of Quantities in accordance with the Instructions to Tenderers, Conditions of Contract Parts I and II, Specifications, Drawings and Bills of Quantities for the work contemplated, acting directly or through a legally appointed representative.
(b) “Approved tenderer” means the tenderer who is approved by the
Employer
(c) Any noun or adjective derived from the word “tender” shall be read and construed to mean the corresponding form of the noun or adjective “bid”. Any conjugation of the verb “tender” shall be read and construed to mean the corresponding form of the verb “bid.”
(d) “Employer” means a Central Government Ministry, Local Authority,
State Corporation or any other Public Institution. 2. Eligibility and Qualification Requirements
2.1 Eligibility requirements
This invitation to tender is open to all tenderers who are qualified as stated in the appendix.
2.2 Qualification Requirements
To be qualified for award of Contract, the tenderer shall provide evidence satisfactory to the Employer of their eligibility under Sub clause 2.1. above and of their capability and adequacy of resources to effectively carry out the subject Contract. To this end, the tenderer shall be required to update the following information already submitted during prequalification:-
(a) Details of experience and past performance of the tenderer on the works of a similar nature and details of current work on hand and other contractual commitments.
(b) The qualifications and experience of key personnel proposed for
administration and execution of the contract, both on and off site.
8
(c) Major items of construction plant and equipment proposed for use in carrying out the Contract. Only reliable plaint in good working order and suitable for the work required of it shall be shown on this schedule. The tenderer will also indicate on this schedule when each item will be available on the Works. Included also should be a schedule of plaint, equipment and material to be imported for the purpose of the Contract, giving details of make, type, origin and CIF value as appropriate.
(d) Details of sub contractors to whom it is proposed to sublet any
portion of the Contract and for whom authority will be requested for such subletting in accordance with clause 4 of the Condition of Contract.
(e) A draft Program of Works in the form of a bar chart and Schedule of Payment which shall form part of the Contract if the tender is accepted. Any change in the Program or Schedule shall be subjected to the approval of the Engineer.
(f) Details of any current litigation or arbitration proceedings in which
the tenderer is involved as one of the parties.
2.3 Joint Ventures
Tenders submitted by a joint venture of two or more firms as partners shall comply with the following requirements:-
(a) The tender, and in case of a successful tender, the Form of Agreement, shall be signed so as to be legally binding on all partners
(b) One of the partners shall be nominated as being in charge, and this
authorization shall be evidenced by submitting a power of attorney signed by legally authorized signatories of all the partners
(c) The partner in charge shall be authorized to incur liabilities and
receive instructions for an on behalf of any and all partners of the joint venture and the entire execution of the Contract including payment shall be done exclusively with the partner in charge.
(d) All partners of the joint venture shall be liable jointly and severally for the execution of the Contract in accordance with the Contract terms, and a relevant statement to this effect shall be included in the authorization mentioned under (b) above as well as in the Form of Tender and the Form of Agreement (in case of a successful tender)
(e) A copy of the agreement entered into by the joint venture partners
shall be submitted with the tender.
9
3. Cost of Tendering
3.1 The Tenderer shall bear all costs associated with the preparation and submission of his tender and the Employer will in no case be responsible or liable for those costs, regardless of the conduct or outcome of the tendering process.
3.2 The price to be charged for the tender document shall not exceed Kshs.5,000/=
3.3 The procuring entity shall allow the tenderer to view the tender document free of charge before purchase.
4. Site Visit
4.1. The tenderer is advised to visit and examine the Site and its surroundings and obtain for himself on his own responsibility, all information that may be necessary for preparing the tender and entering into a contract. The costs of visiting the Site shall be the tenderer’s own responsibility
4.2. The tenderer and any of his personnel or agents will be granted permission by the Employer to enter upon premises and lands for the purpose of such inspection, but only upon the express condition that the tenderer, his personnel or agents, will release and indemnify the Employer from and against all liability in respect of, and will be responsible for personal injury (whether fatal or otherwise), loss of or damage to property and any other loss, damage, costs and expenses however caused, which but for the exercise of such permission, would not have arisen.
4.3. The Employer shall organize a site visit at a date to be notified. A representative of the Employer will be available to meet the intending tenderers at the Site.
Tenderers must provide their own transport. The representative will not be available at any other time for site inspection visits.
Each tenderer shall complete the Certificate of Tenderer’s Visit to the Site, whether he in fact visits the Site at the time of the organized site visit or by himself at some other time.
10
TENDER DOCUMENTS 5 Tender Documents
5.1 The Tender documents comprise the documents listed here below and should be read together with any Addenda issued in accordance with Clause 7 of these instructions to tenderers.
a. Form of Invitation for Tenders b. Instructions to Tenderers
c. Form of Tender d. Appendix to Form of Tender
e. Form of Tender Surety f. Statement of Foreign Currency Requirements g. Tender and Confidential Business Questionnaires
h. Details of Sub contractors i. Schedules of Supplementary Information j. General Conditions of Contract – Part I
k. Conditions of Particular Application – Part II l. Specifications
m. Bills of Quantities n. Drawings o. Declaration Form
5.2 The tenderer is expected to examine carefully all instructions, conditions, forms, terms, specifications and drawings in the tender documents. Failure to comply with the requirements for tender submission will be at the tenderer’s own risk. Pursuant to clause 22 of Instructions to Tenderers, tenders which are not substantially responsive to the requirements of the tender documents will be rejected.
5.3 All recipients of the documents for the proposed Contract for the purpose of submitting a tender (whether they submit a tender or not) shall treat the details of the documents as “private and confidential”.
6 Inquiries by tenderers
6.1 A tenderer making an inquiry relating to the tender document may notify the Employer in writing or by telex, cable or facsimile at the Employer’s mailing address indicated in the Invitation to Tender. The Employer will respond in writing to any request for clarification which he receives earlier than 7 days prior to the deadline for the submission of tenders. Written copies of the Employer’s response (including the query but without identifying the source of the inquiry) will be sent to all prospective tenderers who have purchased the tender documents.
6.2 The procuring entity shall reply to any clarifications sought by the tenderer within 3 days of receiving the request to enable the tenderer to make timely submission of its tender.
11
7 Amendment of Tender Documents
7.1 At any time prior to the deadline for submission of tenders the Employer may, for any reason, whether at his own initiative or in response to a clarification requested by a prospective tenderer, modify the tender documents by issuing Addenda.
7.2 Any Addendum will be notified in writing or by cable, telex or facsimile to all prospective tenderers who have purchased the tender documents and will be binding upon them.
7.3 In order to allow prospective tenderers reasonable time in which to take the Addendum into account in preparing their tenders, the Employer may, at his discretion, extend the deadline for the submission of tenders.
PREPARATION OF TENDERS
8 Language of Tender
8.1 The tender and all correspondence and documents relating to the tender exchanged between the tenderer and the Employer shall be written in the English language. Supporting documents and printed literature furnished by the tenderer with the tender may be in another language provided they are accompanied by an appropriate translation of pertinent passages in the above stated language. For the purpose of interpretation of the tender, the English language shall prevail.
9 Documents Comprising the Tender
9.1 The tender to be prepared by the tenderer shall comprise:
i. the Form of Tender and Appendix thereto,
ii. a Tender Security iii. the Priced Bills of Quantities and Schedules
iv. the information on eligibility and qualification v. any other materials required to be completed and submitted in
accordance with the Instructions to Tenderers.
The Forms, Bills of Quantities and Schedules provided in the tender documents shall be used without exception (subject to extensions of the schedules in the same format and to the provisions of clause 13.2 regarding the alternative forms of Tender Surety].
10 Tender Prices
10.1 All the insertions made by the tenderer shall be made in INK and the tenderer shall clearly form the figures. The relevant space in the Form of Tender and Bills of Quantities shall be completed accordingly without interlineations or erasures except those necessary to correct errors made by the tenderer in which case the erasures and interlineations shall be initialed by the person or persons signing the tender.
12
10.2 A price or rate shall be inserted by the tenderer for every item in the Bills of Quantities whether the quantities are stated or not. Items against which no rate or price is entered by the tenderer will not be paid for by the Employer when executed and shall be deemed covered by the rates for other items and prices in the Bills of Quantities.
The prices and unit rates in the Bills of Quantities are to be the full [all-inclusive] value of the Work described under the items, including all costs and expenses which may be necessary and all general risks, liabilities and obligations set forth or implied in the documents on which the tender is based. All duties, taxes and other levies payable by the Contractor under the Contract, or for any other cause prior to the deadline for submission of tenders, shall be included in the rates and prices and the total Tender Price submitted by the tenderer.
Each price or unit rate inserted in the Bills of Quantities should be a realistic estimate for completing the activity or activities described under that particular item and the tenderer is advised against inserting a price or rate against any item contrary to this instruction.
Every rate entered in the Bills of Quantities, whether or not such rate be associated with a quantity, shall form part of the Contract. The Employer shall have the right to call for any item of work contained in the Bills of Quantities, and such items of work to be paid for at the rate entered by the tenderer and it is the intention of the Employer to take full advantage of unbalanced low rates.
10.3 Unless otherwise specified the tenderer must enter the amounts representing 10% of the sub-total of the summary of the Bills of Quantities for Contingencies and Variation of Prices[V.O.P.] payments in the summary sheet and add them to the sub-total to arrive at the tender amount.
10.4 The tenderer shall furnish with his tender written confirmation from his suppliers or manufacturers of basic unit rates for the supply of items listed in the Conditions of Contract clause 70 where appropriate. The Employer may require the tenderer to justify such rates so obtained from the suppliers or manufacturers.
10.5 The rates and prices quoted by the tenderer are subject to adjustment during the performance of the Contract only in accordance with the Provisions of the Conditions of Contract. The tenderer shall complete the schedule of basic rates and shall submit with his tender such other supporting information as required under clause 70 of the Conditions of Contract Part II.
10.6 Contract price variations shall not be allowed within the first 12 months of the contract.
13
10.7 Where quantity contract variation is allowed, the variation shall not exceed 15% of the original contract quantity.
10.8 Price variation requests shall be processed by the procuring entity within 30 days of receiving the request.
11 Currencies of Tender and Payment
11.1 Tenders shall be priced in Kenya Shillings and the tender sum shall be in Kenya Shillings.
11.2 Tenderers are required to indicate in the Statement of Foreign Currency Requirements, which forms part of the tender, the foreign currency required by them. Such currency should generally be the currency of the country of the tenderer’s main office. However, if a substantial portion of the tenderer’s expenditure under the Contract is expected to be in countries other than his country of origin, then he may state a corresponding portion of the contract price in the currency of those other countries. However, the foreign currency element is to be limited to two (2) different currencies and a maximum of 30% (thirty percent) of the Contract Price.
11.3 The rate or the rates of exchange used for pricing the tender shall be the selling rate or rates of the Central Bank ruling on the date thirty (30) days before the final date for the submission of tenders.
11.4 Tenderers must enclose with their tenders, a brief justification of the foreign currency requirements stated in their tenders.
12 Tender Validity
12.1 The tender shall remain valid and open for acceptance for a period of sixty
(60) days from the specified date of tender opening or from the extended date of tender opening (in accordance with clause 7.4 here above) whichever is the later.
12.2 In exceptional circumstances prior to expiry of the original tender validity period, the Employer may request the tenderer for a specified extension of the period of validity. The request and the responses thereto shall be made in writing or by cable, telex or facsimile. A tenderer may refuse the request without forfeiting his Tender Surety. A tenderer agreeing to the request will not be required nor permitted to modify his tender, but will be required to extend the validity of his Tender Surety correspondingly.
14
13 Tender Security
13.1 The tenderer shall furnish as part of his tender, a Tender Security in the amount and form stated in the Appendix to Instructions to Tenderers.
13.2 The tender security shall not exceed 2 percent of the tender price.
13.3 The Tender Security shall be valid at least thirty (30) days beyond the tender validity period.
13.4 Any tender not accompanied by an acceptable Tender Surety will be rejected by the Employer as non-responsive.
13.5 The Tender Sureties of unsuccessful tenderers will be returned as promptly as possible but not later than twenty eight (28) days after expiration of the tender validity period. The Tender Surety of the successful tenderer will be returned upon the tenderer executing the Contract and furnishing the required Performance Security.
13.6 The Tender Surety may be forfeited:
a) if a tenderer withdraws his tender during the period of tender validity: or
b) in the case of a successful tenderer, if he fails, within the specified time limit
i. to sign the Agreement, or
ii. to furnish the necessary Performance Security c) if a tenderer does not accept the correction of his tender price
pursuant to clause 23.
14 No Alternative Offers
14.1 The tenderer shall submit an offer which complies fully with the
requirements of the tender documents unless otherwise provided for in the appendix.
Only one tender may be submitted by each tenderer either by himself or as partner in a joint venture. A tenderer who submits or participates in more than one tender will be disqualified.
14.2 The tenderer shall not attach any conditions of his own to his tender. The tender price must be based on the tender documents. The tenderer is not required to present alternative construction options and he shall use without exception, the Bills of Quantities as provided, with the amendments as notified in tender notices, if any, for the calculation of his tender price. Any tenderer who fails to comply with this clause will be disqualified.
15
15 Pre-tender Meeting
15.1 If a pre-tender meeting is convened, the tenderer’s designated representative is invited to attend at the venue and time in the Invitation to Tender. The purpose of the meeting will be to clarify issues and to answer questions on any matter that may be raised at that stage.
15.2 The tenderer is requested as far as possible to submit any questions in writing or by cable, to reach the Employer not later than seven (7) days before the meeting. It may not be practicable at the meeting to answer questions received late, but questions and responses will be transmitted in accordance with the following:
(a) Minutes of the meeting, including the text of the questions raised and the responses given together with any responses prepared after the meeting, will be transmitted without delay to all purchasers of the tender documents. Any modification of the tender documents listed in – Clause 9 which may become necessary as a result of the pre-tender meeting shall be made by the Employer exclusively through the issue of a tender notice pursuant to Clause 7 and not through the minutes of the pre-tender meeting.
(b) Non attendance at the pre-bid meeting will not be cause for
disqualification of a bidder.
16 Format and Signing of Tenders
16.1 The tenderer shall prepare his tender as outlined in clause 9 above and
mark appropriately one set “ORIGINAL” and the other “COPY”.
16.2 The copy of the tender and Bills of Quantities shall be typed or written in indelible ink and shall be signed by a person or persons duly authorized to sign on behalf of the tenderer. All pages of the tender where amendments have been made shall be initialed by the person or persons signing the tender.
16.3 The complete tender shall be without alterations, interlineations or erasures, except as necessary to correct errors made by the tenderer, in which case such corrections shall be initialed by the person of persons signing the tender.
SUBMISSION OF TENDERS
17 Sealing and Marking of Tenders
17.1 The tenderer shall seal the original and copy of the tender in separate
16
envelopes, duly marking the envelopes as “ORIGINAL” and “COPY”. The envelopes shall then be sealed in an outer separate envelope.
17.2 The inner and outer envelopes shall be addressed to the Employer at the address stated in the Appendix to Instructions to Tenderers and bear the name and identification of the Contract stated in the said Appendix with a warning not to open before the date and time for opening of tenders stated in the said Appendix.
17.3 The inner envelopes shall each indicate the name and address of the tenderer to enable the tender to be returned unopened in case it is declared “late”, while the outer envelope shall bear no mark indicating the identity of the tenderer.
17.4 If the outer envelope is not sealed and marked as instructed above, the Employer will assume no responsibility for the misplacement or premature opening of the tender. A tender opened prematurely for this cause will be rejected by the Employer and returned to the tenderer.
18 Deadline for Submission of Tenders
18.1 Tenders must be received by the Employer at the address specified in
clause 17.2 and on the date and time specified in the Letter of Invitation, subject to the provisions of clause 7.4, 18.2 and 18.3.
Tenders delivered by hand must be placed in the “tender box” provided in the office of the Employer.
Proof of posting will not be accepted as proof of delivery and any tender delivered after the above stipulated time, from whatever cause arising will not be considered.
18.2 The Employer may, at his discretion, extend the deadline for the submission of tenders through the issue of an Addendum in accordance with clause 7, in which case all rights and obligations of the Employer and the tenderers previously subject to the original deadline shall thereafter be subject to the new deadline as extended.
18.3 Any tender received by the Employer after the prescribed deadline for submission of tender will be returned unopened to the tenderer.
19 Modification and Withdrawal of Tenders
19.1 The tenderer may modify or withdraw his tender after tender submission, provided that written notice of the modification or withdrawal is received by the Employer prior to prescribed deadline for submission of tenders.
17
19.2 The tenderer’s modification or withdrawal notice shall be prepared, sealed, marked and dispatched in accordance with the provisions for the submission of tenders, with the inner and outer envelopes additionally marked “MODIFICATION” or “WITHDRAWAL” as appropriate.
19.3 No tender may be modified subsequent to the deadline for submission of tenders.
19.4 No tender may be withdrawn in the interval between the deadline for submission of tenders and the period of tender validity specified on the tender form. Withdrawal of a tender during this interval will result in the forfeiture of the Tender Surety.
19.5 Subsequent to the expiration of the period of tender validity prescribed by the Employer, and the tenderer having not been notified by the
Employer of the award of the Contract or the tenderer does not intend to conform with the request of the Employer to extend the period of tender validity, the tenderer may withdraw his tender without risk of
forfeiture of the Tender Surety.
TENDER OPENING AND EVALUATION
20 Tender Opening
20.1 The Employer will open the tenders in the presence of the tenderers’ representatives who choose to attend at the time and location indicated in the Letter of Invitation to Tender. The tenderers’ representatives who are present shall sign a register evidencing their attendance.
20.2 Tenders for which an acceptable notice of withdrawal has been
submitted, pursuant to clause 19, will not be opened. The Employer will examine the tenders to determine whether they are complete, whether the requisite Tender Sureties have been furnished, whether the documents have been properly signed and whether the tenders are generally in order.
20.3 At the tender opening, the Employer will announce the tenderer’s names, total tender price, tender price modifications and tender withdrawals, if any, the presence of the requisite Tender Surety and such other details
as the Employer, at his discretion, may consider appropriate. No tender shall be rejected at the tender opening except for late tenders.
20.4 The Employer shall prepare minutes of the tender opening including the
information disclosed to those present.
20.5 Tenders not opened and read out at the tender opening shall not be
18
considered further for evaluation, irrespective of the circumstances.
21 Process to be Confidential
21.1 After the public opening of tenders, information relating to the examination, clarification, evaluation and comparisons of tenders and recommendations concerning the award of Contract shall not be disclosed to tenderers or other persons not officially concerned with such process until the award of Contract is announced.
21.2 Any effort by a tenderer to influence the Employer in the process of examination, evaluation and comparison of tenders and decisions concerning award of Contract may result in the rejection of the tenderer’s tender.
22 Clarification of Tenders
22.1 To assist in the examination, evaluation and comparison of tenders, the Employer may ask tenderers individually for clarification of their tenders, including breakdown of unit prices. The request for clarification and the response shall be in writing or by cable, facsimile or telex, but no change in the price or substance of the tender shall be sought, offered or permitted except as required to confirm the correction of arithmetical errors discovered by the employer during the evaluation of the tenders in accordance with clause 24.
22.2 No tenderer shall contact the Employer on any matter relating to his
tender from the time of the tender opening to the time the Contract is awarded. If the tenderer wishes to bring additional information to the notice of the Employer, he shall do so in writing.
23 Determination of Responsiveness
23.1 Prior to the detailed evaluation of tenders, the Employer will determine
whether each tender is substantially responsive to the requirements of the tender documents.
23.2 For the purpose of this clause, a substantially responsive tender is one which conforms to all the terms, conditions and specifications of the
tender documents without material deviation or reservation. A material deviation or reservation is one which affects in any substantial way the scope, quality, completion timing or administration of the Works to be undertaken by the tenderer under the Contract, or which limits in any
substantial way, inconsistent with the tender documents, the Employer’s rights or the tenderers obligations under the Contract and the rectification of which would affect unfairly the competitive position
of other tenderers who have presented substantially responsive tenders.
23.3 Each price or unit rate inserted in the Bills of Quantities shall be a
19
realistic estimate of the cost of completing the works described under the particular item including allowance for overheads, profits and the like. Should a tender be seriously unbalanced in relation to the Employer’s estimate of the works to be performed under any item or groups of items, the tender shall be deemed not responsive.
23.4 A tender determined to be not substantially responsive will be rejected by the Employer and may not subsequently be made responsive by the tenderer by correction of the non-conforming deviation or reservation.
24 Correction of Errors
Tenders determined to be substantially responsive shall be checked by the Employer for any arithmetic errors in the
computations and summations. Errors will be corrected by the Employer as follows:
(a) Where there is a discrepancy between the amount in figures and the amount in words, the amount in words will govern.
(b) Where there is a discrepancy between the unit rate and the line item total resulting from multiplying the unit rate by the quantity, the unit rate as quoted will prevail, unless in the opinion of the Employer, there is an obvious typographical error, in which case adjustment will be made to the entry containing that error.
(c) In the event of a discrepancy between the tender amount as stated in the Form of Tender and the corrected tender figure in the main summary of the Bills of Quantities, the amount as stated in the Form of Tender shall prevail.
(d) The Error Correction Factor shall be computed by expressing the difference between the tender amount and the corrected tender sum as a percentage of the corrected builder’s work (i.e. corrected tender sum less Prime Cost and Provisional Sums.
(e) The Error Correction Factor shall be applied to all builder’s work (as a rebate or addition as the case may be) for the purposes of valuations for Interim Certificates and valuations of variations.
(f) The amount stated in the tender will be adjusted in accordance with the above procedure for the correction of errors and, with concurrence of the tenderer, shall be considered as binding upon the tenderer. If the tenderer does not accept the corrected amount, the tender may be rejected and the Tender Security
20
may be forfeited in accordance with clause 13.
25 Conversion to Single Currency
25.1 For compensation of tenders, the tender price shall first be broken down into the respective amounts payable in various currencies by using the
selling rate or rates of the Central Bank of Kenya ruling on the date twenty one (21) days before the final date for the submission of tenders.
25.2 The Employer will convert the amounts in various currencies in which the tender is payable (excluding provisional sums but including Dayworks where priced competitively) to Kenya Shillings at the selling rates stated in clause 25.1.
26 Evaluation and Comparison of Tenders
26.1 The Employer will evaluate only tenders determined to be substantially
responsive to the requirements of the tender documents in accordance with clause 23.
26.2 In evaluating tenders, the Employer will determine for each tender the
evaluated tender price by adjusting the tender price as follows:
(a) Making any correction for errors pursuant to clause 24.
(b) Excluding Provisional Sums and provision, if any, for
Contingencies in the Bills of Quantities, but including Day works where priced competitively.
26.3 The Employer reserves the right to accept any variation, deviation or alternative offer. Variations, deviations, alternative offers and other factors which are in excess of the requirements of the tender
documents or otherwise result in the accrual of unsolicited benefits to the Employer, shall not be taken into account in tender evaluation.
26.4 Price adjustment provisions in the Conditions of Contract applied over the period of execution of the Contract shall not be taken into account in tender evaluation.
26.5 If the lowest evaluated tender is seriously unbalanced or front loaded in relation to the Employer’s estimate of the items of work to be performed under the Contract, the Employer may require the tenderer to produce detailed price analyses for any or all items of the Bills of Quantities, to demonstrate the relationship between those prices, proposed construction methods and schedules. After evaluation of the price analyses, the Employer may require that the amount of the Performance Security set forth in clause 29 be increased at the expense of the successful tenderer to a level sufficient to protect the Employer
21
against financial loss in the event of subsequent default of the successful tenderer under the Contract.
26.6 Firms incorporated in Kenya where indigenous Kenyans own 51% or more of the share capital shall be allowed a 10% preferential bias provided that they do not sub-contract work valued at more than 50% of the Contract Price excluding provisional sums to a non-indigenous sub-contractor.
26.7 Preference where allowed in the evaluation of tenders shall not exceed
15%
26.8 The procuring entity may at any time terminate procurement proceedings before contract award and shall not be liable to any person for the termination.
26.9 The procuring entity shall give prompt notice of the termination to the tenderers and on request give its reasons for termination within 14 days of receiving the request from any tenderer.
26.10 A tenderer who gives false information in the tender document about its qualification or who refuses to enter into a contract after notification of contract award shall be considered for debarment from participating in future public procurement.
26.11 Poor past performance shall not be used as an evaluation criteria unless specifically provided for in the appendix.
27 AWARD OF CONTRACT
Award Criteria
27.1 Subject to Sub-clause 27.2, the Employer will award the Contract to the tenderer whose tender is determined to be substantially responsive to the tender documents and who has offered the lowest evaluated tender price subject to possessing the capability and resources to effectively carry out the Contract Works as required in Sub-clause 2.1 and 2.2 hereabove.
27.2 The Employer reserves the right to accept or reject any tender, and to annual the tendering process and reject all tenders, at any time prior to award of Contract, without thereby incurring any liability to the affected tenderers or any obligation to inform the affected tenderers of the grounds for the Employer’s action.
28 Notification of Award
28.1 Prior to the expiration of the period of tender validity prescribed by the
22
Employer, the Employer will notify the successful tenderer by cable, telefax or telex and confirmed in writing by registered letter that his tender has been accepted. This letter (hereinafter and in all Contract documents called “Letter of Acceptance”) shall name the sum (hereinafter and in all Contract documents called “the Contract Price”) which the Employer will pay to the Contractor in consideration of the execution and completion of the Works as prescribed by the Contract.
28.2 At the same time that the Employer notifies the successful tenderer that his tender has been accepted, the Employer shall notify the other tenderers that the tenders have been unsuccessful.
28.3 Within fourteen [14] days of receipt of the Form of Contract Agreement from the Employer, the successful tenderer shall sign the form and return it to the Employer together with the required Performance Security.
28.4 The parties to the contract shall have it signed within 30 days from the date of notification of contract award unless there is an administrative review request.
29 Performance Guarantee
29.1 Within twenty eight [28] days of receipt of the notification of award from the Employer, the successful tenderer shall furnish the Employer with a Performance Security in the amount stated in the Appendix to Instructions to Tenderers and in the format stipulated in the Conditions of Contract.
29.2 The Performance Security to be provided by the successful tenderer shall be an unconditional Bank Guarantee issued at the tenderer’s option by a reputable Bank approved by the Employer and located in the Republic of Kenya and shall be divided into two elements namely, a performance security payable in foreign currencies (based upon the exchange rates determined in accordance with clause 60(5) of the Conditions of Contract) and a performance security payable in Kenya Shillings. The value of the two securities shall be in the same proportions of foreign and local currencies as requested in the form of foreign currency requirements.
29.3 Failure of the successful tenderer to lodge the required Performance Security shall constitute a breach of Contract and sufficient grounds for the annulment of the award and forfeiture of the Tender Security and any other remedy under the Contract. The Employer may award the Contract to the next ranked tenderer.
23
30 Advance Payment
An advance payment, if approved by the Employer, shall be made under the Contract, if requested by the Contractor, in accordance with clause 60(1) of the Conditions of Contract. The Advance Payment Guarantee shall be denominated in the proportion and currencies named in the form of foreign currency requirements. For each currency, a separate guarantee shall be issued. The guarantee shall be issued by a Bank located in the Republic of Kenya, or a foreign Bank through a correspondent Bank located in the Republic of Kenya, in either case subject to the approval of the Employer.
31 Corrupt or fraudulent practices
31.1 The procuring entity requires that tenderers observe the highest standard of ethics during the procurement process and execution of contracts. A tenderer shall sign a declaration that he has not and will not be involved in corrupt or fraudulent practices.
24
APPENDIX TO INSTRUCTIONS TO TENDERERS
Notes on the Appendix to Instructions to Tenderers
The following appendix to instructions to tenderers shall complement or amend the provisions of the instructions to tenderers (Section II). Wherever there is a conflict between the provisions of the instructions to tenderers and the provisions of the appendix, the provisions of the appendix herein shall prevail over those of the instructions to tenderers.
(Complete as appropriate)
APPENDIX TO INSTRUCTION TO TENDERER
CLUASES REFERENCES
INSTRUCTION TO TENDERERS CONSTRUCTION OF STORM WATER DRAINAGE FROM KPLC YARD-WEST MARKET WETLAND THROUGH ARAP KITONGO & FARMERS STREET, ELDORET BEAUTIFICATION (GREENING) OF ACK-MTRH, 64 STREET-A104&CBD CONSTRUCTION OF HIGH MASTS AT KIPKAREN, ASIS &NGOMONGO; FRONTAGE IMPROVEMENT FROM ITEN ROAD(C51) TO MULIRO STREET ALONG A104 PLUS DRAINAGE WORKS
1.1 All Registered Civil Works Contractor with the Required NCA Qualifications
MANDATORY REQUIREMENT i. A Copy of Valid certificate of Company Registration/Incorporation
ii. Proof of Registration as a contractor eligible to undertake construction and building works with National Construction Authority CATEGORY NCA 3,4,5,6 for Main Works, NCA 6 or above for Domestic Sub-contractor Electrical Services and ERC Licences (ERC B)
iii. Valid Tax compliance certificates; for Main Contractor, Domestic Electrical & Mechanical sub-Contractors.
iv. Attach Bid security of 1,500,000.00 from PPRA authorised financial institutions valid for 150 days from the day of Tender opening.
v. Attach Current Valid CR12 for the last one year with copies of Directors Identification documents contractor
vi. Tender forms and confidential Business questionnaire dully filled and signed by an authorized person.
vii. MUST attach Pre-tender site visit certificate duly signed by county authorised person. Which will be on 31
st January, 2019. (Assemble at the County Headquarter at 9:00am)
viii. MUST submit a serialized (pagination) Original Document (please make your own page numbering from first page to the last page)
ix. Attach a sworn statement or declaration stating that:
(a)The firm has not been debarred from participating in any public procurement by PPRA. (b)No person related to the firm has any spouse or children working at Uasin Gishu County Government (c)The firm has not been engaged in any unethical, corrupt, collusive or fraudulent activities in public procurement matters. (d)The firm has not been declared bankrupt, insolvent or under receivership.
25
Failure to provide any or all of the above information will render the bid to be considered as non-responsive resulting to its rejection at preliminary stage.
4.2 The tender will close on 8th February, 2019 at 10:30am automatically through the IFMIS system.
1.7/5.4 TECHNICAL EVALUATION CRITERIA
REQUIREMENT REQUIRED REFERENCE TO BE SUBMITTED IN
TENDERING FORMS FROM TENDER FOR
EVALUATION AS INDICATED IN THE
DOCUMENT,
MAX
SCORE
Equipment holding Prove of ownership or lease agreement and not hire of the
following equipment:
(i) Tipper/lorry (2 marks)
(ii) Concrete mixer (2 marks)
(iii) Vibrator (2 marks)
(iv) Excavator (2 marks)
(v) Water bowser (2 marks)
(attach Logbooks or lease agreement)
10
Key staff (i) Director having management experience of at least five
years of similar works and magnitude.
(1 Mark per year) (attach C.V and Qualification
Documents)
(ii) Technical Manager holding Degree in relevant
Engineering field with 5 years experience of similar works
and magnitude (1Mark per year) ) (attach C.V and
Qualification Documents)
(iii) At least three personnel holding Diploma in the
following fields with 5 years minimum experience:
(a) Civil Engineering 3 marks
(b) Electrical Engineering 3 marks
(c) Landscaping 3 marks
(attach C.V and Qualification Documents)
(iv) At least 3No personnel holding Artisan certificate the
following fields with 5 year minimum experience:
(a) Civil Engineering 2 marks
(b) Electrical Engineering 2 marks
(c) Landscaping 2 marks
(attach C.V and Qualification Documents)
25
Past relevant work
experience
(i)Provide proof of at least 5No previous works done and
completed of not less that Ksh 7million and of the
similar nature. (5 Marks) (attach completion certificate)
(ii) Provide list of 5No of On-going projects and
percentage to completion of similar magnitude and nature.
(5 Marks)
(attach letter of award or contract agreement and
certified progress report)
(iii) Provide list of terminated project and the reason
16
26
therein in the last 5No. years (if any). (3Marks) (attach
affidavit)
(iv) Provide list of incompleted project where warning
letters or default notices have been issued(if any). (3
Marks) (attach affidavit)
Contractual
misconduct and
litigation
Records of contractual misconduct in the last 1 year attach
Sworn affidavit certified by magistrate or commissioner of
oaths. Note: the higher the misconduct the lower the
scores (3 Marks)
3
Financial capability (i) Attach Certified audited accounts for the year
2017 showing the following ratios: -
(a)Profitability margin (show extract indicating the
same) A margin above 30% will score 5 Marks;
10-29 % - 2 Marks;
1-9% - 1 Marks and
below 1% - 0 Marks
(b) Liquidity Ratio margin (show extract
indicating the same ) 2:1 – 5 Marks;
1:1 –2 Marks;
0.5:1- 1 Marks;
and less than 0.5:1- 0 Marks
(c) Proof of Average annual construction turnover
of KShs.15Million (Fifteen Million), calculated as
total certified payments received for contracts in
progress or completed, within the last two (2) years
(5 Marks)
(ii) Provide letter of credit from any commercial
bank in Kenya as proof of their readiness to
facilitate your firm financially (5 Marks)
20
Work schedule Proposal work progress charts showing payment
schedule of not less that Kshs. 5,000,000.00 per
month. (5 Marks)
Proposal cash flow plan showing financial capacity
to fund the project to the tune of not less than Kshs.
5,000,000.00 per month prior to request for
certificate. (5 Marks)
10
Work safety
management Attach proposal of Worker safety plan (3marks)
Attach proposal of Accident prevention n measures
( 3 Marks)
6
Technical schedule /
brochures
Relevant technical information and brochures of items to
be supplied ( e.g.) lowering gear, safety flush lights,
lighting fittings, fitting configuration between the base and
foundation works, Training manual and any other
equipment described in the bills of quantities for Electrical
works
10
TOTAL 100
RECOMMENDATION
The bidder who score 75% or above qualify to final stage.
27
FINANCIAL CRITERIA
Any bid price which is not within 10% margin of Engineers Estimated amount will be rejected
and will not be subjected to further evaluation. The Proposed budget allocation is Kshs
75,000,000.00 (Seventy five Million only)
STAGE THREE: POST QUALIFICATION
This shall be done by visiting the premises and previous projects site to assess the actual
qualification of the proposed lowest evaluated bidder. Any bidder who qualifies but not satisfy
the observation of the evaluation team during the Post qualification will be disqualified and
second bidder shall be considered.
28
SECTION III: CONDITIONS OF CONTRACT, PART I – GENERAL CONDITIONS
The Conditions of Contract, Part I – General Conditions, shall be those forming Part I of the “Conditions of Contract for works of Civil Engineering Construction, Fourth Edition 1987, re-printed in 1992 with further amendments, prepared by the Federation Internationale des Ingenieurs – conseils (FIDIC). The Conditions are subject to variations and additions set out in Part II hereof entitled “Conditions of Contract, Part II - Conditions of Particular Application”.
Note
i. The standard text of the General Conditions of Contract must be retained intact to facilitate its reading and interpretation by tenderers. Any amendments and additions to the General Conditions, specific to a given Contract, should be introduced in the Conditions of Particular Application or in the Appendix to Form of Tender.
ii. The Conditions of Particular Application take precedence over the General
Conditions of Contract.
iii. Copies of the FIDIC Conditions of Contract can be obtained
from: FIDIC Secretariat P.O. Box 86
1000 Lausanne 12 Switzerland Fax: 41 21 653 5432 Telephone: 41 21 653 5003
29
SECTION IV: CONDITIONS OF CONTRACT PART II
(CONDITIONS OF PARTICULAR APPLICATION)
TABLE OF CLAUSES
CLAUSE NUMBERS DESCRIPTION PAGE
1. Definitions and interpretation………………………. 24 2. Engineer’s Duties and Authority………………….. 24
4. Assignment and sub-contracting 5. Contract Document ……………………… 25 8. ……………………… 25
10 Performance security ………………………. 26
11 Inspection of Site ……………………… 27 14 Programme to be submitted …………………… 27
15 Contractor’s superintendence …………………….. 28 16 Engineers at liberty to object……………..
19 Safety, security and profession of the environment … 29
21 Insurance of works and contractors equipment……… 30 23 Third Party Insurance ………………………………….. 30
25 Insurance notices …………………………………………… 31 26 Compliance with statutes and regulations ……………. 31
28 Royalties 32 29 Interference with traffic and Adjoining properties 32
34 Labour 32
41 Commencement and delays 34 42 Possession of site 35 45 Working hours 35
47 Liquidated damage 36
49 Defects liability 36
52 Variations 36 54 Plant, Temporary works and materials 36 55 Quantities 37
56 Measurements 37
58 Provisional sums 38
60 Certificate and payments 40 63 Remedies 46 65 Special Risks 46
67 Settlement of Disputes 46
68 Notices 47 69 Default of Employer 47
70 Changes in cost and legalization 48 73 Declaration Against waiver 50
74 Bribery and collusion 50
75 Contract Confidential 51 76 Employer’s officers 51
30
77 Taxes and duties 51 78 Joint Ventures 52
31
SECTION IV: CONDITIONS OF CONTRACT PART II – CONDITIONS OF
PARTICULAR APPLICATION
GENERAL
The Conditions of Contract Part II – Conditions of Particular Application, modify and compliment like-numbered clauses in the Conditions of Contract Part I – General Conditions. Both Parts shall be read together, with the Conditions of Particular Application prevailing in case of conflict or discrepancy. Clauses of the General Conditions not specifically modified and supplemented shall remain in effect.
Clause No.
Definitions and Interpretation
1.1 (a)(i) The said “Employer” shall _____________________________(Name of Employer) represented _________________________________(Name of Employer’s representative)
be
by
(iv) The said “Engineer” shall be ________________________________(Name of the Engineer) or any other competent person appointed by the Employer, and notified to the Contractor, to act in replacement of the Engineer.
(b)(i)
Insert in line 2 after “the Bills of Quantities”, the following, ”the rates entered by the Contractor (whether or not such rate be employed in computation of the Contract Price)”.
Add the following sub-clause;
Engineer’s Duties and Authority
2.1 (b) The Engineer shall obtain specific approval of the Employer before taking any of the following actions specified in Part I:
(i) Consenting to the sub-letting of any part of the Works under clause 4.
(ii) Certifying additional cost determined under Clause 12
(iii) Determining an extension of time under Clause 44
(iv) Issuing a variation under Clause 51 except in an emergency
situation as reasonably determined by the Engineer.
32
(v) Fixing rates or prices under clause 52
4 Assignment and Subcontracting
4.1 Delete the second and third sentence and substitute:
No single subcontract may be for more than 10 percent of the Contract Price nor shall the sum of all subcontracts exceed 25 percent of the Contract price. No one subcontractor may be awarded subcontracts to a total value greater than 10 percent of the Contract Price. All subcontracts greater than 2 percent of the Contract Price are to have the prior consent of the Engineer. The Contractor shall however, not required such consent for purchases of materials or to place contracts for minor details or for any part of the Works of which the manufacturer of supplier is named in the Contract. Any such consent shall not relieve the Contractor from any liability or obligation under the Contract and he shall be responsible for the acts, defaults and neglects of any subcontractor, his agents, servants or workmen as fully as if they were the acts, defaults or neglects of the Contractor, his agents, servants or workmen.
5 Contract Documents
5.1 (a) The language governing this Contract shall be English.
The “Ruling Language” which shall be used to interpret this Contract shall be English. Communication between the Contractor and Engineer or Engineer’s representative shall be in English.
(b) The law applicable to this Contract shall be the laws of the Republic of Kenya. Except to the extent otherwise provided by the Contract, the Kenyan courts shall have exclusive jurisdiction to hear and to determine all actions and proceedings in connection with and arising out of the Contract, and the Contractor shall submit to the jurisdiction of Kenyan courts for the purpose of any such actions and proceedings.
5.2 Delete the documents listed 1-6 and substitute:
(1) The Contract Agreement; (2) The Notification of Award; (3) Tender and Appendix to Form of Tender;
(4) The Conditions of Contract Part II; (5) The Conditions of Contract Part I (FIDIC);
(6) The Special Specifications; (7) The Standard Specifications for Road and Bridge
33
Construction, MOTC – 1986;
(8) Clarifications and rectifications accepted by the Employer; and
(9) The Drawings; (10) The priced Bills of Quantities; and (11) Schedules and other documents forming part of the
Contract.
8.1 Add to sub clause 8.1 the following:
(a) Within 28 days after receipt of the Engineer’s order to commence the Works, the Contractor shall establish an office at the Site duly equipped for the Contractor’s representative and his supervisory personnel.
The Contractor shall maintain this office throughout the Contract period. The said office shall be the legal domicile of the Contractor, and all correspondence sent to this office shall be deemed to have been sent to the Contractor’s head office.
(b) A foreign Contractor or a Kenya-foreign joint venture, if
not registered in Kenya under the applicable laws of Kenya, shall undertake registration upon receipt of the letter of acceptance and prior to signing of the Contract.
10.1 Performance Security
In lines 1,2 and 3 delete the words “If the Contract… within 28 days” and substitute “The Contractor shall obtain a Performance Security within 28 days ………”
Add the following at the end of this Sub-Clause:-
The Performance Security shall be issued by a Bank incorporated in Kenya. The amount of guarantee shall be as stated in the Appendix to Form of Tender.
The bank guarantee, shall be issued either (a) by an established and reputable bank approved by the Employer and located in Kenya or a foreign bank through a correspondent established and reputable bank located in Kenya and approved by the Employer or (b) directly by a foreign bank acceptable to the Employer. The performance security shall normally be in the currency or currencies requested for payment by the Contractor and in the same proportions as those requested for payment in the Contract.
34
The performance security may, subject to the approval of the Engineer, be adjusted at the end of each period of 12 months to reflect the residual value of the Contract Works.
10.2 The performance guarantee shall be valid until a date 28 days after the date of issue of the Taking-Over Certificate. The security shall be returned to the Contractor within 28 days of the expiration.
10.3 Delete sub-clause 10.3
11.1 Inspection of Site
Add the words “and the Contractor shall be deemed to have based his tender on all the aforementioned” after the words “affect his tender”.
Delete the last paragraph completely and replace with the following:
“The Employer in no way guarantees completeness nor accuracy of the soil, materials, subsurface and hydrological information made available to the Contractor at the time of tendering or at any other time during the period of the Contract, and the Contractor shall be responsible for ascertaining for himself all information as aforesaid for the execution of Works and his tender shall be deemed to have been priced accordingly.
14.1 Programme to be Submitted
The time within which the Programme shall be submitted shall be twenty eight (28) days . This detailed Programme shall be based upon the programme submitted by the Contractor as part of his tender and shall, in no material manner, deviate from the said programme.
The Contractor shall allow in his Programme for the following 11 public holidays per calendar year in Kenya upon which the Contractor shall not be permitted to work
New Year’s Day (1st January) Good Friday
Easter Monday
Labour Day (1st May)
Madaraka Day (1st June) Idd-Ul-Fitr
29
Moi Day (10th October)
35
Kenyatta Day (20th October)
Jamhuri Day (12th December) Christmas Day (25th December)
Boxing Day (26th December)
The Contractor should also allow per calendar year for a further 2 unspecified public holidays which may be announced by the Government of Kenya with no prior notification, and upon which he shall not be permitted to work.
14.2 Add the following at the end of this sub clause:-
The Employer shall have the right to withhold payment at any time if the Contractor fails to submit the contractual construction programmes in accordance with sub clause 14.1 above or revise construction programmes due to his negligence, failure or omission.
14.3 Cash Flow Estimate to be Submitted
The time limit within which a detailed cash flow estimate is to be submitted shall be twenty eight (28) days.
In preparing the estimates, the Contractor shall make provision for Advance payment, repayment of advance, retention, payment for services provided by the Employer and timing implications of sub clause 60 – Certificates and Payments.
15 Contractor’s Superintendence
Add the following at the end of the first paragraph of sub-clause 15.1:
15.1 The Contractor shall, within seven (7) days of receipt of the Engineer’s order to commence the Works, inform the Engineer in writing, the name of the Contractor’s representative and the anticipated date of his arrival on Site.
Add the following sub-clause 15.2:
15.2 The Contractor’s agent or representative on the Site shall be an Engineer registered by the Engineer’s Registration Board of Kenya in accordance with the Laws of Kenya cap. 530 or have equivalent status approved by the Engineer and shall be able to read, write and speak English fluently.
16.2 Engineer at Liberty to object
At the end of this clause add “by a competent substitute
36
approved by the Engineer at the Contractor’s own expense”.
The Contractor is encouraged to the extent practicable and reasonable, to employ staff and labour with appropriate qualifications who are Kenyan citizens.
Safety, Security and Protection of the Environment
19.1 Add at the end of sub clause 19.1 the following: -
The formulation and enforcement of an adequate safety program shall be the obligation of the Contractor with respect to all the Works under this Contract, regardless of whether performed by the Contractor or his subcontractors. The Contractor shall, within 14 days after commencement of the Works, meet the Engineer to present and discuss his plan for the establishment of such safety measures as may be necessary to provide against accidents, unsafe acts and so forth. Within 28 days after commencement of the Works, the Contractor shall submit a written safety program to the Engineer covering the overall Works and based on the laws and regulations of Kenya. In addition, he shall prepare special safety programs for blasting and handling of explosives as stipulated in the General and Special Specifications.
Notwithstanding the foregoing, the Contractor shall observe the following measures with a view to reducing or eliminating adverse environmental effects by the Site Works:
(i) All queries and borrow pits shall be filled and landscaped to their original state after extraction of construction material
(ii) Soil erosion due to surface runoff or water from culverts or other drainage structures should be avoided by putting in place proper erosion control measures that shall include, but not limited to grassing , planting of trees, gabions etc.
(iii) Long traffic diversion roads shall be avoided so as to
minimize the effect of dust on the surrounding environment. In any case all diversions shall be kept damp and dust free at the Contractor’s expense.
(iv) Spillage of oils, fuels and lubricants shall be avoided and
if spilt, shall be collected and disposed off in such a way as not to adversely affect the environment.
(v) Rock blasting near settlement areas shall be properly
37
coordinated with the relevant officers of the Government so as to minimize noise pollution and community interference.
(vi) Dumping shall be done only at designated dumping areas and not haphazardly on surroundings.
Insurance of Works & Contractor’s Equipment
21.1 (a) Delete the first sentence of this clause and replace with the following:
“Prior to commencement of the Works the Contractor shall, without limiting his or the Employer’s obligations and responsibilities under Clause 20, insure to the satisfaction of the Employer.”
(b) Add the following words at the end of sub - paragraph (a) and immediately before the last word in (b)
“it being understood the insurance shall provide for compensation to be payable in the types and proportions of the currencies required to rectify the loss or damage incurred.”
In sub clause 21.1(b), delete the words “or as may be specified in Part II of these Conditions”.
21.2 (a) Delete the words “from the start of Work at the Site” and substitute with the words “from the first working day after the commencement date”
(c) Add the following sub-clause: “It shall be the responsibility of the Contractor to notify the insurance company of any change in the nature and extent of the Works and to ensure the adequacy of the insurance coverage at all times during the period of the Contract”.
23.1 Third Party Insurance
Add the following at the beginning of this sub-clause:-
“Prior to commencement of the Works ……………………….”
23.2 Minimum Amount of Insurance
Add the following at the end of this sub-clause:- “ ……………… with no limits to the number of occurrences.”
25.1 Insert the words “as soon as practicable after the respective insurances have been taken out but in any case” before the words “Prior to the start of Work at the Site”
38
Add the following sub-clauses 25.5 to 25.7
25.5 Insurance Notices
Each policy of insurance effected by the Contractor for the purpose of the Contract shall include a provision to the effect that the Insurer shall have a duty to give notice in writing to the Contractor and Employer of the date when a premium becomes payable not more than thirty (30) days after the giving of such notice.
25.6 Re-insurance in Kenya
The risks against which the Contractor is obliged to insure under the Contract shall be insured through established and reputable companies approved by the Employer and located in Kenya and any cover against risks which the Contractor may enjoy shall be reinsured in Kenya by an approved Kenyan Insurance Company In respect of the Contractor’s obligations under the Contract.
25.7 It shall be the responsibility of the Contractor to notify the insurers under any of the insurances referred or event which by the terms of such insurances are required to be so notified and the Contractor shall indemnify and keep indemnified the Employer against all losses, claims, demands, proceedings, costs, charges and expenses whatsoever arising out of or in consequence of any default by the Contractor in complying with the requirements of this sub clause whether as a result of avoidance of such insurance or otherwise.
26. Compliance with Statutes, Regulations
Add the following sub-clause 26.2;-
The Employer will repay or allow to the Contractor all such sums as the Engineer shall certify to have been properly payable and paid by the Contractor in respect of such fees. Provided always that, without prejudice to sub clause, nothing contained in this clause shall be deemed to render the Employer liable to all claims which may be considered to fall within the provisions of clause 22.1.
Royalties
28.2 Add the following at the end of this sub-clause;
“The Contractor shall also be liable for all payments or compensation, if any, that are levied in connection with the dumping of part or all of any such material.”
39
Interference with Traffic and Adjoining Properties
29.2 Add new sub-clause 29.2;
The Contractor shall reinstate all properties whether public or private which are damaged in consequence of the construction and maintenance of the Works to a condition at least equal to that prevailing before his first entry on them.
If in the opinion of the Engineer the Contractor shall have failed to take reasonable and prompt action to discharge his obligations in the matter of reinstatement, the Engineer will inform the Contractor in writing of his opinion, in which circumstances the Employer reserves the right to employ others to do the necessary work of reinstatement and to deduct the cost thereof from any money due or to become due to the Contractor.
The Contractor shall promptly refer to the Employer all claims, which may be considered to fall within the provisions of Clause 22.1.
LABOUR
34.2 Conditions of Employment of Labour
The Contractor shall be responsible for making all arrangements for and shall bear all costs relating to recruitment, obtaining of all necessary visas, permits or other official permission for movements of staff and labour.
34.3 Fair Wages
The Contractor shall, in respect of all persons employed anywhere by him in the execution of the Contract, observe and fulfill the following conditions:
(a) The Contractor shall pay the rates of wages, observe hours of labour and provide conditions, housing amenities and facilities not less favorable than those required by the Regulation of wages (Building and Construction Industry) Order 1998, and any subsequent amendments thereto, or in any ministry of labour or other government department in consultation with the district whose general circumstances in the trade or industry in which the Contractor is engaged are similar. The Contractor shall at all times during the continuation of the Contract display, for the information of his employees, a notice setting out the general rates of wages, hours and conditions of labour of his employees and a copy of this clause.
(b) In the absence of any rates for wages, hours or conditions of labour so established, the Contractor shall pay rates or wages and observe hours and conditions for labour which are not less favourable than the general circumstances in the trade or industry in which the Contractor is engaged.
40
(c) Where the absence of established rates of wages, hours and conditions of labour or the dissimilarity of the general circumstances in the trade or industry in which the Contractor is engaged prevent the Contractor from observing rates of wages, hours and conditions of labour ascertained under sub-paragraph (a) or (b) above, the Contractor in fixing the rates of wages, hours and conditions of labour of his employees shall be guided by the advise of the labour department.
(d) The Contractor shall recognize the freedom of his employees to be
members of trade unions.
(e) The Contractor shall maintain records of the times worked by, and the wages paid to his employees. The Contractor shall furnish to the Employer, if called upon so to do, particulars of the rates of wages, hours and conditions of labour as the employer may direct.
(f) The Contractor shall be responsible for observance by his sub-
Contractors of the foregoing provisions.
34.4 Breach of Fair Wages Clause
Should a claim be made to the Employer alleging the Contractor’s default in payment of fair wages to any workman employed on the Contract and if proof thereof satisfactory to the Employer is furnished by the labour department, the Employer may, failing payment by the Contractor, pay the claims out of any monies due or which may become due to the Contractor under the Contract.
34.5 Recruitment of Unskilled Labour
Any additional unskilled labour which may be required by the Contractor for the Works and which is not in his employ at the time of the acceptance of the tender shall be recruited by the Contractor from the labour office nearest to the Site of the Works.
34.6 Compensation for injury
The Contractor shall, in accordance with the Workman’s Compensation Act Chapter 236 of the laws of Kenya and any other regulations in force from time to time in Kenya ,pay compensation for loss or damage suffered in consequence of any accident or injury or disease resulting from his work to any workman or other person in the employment of the Contractor or any sub-contractor.
34.7 Labour Standards
a) The Contractor shall comply with the existing local labour laws,
41
regulations and labour standards.
b) The Contractor shall formulate and enforce an adequate safety program with respect to all Work under this Contract, whether
performed by the Contractor or his sub-contractors. The Contractor has assurance from the Employer of cooperation where the implementation of these safety measures requires joint cooperation.
c) Upon written request of the Employer the Contractor will remove or
replace any of his employees employed under this Contract.
34.8 Recruitment
The Contractor shall not induce personnel of the employer or the Engineer to leave their regular employment and shall not, without the prior consent in writing of the Employer, employ personnel who have resigned from such service within the preceding twelve months.
35 Add the following subclauses 35.2 and 35.3:-
35.2 The Contractor shall maintain such records and make such reports concerning safety, health and welfare of persons and damage to property as the Engineer may from time to time prescribe.
35.3 The Contractor shall report to the Engineer details of any accident as soon as possible after its occurrence. In the case of any fatality or serious accident, the Contractor shall, in addition, notify the Engineer immediately by the quickest available means. The Contractor shall also notify the relevant authority(s) whenever such report is required by the law.
41.1 Commencement and Delays
Insert immediately after the word Works------ “on Site within 28 days” and before the word ----------after
41.2 Definition of Commencement
For the purposes of this clause, the Works shall be deemed to have commenced when all of the following conditions are satisfied;
a) The approved competent and authorized agent or representative of the Contractor is resident in the project area and is giving his whole time to the superintendence of the Works.
42
b) The provision by the Contractor of evidence that all insurances required by the Contract are in force.
c) The Contractor has an established office in the project area with
postal address for receipt of correspondence.
d) The principal items of constructional plant have been brought to Site
and put to work in the execution of the permanent Works.
42.4 Possession of Site and Access Thereto
Add the following to this clause 42.4;
The Contractor shall not enter any part of the Site until he has requested and received permission to do so from the Employer or the Engineer.
The Contractor shall not use any portion of the Site for any purpose not connected with the Works.
44.1 Add at the end of sub-clause 44.1 the following:
Neither rains falling between 1st November and 31 st December (inclusive)
and between 1st February and 31st May (inclusive) nor floods caused by such rains shall be deemed exceptional weather conditions such as may fairly entitle the Contractor to an extension of time for the completion of the Work.
45 Working Hours
Delete sub-clause 45.1 and substitute:
“subject to any provision to the contrary contained in the Contract, the Contractor shall have the option to work continuously by day and by night and on locally recognized days of rest.
If the Contractor requests for permission to work by day and night and if the
Engineer shall grant such permission, the Contractor shall not be entitled to
any additional payment for so doing. All such work at night shall be carried out
without unreasonable noise or other disturbance and the Contractor shall
indemnify the Employer from and against any liability for damages on account
of noise or other disturbance created while or in carrying out night work and
from and against all claims, demands, proceedings, costs, charges and
expenses whatsoever in regard or in relation to such liability. In addition, the
Contractor shall be required to provide, for any work carried out by night or
recognized days of rest, adequate lighting and other facilities
so that the Work is carried out safely and properly. In the event of the Engineer granting permission to the Contractor to work double or rotary shifts or on Sundays, the Contractor shall be required to meet any
43
additional costs to the Employer in the administration and supervision of the Contract arising from the granting of this permission.
47.2 Reduction of Liquidated Damages
There shall be no reduction in the amount of liquidated damages in the event that a part or a section of the Works within the Contract is certified as completed before the whole of the Works comprising that Contract.
No bonus for early completion of the Works shall be paid to the Contractor by the Employer.
The sum stated in the Appendix to Form of Tender as liquidated damages shall be increased by a sum equivalent to any amount payable by the Employer to the Contractor under clause 70.1 in respect of an increase in costs in such period that would not have been incurred by the Contractor if the Works had been completed by the due date for completion prescribed by clause 43.
Defects Liability
49.2 Add at the end of this sub-clause the following sentence:-
Any work ordered to be executed under this clause shall be done at a time and in a manner as directed by the Engineer so as to interfere as little as possible with the operations of the Employer or of other contractors and no extension(s) of the defects liability period will be allowed for the execution of this Work.
Add the following sub-clause 49.5 to this Clause:-
52 Variations
52.1 Add the following final sentence to this subclause:-
The agreement, fixing or determination of any rates or prices as aforesaid shall include any foreign currency and the proportion thereof.
52.4 Daywork
Add the following at the end of this sub-clause:
The Work so ordered shall immediately become part of the Works under the Contract. The Contractor shall, as soon as practicable after receiving the Daywork Order from the Engineer undertake the necessary steps for due execution of such Work. Prior to commencement of any work to be done on a Daywork basis, the Contractor shall give a notice to the Engineer stating the exact time of such commencement.
44
54 Plant, Temporary Works and Materials
Delete Sub-Clauses 54.3 to 54.4 entirely.
For the purpose of these Clauses, the term “Equipment” shall be read as “Contractor’s Equipment” where the context so requires.
54.1 Line 5: - Add “written” between “the” and “consent”.
Quantities
55.1 Delete sub-clause 55.1 and substitute with the following;
The quality and quantity of the Work included in the Contract Price shall be deemed to be that which is set out in the Contract Bills. The Bills, unless otherwise expressly stated therein, shall be deemed to have been prepared in accordance with the principles of the latest edition of the Civil Engineering Standard Method of Measurement.
Any error in description or in quantity or any omission of items from the Contract Bills or Specifications shall not vitiate this Contract but shall be corrected and deemed to be a variation required by the Engineer. Subject to the foregoing, any error whether arithmetical or not in the computation of the Contract Price shall be deemed to have been accepted by the parties hereto.
The Contract Price shall not be adjusted or altered in any way whatsoever otherwise than in accordance with the express provisions of these Conditions.
55.2 Add as a new sub-clause:
“Items of Work described in the Bills of Quantities for which no rate or price has been entered in the Contract shall be considered as included in other rates and prices in the Contract and will not be paid for separately by the Employer.
Measurement
56.1 Delete sub clause 56.1 and replace with the following:-
The Contractor shall prepare and submit to the Engineer all necessary field notes and other records taken and computations made for the purpose of quantity measurements, of which the forms shall be approved by the Engineer, for the monthly progress payment under clause 60. The measurement of work quantities made by the Contractor shall be verified and certified by the Engineer based on the above-mentioned documents.
The Contractor shall furnish all personnel, equipment and materials to
45
make such surveys and computations as necessary to determine the quantities of work performed. Unless otherwise prescribed in the specifications or the drawings, all measurements for payment shall be made by the dimensions, lines and grades as shown on the drawings or by direct survey of which the methods shall be approved by the Engineer.
The documents submitted for measurement and payment shall become the property of the Employer and shall be used to the extent necessary to determine the monthly progress payment to be made to the Contractor under the Contract. Direct survey, if done, shall be subject to checking and verification by the Engineer and all errors in the said survey work and related computations as found during such checking shall be immediately corrected by the Contractor.
57.1 Delete sub clause 57.1 and substitute with the following:-
The Works shall be measured net with deductions made in accordance with the principles of the latest edition of the Civil Engineering Standard Method of Measurement. All measurements shall be given in metric (SI) units.
Provisional Sums
58.4 Prime Cost sum
Wherever an item in the Bills of Quantities has been referred to as a “P.C. Sum” (Prime Cost Sum), that item shall be construed as a Provisional sum and the provisions of Sub-clauses 58.1 to 58.3 will apply.
59.5 Add the following paragraph at the end of sub clause 59.5:-
If the Engineer desires to secure final payment to any nominated sub-contractor before final payment is due to the Contractor and if such sub-contractor has satisfactorily indemnified the Contractor against any latent defects, the Engineer may, in an interim certificate, include an amount to cover the said final payment, and thereupon the Contractor shall pay to such nominated sub-contractor the amount so certified. Upon such final payment, the amount named in the Appendix to Form of Tender as Limit of Retention Money shall be reduced by the sum which bears the same ratio to the amount as does the subcontract and sub-contractor shall be discharged from all liability for the Work, materials or goods executed or supplied by such subcontractor under the Contract to which the payment relates.
Certificates and Payment
Delete Sub-clauses 60.1 to 60.10 entirely and substitute with the following:-
60.1 Advance Payment
In the event that an advance payment is granted, the following shall apply:-
46
a) On signature of the Contract, the Contractor shall at his request, and without furnishing proof of expenditure, be entitled to an advance of 10% (ten percent) of the original amount of the Contract. The advance shall not be subject to retention money.
b) No advance payment may be made before the Contractor has submitted proof of the establishment of deposit or of a directly liable guarantee satisfactory to the Employer in the amount of the advance payment. The guarantee shall be in the same currency as the advance.
c) Reimbursement of the advance shall be effected by deductions from
monthly interim payments.
d) Reimbursement of the lump sum advance shall be made by deductions from the Interim payments and where applicable from the balance owing to the Contractor. Reimbursement shall begin when the amount of the sums due under the Contract reaches 20% of the original amount of the Contract. It shall have been completed by the time 80% of this amount is reached.
The amount to be repaid by way of successive deductions shall be calculated by means of the formula:
R = A ( x1 – x11) 80 – 20
Where: R = the amount to be reimbursed
A = the amount of the advance which has been granted
X1 = the amount of proposed cumulative payments as a percentage of the original amount of the Contract. This figure will exceed 20% but not exceed 80%.
X11 = The amount of the previous cumulative payments as a percentage of the original amount of the Contract. This figure will be below 80% but not less than 20%.
(e) with each reimbursement the counterpart of the directly liable guarantee may be reduced accordingly.
60.2 Interim Payment Certificate
The Contractor shall submit to the Engineer, in the manner required by the Engineer after the end of each month a statement showing the estimated total value of permanent Work properly executed and materials or goods for permanent works brought to Site up to the end of the previous month (if the value shall justify the issue of an interim certificate) together with any
47
adjustments under clause 70 and any outstanding claims and sums the Contractor considers may be due to him. The Contractor shall amend or correct his estimate as directed by the Engineer and the latter shall not accept it until he is satisfied that it is fair and reasonable. With respect to the said materials and goods, no payment for them shall be made unless ;- (i) The materials are in accordance with the specifications for the Works;
(ii) The materials have been delivered to Site and are properly stored and
protected against loss, damage or deterioration;
(iii) The Contractor’s record of the requirements, orders, receipts and use
of materials are kept in a form approved by the Engineer, and such records are available for inspection by the Engineer;
(iv) The Contractor has submitted a statement of his cost of acquiring and
delivering the materials and goods to the Site, together with such documents as may be required for the purpose of evidencing such cost;
(v) The materials are to be used within a reasonable time.
The Contractor will be paid on the certificate of the Engineer the amount due to him on account of the estimated total value of the permanent Work executed up to the end of the previous month together with such amount (not exceeding 75% of the value) as the Engineer may consider proper on account of materials and goods for permanent Work delivered by the Contractor on Site and in addition, such amount as the Engineer
may consider fair and reasonable for any Temporary Works for which separate amounts are provided in the Bill of Quantities, all of which shall be subject to a retention of the percentage named in the Appendix to Form of Tender until the amount retained (hereinafter and in all Contract documents called the “Retention Money”) shall reach the “Limit of Retention Money” named in the said Appendix. Provided always that no interim certificate shall be issued for a sum [such sum always being the net amount thereof after all deductions for retention etc) less than that named in the Appendix to Form of Tender as “Minimum Amount of Interim Certificate” at one time.
Within 14 days after receiving a statement from the Contractor as aforesaid, and subject to the Contractor having made such further amendments and corrections as the Engineer may require, the Engineer shall issue a Certificate of Payment to the Employer showing the amount due, with a copy to the Contractor.
The Engineer shall not unreasonably withhold certifying an Interim Payment Certificate and where there is a dispute regarding an item for payment, the
Engineer may delete this disputed item from the Interim Payment Certificate and certify the remainder for payment provided the said payment is in
accordance with the preceding paragraph. In cases of difference in opinion
48
as to the value of any item, the Engineer’s view shall prevail.
60.3 Final Account and Final Payment Certificate
As soon as possible after the issue of Taking - Over Certificate or the termination of the Contract and not later than the time of issue of Defects Liability Certificate, the Contractor shall prepare and submit to the Engineer (with a copy to the Employer), a Statement of Final Account showing in detail the total value of work done in accordance with the Contract together with all sums paid in previous payments. Within thirty(30) after receipt of such further information as may be reasonably required from the Contractor for its verification, the Engineer shall check the said statement, prepare and submit a Final Payment Certificate to the Employer (with a copy to the Contractor).
The Final Payment Certificate shall state;
(a) The (final) total value of all Work done in accordance with the Contract;
(b) After giving credit to the Employer for all amounts previously paid to
the Contractor, the balance, if any, due from the Employer to the Contractor or the Contractor to the Employer, as the case may be.
Unless the Contractor notifies the Engineer of his objection to the Final Payment Certificate within twenty eight [28] days of delivery thereof , he shall be deemed to have agreed that he accepts the total Contract Price as set out in the Final Payment Certificate as full settlement for all work done under the Contract including any claims, variations and omissions thereof.
However, a Final Certificate of Payment shall not be conclusive:
a) to the extent that fraud or dishonesty relates to or affects any matter dealt with in the Certificate, or
b) if any arbitration or court proceedings under the Contract have been
commenced by either party before the expiry of 84 days after the issue of the Final Certificate of Payment.
60.4 Payment of Certificates
Payment upon each of the Engineer’s Certificates for Interim Payments shall be made by the Employer within the time stated in the Appendix to Form of Tender from the date of issue of each Certificate of Payment.
Payment upon the Engineer’s Final Payment Certificate shall be made by the Employer within the time stated in the Appendix to Form of Tender from
49
the date of issue of the Final Certificate of Payment signed by the Engineer and countersigned by the Contractor or his authorised agent or representative.
Making of a payment by the Employer shall be considered to have been duly executed on the day that the Employer has issued a cheque.
60.5 Payment of Retention Money
One half of the retention money shall become due upon the issue of a Taking – Over Certificate and shall be paid to the Contractor when the Engineer shall certify in writing that the last section of the whole of the Works has been substantially completed and the other half shall be paid to the Contractor after the expiration of the Defects Liability Period and the issue of a Certificate under Clause 62. Provided always that if such time there shall remain to be executed by the Contractor any Works ordered during such period pursuant to Clauses 49 and 50 thereof ,the Employer
shall be entitled to withhold payment [until the completion of such Works] of so much of the second half of the Retention Money as shall in the opinion of the Engineer represent the Costs of the Works so remaining to be executed. Provided further that in the event of different Defects Liability Periods having become applicable to different parts of the Works pursuant to clause 48 hereof the expression “expiration of the Defect Liability Period” shall for the purpose of this Sub-clause be deemed to mean the expiration of the latest of such periods.
60.6 Currency of Payment
The Contract price shall be stated in Kenya Shillings. All payments to the Contractor shall be made in Kenya shillings and foreign currency(s) in the proportion indicated in the tender, or agreed prior to the execution of the Contract Agreement and indicated therein. The rate[s] of exchange for the calculation of the amount of foreign currency payment[s] shall be the rate of exchange indicated in the Tender. If the Contractor indicated foreign currencies for payment other than the currencies of the countries of origin of related goods and services, the Employer reserves the right to pay the equivalent at the time of payment in the currencies of the countries of such goods and services. The Employer and the Engineer shall be notified promptly by the Contractor of any changes in the expected foreign currency requirements of the Contractor during the execution of the Works as indicated in the Statement of Foreign Currency Requirements and the foreign and local currency portions of the balance of the Contract Price shall then be amended by agreement between Employer and the Contractor in order to reflect appropriately such changes.
60.7 Overdue Payments
50
Unless otherwise stated in the appendix interest shall be paid on the overdue amounts and the interest to be paid shall be in accordance with prevailing commercial bank rates.
60.8 Correcting and With-holding
The Engineer may by any interim certificate or through the final account make any correction or modification to any previous certified sum and shall have authority, if any work or part thereof is not being carried out to his satisfaction, to omit or reduce the value of such work in any Interim Payment Certificate.
60.9 Completion by Sections.
If a Taking-Over Certificate shall be issued for any section or part of the Works separately, the payments herein provided for on or after issue of such a Certificate shall be made in respect of such section or part and references to the Contract Price shall mean such part of the Contract Price as shall in the absence of agreement be apportioned thereto by the Engineer.
60.10 Proportion of Foreign Currency
Subject to the provision of sub clause 60.5 the proportion of foreign currency in any amount due to the Contractor or Employer shall be determined in the following manner:-
a) For all measured Work, the percentages of foreign currency for the appropriate section of the Bill of Quantities as stated in the schedule of foreign currency requirements shall be applied.
b) Variations in the cost of imported materials shall be paid in foreign
currency.
c) Variations in the cost of locally purchased materials and those due to
changes of legislation shall be paid in local currency.
d) For Day works labour and plant, the respective percentages of foreign
currency stated in the schedule shall be applied.
e) For Day works materials and materials on site, payment in foreign currency will only be made for imported materials.
f) The provisions for the deduction and release of Retention Money and
the payment of interest shall be applied similarly to both the local and foreign portions.
g) The advance mobilization loan, its repayment thereof and liquidated
damages shall all be apportioned on the basis of the ration between local and foreign currency indicated in the Contract Price.
51
h) In the event that the payment is for an item not covered in the foregoing paragraphs, the Engineer shall determine the proportion of foreign and local currency based on the information given in the Schedule of Foreign Currency Requirements, together with any additional information he may request the Contractor to provide.
60.11 Statement at Completion
Not later than 14 days after the issue of the Taking-Over Certificate in respect of the whole of the works, the Contractor shall submit to the Engineer a statement at completion showing in detail, in a form approved by the Engineer;
(a) The final value of all work done in accordance with the Contract up to the date stated in such Taking-Over Certificate.
(b) Any further sums which the Contractor considers to be due; and
(c) An estimate of amounts, which the Contractor considers, will become
due to him under the Contract.
Estimate amounts shall be shown separately in the Statement at Completion. The Contractor shall amend and correct the Statement as directed by the Engineer who shall issue a Certificate at Completion to be processed in accordance with sub-clause 60.4.
60.12 Final Statement
Not later than 56 days after the issue of the Defects Liability Certificate, the Contractor shall submit to the Engineer for consideration a draft final statement with supporting documents showing in detail, in the form approved by the Engineer;
(a) The final value of all work done in accordance with the Contract;
(b) Any further sums which the Contractor considers to be due to him.
If the Engineer disagrees with or cannot verify any part of the draft final statement, the Contractor shall submit such further information as the Engineer may reasonable require and shall make such changes in the draft as may be required.
60.13 Discharge
Upon submission of the Final Statement, the Contractor shall give to the Employer, with a copy to the Engineer, a written discharge confirming that
52
the total of the Final Statement represents full and final settlement of all monies due to the Contractor arising out of or in respect of the Contract. Provided that such discharge shall become effective only after payment under the Final Payment Certificate issued pursuant to Sub-clause 60.14 has been made and the Performance Security referred to in Sub-clause 10.1 has been returned to the Contractor.
60.14 Final Payment Certificate
Upon acceptance of the Final Statement as given in Sub-clause 60.12, the Engineer shall prepare a Final Payment Certificate which shall be delivered to the Contractor’s authorized agent or representative for his signature. The Final Payment Certificate shall state:
(a) The final value of all work done in accordance with the Contract;
(b) After giving credit to the Employer for all amounts previously paid by the
Employer, the balance, if any, due from the Employer to the Contractor or the Contractor to the Employer as the case may be
Final Certificate shall be issued for any sum due to the Contractor even if such is less than the sum said named in the Appendix to the Form of Tender.
60.15 Cessation of Employer’s Liability
Unless the Contractor notifies the Engineer of his objection to the Final Certificate within fourteen days of delivery thereof he shall be deemed to have agreed that he accepts the total Contract Price as set out in the Final Certificate as full settlement for all work done under the Contract including any variations and omissions thereof.
62.1 Defects Liability Certificate
Delete the last sentence of this Sub-Clause beginning “Provided that the issue……………………..in Sub-Clause 60.3”.
Remedies
63.4 Assignment of Benefit of Agreement
Add the following at the end of this sub-clause:-
“But on the terms that a supplier or sub-contractor shall be entitled to make any reasonable objection to any further assignment thereof by the Employer and the Employer may pay the supplier or sub-contractor for any
53
such materials supplied or Works executed under such agreement, whether the same be assigned as aforesaid or not, before or after the said determination, the amount due by such arrangement in so far as it has not already been paid by the Contractor”.
65 Special Risks
Add sub clause 65.9 as follows:
(a) In the event of the Employer unilaterally ordering the final cessation of performance of the Contract for reasons not specified elsewhere in the Conditions of Contract the Contract shall be considered to be frustrated and the Contractor shall be indemnified as provided for under clause 65.1.
(b) In the event of the Employer ordering the adjournment of the Contract before or after commencement of the Works for reasons not specified elsewhere in the Conditions of Contract, the Contractor shall be entitled to indemnity for any injury which he may have suffered as a consequence of such adjournment. The Engineer shall award the Contractor payment of such sum as in his opinion shall be reasonable giving regard to all material and relevant factors including the Contractor’s on costs and overheads, and the nature of the instruction to adjourn the Contract.
Settlement of Disputes
67.3 Arbitration
For the purposes of this Clause, the Arbitrator shall be a person to be agreed between the parties or failing agreement, the Arbitrator shall be appointed by the appointer designated in the Appendix to the Form of Tender.
48
Add the following paragraph after the last paragraph of sub-clause
67.3:
Arbitration shall take place in Nairobi, Kenya. The language of all arbitration proceedings shall be in English. The cost of arbitration shall be apportioned by the Arbitrator according to his findings.
54
Notices
68.1 Add the following at the end of this subclause:-
Notwithstanding the foregoing, the Contractor shall either maintain an address close to the Works or appoint an agent residing close to the Works for the purpose of receiving notices to be given to the Contractor under the terms of the Contract. This obligation shall be terminated upon the issue of the Certificate of Completion.
68.2 Delete the words “nominated for that purpose in Part II of these Conditions” in this sub-clause.
Default of Employer
69.1 Default of Employer
In paragraph (a) of this Sub-Clause, delete the words “within 28 days of expiry of the time stated in Sub-clause 60.10” and insert “within 56 days after the expiry of the time stated in Sub-Clause 60.4”.
69.4 Contractor’s Entitlement to Suspend Work
Delete the first four lines of this Sub-Clause and replace with the following:-
“Without prejudice to the Contractor’s entitlement to interest under Sub-clause 60.7 and to terminate his employment under Sub-Clause 69.1, the Contractor may, if the Employer fails to pay the Contractor the amount due under any certificate of the Engineer within 56 days after the expiry of the time stated in Sub-Clause 60.4…..”
Delete sub-clause 69.4 (b) and substitute with the following----“the amount of such cost, which shall be added to the Contract Price. However, the costs due to idle time for plant, equipment and labour shall not be included in the said costs and shall be borne by the Contractor.
69.5 Resumption of Work
In line 3 of this Sub-Clause delete the Words “Sub-Clause 60.10” and replace with “Sub-Clause 60.7”
Changes in Cost and Legislation
70.1 Delete the sub-clause 70.1 in its entirety and substitute with the following:-
“The Contract Price shall be deemed to have been calculated in the matter set below and shall be subject to the adjustment in the event specified hereunder:
55
(a) The rates contained in the priced Bill of Quantities are based upon the rates of wages and other emoluments and expenses applicable at the site and the date of tender pricing (as defined in sub-clause 70.4 hereinafter);
(b) If the said rates of wages and other emoluments and expenses shall be increased or decreased by act, statue, decree, regulation and the like after the said date of tender pricing then the net amount of increase the emoluments and expenses shall, as the case may be, paid to or allowed by Contractor;
(c) The rates contained in the price Bill of Quantities are based upon the rates of the Contractor’s compulsory contributions payable at the date of tender under or by virtue of any Act, Statue, Regulations and the like applicable at the site;
(d) If any of the said rates of contribution becomes payable after that date then the net amount of new statutory contribution becomes payable after that date then the net amount of increase or decrease of the emoluments and expenses shall, as the case may be, be paid to or allowed by the Contractor. Difference between what the Contractor actually pays in respect of work people engaged upon or in connection with the works and what he would have paid in respect of such person had any of the said rates not been increased or decreased or had a new contribution not become payable as aforesaid, shall as the case may be, be paid to or allowed by the Contractor. Provided always that the Engineer and the Contractor may agree a sum, which shall be deemed to be the net amount of the aforesaid difference, and such sum shall be deemed for the purpose of this Contract to be, that which is to be paid to or allowed by the Contractor by the virtue of this sub-paragraph;
(e) If the market price or any materials or goods specified as aforesaid shall be increased or decreased after the said Date of Tender Pricing, then the net amount of difference between the basic price and the market price payable by the Contractor and current when any such goods and materials are bought shall, as the case may be, be paid to or allowed by the Contractor. Orders for materials and goods listed as aforesaid shall have been placed within a reasonable time after the date at which sufficient information is available for the placing of such orders, and the placing of orders at that time shall be a condition precedent to any payments being made to the Contractor in respect of increased market prices.”
Substitute and add the following sub-clauses:
70.2 (a) If the Contractor shall decide subject to Clause 4 thereof to sub-let any portion of the work he shall incorporate in the sub-contract provisions to the like effect as those contained in sub-clause (1) of this Clause;
(c) If the price payable under a sub-contract as aforesaid is increased above or decreased below the price in such sub-contract by reason of the operation of the incorporated provisions of sub-clause (1) of this clause
56
then the net amount of such increase or decrease shall as the case may be, be paid to or allowed by the Contractor under this Contract.
70.3 The expression “the date of tender pricing” as used in this Clause means the date 28 days prior to the final date for submission of Tenders as determined by the Employer in the Tender documents.
70.4 For imported materials, the supplier’s/manufacturer’s Prime costs shall be C.I.F. cost at point of entry by the same means of transport as determined by the Contractor’s Basic Rate.
For locally produced materials, the supplier’s or manufacturer’s prime costs shall be at their nearest depot or the nearest railway station relevant to the works.
For materials, which are subject to Government Price Control, payments for price variations will be determined from the difference between the control price in force at a date 28 days prior to date for submission of Tenders and the price in force on the date of purchase.
70.5 The materials to which this Variation Clause applies are:
All bitumen material Fuels, oils and lubricant Cement Lime Flex beam guardrail Explosives Gabion mesh Reinforcing steel
70.6 The Contractor shall not change the supplier or manufacturer during the Contract without the approval of the Engineer.
70.7 No payments will be made for price variation related to expenses incurred by the Contractor in his Head Office in Kenya, or overseas.
70.8 All payments made pursuant to Clause 70 shall be in Kenya Shillings.
70.9 No payments will be made for the cost of preparing V.O.P. claims.
70.10 Add the following at the end of this clause.
“Notwithstanding the foregoing, such additional or reduced cost shall not be separately paid or credited as aforesaid if the same shall already have been taken into account in accordance with the provisions of sub-clause 70.1”.
ADDITIONAL CLAUSES
Clause 73 Declaration Against Waiver
57
The condoning by the Employer of any breach or breaches by the Contractor or any authorized sub-contractor of any of the stipulations and Conditions contained in the Contract shall in no way prejudice or affect or be construed as a waiver of the Employer’s rights, powers and remedies under the Contract in respect of any breach or breaches as aforesaid.
Clause 74 Bribery and Collusion
The Employer shall be entitled to determine the Contract and recover from the Contractor the amount of any loss resulting from such determination if the Contractor shall have offered or given or agreed to give any person any gift or consideration of any kind as an inducement of regard for doing or fore bearing to do or for having done or fore borne to do any action in relation to obtaining or the execution of the Contract or any other contract with the Employer or if any of the like acts shall have been done by any person employed by the Contractor or acting on his behalf (whether with or without the
knowledge of the Contractor) or if the Contractor shall have come to any agreement with another contractor or number of contractors whereby an agreed quotation or estimate shall be tendered to the Employer by one or more contractors.
Clause 75 Contract Confidential
The Contractor shall treat the Contract and everything in connection therewith as private and confidential. In particular, the Contractor shall not publish any information, drawings or photographs concerning the Works in any trade or technical paper etc, and shall not use the Site for the purpose of advertising except with the written consent of the Engineer and subject to such conditions as the Engineer may prescribe.
Clause 76 Employer’s Officials etc., Not Personally Liable
No official of the Employer or the Engineer or the Engineer’s
Representative or anyone of their respective staffs or their employees shall be in any way personally bound or liable for the acts or obligations of the Employer under the Contract or answerable for default or omission in the observance or performance of any of the acts, matters or things which are herein contained.
Clause 77 Taxes and Duties
(1) The Contractor shall list in his tender the plant and vehicles which he intends to import for the execution of the Works. The Engineer will consider the list in the context of the program of the Works and will give his approval subject to any
58
modifications that he may see fit to make. No appeal against the Engineer’s decision shall be permitted.
The Contractor will be permitted to import approved plant and vehicles required for the execution of the Works on the basis of temporary admission into Kenya and re-export thereafter upon completion of the Contract without payment of customs duties and Value Added Tax for them. If the plant and equipment shall not be re-exported, duties and taxes shall then be paid based upon their residual value at the date of completion of the Contract, or the date of withdrawal from the Works, if earlier. Plant and vehicles so imported shall not be utilized on other works not associated with the Contract unless specifically authorized by the Engineer.
(2) The Contractor will be permitted to import approved spare parts, tires and tubes without payment of customs duty and Value Added Tax for maintenance of any imported vehicles and plant as provided in sub-clause 77.1 above, within a financial limit indicated by himself. However, this limit will not exceed 15% of the Contract Price excluding Contingencies.
(3) All materials approved by the Engineer to be incorporated into the Works or temporary works, and whose importation into Kenya is agreed to be essential shall be free of customs duties and Value Added Tax. The Contractor shall submit a list of such materials required with the tender. The Contractor shall be required to satisfy the Engineer that such materials have actually been incorporated into the Works.
Items produced in Kenya will not be permitted to be imported without payment of customs duty and Value Added Tax.
Items produced in Kenya shall mean commercially recognized goods or products that are either mined, grown, manufactured, processed or assembled (whether the components are imported or not) in Kenya.
Clause 78 Joint Ventures
78.1 If the Contractor is a joint venture, all partners of the joint venture shall be jointly and severally liable to the Employer for the execution of the entire Contract in accordance with its terms and Conditions.
V) SPECIFICATIONS
Notes for preparing Specifications
1.0 Specifications must be drafted to present a clear and precise statement of the required standards of materials and
59
workmanship for tenderers to respond realistically and competitively to the requirements of the Employer and ensure responsiveness of tenders. The Specifications should require that all materials, plant and other supplies to be incorporated in the permanent Works be new, unused, of the most recent or current models and incorporating all recent improvements in design and materials unless provided otherwise in the Contract. Where the Contractor is responsible for the design of any part of the permanent Works, the extent of his obligations must be stated.
2.0 Specifications from previous similar projects are useful and it may not be necessary to re- write specifications for every works contract.
3.0 There are considerable advantages in standardizing General Specifications for repetitive Works in recognized public sectors, such as highways, urban housing, irrigation and water supply. The General Specifications should cover all classes of workmanship, materials and equipment commonly involved in construction works, although not necessarily to be used in a particular works contract. Deletions or addenda should then adapt the General Specifications to the particular Works.
4.0 Care must be taken in drafting Specifications to ensure they are not restrictive. In the specifications of standards for materials, plant and workmanship, existing Kenya Standards should be used as much as possible, otherwise recognized International Standards may also be used.
5.0 The Employer should decide whether technical solutions to specified parts of the Works are to be permitted. Alternatives are appropriate in cases where obvious (and potentially less costly) alternatives are possible to the technical solutions indicated in tender documents for certain elements of the Works, taking into consideration the comparative specialized advantage of potential tenderers.
The Employer should provide a description of the selected
parts of the Works with appropriate reference to Drawings, Specifications, Bills of Quantities, and Design or Performance criteria, stating that the alternative solutions shall be at least structurally and functionally equivalent to the basic design parameters and Specifications.
Such alternative solutions shall be accompanied by all information necessary for a complete evaluation by the Employer, including drawings, design calculations, technical specifications, breakdown of prices, proposed construction
60
methodology and other relevant details. Technical alternatives permitted in this manner shall be considered by the Employer each on its own merits and independently of whether the tenderer has priced the item as described in the Employer’s design included with the tender documents
6.0 Health Care and Welfare
In addition to providing, equipping and maintaining adequate first aid stations throughout the works in accordance with the Laws of Kenya, the Contractor shall provide and maintain on Site during the duration of the Contract, a fully equipped dispensary. This shall be with a qualified Clinical Officer/Nurse who shall offer the necessary medical advice on AIDS/HIV and related diseases to the Engineer’s and Contractor’s Site staff. The Contractor shall allow for this in the rates and be responsible for all site welfare arrangements at his own cost.
61
SECTION VI: DRAWINGS
62
63
64
65
66
67
68
69
70
71
72
73
74
SECTION VII – BILLS OF QUANTITIES
Notes for preparing Bills of Quantities
1.0 Preamble To Bill of Quantities
a) The Bill of Quantities shall form part of the Contract Documents and is to be read in conjunction with the Instructions to Tenderers, Conditions of Contract Parts I and II, Specifications and Drawings.
b) The brief description of the items in the Bill of Quantities is purely for the purpose of identification, and in no way modifies or supersedes the detailed descriptions given in the conditions of Contract and Specifications for the full direction and description of work and materials.
c) The Quantities set forth in the Bill of Quantities are estimated and provisional, representing substantially the work to be carried out, and are given to provide a common basis for tendering and comparing of Tenders. There is no guarantee to the Contractor that he will be required to carry out all the quantities of work indicated under any one particular item or group of items in the Bill of Quantities. The basis of payment shall be the Contractor’s rates and the quantities of work actually done in fulfillment of his obligation under the Contract.
d) The prices and rates inserted in the Bills of Quantities will be used for
valuing work executed, and the Engineer will measure the whole of the works executed in accordance with this Contract.
e) A price or rate shall be entered in ink against every item in the Bill of Quantities with the exception of items, which already have provisional sums, affixed thereto. The Tenderers are reminded that no “nil” or “included” rates or “lump-sum” discounts will be accepted. The rates for various items should include discounts if any. Tenderers who fail to comply will be disqualified.
f) Provisional sums (including Day works) in the Bill of Quantities shall be expended in whole or in part at the discretion of the Engineer in accordance with Sub-clause 52.4 and Clause 58 of part of the Conditions of Contract.
g) The price and rates entered in the Bill of Quantities shall, except insofar as it is otherwise provided under the Contract, include all Constructional plant to be used, labour, insurance, supervision, compliance, testing, materials, erection, maintenance or works, overheads and profits, taxes and duties together with all general risks, liabilities and obligations set out or implied in the Contract, transport, electricity and telephones, water, use and replenishment of all consumables, including those required under the Contract by the
Engineer and his staff.
75
h) Errors will be corrected by the Employer for any arithmetic errors in computation or summation as follows:
(a) Where there is a discrepancy between amount in words and
figures, the amount in words will govern; and (b) Where there is a discrepancy between the unit rate and the total
amount derived from the multiplication of the unit price and the quantity, the unit rate as quoted will govern, unless in the opinion of the Employer, there is an obviously gross misplacement of the decimal point in the unit price, in which event the total amount as quoted will govern and the unit rate will be corrected.
(c) If a Tenderer does not accept the correction of errors as outlined above, his Tender will be rejected.
i) The Bills of Quantities, unless otherwise expressly stated therein, shall be deemed to have been prepared in accordance with the principles of the latest edition of the Civil Engineering Standard Method of Measurement (CESMM).
j) “Authorised” “Directed” or “Approved” shall mean the authority,
direction or approval of the Engineer.
k) Unless otherwise stated, all measurements shall be net taken on the finished work carried out in accordance with the details shown on the drawings or instructed, with no allowance for extra cuts or fills, waste or additional thickness necessary to obtain the minimum finished thickness or dimensions required in this Contract. Any work performed in excess or the requirements of the plans and specifications will not be paid for, unless ordered in writing by the Engineer.
l) (a) Hard material, in this Contract, shall be defined as the material which, in the opinion of the Engineer, require blasting, or the use of metal wedges and sledgehammers, or the use of compressed air drilling for their removal, and which cannot be extracted by ripping with a dozer tractor of at least 150 brake horse power (112 kilowatt) with a single, rear-mounted, hydraulic ripper. Boulders of more than
0.2m3 occurring in soft material shall be classified as hard material.
(b) Soft material shall be all material other than hard material.
2.0 The objectives of the Bills of Quantities are;
(a) to provide sufficient information on the quantities of Works to be
performed to enable tenders to be prepared efficiently and accurately; and
(b) when a Contract has been entered into, to provide a priced Bills of Quantities for use in the periodic valuation of Works executed.
76
In order to attain these objectives, Works should be itemized in the Bills of Quantities in sufficient detail to distinguish between the different classes of Works, or between Works of the same nature carried out in different locations or in other circumstances which may give rise to different considerations of cost. Consistent with these requirements, the layout and content of the Bills of Quantities should be as simple and brief as possible.
3.0 The Bills of Quantities should be divided generally into the following sections:
(a) Preliminaries.
The preliminaries should indicate the inclusiveness of the unit prices, and should state the methods of measurement which have been adopted in the preparation of the Bills of Quantities and which are to be used for the measurement of any part of the Works.
The number of preliminary items to be priced by the tenderer should be limited to tangible items such as site office and other temporary works, otherwise items such as security for the Works which are primarily part of the Contractor’s obligations should be included in the Contractor’s rates.
(b) Work Items
(i) The items in the Bills of Quantities should be grouped into sections to distinguish between those parts of the Works which by nature, location, access, timing or any other special characteristics may give rise to different methods of construction or phasing of the Works or considerations of cost. General items common to all parts of the Works may be grouped as a separate section in the Bills of Quantities.
(ii) The brief description of the items in the Bill of Quantities
should in no way modify or supersede the detailed descriptions given in the Contract drawings, Conditions of Contract and Specifications.
(iii) Quantities should be computed net from the Drawings, unless directed otherwise in the Contract, and no allowance should be made for bulking, shrinkage or waste. Quantities should be rounded up or down where appropriate.
(iv) The following units of measurement and abbreviations are recommended for use.
77
Unit Abbreviation Unit Abbreviation
cubic meter m3 or cu m millimeter mm hectare ha month mon hour h number nr kilogram kg square meter m2 or sq m
lump sum sum square millimeter mm2 or sq mm
m meter week wk
t metric ton
(1,000 kg)
(v) The commencing surface should be identified in the description of each item for Work involving excavation, boring or drilling, for which the commencing surface is not also the original surface. The excavated surface should be identified in the description of each item for Work involving excavation for which the excavated surface is not also the final surface. The depths of Work should be measured from the commencing surface to the excavated surface, as defined.
(c) Daywork Schedule
A Daywork Schedule should be included if the probability of unforeseen work, outside the items included in the Bills of Quantities is relatively high. To facilitate checking by the Employer of the realism of rates quoted by the tenderers, the Daywork Schedule should normally comprise:
(i) a list of the various classes of labour, and materials for which basic Daywork rates or prices are to be inserted by the tenderer, together with a statement of the conditions under which the Contractor will be paid for Work executed on a Daywork basis; and
(ii) a percentage to be entered by the tenderer against each basic
Daywork Subtotal amount for labour, materials and plant representing the Contractor’s profit, overheads, supervision and other charges.
(d) Provisional Quantities and Provisional Sums
(i) Provision for quantity contingencies in any particular
item or class of Work with a high expectation of quantity
78
overrun should be made by entering specific “Provisional Quantities” or “Provisional Items” in the Bills of
Quantities, and not by increasing the quantities for that item or class of Work beyond those of the Work normally expected to be required. To the extent not covered above,
a general provision for physical contingencies (quantity overruns) should be made by including a “Provisional Sum” in the Summary of the Bills of Quantities. Similarly,
a contingency allowance for possible price increases should be provided as a “Provisional Sum” in the
Summary of the Bills of Quantities. The inclusion of such provisional sums often facilitates budgetary approval by avoiding the need to request periodic supplementary
approvals as the future need arises.
(ii) Provisional Sums to cover specialized works normally carried out by Nominated Sub Contractors should be avoided and instead Bills of Quantities of the specialised Works should be included as a section of the main Bill of Quantities to be priced by the Main Contractor. The Main Contractor should be required to indicate the name (s) of the specialised firms he proposes to engage to carry out the specialized Works as his approved domestic sub-contractors. Only Provisional Sums to cover specialized Works by statutory authorities should be included in the Bills of Quantities.
(iii) Unless otherwise provided in the Contract, the Provisional Sums included in the Bills of Quantities should always be expended in whole or in part at the discretion of the Engineer after full consultation with the Employer.
(e) Summary
The Summary should contain a tabulation of the separate parts of the Bills of Quantities carried forward, with Provisional Sums for Dayworks, physical (quantity) contingencies, and price contingencies (upward price
adjustment) where applicable.
79
Bill DESCRIPTION AMOUNT
No. (KSHS)
1
4
5
7
8
9
17
20
21
23
25
26
27
SITE CLEARANCE AND TOPSOIL STRIPPING
EARTHWORKS
GRAND TOTAL CARRIED FORWARD TO FORM OF BID
PASSAGE OF TRAFFIC
CONCRETE WORKS
SUMMARY OF BILLS OF QUANTITIES
PRELIMINARY AND SUPERVISORY/SUPPORT SERVICES
MISCELLANEOUS BRIDGE WORKS
EXCAVATION AND FILLING FOR STRUCTURES
CULVERTS AND DRAINAGE WORKS
Add 16% of Sub-Total (1) for V.A.T.
HIV/AIDS AWARENESS AND EDUCATION
SUB TOTAL (1)
ROAD FURNITURE
FRONTAGE IMPROVEMENT AND BEATIFICATION
HIGH MASTS
CONCRETE PAVING BLOCKS
80
ITEM DESCRIPTION UNIT QUANTITY RATE AMOUNT
Brought forward from previous page.
1.11
Provide, fuel and maintain with drivers one (1)
new 4WD double cabin pickups of min. 2500cc
engine capacity Turbo charged diesel propelled
fully loaded as approved by the Engineer,
inclusive of the first 4000km per vehicle month.
V.mth. 18
1.13E.O Item 1.11 for mileages over 4000km per
vehicle month. Km 2,000
1.14
Allow Prime Cost (P.C.) sum of Kshs.
2,000,000 for the Resident Engineer's
Miscellaneous account to be spent in whole or
part as directed by the Resident Engineer
against receipts.
PC PC 2,000,000
1.15E.O. item 1.14 for the contractor's overheads
and profit.% 2,000,000
1.16Provide, erect and maintain publicity signs as
directed by the Engineer.No. 2
1.17Allow Prime Cost (P.C.) sum of Kshs 500,000
for relocation of services.PC Sum PC 500,000
1.18E.O. item 1.17 for the contractor's overheads
and profit.% 500,000
1.19
Allow a prime cost (P.C) sum of Kshs
1,500,000 for the R.E attendance upon his staff
including overtime in accordance with clause
137 of special specification.
PC PC 1,500,000
1.20E.O. item 1.19 for the contractor's overheads
and profit.% 1,500,000
1.21
Allow for Prime Cost (P.C) Sum of KShs.
200,000 for Resident Engineer and staff mobile
phone airtime.
PC Sum PC 200,000
1.22E.O. item 1.21 for the contractor's overheads
and profit.% 200,000
Total of Bill carried forward to summary
81
ITEM DESCRIPTION UNIT QUANTITY RATE AMOUNT
4.01
Clear site on road reserve including removal
of trees, hedges, bushes and other
vegetation or deleterious organic material,
grub up roots in accordance with clause 401
and 404 of the specification.
Ha 2
4.02
Strip topsoil 200mm deep or as may be
directed by the Engineer and in accordance
with cl. 402 & 404 of the specs.m
3 1,500
4.03
Allow a Prime Cost (P.C) sum of
KShs.500,000 for the removal of structures
including bridges on the road reserve in
accordance with cl. 403 of the specifications.
Measurement to be done on Dayworks basis
PC 1 500,000
Total of Bill carried forward to summary
BILL NO. 4 : SITE CLEARANCE AND TOPSOIL STRIPPING
82
ITEM DESCRIPTION UNIT QUANTITY RATE AMOUNT
No separate payment shall be made for the overhaul
of material and the cost of such haulage shall be
included in the rates and/or prices inserted
CW+WW=
5.01
Fill in soft material to 95% MDD (AASHTO T99) in
layers of 150mm each in accordance with Cl. 502,
504, 505, 508, 511, 512, & 513 of the specs.
m3 960
5.02
Cut to spoil in soft material in accordance with Cl. 502,
504, 510, 511, & 513 of the specs. Includes
excavations in swampy areas.
m3 1,125
5.03 As item 5.02 but in hard materials. m3 1,125
5.04
Provide, transport, spread and compact to at least
100% MDD AASHTO T99 improved subgrade
materials as instructed by the Engineer.m
3 -
5.05
Compaction of 150mm thick original ground under fills
to 95% MDD.(AASHTO T99) in accordance with Cl.
502, 504, 508, & 512 of the specs.
m3 -
5.06
Compaction of 300mm below formation level in cutting
to 100% MDD (AASHTO T99) in accordance with Cl.
502, 503, 504, 508, 510, 511, 512 & 513 of the specs..m
3 -
5.07
Extra over item 5.01 for compaction of top 300mm
below formation level (subgrade) to 100% MDD.
(AASHTO T99)
m3 -
5.08Provide, place and compact rockfill as directed by the
Engineer, Cl. 507 of the specs.m
3 100
5.09
Provide, transport and install geotextile filter fabric
(280 g/m2) to under, over or around rockfill as per
clause 506 & 507 of standard specifications or as
directed by the Engineer
m2 200
Total of Bill carried forward to summary
BILL NO. 5 : EARTHWORKS
83
ITEM DESCRIPTION UNIT QUANTITY RATE AMOUNT
These work items covers all excavations and filling
operations to bridges, box culverts, retaining walls and
other major structures.
7.01
Excavate for structures in soft material, backfill with suitable
material, spoil surplus/unsuitable material and keep the
excavation free of water in compliance with cl. 702, 703,
704, 705, 706, 707 and 708 of the specifications.
m3 100
7.02
Carry out river training works in soft material as directed by
the Engineer in compliance with Cl. 702, 704, 708, & 709 of
specs.
m3 10
7.03 As item 7.01 & 7.02 for excavation but in hard materials. m3 10
7.04Provide selected granular material for backfill around
structuresm
3 20
7.06
Excavate and backfill for gabions in soft material and
compact the excavation to receive the gabion boxes and/or
spoil the excavated material as directed by the Engineer
m3 10
7.07 Extra over Item 7.06 for excavation in hard material m3 10
7.08
Provide and place macafferri or equivalent 2x1x1 m gabions
or matresses as shown on the drawings, as directed by the
Engineer or as per clause 711 of the standard
specifications.
m2 100
7.09Provide and place rock fill to gabion boxes as per clause
711 of the standard specifications.m
3 100
7.10Provide and place filter fabric (280g/m
2) under and/or
behind gabions as per clause 711 of standard specifications
or as directed by the Engineer.
m3 100
Total of Bill carried forward to summary
BILL NO. 7: EXCAVATION AND FILLING FOR STRUCTURES
84
ITEM DESCRIPTION UNIT QUANTITY RATE AMOUNT
CW+WW=
Note: No separate payments shall be made for gravel for
blinding or hauling to spoil unsuitable excavation materials
and the cost of such shall be included in the rates and
prices.
8.01 Excavate in soft material for culverts & subsoil drains
including concrete pipe culverts headwalls, wingwalls,
apron, toe walls, drop inlets, and compact as specified or
as directed by the Engineer.
m3 1,000
8.02 Excavate for inlet, outfall, mitre in soft material as specified
or as directed by the Engineer.m
3 1,000
8.06 Provide, lay and joint 900mm I.D precast concrete pipes
culverts
m 200
8.07 As for item 8.07 but 1200mm I.D m 151
8.09 Provide, place and compact class 15/20 concrete to beds,
sorrounds and haunches as shown in the drawings or as
directed by the Engineer including formwork.
m3 151
8.10 Provide and place class 20/20 concrete to head walls,
wingwalls, aprons, toe walls, inlets and outlets to pipe
culverts including formwork.
m3 50
8.11 Excavate, remove and dispose existing pipe culverts
including demolition of inlet and outlet structures as
directed by the Engineer.
m 10
8.12 Provide and place 300mm half Round m 10
Total Carried forward to summary page
BILL NO. 8 : CULVERTS AND DRAINAGE WORKS
85
ITEM DESCRIPTION UNIT QUANTITY RATE AMOUNT
9.01
Allow for the passage of traffic through the works
in compliance with cl. 906, 907, 908, 909, 911 of
the specifications
LS 1
Total of Bill carried forward to summary
BILL NO. 9 : PASSAGE OF TRAFFIC
86
ITEM DESCRIPTION UNIT QUANTITY RATE AMOUNT
17.01 Structural Concrete
Providing, hauling all materials, preparation,
handling, mixing, placing compacting and
curing.
a) Concrete Class 30/20 m³ 75
b) Concrete Class 25/20 m³ 300
17.02 Blinding Concrete
Providing, hauling all materials, preparation,
handling, mixing, placing, compacting to class
UF1 finishing and curing.
a) Concrete Class 15/20 m³ 30
17.03 Formwork for formed surface finishes
Supply, erect and dismantle formwork for
concrete of the following classes. The rates
shall cover inclined formwork of all slopes,
radii, and angles.
a) Class F1 finish - vertical m² 50
b) Class F1 finish - Sloping m² 40
c) Class F3 finish - horizontal m² 30
d) Class F3 finish - vertical m² 10
e) Class F3 finish - sloping m² 10
17.04Ditto but for formwork less than 300m high to
edges of slabs m 100
17.05 Reinforcement
Providing, cutting, shaping and placing high
yield, high bond strength bars.
a) Diameter equal or less than 16 mm. tonnes 5
b) Diameter greater than 16 mm. tonnes 5
c) A252.3 BRC mesh to BS4483 m² 100
Total of Bill carried forward to summary
BILL NO. 17: CONCRETE WORKS
87
ITEM DESCRIPTION UNIT QUANTITY RATE AMOUNT
20.01Provide and erect standard warning type signs
750mm sizeNo. 1
CW+WW=
20.02Provide and erect standard informatory signs 400 x
300 mmNo. 1
20.03 Provide and erect Non-Standard
Informatory signs:
(a) Less than 1 m2 No. 1
(b) 1 - 2 m2 area No. 1
(c ) 2 - 5 m2 area No. 1
20.04 Provide standard mandatory signs 600mm diameter No. 1
20.05 As item 20.04 but 1000 mm STOP sign No. 1
20.06
Paint 0.1 m wide yellow centerline on the road using
hot applied internally reflectorised thermoplastic
material
m2 50
20.07As item 20.06 but 0.1 m wide white lines on the road
edge m
2 20
20.08As item 20.06 but 0.2 m wide (Bus-bay Separation
marking)m
2 20
20.10 As item 20.06 but 0.5 m wide for pedestrian crossing m2 20
20.11Provide, lay and joint raised kerbs as per Cl. 2007 of
standard specifications.
(a) - straight 125X250mm size kerbs m 10
(b) radius 5m - 1m. m 10
(c) radius 12m - 6m. m 10
20.12
Provide and place precast concrete channel blocks to
footpaths, kerb gutter drain, busbays etc inclusive of
excavation, laying and jointing, concrete bedding and
haunching etc. as shown in the drawings.
m 200
Total Carried forward to next page
BILL NO. 20: ROAD FURNITURE
88
ITEM DESCRIPTION UNIT QUANTITY RATE AMOUNT
21.01 Waterproofing to Structures
Providing and placing bitumen emulsion or
cutback bitumen or bitumen/rubber latex emulsion
to all structural concrete in contact with fill material
or cut soil.
m² -
21.02 Bridge Bearings
Providing and installing PSC fressynet laminated
elastomeric bearings or similar approved as per
the drawings
a) Fixed type 406x356x35mm No -
b) Free type 406x356x35mm No -
21.03 Movement joints and sealants
Providing and installing 20mm compression joint
filler and sealant polystyrene or similar in areas of
expansion joints as shown in the drawings.
m² 100
21.04Pipe Handrail and Guardrail to Bridges and Box
Culverts
Providing and erecting handrail, guardrail, posts
and fittings as per clause 2006 of special
specifications and 2108(d) of standard
specifications
m 220
21.05 Weepholes
Provide and fix 75 mm diameter upvc pipes to
form weepholes in structure, include for filter
fabric at inlet
No -
21.06 Provide and fix 75 mm Dia drain pipe to deck slab No -
21.07 100mm diameter PVC service ducts on deck No. -
-
21.,08
300mm x 300mm Drain opening on the slab ,
covered with approved grated steel for surface
run-off drainage
No. 100
Total of Bill carried forward Summary
BILL NO. 21: MISCELLENEOUS BRIDGE WORKS
89
ITEM DESCRIPTION UNIT QUANTITY RATE AMOUNT
23.01
Supply, lay and compact 80mm thick precasr
concrete paving with blocks with 49N/mm2
cube strebgth conforming to BS 6717 part 1 of
1986 or Kenya beareau of standard equivalnt
including 50mm thick sand /quary dust
m2 350
CW+WW=
Total of Bill carried forward to summary
BILL NO. 23: CONCRETE PAVING BLOCKS
90
ITEM DESCRIPTION UNIT QUANTITY RATE AMOUNT
25.01 Instituting an HIV/AIDS awareness Campaign Month 3
25.02 Instituting an HIV/AIDS prevention Campaign Month 3
25.03 Allow PC sum of Five hundredNThousand kenya
Shllings (Ksh 500,000) for HIV/AIDS training
PC 1 500,000
25.04 Extra-over item 25.03 for contractor's overheads
and profits
% 500,000
Total of Bill carried forward Summary
BILL NO. 25 : HIV/AIDS AWARENESS AND EDUCATION
91
ITEM DESCRIPTION UNIT QNTY RATE (Ksh) AMOUNT (Ksh)
26.01 Cutting trees,excavate and uproot tree roots girth
exceeding 0.5m deep and cart awayNO 5
26.02 Excavate oversite average 300mm deep to remove top
soil and cart away m
2 800
26.03 150mm thick hardcore filling to level the surfaces
consolidated,watered and well rammed to receive
gabbro blocks at the access roads.
m2 800
26.04 75mm thick quarry murram filling to level the surfaces
consolidated,watered and well rammed to receive
gabbro blocks.
m2 800
26.05 50mm thick light duty lock blocks paving cabros blocks
with minimum strength of 45-50N/mm .m
2 775
26.06 Provide, spread and compact river sand m2 775
26.07 125×100×900 mm long precast concrete kerbs with
cement sand(1:2).LM 215
26.08 Guaranted strength concrete class 8-8mm
aggregate(1:2:4)inside of kerbs at an angle for supportm
2 30
26.09 prepare touch up primier and apply one undercoat and
two finishing coats first grade gloss Enamel paint on
metal surfaces.
LM 215
26.10 Provide and place open IBD as instructed by the
Engineer.LM 168
SOSIANI PARK
FENCING FOR PROTECTION
26.11 Excavate holes 200mm diameter average 500mm deep to remove soil away.NO. 115.00
26.12 install concrete pipes 150 mm diameter average 1m
long welded clamps at one endNO. 30.00
26.13 weld 50mm GI pipes across the 1m concrete poles
300mm apart to protect trespass of people to the flower
beds.
NO. 87.00
Sub-Total 1 Carried to collection page
BILL NO. 26: FRONTAGE IMROVEMENT
92
26.14 Provide concrete class 20-20mm
aggregate(1:2:4)sarround to make the GI pipes firm and
fill the hollow gap
m3 10.00
26.15 prepare touch up primer and apply one undercoat and
two finishing coats first grade gloss Enamel paint on
metal surfaces.
m2 200.00
OIL LIBYA PARK(ALONG KAGO STREET)
2M WIDE FOOTPATH
26.16 Excavate oversite average 450mm deep to remove top
soil and cart awaym
2 2,040.00
26.17 300mm thick approved handpacked hardcore filling
spread,levelled well rammed and consolidated in
150mm layers to receive concrete surface bed(MS)
m2 210.00
26.18 75mm thick quarry murram filling to level the surfaces
consolidated,watered and well rammed to receive
Cabro blocks.
m2 210.00
26.19 50mm thick lihgt duty lock blocks paving cabros blocks
with minimum strength of 45-50N/mmm
2 210.00
26.20 125×100×900 mm long precast concrete kerbs with
sand.LM 250.00
26.21
Guaranted strength concrete class 8-8mm
aggregate(1:2:4)inside of kerbs at an angle for support
m2 35.00
26.22 prepare touch up primier and apply one undercoat and
two finishing coats first grade gloss Enamel paint on
metal surfaces.
LM 250.00
FENCING FOR PROTECTION
26.23 Excavate holes 200mm diameter average 500mm deep to remove soil away.NO. 100.00
26.24 Install concrete pipes 150 mm diameter average 1m
long welded cramps at one endNO. 26.00
26.25 weld 50mm GI pipes across the 1m concrete poles
500mm apart to protect trace pass of people to the
flower beds.
NO. 60.00
26.26 Provide concrete class 20-20mm
aggregate(1:2:4)sarround to make the GI pipes firm and
fill the hollow gap
m3 8.00
Sub-Total 2 Carried to collection page
93
26.27 prepare touch up primier and apply one undercoat and
two finishing coats first grade gloss Enamel paint on
metal surfaces.
m2 80.00
PLANTS
Grass-springs
26.28 supply,store in approved condition grass springs at
50mm centres both ways.SUM 1.00
Chinese-Cyprus
26.29 supply,store in approved condition chinese cyprus. NO. 400
26.30 Dig planting holes of 800 x 800 x 800mm,mix manure
with red soil and plant hibsicus 5m apart from the
chinese cyprus while compacting root base and protect
the plant appropriately.
NO. 400
Hibsicus flowers
26.31 supply,store in approved condition hibsicus flowers. NO. 350
26.32 Dig planting holes of 800 x 800 x 800mm,mix manure
with red soil and plant hibsicus 5m apart from the
chinese cyprus while compacting root base and protect
the plant appropriately.
NO. 350
SUPPLY AND DELIVER MANURE
26.33 Provide well dried farmyard manure for planting/soil
enrichment for lawn areasTONS 13
MAINTENANCE FOR 6 MONTHS
26.34 watering grassed and flower areas
weeding of grassed and flowered ares as necessitated
mowing of grassed areas twice a month
pest and disease control
maintenance Mths 6
26.35 supply a bush cutter NO. 2
26.36 supply mechanized lawn mower NO. 2
FLOWER BED PROTECTION ALONG A104 FROM
LIBRAY TO ITEN ROAD
26.37 Excavate oversite average 250mm deep to remove top
soil and cart awaym
2 2200
26.38 Excavate and uproot tree roots girth exceeding 1.5m
deep and cart awaym
3 40
Sub-Total 3 Carried to collection page
94
26.39 150mm thick quary murram filling to level the surfaces
consoldated,watered and well rammed put in two layers
of 50mm thick to receive concrete
m2 2200
26.40 Excavate holes 150mm diameter average 250mm deep to remove soil away.m3 12
26.41 install GI pipes 100 mm diameter average 700mm long
welded cramps at one end at a distance of 2m apartNO. 65
26.42 Provide concrete class 20/20mm
aggregate(1:2:4)sarround to make the GI pipes firm and
fill the hollow gap
m3 8
26.43 Provide all the materials, mix place and compact
concrete class 25/20 as 300mm thick slab along the
flower bed
m3 160
26.44 weld 50mm GI pipes across the 700mn concrete poles
200mm apart to protect trace pass of people to the
flower beds.
NO. 180
26.45 prepare touch up primier and apply one undercoat and
two finishing coats first grade gloss Enamel paint on GI
surfaces.
m2 70
4M WIDE FOOTPATH
26.46 Excavate oversite average 450mm deep to remove top
soil and cart awaym
2 2000
26.47 200mm thick approved handpacked hardcore filling
spread,levelled well rammed and consolidated in
150mm layers to receive concrete surface bed(MS)
m2 1600
26.48 75mm thick quarry murram filling to level the surfaces
consolidated,watered and well rammed to receive
Cabro blocks.
m2 1600
26.49 50mm thick light duty lock blocks paving blocks with
minimum strength of 45 N/mm2m
2 1600
Provide , spread and compact river sand m2 1600
125×100×900 mm long precast concrete kerbs with
sand.LM 800
26.50 Provide concrete class 15/20 for haunching and lateral
supports for PCC kerbs and channelsm3 60
Sub-Total 4 Carried to collection page
95
26.51 Prepare touch up primier and apply one undercoat and
two finishing coats first grade gloss Enamel paint on
metal surfaces.
LM 800
CONCRETE BENCHES
26.52 Provision and installation of concrete benches, all in
accordance with the specifications and Engineer's
instructions.
NO. 20
MONUMENTS AND WATER FOUNTAIN
26.53 provision and erection of 1 monument and a fountain,all
in accordance with the specifications and Engineer's
instructions.
PC
SUM1 5,000,000.00
Sub-Total 5 Carried to collection page
Total of Bill carried forward Summary (Sub Total1+
Sub Tota 2+ Sub Total 3+ Sub TotaL 4 + Sub Total 5)
96
ITEM DESCRIPTION UNIT QNTY RATE (Ksh) AMOUNT (Ksh)
27.01 Procure, supply and fix in place galvanised
root mounted, continious taper, polygonal
cross-section steel columns, to meet 30m
mounting height requirements with Luninarie
carriage assembly for 9 No. 400W LED
floodlights, pulleys, ancharing bolts and the
lowering steel ropes. The Contractor to submit
all shop drawings to the engineer for
APPROVAL before commencement of works No. 3
27.02 Electrical Winch for lowring and raising the
luminaire carriage assembly as described in
the specifications No 3
27.03 Allow for painting of the mast with reflective
red/white paint to meet the requirement of the
Kenya Aviation Authority and Energy
Regulation Commission ITEM 3
27.04 Supply and install 30m copper plate for the
lighting arestor as on the drawing to the
Electrical Engineer Approval m 90
27.05 Supply and install lighting arrestor spikes
complete with the base No 3
27.06 Allow for installation of 200W obstuctive
aircraft warning lights (avation lights) with
flashing as Thorn or equivalent with catalogue
number TBANo 12
27.07 ROADS CROSSING:
27.08 Microtunneling for cables in Bituminous
pavement for cabling. Size 100mm diameter LM 20
27.09 Ditto gravel roads LM 20
27.1 Clear site including removal of hedges,
bushes, trees (except those designed to
remain by the Engineer) and other vegetation
and objectionable materials as prescribed in
the Specifications. SM 450
27.11 Remove top soil to a depth of 200mm and in
locations directed by the Engineer CM 10
27.12 Excavate pit size 2.4x2.4x2.4m deep (internal
dimensions) for the foundations on site , back
fill and spread surplus on site, including all
works for side protection and for keeping site
far fromwater, mud and fallen materials CM 42
27.13 Provide hardcore in areas where stable
ground is far CM 3
27.14 50mm thick base slab as blinding layer CM 2
27.15 Provide formwork class F2 SM 70
27.16 Vibrated concrete grade 20/20 in:
2400mmx2400mmx2400m deep footing CM 42
Reinforcement high yield mild steel bars to BS
4449
27.17 Y12 KGS 735
27.18 Y10 KGS 250
Total of Bill carried forward Summary
BILL NO. 27: HIGH MASTS
97
SECTION VIII – STANDARD FORMS
LIST OF STANDARD FORMS
(i) Form of Invitation for Tenders (ii) Form of Tender (iii) Appendix to Form of Tender (iv) Letter of Acceptance (v) Form of Agreement (vi) Form of Tender Security (vii) Performance Bank
(viii) Bank Guarantee for Advance Payment (ix) Tender Questionnaire (xi) Confidential Business Questionnaire
(x) Statement of Foreign Currency Requirement
(xi) Schedule of Materials;- Basic Prices (xii) Schedule of Labour;- Basic Prices (xiii) Schedule of Plant and Equipment (xv) Details of Sub-Contractors (xvi) Certificate of Tenderer’s Site visit (xvii) Form of Written Power of Attorney (xviii) Key Personnel (xix) Completed Civil Works (xx) Schedule of Ongoing Projects (xxi) Other Supplementary Information (xxii) Declaration Form (xxiii) Request for Review
98
FORM OF INVITATION FOR TENDERS
_______________________[date]
To: _____________________________________ [name of Contractor]
_____________________________________[address] _____________________________________
_____________________________________
Dear Sirs:
Reference:______________________________________________[Contract Name]
You have been prequalified to tender for the above project.
We hereby invite you and other prequalified tenderers to submit a tender for the execution and completion of the above Contract.
A complete set of tender documents may be purchased by you from ____
________________________________________________________________________ [mailing address, cable/telex/facsimile numbers].
Upon payment of a non-refundable fee of Kshs __________________________
All tenders must be accompanied by ________________number of copies of the same and a security in the form and amount specified in the tendering documents, and must be delivered to
________________________________________________________________________ [address and location]
at or before _______________________(time and date). Tenders will be opened immediately thereafter, in the presence of tenderers’ representatives who choose to attend.
Please confirm receipt of this letter immediately in writing by cable/facsimile or telex.
Yours faithfully,
_____________________________________ Authorised Signature
_____________________________________ Name and Title
99
FORM OF TENDER
TO: __________________________[Name of Employer) ____________[Date]
__________________________[Name of Contract]
Dear Sir,
1. In accordance with the Conditions of Contract, Specifications, Drawings and Bills of Quantities for the execution of the above named Works, we, the undersigned offer to construct, install and complete such Works and remedyanydefectsthereinforthesumof Kshs._____________________________[Amount in figures]Kenya Shillings__________________________________________________________________ _________________________[Amount in words]
2. We undertake, if our tender is accepted, to commence the Works as soon as is reasonably possible after the receipt of the Project Manager’s notice to commence, and to complete the whole of the Works comprised in the Contract within the time stated in the Appendix to Conditions of Contract.
3. We agree to abide by this tender until ___________________[Insert date], and it
shall remain binding upon us and may be accepted at any time before that date.
4. Unless and until a formal Agreement is prepared and executed this tender
together with your written acceptance thereof, shall constitute a binding Contract between us.
5. We understand that you are not bound to accept the lowest or any tender you
may receive.
Dated this ____________________ day of _______20________________
Signature __________________in the capacity of___________________
duly authorized to sign tenders for and on behalf of
_____________________________________________[Name of Employer] of___________________________________________[Address of Employer]
Witness; Name______________________________________
Address_____________________________________
Signature___________________________________
Date_______________________________________
100
APPENDIX TO FORM OF TENDER
CONDITIONS OF CONTRACT CLAUSE AMOUNT Bid Security Kshs. 1,500,000.00 from PPRA authorized
institutions valid for 150days for the date of opening.
Instructions in Writing 2.5 Execution of works under site instructions from Resident Engineer to commence within three (3) days
Amount of Performance Security (Unconditional Bank Guarantee)
10.1
5 per cent of Tender Sum in the form of Unconditional Bank Guarantee to be submitted prior to signing of the contract.
Program to be submitted 14.1 Immediately after issuance of Order to Commence Cash flow estimate to be submitted 14.3 Immediately after issuance of Order to Commence Minimum amount of Third Party Insurance 23.2
1% of the Contract Sum
Period for commencement, from Engineer’s order to commence
41.1 14 days
Time for completion
43.1 (60) Sixty weeks
Amount of liquidated damages
47.1 0.05% of Contract Sum per day
Limit of liquidated damages 47.1 5% of Contract Sum
Defects Liability period
49.1 (24) Twenty four weeks
Percentage of Retention
60.3 10% of Interim Payment Certificate
Limit of Retention Money 60.3 10% of Contract Sum Minimum amount of interim certificates 60.2 Ksh. 5,000,000.00 per month. Time within which payment to be made after Interim Payment Certificate signed by Engineer
60.10 30days
Time within which payment to be made after Final Payment Certificate signed by Engineer
60.10 30 days
Appointer of Adjudicator
67.3 The Chartered Institute of Arbitrators (Kenya)
Notice to Employer and Engineer 68.2 The Employers address is:
The County Secretary, County Government of Uasin Gishu, P.O. Box 40 - 30100 ELDORET The Project Manager’s address is: The Chief Officer – Physical Planning and Urban Development
County Government of Uasin Gishu, P.O. Box 40 - 30100
ELDORET
Signature of Tenderer…………………………………….……. Date ………………………
101
LETTER OF ACCEPTANCE
[letterhead paper of the Employer]
_______________________[date]
To: _______________________ [name of the Contractor]
_____________________ [address of the Contractor]
Dear Sir,
This is to notify you that your Tender dated ___________________________
for the execution of ________________________________________________ [name of the Contract and identification number, as given in the Tender documents] for the Contract Price of Kshs. __________________________ [amount in figures][Kenya Shillings______________________________(amount in words) ] in accordance with the Instructions to Tenderers is hereby accepted.
You are hereby instructed to proceed with the execution of the said Works in accordance with the Contract documents.
Authorized Signature …………………………………………………………………
Name and Title of Signatory …………………………………………………………
Attachment : Agreement
102
FORM OF AGREEMENT
THIS AGREEMENT, made the _________________ day of ________ 20 ______ between________________________________________________of[or whose registered office is situated at]__________________________________________ (hereinafter called “the Employer”) of the one part AND
________________________________________________________of[or whose registered office is situated at]_________________________________________ (hereinafter called “the Contractor”) of the other part.
WHEREAS THE Employer is desirous that the Contractor executes ________________________________________________________________________
(name and identification number of Contract ) (hereinafter called “the Works”) located at______________________________[Place/location of the Works]and the Employer has accepted the tender submitted by the Contractor for the execution and completion of such Works and the remedying of any defects therein for the Contract Price of Kshs___________________________[Amount in figures],Kenya Shillings_____________________________________________[Amount in words].
NOW THIS AGREEMENT WITNESSETH as follows:
1. In this Agreement, words and expressions shall have the same meanings as are respectively assigned to them in the Conditions of Contract hereinafter referred to.
2. The following documents shall be deemed to form and shall be read and
construed as part of this Agreement i.e.
(i) Letter of Acceptance
(ii) Form of Tender
(iii) Conditions of Contract Part I
(iv) Conditions of Contract Part II and Appendix to Conditions of Contract
(v) Specifications
(vi) Drawings
(vii) Priced Bills of Quantities
3. In consideration of the payments to be made by the Employer to
the Contractor as hereinafter mentioned, the Contractor hereby
covenants with the Employer to execute and complete the Works and remedy any defects therein in conformity in all respects with the provisions of the Contract.
4. The Employer hereby covenants to pay the Contractor in
103
consideration of the execution and completion of the Works and the remedying of defects therein, the Contract Price or such other sum as may become payable under the provisions of the Contract at the times and in the manner prescribed by the Contract.
IN WITNESS whereof the parties thereto have caused this Agreement to be executed the day and year first before written.
The common Seal of _________________________________________________
Was hereunto affixed in the presence of ________________________________
Signed Sealed, and Delivered by the said ______________________________
Binding Signature of Employer ________________________________________
Binding Signature of Contractor _______________________________________
In the presence of (i) Name_______________________________________
Address_____________________________________
Signature___________________________________
[ii] Name _______________________________________
Address_____________________________________
Signature____________________________________
104
FORM OF TENDER SECURITY
WHEREAS ………………………………………..(hereinafter called “the Tenderer”) has submitted his tender dated ………………………… for the construction of
……………………………………………………………………… …………………… (name of Contract)
KNOW ALL PEOPLE by these presents that WE ……………………… having our registered office at ………………(hereinafter called “the Bank”), are bound unto
……………………………(hereinafter called “the Employer”) in the sum of
Kshs.……………………… for which payment well and truly to be made to the said Employer, the Bank binds itself, its successors and assigns by these presents sealed with the Common Seal of the said Bank this ……………. Day of
………20…………
THE CONDITIONS of this obligation are:
1. If after tender opening the tenderer withdraws his tender during the period of tender validity specified in the instructions to tenderers Or
2. If the tenderer, having been notified of the acceptance of his tender by the
Employer during the period of tender validity:
(a) fails or refuses to execute the form of Agreement in accordance with
the Instructions to Tenderers, if required; or (b) fails or refuses to furnish the Performance Security, in accordance
with the Instructions to Tenderers; (c) Rejects a correction or an arithmetic error in the tender.
We undertake to pay to the Employer up to the above amount upon receipt of his first written demand, without the Employer having to substantiate his demand, provided that in his demand the Employer will note that the amount claimed by him is due to him, owing to the occurrence of one or both of the two conditions, specifying the occurred condition or conditions.
This guarantee will remain in force up to and including thirty (30) days after the period of tender validity, and any demand in respect thereof should reach the Bank not later than the said date.
___________________________ ______________________________ [date[ [signature of the Bank]
___________________________ [witness]
______________________________ [seal]
105
(Amend accordingly if provided by the Insurance Company)
106
PERFORMANCE BANK GUARANTEE (UNCONDITIONAL)
To: _________________________(Name of Employer) ___________(Date) __________________________(Address of Employer)
Dear Sir,
WHEREAS ______________________(hereinafter called “the Contractor”) has undertaken, in pursuance of Contract No. _____________ dated _________ to execute _______________ (hereinafter called “the Works”);
AND WHEREAS it has been stipulated by you in the said Contract that the Contractor shall furnish you with a Bank Guarantee by a recognised bank for the sum specified therein as security for compliance with his obligations in accordance with the Contract;
AND WHEREAS we have agreed to give the Contractor such a Bank Guarantee:
NOW THEREFORE we hereby affirm that we are the Guarantor and responsible to you, on behalf of the Contractor, up to a total of Kshs. ________________ (amount of Guarantee in figures) Kenya Shillings__________________________________________ (amount of Guarantee in words), and we undertake to pay you, upon your first written demand and without cavil or argument, any sum or sums within the limits of Kenya Shillings _________________________ (amount of Guarantee in words) as aforesaid without your needing to prove or to show grounds or reasons for your demand for the sum specified therein.
We hereby waive the necessity of your demanding the said debt from the Contractor before presenting us with the demand.
We further agree that no change, addition or other modification of the terms of the Contract or of the Works to be performed there under or of any of the Contract documents which may be made between you and the Contractor shall in any way release us from any liability under this Guarantee, and we hereby waive notice of any change, addition, or modification.
This guarantee shall be valid until the date of issue of the Certificate of Completion.
SIGNATURE AND SEAL OF THE GUARANTOR ___________________
Name of Bank ____________________________________________
Address ________________________________________________
Date ______________________________________________________
(Amend accordingly if provided by Insurance Company)
107
BANK GUARANTEE FOR ADVANCE PAYMENT
To: ________________________ [name of Employer] ___________(Date) ________________________[address of Employer]
Gentlemen,
Ref: _______________________________________________[name of Contract]
In accordance with the provisions of the Conditions of Contract of the above-mentioned Contract, We,_______________________________________[name and Address of Contractor] (hereinafter called “the Contractor”) shall deposit with _______________________________[name of Employer] a bank guarantee to guarantee his proper and faithful performance under the said Contract in an amount of Kshs._____________[amount of Guarantee in figurers] Kenya Shillings_____________________________________[amount of Guarantee in words].
We, ________________[bank or financial institution], as instructed by the Contractor, agree unconditionally and irrevocably to guarantee as primary obligator and not as Surety merely, the payment to ___________________________[name of Employer] on his first demand without whatsoever right of objection on our part and without his first claim to the Contractor, in the amount not exceeding Kshs________________________[amount of Guarantee in figures] Kenya Shillings
_____________________________________________________________[amount of
Guarantee in words], such amount to be reduced periodically by the amounts recovered by you from the proceeds of the Contract.
We further agree that no change or addition to or other modification of the terms of the Contract or of the Works to be performed there under or of any of the Contract documents which may be made between ________________________[name of Employer] and the Contractor, shall in any way release us from any liability under this guarantee, and we hereby waive notice of any such change, addition or modification.
No drawing may be made by you under this guarantee until we have received notice in writing from you that an advance payment of the amount listed above has been paid to the Contractor pursuant to the Contract.
This guarantee shall remain valid and in full effect from the date of the advance payment under the Contract until ______________________________________________(name of Employer) receives full payment of the same amount from the Contract.
Yours faithfully,
Signature and Seal __________________________________________________
108
Name of the Bank or financial institution ______________________________
Address ______________________________________________________________
Date _________________________________________________________________
Witness: Name: ____________________________________________________
Address: __________________________________________________
Signature: ________________________________________________
Date: _____________________________________________________
31. TENDER
QUESTIONNAIRE
Please fill in block
letters.
1. Full names of tenderer
………………………………………………………………………………………
2. Full address of tenderer to which tender correspondence is to be
sent (unless an agent has been appointed below)
……………………………………………………………………………………… 3. Telephone number (s) of tenderer
………………………………………………………………………………………
4. Telex address of tenderer
………………………………………………………………………………………
5. Name of tenderer’s representative to be contacted on matters of the
tender during the tender period
………………………………………………………………………………………
6. Details of tenderer’s nominated agent (if any) to receive tender notices.
This is essential if the tenderer does not have his registered address in Kenya (name, address, telephone, telex)
………………………………………………………………………………………
109
Signature of Tenderer
Make copy and deliver to :_____________________( Name of Employer)
110
CONFIDENTIAL BUSINESS QUESTIONNAIRE
You are requested to give the particulars indicated in Part 1 and either Part 2 (a), 2 (b) or 2 (c) and 2 (d) whichever applies to your type of business.
You are advised that it is a serious offence to give false information on this
Form. Part 1 – General
Business Name ………………………………………………………………………
Location of business premises; Country/Town……………………….
Plot No……………………………………… Street/Road …………………………
Postal Address……………………………… Tel No………………………………..
Nature of Business…………………………………………………………………..
Current Trade Licence No…………………… Expiring date…………………
Maximum value of business which you can handle at any time: K. pound………………………..
Name of your bankers………………………………………………………………
Branch…………………………………………………………………………………
Part 2 (a) – Sole Proprietor
Your name in full…………………………………… Age…………………………
Nationality………………………………… Country of Origin…………………
*Citizenship details …………………………………………………………………
Part 2 (b) – Partnership
Give details of partners as follows:
Name in full Nationality Citizenship Details Shares
1…………………………………………………………………………………… 2……………………………………………………………………………………
3……………………………………………………………………………………
Part 2(c) – Registered Company:
Private or public……………………………………………………………
State the nominal and issued capital of the Company-
111
Nominal Kshs…………………………………………………………………
Issued Kshs……………………………………………………………………
Give details of all directors as follows:
Name in full . Nationality. Citizenship Details*. Shares.
1.
……………………………………………………………………………………… 2. ………………………………………………………………………………………
3. ……………………………………………………………………………………… 4. ………………………………………………………………………………………
Part 2(d) – Interest in the Firm:
Is there any person / persons in …………… ………(Name of Employer) who
has interest in this firm? Yes/No………………………(Delete as necessary)
I certify that the information given above is correct.
……………………… (Title)
……………………… (Signature)
…………………
(Date)
112
* Attach proof of citizenship
113
STATEMENT OF FOREIGN CURRENCY REQUIREMENTS
(See Clause 60[5] of the Conditions of Contract)
In the event of our Tender for the execution of____________________
__________________________(name of Contract) being accepted, we would require in accordance with Clause 21 of the Conditions of Contract, which is attached hereto, the following percentage:
(Figures)………………………… (Words)…………………………………
of the Contract Sum, (Less Fluctuations) to be paid in foreign currency.
Currency in which foreign exchange element is required:
………………………………………………………………………………… ……
Date: The ………… Day of …………….. 20…………….
Enter 0% (zero percent) if no payment will be made in foreign currency.
Maximum foreign currency requirement shall be _____________(percent) of the Contract Sum, less Fluctuations.
________________________________ (Signature of Tenderer)
114
SCHEDULE OF MATERIALS;-BASIC PRICES
(Ref: Clause 70 of Conditions of Contract)
TRANSPORT
MATERIAL UNIT ORIGIN AND PRICE ATION COST
FROM SOURCE
OF ORIGIN
COUNTRY OF ORIGIN SUPPLIER PRICE MODE PRICE
(KSHS)
Cement Mg
Lime Mg
Sand Mg
Aggregate Mg
Diesel L
Regular Petrol L
Super Petrol L
Kerosene L
Structural steel Mg
Gabion Mesh M2
Reinforcement
Steel Mg
Explosives Kg
Oil and
Lubricants L
Bitumen
Emulsion A3 L
Bitumen
Emulsion A4 L
Bitumen
Emulsion K1 L
Bitumen
Emulsion K3 L
Bitumen 80/100 Kg
Bitumen MC 30 ML
Bitumen MC 70 L
Bitumen MC 3000 L
Ammonium
nitrate for blasting Kg
I certify that the above information is correct.
…………………………… ………………………… ……………………
(Title) (Signature) (Date)
The prices inserted above shall be those prevailing 30 days before the submission of Tenders and shall be quoted in Kenya Shillings using the exchange rates
78
115
Issued by the Public Procurement Oversight Authority in January, 2007
116
specified in the Appendix to Form of Tender.
Prices of imported materials to be quoted CIF Mombasa or Nairobi as appropriate depending on whether materials are imported by the tenderer directly or through a local agent.
Transportation costs for imported materials to be quoted from Mombasa or Nairobi as appropriate to _______________ (Contract Site) depending on whether materials are imported directly by the tenderer or through a local agent.
117
SCHEDULE OF LABOUR:- BASIC RATES (Reference: Clause 70 of Conditions of Contract)
LABOUR UNIT RATES
CATEGORY (MONTH/SHIFT/HOUR)
Categories to be generally in accordance with those used by the Kenya Building Construction and Engineering and Allied Trades Workers’ Union.
118
DETAILS OF SUB-CONTRACTORS
If the Tenderer wishes to sublet any portions of the Works under any heading, he must give below details of the sub-contractors he intends to employ for each portion.
Failure to comply with this requirement may invalidate the tender.
(1) Portion of Works to be sublet: ………………………………
[i) Full name of Sub-contractor and address of head office: ………………………………
………………………………
(ii) Sub-contractor’s experience of similar works carried out in the last 3 years with Contract value:
………………………………
………………………………
………………………………
(2) Portion of Works to sublet:
………………………………
(i) Full name of sub-contractor and address of head office:
………………………………
………………………………
………………………………
(ii) Sub-contractor’s experience of similar works carried out
in the last 3 years with contract value:
……………………………
……………………………
____________________ [Signature of Tenderer)
_______________________ Date
119
CERTIFICATE OF TENDERER’S VISIT TO SITE
This is to certify that
[Name/s]……………………………………………………………………
…………………………………………………………………………………
Being the authorized representative/Agent of [Name of Tenderer]
……………………………………………………………………………………
……………………………………………………………………………………
participated in the organized inspection visit of the site of the works for the (Name of Contract: ……………………………………………………………)
……………………………………… day of………………………20……………
Signed……………………………………………………………………………… (Employer’s Representative)
………………………………………………………………………………………
NOTE: This form is to be completed whether the site visit is made at the time of the organized site or privately organized.
120
FORM OF WRITTEN POWER-OF-ATTORNEY
The Tenderer consisting of a joint venture shall state here below the name and address of his representative who is authorised to receive on his behalf correspondence in connection with the Tender.
……………………………………………………………… (Name of Tenderer’s Representative in block letters)
……………………………………………………………… (Address of Tenderer’s Representative)
………………………………………………………………
(Signature of Tenderer’s Representative)
121
KEY PERSONNEL
DESIGNATION NAME NATIONALITY SUMMARY OF QUALIFICATIONS AND EXPERIENCE
Headquarters:
1. Director
2.
3.
4.
5.
etc.
Site Office:
1. Site
Superintendent
2.
3.
4.
5.
etc.
I certify that the above information is correct.
………………………… (Title)
…………………… (Signature)
……………….. (Date)
122
SCHEDULE OF COMPLETED CIVIL WORKS CARRIED OUT BY THE TENDERER IN THE LAST EIGHT YEARS
DESCRIPTION TOTAL VALUE CONTRACT YEAR COMPLETED
OF WORKS AND OF WORKS PERIOD
CLIENT (KSHS) (YEARS)
I certify that the above Civil Works were successfully carried out and completed by ourselves.
………………………… (Title)
………………………… (Signature)
……………… (Date)
123
*Value in Kshs using Central Bank of Kenya mean exchange rate at a reference date 30 days before date of tender opening.
SCHEDULE OF ONGOING PROJECTS
DESCRIPTION CONTRACT DATE OF DATE OF TOTAL PERCENTAGE
OF WORK PERIOD COMMEN- COMPLETION VALUE OF COMPLETED
AND CLIENT CEMENT WORKS TO DATE (KSHS.)
I certify that the above Civil Works are being carried out by ourselves and that the above information is correct.
…………………… (Title)
……………………
(Signature)
……………………
(Date)
124
OTHER SUPPLEMENTARY INFORMATION
1. Financial reports for the last five years, balance sheets, profit and loss statements, auditors’ reports etc. List them below and attach copies. ……………………………………………………………………… ………………………………………………………………………
………………………………………………………………………
2. Evidence of access to financial resources to meet the qualification
requirements. Cash in hand, lines of credit etc. List below and attach copies of supporting documents ……………………………………………………………………… ………………………………………………………………………
………………………………………………………………………
3. Name, address , telephone, telex, fax numbers of the Tenderer’s
Bankers who may provide reference if contacted by the Employer. …………………………………………………………………………
………………………………………………………………………… …………………………………………………………………………
4. Information on current litigation in which the Tenderer is involved.
OTHER PARTY (IES) CAUSE OF DISPUTE AMOUNT INVOLVED (KSHS)
I certify that the above information is correct.
……………………
………………………
………………………
Title
Signature
Date
125
DECLARATION FORM
Date
To
The tenderer i.e. (name and address)
declare the following:
a) Has not been debarred from participating in public procurement.
b) Has not been involved in and will not be involved in corrupt and
fraudulent practices regarding public procurement.
Title Signature Date
(To be signed by authorized representative and officially stamped)
126
LETTER OF NOTIFICATION OF AWARD
Address of Procuring Entity _____________________ _____________________
To:
RE: Tender No.
Tender Name
This is to notify that the contract/s stated below under the above mentioned tender have been awarded to you.
1. Please acknowledge receipt of this letter of notification signifying your acceptance.
2. The contract/contracts shall be signed by the parties within 30 days of the
date of this letter but not earlier than 14 days from the date of the letter.
3. You may contact the officer(s) whose particulars appear below on the subject matter of this letter of notification of award.
(FULL PARTICULARS)
SIGNED FOR ACCOUNTING OFFICER
127
FORM RB 1
REPUBLIC OF KENYA
PUBLIC PROCUREMENT ADMINISTRATIVE REVIEW BOARD
APPLICATION NO…………….OF……….….20……...
BETWEEN
…………………………………………….APPLICANT
AND
…………………………………RESPONDENT (Procuring Entity)
Request for review of the decision of the…………… (Name of the Procuring Entity) of
……………dated the…day of ………….20……….in the matter of Tender No………..…of
…………..20…
REQUEST FOR REVIEW
I/We……………………………,the above named Applicant(s), of address: Physical
address…………….Fax No……Tel. No……..Email ……………, hereby request the Public
Procurement Administrative Review Board to review the whole/part of the above
mentioned decision on the following grounds , namely:-1.
2.
etc.
By this memorandum, the Applicant requests the Board for an order/orders that: -
1. 2.
etc
SIGNED ……………….(Applicant)
Dated on…………….day of ……………/…20…
FOR OFFICIAL USE ONLY
Lodged with the Secretary Public Procurement Administrative Review Board on …………
day of ………....20….………
SIGNED
Board Secretary
128