prolongation cost in eot claims
TRANSCRIPT
-
8/19/2019 Prolongation Cost in Eot Claims
1/3
PROLONGATION COST IN EOT CLAIMS
Once a Contractor has secured an extension of time and relief from liquidated
damages, thoughts will quickly turn to recovery of the costs incurred due to
the delayed completion date – i.e. “Prolongation Costs.
!f you ask an "mployer#s $% how such costs should &e determined the answer
is often an unequivocal statement that the rates and prices from the
Preliminaries 'O$ shall &e divided &y the original contract duration and the
derived daily rate for preliminaries shall then &e applied to the extended
duration. (he sharp witted "mployer#s $% may even refine this logic with the
caveat that the 'O$ rates and prices should first &e ad)usted to remove fixed
costs, mo&ili*ation and demo&ili*ation costs, overheads and profit.
+hilst &oth answers are quite wrong, these approaches are often used in order
to achieve result, despite the inaccurate answer. (he pro&lem is that neither
approach attempts to address the underlying question of what costs losses
were actually incurred &y the Contractor as a consequence of the delaying
events for which the "mployer was responsi&le. (he answer to this question
cannot &e found in the 'O$, &ut can -and should &e found in a detailed
analysis of the Contractor#s cost records (he express wording of the contract
will dictate which heads of claim are admissi&le, &ut in general terms an
-
8/19/2019 Prolongation Cost in Eot Claims
2/3
accurate understanding of Prolongation Cost entitlement can &e derived &y
application of the following &asic principles/
0Identify the events that gave rise to the extension of time – as it is the cost loss
arising from these events that the Contractor is entitled to recover1
0Identify the point in time that the delay occurred – a common mistake is to
identify the costs that were incurred over the extended duration at the end of
the contract period. (his is incorrect. (he delay may have occurred prior to
full mo&ili*ation and thus the actual costs incurred at that time may &e lower1
-Identify the direct costs that follow from the compensable delay events – the
Contractor is not entitled to costs arising from delay events for which it is
responsi&le. %eparation of the two can defeat arguments that the claim is
glo&al and includes elements of the Contractor#s own culpa&ility1
0Assess only time related costs and not one off capital costs – time related costs
are those which necessarily arise as a consequence of additional time spent on
the pro)ect and would typically include staff salaries1 insurance, rents, utilities,
&onds, accommodation, office services, car leases 2 running costs, etc. &ut
would not include purchase costs of offices, photocopiers, vehicles etc.
0Exclude task related costs – a common mistake is to include task related costs
-e.g. la&our, plant hire or scaffolding costs that would have &een incurred in
any event. (hese costs may only have &een incurred at a later point in time
and are therefore not additional. %uch costs would need to &e separately
recovered through a properly formulated disruption cost claim1
0Exclude profit – the purpose of the claim is to put the Contractor &ack into
the position it would have &een, &ut for the delay. 3Profit# is not 3cost# and thus
any claim for profit can only &e &y way of a 3loss of opportunity# claim – which
may &e expressly precluded &y the wording of the contract and would in any
-
8/19/2019 Prolongation Cost in Eot Claims
3/3
case have to &e proved, i.e. that opportunities did in fact present themselves
and were refused &ecause key resources could not &e released from the
delayed pro)ect1
0Allow for off-site costs – costs incurred in the Contractor#s head office -and
elsewhere may &e as a direct result of the pro)ect delay. (he fact that these
costs were incurred off site does not mean that the Contractor is not entitled to
receive them1
0If possible, avoid formulae for determining overheads -e.g. 4udson#s, "mden#s
etc. – unless you are a Contractor and you fully understand the &asis of your
3loss of opportunity# claim and how to present it5 'y indentifying actual
incurred overhead costs rather than rely on theory &ased formulae that
commonly produce high assessments1
0Interest / Finance Charges – remem&er that charging interest on a de&t may
&e prohi&ited in your )urisdiction or &y your contract. 6ost interest or finance
claims suffer from a lack of facts and are commonly/ unsupported, theoretical
assessments of loss. 4owever, a skilled claimant can often find ways to lend
credi&ility to this type of claim.