milwaukee transport services, inc. operator of the ......jun 25, 2020 · bids shall include...

MILWAUKEE TRANSPORT SERVICES, INC. Operator of the Milwaukee County Transit System

1942 NORTH 17TH STREET MILWAUKEE, WI 53205

(414) 937-3296 Purchasing Agent: JASON ROSS

[email protected] | www.ridemcts.com

BID NO 2020-12: TRANSIT BUS BEARINGS, BUSHINGS, AND SEALS RELEASE DATE: JUNE 25, 2020

Milwaukee Transport Services (MTS), a quasi-governmental instrumentality of Milwaukee County and operator of the Milwaukee County Transit System (MCTS). MTS is accepting bids for BEARINGS, BUSHINGS, AND SEALS for Transit Coaches until

DUE DATE: JULY 28, 2020 by 2:00 P.M. CST. Bids will be publicly opened and read at the above opening date and time in Room 104 of the Administration Building- Materials Management Department. Late bids will not be opened or accepted. Any bids received after the established due date and time at the place designated for receipt of bids is late, without exception. Faxed or emailed bids are not be allowed or accepted. Specifications: To comply with Specification No. FM-09-20, dated 05/05/2020. Requirements: To supply Milwaukee Transport Services, Inc with transit coach bus BEARINGS, BUSHINGS, AND SEALS per specification. Contract Type and Term This is a firm fixed price contract for two (2) years. How to Bid and Award of Contract: Bid a unit price per line item for the full term of the contract. Award will be based on the line-item pricing for Items 1 through 26, less invoice discount of 30 days (if

any). Award will be made per line item to the lowest responsible bidder complying with the specifications. Award will be based on what is deemed in the best interest of Milwaukee Transport Services, Inc. Question Deadline & Amendments to Bid Document: Questions regarding the solicitation of this Bid, as well as, any clarifications or further instructions to bidders will be sent to all prospective offerors in addendum form. All questions and comments regarding

mailto:[email protected]

this solicitation must be submitted via email to Jason Ross at [email protected] by July 14, 2020 end of business day. Right to Reject: MTS reserves the right to make an award based on its own determination, or to reject any or all bids or portions of same, if in the opinion of MTS, the best interest of MTS will be served thereby. In awarding a contract, MTS reserves the right to consider all elements entering the determination of the responsibility of the bidder. Any bid which is incomplete, conditional, obscure, or which contains additions not required, or irregularities of any kind, may be deemed non-responsive. In case of any discrepancy between the price written in the bid and that given in figures for any item, the price in writing will be considered as the bid. MTS also reserves the right to take into consideration the Bidders past performance with MTS or and other entity in determining if the Bidder is responsible and qualified. Waiver of Informalities: In its sole discretion, MTS may waive informalities and minor irregularities in bids received. Binding Contract: A proposal received in response to this solicitation is an offer that can be accepted by MTS to create a binding contract without negotiation with any Firm. Order of Precedence: An order of precedence is hereby formally established and will be used to form a binding contract. The order is as follows:

1. Purchase of Services Agreement 2. Purchase Order

2. All documents contained within and related to Bid 2020-08, including all Addenda 3. Bid from the successful vendor The order of precedence establishes that, in any conflict between the bid and the Purchase Order and/or Bid Documents, the Purchase Order and/or Bid Documents take precedence and control. Tax Exemption: MTS is an agency of Milwaukee County and is exempt from Wisconsin Sales Tax under Section 77.54 (9a) (b) of the Wisconsin Statutes, and is exempt from the Federal Excise Tax, and has been granted Exempt No. 39-73-0429K. Wisconsin Exempt No. CES014818. Bids shall be submitted excluding any of these taxes. Method of Award MTS reserves the right to make an award based upon the lowest, responsive, responsible bid or to reject any or all bids. Single Bid, If Received: If only a single bid is received, MTS may require that the Bidder provide the necessary cost or pricing data to enable MTS to perform a cost or price analysis to ensure that the bid price is fair and reasonable. If requested, the Bidder shall provide the cost or price data within five (5) working days of the date requested. MTS reserves the right to reject or accept the bid based on the cost or pricing data. Where only one responsive and responsible bid is received, MTS may also negotiate price with the sole responsive bidder.


Inspection: Materials or equipment purchased are subject to inspection and approval at MTS’s destination. MTS reserves the right to reject and refuse acceptance of items which are not in accordance with the instructions, specifications, or a part of the contractor’s warranty (express or implied). Rejected materials or equipment shall be removed by, or at the expense of the contractor promptly after rejection. Buy America Requirement: The Bidders shall comply with the federal statute set out below, and complete the Buy America Certification, included in the Bid Forms. This form must be included in the bid package for the offer to be considered responsive. Contract Continuation: Contractor recognizes that the services under this contract are vital to MTS and to the public and must be continued without interruption. Contractor agrees that MTS, in its sole discretion, and by written notice to Contractor at least 30 days prior to contract expiration, may extend this Agreement for up to an additional 120 days. If so, extended by MTS, Contractor shall continue to provide services under this Agreement, on the same terms as set forth in this Agreement. MTS may terminate any such extension by providing Contractor with 30 days’ notice. Contractor further agrees to exercise its best efforts and cooperation to affect an orderly and efficient transition to any successor Contractor. Mission Critical Contract: MTS has identified this Contract as critical to MTS’s ability to provide essential services. During the duration of the current COVID-19 pandemic, while there are federal, state, and/or local orders relating to or arising from this pandemic, or during any future pandemic or state of emergency declared during the term of this contract by federal, state, or local governments, Contractor will:

Dedicate resources to identify and mitigate situations in the workplace or jobsite which may introduce, expose, or spread COVID-19.

Screen employees following current CDC guidelines to verify they have not: : a) Traveled to a Level 2 or 3 Country in the past 14 days, or visited an area that requires self-quarantine because of COVID-19 infection, b) Had close contact (within 6 feet) with anyone known or suspected to have COVID19, c) Exhibited any symptoms (chest or back pain, cough, difficulty breathing) of COVID-19 or had a fever greater than 100.4 in the past 14 days. Educate employees on key CDC recommendations including how employees can protect themselves and what employees should do if they feel sick. Provide MTS services remotely, to the greatest extent possible. Notify MTS within 24 hours of becoming aware of any employee who has been on site at any MTS building, or in contact with any MTS employee, that has a confirmed or suspected case of COVID-19. Notify MTS immediately if Contractor believes, or has reason to believe, Contractor will be unable to provide services or goods under this Contract.

Agrees that MTS is not responsible for any costs, and will not be invoiced for any incomplete work, if MTS revokes permission for Contractor’s employees to be on MTS property due to that employee exhibiting symptoms of COVID-19, or any other illness. County Rights of Access and Audit The Contractor, Lessee, or other party to the contract, its officers, directors, agents, partners and employees shall allow the County Audit Services Division and department contract administrators (collectively referred to as Designated Personnel) and any other party the Designated Personnel may name, with or without notice, to audit, examine and make copies of any and all records of the Contractor, Lessee, or other party to the contract, related to the terms and performance of the Contract for a period of up to three years following the date of last payment, the end date of this contract, or activity under this contract, whichever is later. Any subcontractors or other parties performing work on this Contract will be bound by the same terms and responsibilities as the Contractor. All subcontracts or other agreements for work performed on this Contract will include written notice that the subcontractors or other parties understand and will comply with the terms and responsibilities. The Contractor, Lessee, or other party to the contract, and any subcontractors understand and will abide by the requirements of Section 34.09 (Audit) and Section 34.095 (Investigations Concerning Fraud, Waste, and Abuse) of the Milwaukee County Code of General Ordinances. Funds If funds are not appropriated for payment of this contract, Purchaser may terminate contract at the end of any fiscal year upon 30 days written notice. MTS operates the transit system for, and under an agreement with, Milwaukee County, Wisconsin. All multi-year contracts / agreements with MTS are contingent upon Milwaukee County retaining MTS as the operator of the transit system. The continuation of this agreement beyond December 31 of any given year, shall be contingent upon MTS receiving the necessary funding from the government agency. Variations in Word and Figures In case of variation between the amounts in words and figures, the amount prescribed in words will prevail. Delays in Delivery Delays in delivery caused by bona fide strikes, government priority or requisition, riots, fires, sabotage, acts of God or any other delays deemed by the Director of Materials Management to be clearly and unequivocally beyond the contractor's control, will be recognized. The vendor may be relieved of meeting the delivery time specified if vendor files with the Director of Materials Management a request for an extension of time, signed by a responsible official, giving in detail all the essential circumstances which upon verification by Director of Materials Management justifies such extension. Delivery Terms Bids shall include delivery costs to the specified delivery point, all transportation charges prepaid and borne by you. MTS reserves the right to change the location of tire delivery at any time during the life of the contract. Warranty: Warranty terms will be negotiated by MTS with excepted offer.

Liquidated Damages:

A. Contractor agrees to reimburse MTS $115/hr. for any labor or charges incurred by MTS to repair

or address any quality defects in leased tires provided by Contractor that must be addressed

immediately. If time is not of the essence, MTS will request Contractor to repair or replace

leased tires.

B. In the event that Contractor fails to comply with a request from MTS to repair, replace leased

tires, MTS shall, upon written notice to Contractor, have the authority to deduct the cost(s)

incurred by MTS to address the request from the next payment due under the contract.

C. Contractor agrees to reimburse MTS for the cost of towing if towing is needed due to any quality

defects in the leased tires provided by Contractor. Code of Ethics The Milwaukee County Code of Ethics states in part, "No person may offer to give to any Public official or employee or his immediate family, and no Public official or employee or his immediate family may solicit or receive anything of value pursuant to an understanding that such officers or employees' vote, official actions or judgment would be influenced thereby." No person(s) with a personal financial interest in the approval or denial of a contract being considered by a County department or with an agency funded and regulated by a County department, may make a campaign contribution to any County official who has approval authority over that contract during its consideration. Contract consideration shall begin when a contract is submitted directly to a County department or to an agency until the contract has reached final disposition, including adoption, county executive action, proceedings on veto (if necessary) or departmental approval. This provision does not apply to those items covered by Section 9.15 unless an acceptance by an elected official would conflict with this section. The language in Section 9.05(2)(l) shall be included in all Request for Proposals (RFP) and bid documents. Independent Contractor Nothing contained in the Agreement shall constitute or be construed to create a partnership or joint venture between MTS, Inc. or its successors and the Contractor or its successors or assigns. In entering into this Agreement, and in acting in compliance herewith, Contractor is at all times acting and performing as an independent Contractor, duly authorized to perform the acts required of it hereunder. Retention of Records Contractor agrees to retain all records related to this contract for a period of at least three years from final date of payment of this contract Audit of Records Contractor shall permit the authorized representative of the Milwaukee County Auditor, after reasonable notice, the right to inspect and audit all data and records of Contractor related to carrying out the contract for a period of up to three years after completion of the contract. If subcontracts

and/or associates are utilized, prime contractor shall have written contractual agreement with County approved subcontractors and/or associates which bind the subcontractor to the same audit contract terms and conditions as the prime Contractor. Non-Discrimination The contractor, lessee, offeror, supplier, purchaser, etc., agrees not to discriminate against any employee or applicant for employment because of race, religion, color, national origin, age, sex, or handicap, which include, but not limited to: recruitment or recruitment advertising; employment; upgrading; demotion or transfer, layoff or termination; rates of pay or other forms of compensation; selection for training, including apprenticeship. A violation of this provision shall be sufficient cause for MTS to terminate the contract, lease, order, etc. pursuant to County Ordinance 56.17 - Non-Discriminatory Contracts. Written Change Orders Oral change orders are not permitted. No change in this contract shall be made unless the contracting officer gives his prior written approval, therefore. The contractor shall be liable for all costs resulting from, and/or for satisfactorily correcting, any specification changes not properly ordered by written modification to the contract and signed by the contracting officer. Bidders shall complete and return all bid forms required. The required forms must be submitted using the exact forms provided and must be signed by an authorized representative of the Bidder. Any alterations of the Forms or failure to submit required Forms may cause the Bid to be rejected as non-responsive.

Enclosures:

1. Signature Sheet 2. Bid Sheet 3. Specification FM-09-20 4. Sample Purchase of Service Agreement 5. EEO Certificate 6. Conflict of Interest Statement 7. Buy America 8. False Claims Form 9. Debarment Form 10. Anti-Lobby 11. Non-Collusion 12. Federal Clauses

Forms that must be returned with Bid: 1. Signature Sheet 2. BID SHEET 3. EEO Certificate 4. Conflict of Interest Statement 5. Buy America Certification 6. False Claims form 7. Debarment Form 8. Anti-Lobbying Form 9. Non-collusion affidavit 10. Copy of Warranty for Proposed Bid Items

SIGNATURE SHEET CASH DISCOUNT: Cash invoice discount for payment of invoices following receipt and acceptance of goods or services _________% 30 days. DELIVERY: Price shall include delivery, FOB destination freight prepaid to Milwaukee Transport Services, Inc., 1525 W. Vine St., Milwaukee, WI 53205, unless otherwise noted in this solicitation. BY SIGNING THIS BID, YOU ARE AGREEING WITH FOLLOWING STATEMENTS:

1. This bid has been made without any connection with any other bidder and is in all respects fair and without collusion or fraud.

2. This bid has been made with the understanding that no elected officer/employee of Milwaukee

Transport Services, Inc., or Milwaukee County is interested therein, directly or indirectly. 3. The specifications for this bid has been read and understood. 4. Your company has never defaulted on any contract with Milwaukee Transport Services, Inc., or

Milwaukee County. In signing and submitting this quote, the proposer assures Milwaukee Transport Services, Inc., that the furnishing of the subject materials, services or equipment is under his/her control and accepts and has read all the Terms and Conditions of MTS, of this quote and all of its documents. If the proposer’s performance, in the event he/she is successful is contingent upon the act of another party, the proposer assures MTS that he/she has the necessary commitments to complete the contract which may be awarded him/her. Date: _____________ Submitted by: _______________________________________________________ Name of firm: _______________________________________________________ Address of firm: ______________________________________________________ Signed per: __________________________________________________________ (Manual signature required) Print name: __________________________________________________________ Title: ___________________________ Email: ______________________________ Telephone: _______________________ Fax: ____________________________ DUNS #: ________________________ NAICS CODE #___________________

BID SHEET Vendor Name:__________________

The undersigned bidder proposes to furnish the materials and services herein described at and for the prices hereinafter named, according to specification on file in the office of the Director of Materials Management, and, if successful, hereby agrees to enter into an agreement with Milwaukee Transport Services, Inc.

ITEM 1 MCTS LOT # 018-06-009, JOINT-UNIVERSAL DRIVESHAFT, SPICER/DANA CP280X OR APPROVED EQUAL

Bid Price in Words_______________________________________________

Bid Price in Figures $_____________________________________________

ITEM 2 MCTS LOT # 121-10-002, SEAL SHAFT FRONT AXLE, M.A.N.#06.56289.0369,

6333910NFA, OR APPROVED EQUAL


Bid Price in Figures $_______________________________________________

ITEM 3 MCTS LOT # 121-10-003, BEARING TAPER ROLLER FRONT AXLE,

M.A.N.#06.32499.0043, SKF# BR331933 OR APPROVED EQUAL



ITEM 4 MCTS LOT # 121-10-011, BEARING ROLLER TAPER FRONT AXLE, M.A.N.#

06.32499.0016, SKF# BR32310 OR APPROVED EQUAL


Bid Price in Figures $__________________________________________________

ITEM 5 MCTS LOT # 122-11-013, BEARING M.A.N. ONLY, M.A.N.#06.36959.0035 OR APPROVED EQUAL



ITEM 6 MCTS LOT # 122-11-015, RING-SEAL, M.A.N. 06.56279.0311,

6312112NFA OR APPROVED EQUAL



ITEM 7 MCTS LOT # 122-11-016, RING-SEAL BUSHING, M.A.N.#81.50308.0006,




ITEM 8 MCTS LOT # 122-11-038, SEAL-SHAFT, M.A.N.#06.56279.0297,




ITEM 9 MCTS LOT # 123-04-002, END-ROD MALE, NEW FLYER#103278,

CM-8Z AURORA OR APPROVED EQUAL



ITEM 10 MCTS LOT # 324-02-053, BEARING BALL SEALED, 1641DC OR APPROVED EQUAL



ITEM 11 MCTS LOT # 910-10-010, BEARING INNER MUST HAVE 13-14 BALL BEARINGS,

BL209Z OR APPROVED EQUAL



ITEM 12 MCTS LOT # 910-10-011, BEARING-OUTER, DELCO # 9440138 OR APPROVED EQUAL



ITEM 13 MCTS LOT # 121-08-002, SEAL-SHAFT, M.A.N. 06.56279.0262, 6313119NFA OR APPROVED EQUAL



ITEM 14 MCTS LOT # 122-16-009, OUTR REAR WHEEL SEAL, M.A.N.#06.56289.0371,




ITEM 15 MCTS LOT # 122-23-010, BUSHING-THREADED M115, M.A.N.#80.99606.0251,

NEW FLYER# 6313261 OR APPROVED EQUAL



ITEM 16 MCTS LOT # 121-02-004, WASHER SEALING, M.A.N.#81.90711.0941, NEW

FLYER#6313070 OR APPROVED EQUAL



ITEM 17 MCTS LOT # 121-02-006, BUSHING OEM M.A.N. ONLY, M.A.N.#81.93020.0706,




ITEM 18 MCTS LOT # 121-02-007, SEAL-SHAFT, M.A.N.#06.56279.0353 OR APPROVED EQUAL



ITEM 19 MCTS LOT # 121-05-010, PIN- BRAKE SHOE, M.A.N.#81.50212.0036NEW

FLYER#6312122NFA OR APPROVED EQUAL



ITEM 20 MCTS LOT # 121-06-013, BUSHING INTERNAL, M.A.N.#81.93020.0811, NEW

FLYER# 6312085NFA OR APPROVED EQUAL



ITEM 21 MCTS LOT # 121-06-018, BUSHING SMALL, M.A.N.#81.93021.0117, NEW FLYER#




ITEM 22 MCTS LOT # 121-12-012, BEARING-THRUST ROLLER, M.A.N.#06.32819.0033,

NEWFLYER# 6313060 OR APPROVED EQUAL



ITEM 23 MCTS LOT # 121-16-018, BUSHING FRONT RADIUS ROD, M.A.N.#81.43722.0047,

NEW FLYER#6322936 OR APPROVED EQUAL



ITEM 24 MCTS LOT # 122-10-006, SEAL-SHAFT AND HOLDER, M.A.N.#06.56289.0319,




ITEM 25 MCTS LOT # 601-06-001, HUB AND BEARING ASSY. FRONT, M.A.N.#

81.93420.0349, NEW FLYER#6346288 OR APPROVED EQUAL



ITEM 26 MCTS LOT # 602-06-013, SEAL PINION SHAFT, M.A.N.# 81.96503.0531, NEW




ITEM 27 MCTS LOT # 602-09-002, BEARING ASSY-HUB UNIT REAR, M.A.N.#

81.93420.0342, NEW FLYER# 6392545 OR APPROVED EQUAL



ITEM 28 MCTS LOT # 602-09-006, SEAL-SHAFT, M.A.N.# 06.56289.0387, NEW




ITEM 29 MCTS LOT # 602-09-011, RADIAL SHAFT SEAL W/ABS PULSE WHEEL, M.A.N.#

81.96503.0333, NEW FLYER#6392081 OR APPROVED EQUAL



ITEM 30 MCTS LOT # 910-10-010, BEARING INNER SHIELDED, 209ZJ SKF OR APPROVED EQUAL



ITEM 31 MCTS LOT # 370-01-006, KIT-UPPER RADIUS ROD 130MM BUSHING, NEW

FLYER#6335815NFA OR APPROVED EQUAL



ITEM 32 MCTS LOT # 370-01-007, KIT-UPPER RADIUS ROD BUSHING 150MM, NEW




ITEM 33 MCTS LOT # 370-16-018, SEAL-SHAFT, M.A.N.# 81.96503.0530

NEW FLYER# 6361462NFA OR APPROVED EQUAL



ITEM 34 MCTS LOT # 370-16-019, BEARING ASSY. HUB UNIT, M.A.N.# 81.93420.0346,




ITEM 35 MCTS LOT # 370-16-020, SEAL ASSY-ABS RING & SHAFT SEAL, NEW FLYER#

6345864NFA, M.A.N.# 81.96503.6000 OR APPROVED EQUAL



ITEM 36 MCTS LOT # 370-16-033, BEARING ASSY THRUST, NEW FLYER# 6345895 OR APPROVED EQUAL



Vendor DUNS #__________________

VENDOR EMAIL: ___________________________________________

SPECIFICATION NO. FM-09-20

FOR BEARINGS, BUSHINGS AND SEALS

(Updated 5/5/20)

1. SCOPE AND CLASSIFICATION

1 Scope

a It is the intent of this specification to describe the minimum requirements for the

purchase of Bearings, Bushings and Seals for use in Milwaukee County Transit system

buses. All items or features not specifically mentioned which are necessary or which are

regularly furnished in order to provide complete service, shall be furnished by the

successful bidder at the bid price and shall conform in quality of material and service to

that usually provided by the engineering practice indicated in this specification. The

Milwaukee County Transit System is managed and operated by Milwaukee Transport

Services, Inc., and shall be referred to as MTS hereinafter.

2 Classification

a Bearing Standardization - Ball and Roller Bearings shall be manufactured to boundary

dimensions (outside diameter, bore diameter and width) and tolerances which have been

standardized by the Anti-Friction Bearing Manufacturers Association (AFBMA).

2. DOCUMENTATION

1 None Required

3. REQUIREMENTS

1 All bearings, seals and bushings furnished by the supplier shall be the manufacturer's latest

approved design and shall be in the manufacturers sealed container, to preclude corrosion by

contamination from the elements.

2 The supplier shall furnish the make and types of bearings, seals and bushings as specified by

MTS unless authorized, in writing, to substitute another make and type by MTS. Where listed

“OR APPROVED EQUAL”, a request for approved equal status may be submitted , see section

4. Samples, Inspection and Testing. Where listed “OR SEE PRE-APPROVED LIST”, see

section 3.7 a and b only.

3 The supplier and/or manufacturer shall furnish free of charge, engineering and technical

assistance which may be required in connection with the use, maintenance and failure analysis of

bearings, seals and bushings.

4 The seals furnished shall be of the highest industrial quality and meet all applicable coach

manufacturer's requirements.

5 The bearings and seals furnished shall in no way affect engine or coach warranties.

6 All bearings, bushings and seals shall be virgin – as new. Used items will not be accepted

7 Pre-Approved Bearings - The MTS pre-approved Bearings are as follows:

a TORRINGTON MERITOR TIMKEN

FAFNIR ALINABAL FAG

NTN/BOWER MRC SKF

NDH NACHI KOYO

AURORA RBC/HEIM M.A.N.

Pre-Approved Seals - The MTS pre-approved Seals are as follows:

b CHICAGO RAWHIDE

NATIONAL

STEMCO

FEDERAL MOGUL

GARLOCK

VICTOR

TCM

M.A.N.

8

MCTS LOT # DESCRIPTION PART #

018-06-009 JOINT-UNIVERSAL

DRIVESHAFT SPICER/DANA CP280X

121-10-002 SEAL SHAFT FRONT

AXLE

M.A.N.#06.56289.0369,

6333910NFA

121-10-003 BEARING TAPER ROLLER

FRONT AXLE

M.A.N.#06.32499.0043

SKF# BR331933

121-10-011 BEARING ROLLER TAPER

FRONT AXLE

M.A.N.#06.32499.0016

SKF# BR32310

122-11-013 BEARING M.A.N. ONLY M.A.N.#06.36959.0035

122-11-015 RING-SEAL M.A.N. 06.56279.0311

6312112NFA

122-11-016 RING-SEAL BUSHING M.A.N.#81.50308.0006

6312117NFA

122-11-038 SEAL-SHAFT M.A.N.#06.56279.0297

6312099NFA

123-04-002 END-ROD MALE NEW FLYER#103278

CM-8Z AURORA

324-02-053 BEARING BALL SEALED 1641DC

910-10-010 BEARING INNER MUST

HAVE 13-14 BALL

BEARINGS

BL209Z

910-10-011 BEARING-OUTER DELCO # 9440138

121-08-002 SEAL-SHAFT M.A.N. 06.56279.0262

6313119NFA

122-16-009 OUTR REAR WHEEL

SEAL

M.A.N.#06.56289.0371

6319485NFA

122-23-010 BUSHING-THREADED

M115

M.A.N.#80.99606.0251

NEW FLYER# 6313261

121-02-004 WASHER SEALING M.A.N.#81.90711.0941

NEW FLYER#6313070

121-02-006 BUSHING OEM M.A.N.

ONLY

M.A.N.#81.93020.0706

NEW FLYER# 6313057

121-02-007 SEAL-SHAFT M.A.N.#06.56279.0353

121-05-010 PIN- BRAKE SHOE M.A.N.#81.50212.0036

NEW FLYER#6312122NFA

121-06-013 BUSHING INTERNAL M.A.N.#81.93020.0811

NEW FLYER# 6312085NFA

121-06-018 BUSHING SMALL M.A.N.#81.93021.0117


121-12-012 BEARING-THRUST

ROLLER

M.A.N.#06.32819.0033

NEWFLYER# 6313060

121-16-018 BUSHING FRONT RADIUS

ROD

M.A.N.#81.43722.0047

NEW FLYER#6322936

122-10-006 SEAL-SHAFT AND

HOLDER

M.A.N.#06.56289.0319

NEW FLYER# 6312912

601-06-001 HUB AND BEARING

ASSY. FRONT

M.A.N.# 81.93420.0349

NEW FLYER#6346288

602-06-013 SEAL PINION SHAFT M.A.N.# 81.96503.0531

NEW FLYER#6407910

602-09-002 BEARING ASSY-HUB

UNIT REAR

M.A.N.# 81.93420.0342

NEW FLYER# 6392545

602-09-006 SEAL-SHAFT M.A.N.# 06.56289.0387

NEW FLYER#7700177

602-09-011 RADIAL SHAFT SEAL

W/ABS PULSE WHEEL

M.A.N.# 81.96503.0333

NEW FLYER#6392081

910-10-010 BEARING INNER

SHIELDED

209ZJ SKF

370-01-006 KIT-UPPER RADIUS ROD

130MM BUSHING

NEW FLYER#6335815NFA

370-01-007 KIT-UPPER RADIUS ROD

BUSHING 150MM

NEW FLYER#6356495

370-16-018 SEAL-SHAFT M.A.N.# 81.96503.0530


370-16-019 BEARING ASSY. HUB

UNIT

M.A.N.# 81.93420.0346

NEW FLYER# 6348112

370-16-020 SEAL ASSY-ABS RING &

SHAFT SEAL


M.A.N.# 81.96503.6000

370-16-033 BEARING ASSY THRUST NEW FLYER# 6345895

5. SAMPLES, INSPECTIONS, TESTS

1 Bidders seeking approved equal status for products not already approved shall submit the

following information prior to the Deadline for Questions established in the first section of this

solicitation document:

a Specification Data Sheet showing the product meets or exceeds OEM quality and

performance specifications

b A list of three (3) transit properties (minimum) that have used the item(s) you are

proposing to furnish, for a least two (2) years. Provide name, phone number and

contact person.

c A copy of manufacturer’s warranty. Also, see Section 6 of this specification which

outlines additional warranty requirements.

d MTS may request a sample during the approved equal process.

e MTS reserves the right to conduct tests before and after the award of the bid to

determine compliance with this specification and to determine the suitability of the

approved equal item(s) for the use intended.

6. PREPARATION AND DELIVERY

1 Standard orders shall be shipped within 72 hours of receiving verbal or written release from

MTS-Materials Management Department. Bidder(s) shall pay all freight charges to MTS and all

freight charges necessary to return incorrect orders.

2 Emergency orders shall be shipped within 24 hours or receiving verbal or written release from

the Materials Management Department. Additional freight costs deemed necessary by MTS

shall be borne by MTS.

3 Failure to deliver stock orders or to promptly replace rejected material within 15 working days,

shall render the bidder(s) liable for the difference in replacement cost between the open market

price and the contract price, where emergency procurement is necessary.

4 Bearings, bushings and seals shall be permanently stamped with manufacturer’s identification

symbol and or manufacturer’s name. All bearings, bushings and seals shall be packaged in

standard packaging bearing the name or identification symbol of the manufacturer.

Manufacturer shall be responsible for labor to cover R&R and rebuild cost caused by a

manufacturer’s defect.

5 The Shipping/Receiving address is:

Milwaukee County Transit System

1525 West Vine Street

Milwaukee, Wisconsin 53205

6 All deliveries shall be completed between the hours of 7:00 AM and 2:00 PM, Monday

through Friday.

7. WARRANTY

i. All bearings shall carry the manufacturer’s warranty.

ii. A written warranty shall be supplied by bidder.

iii. The successful bidder shall be responsible for ALL warranty claims filed by

MTS. The successful bidder(s) shall act as an agent for the part manufacturer and

shall agree to reimburse MTS for any labor or charges incurred at labor rate

$115.00 an hour to include towing cost for any quality defects in manufacturing

promptly, prior to its reimbursement from the manufacturer, if necessary.

iv. In the event the bidder(s) fails to comply with a request from MTS to repair,

replace materials, correct defective work, equipment and accessories, MTS shall,

upon written notice to the bidder(s), have authority to deduct the cost(s) from the

next payment due under the contract.

v. Any and all shipping cost incurred through the warranty process shall be the

responsibility and be paid by the chosen vendor.

b. Contractual Provisions

i. The agreement shall run for two (2) year from the initial contract date.

ii. This agreement may be extended by mutual consent of both parties. The

extension(s) shall be in the best interests of MTS.

iii. This agreement may be canceled by either party for cause, with a thirty (30) day

written notice. NOTE: MTS will invoke this option if minimum requirements of

this specification are not met.

iv. MTS shall NOT pay any penalties in case of cancellation.

c. Changes to bid/specification

i. No changes whatsoever shall be allowed without prior written consent of the MTS

Materials Management Department.

ii. No verbal responses from any agent of MTS shall be acted upon. For non-protest

clarifications, submit questions in writing.

PROFESSIONAL SERVICE CONTRACT

This Contract between Milwaukee Transport Services, Inc., a quasi-governmental

instrumentality of Milwaukee County and operator of Milwaukee County Transit System located at

1942 North 17th Street, Milwaukee, Wisconsin 53205 (hereinafter called the “MTS”), and___________

located at ____________(hereafter called “Contractor”), is entered into as of ________, 2020.

1. SCOPE OF SERVICES.

The Contract consists of the following _____ documents listed below, all of which are incorporated

herein by reference, in the following order of precedence that will be govern any inconsistencies

between the terms of this Contract and the terms of any Exhibits, Schedules, or Attachments

thereto:

a. This Professional Service Contract

b. MTS Request for Proposal/Bid/Quote #

c. Contractor’s Entire Proposal

d. Contractor’s Best and Final Offer

e. MTS Purchase Order

2. STAFFING.

Contractor’s employees listed below are assigned to MTS and are the main points of contact for

this Contract.

Name Position

Contractor shall not replace the employees listed above without the prior approval of the MTS. If the successor to any of those employees cannot be mutually agreed upon, MTS shall have the right to terminate this Contract upon thirty (30) days’ notice. Any replacement of listed personnel shall be by persons of equal qualifications, which shall be attested to by Contractor. The employees listed above shall be required to give this contractual obligation top priority.

Contractor represents that its employees and subcontractors possess the necessary skill, expertise,

and capability, including sufficient personnel with the necessary qualifications, to perform the

services required by this Contract. Contractor shall provide, at its own expense, all personnel

required in performing the services under this Contract. Such personnel shall not be the employees

of, or have any other contractual relationship with, MTS.

3. DATES OF PERFORMANCE.

The initial term of this Contract shall be from _______ through _______ or until such time as

either party notifies the other of its termination, as provided herein.

4. COMPENSATION.

Contractor shall be compensated for work as listed in Contractor’s Best and Final Offer, attached

and incorporated into this Contract. This compensation shall include any and all out-of-pocket

expenses incurred by Contractor or its employees State Prompt Pay Law, Section 66.285, does not

apply to this Contract. As a matter of practice, MTS attempts to pay all invoices in 30 days.

Contractor shall provide MTS with monthly billings, listing actual costs, which shall include, but

not be limited to, the following:

A. Name and address of contractor

Invoice date and number

B. Remittance name and address

C. Name, title, and phone number of person to notify in event of defective invoice

Invoices should be sent to: [email protected]

MTS reserves the right to use a purchasing card to pay invoices.

5. MISSION CRITICAL CONTRACT.

MTS has identified this Contract as critical to MTS’s ability to provide essential services. During

the duration of the current COVID-19 pandemic, while there are federal, state, and/or local

orders relating to or arising from this pandemic, or during any future pandemic or state of

emergency declared during the term of this contract by federal, state, or local governments,

Contractor will:

a. Dedicate resources to identify and mitigate situations in the workplace or jobsite which may

introduce, expose, or spread COVID-19.

b. Screen employees following current CDC guidelines to verify they have not: : a) Traveled to

a Level 2 or 3 Country in the past 14 days, or visited an area that requires self-quarantine

because of COVID-19 infection, b) Had close contact (within 6 feet) with anyone known or

suspected to have COVID19, c) Exhibited any symptoms (chest or back pain, cough,

difficulty breathing) of COVID-19 or had a fever greater than 100.4 in the past 14 days.

c. Educate employees on key CDC recommendations including how employees can protect

themselves and what employees should do if they feel sick.

d. Provide MTS services remotely, to the greatest extent possible.

e. Notify MTS within 24 hours of becoming aware of any employee who has been on site at

any MTS building, or in contact with any MTS employee, that has a confirmed or suspected

case of COVID-19.

f. Notify MTS immediately if Contractor believes, or has reason to believe, Contractor will be

unable to provide services or goods under this Contract.

g. Agrees that MTS is not responsible for any costs, and will not be invoiced for any incomplete

work, if MTS revokes permission for Contractor’s employees to be on MTS property due to

that employee exhibiting symptoms of COVID-19, or any other illness.

6. OWNERSHIP OF DATA.


Upon completion of the work or upon termination of the Contract, it is understood that all

completed or partially completed data, drawings, records, computations, survey information, and

all other material that Contractor has collected or prepared in carrying out this Contract shall be

provided to and become the exclusive property of MTS Therefore, any reports, information and

data, given to or prepared or assembled by Contractor under this Contract shall not be made

available to any individual or organization by Contractor without the prior written approval of

MTS.

No reports or documents produced in whole or in part under this Contract shall be the subject of

an application for copyright by or on behalf of the Contractor.

7. RIGHTS OF ACCESS AND AUDIT.

The Contractor, Lessee, or other party to the contract, its officers, directors, agents, partners and

employees shall allow MTS and Milwaukee County Audit Services Division and department

contract administrators (collectively referred to as Designated Personnel) and any other party the

Designated Personnel may name, with or without notice, to audit, examine and make copies of

any and all records of the Contractor, Lessee, or other party to the contract, related to the terms

and performance of the Contract for a period of up to three years following the date of last

payment, the end date of this contract, or activity under this contract, whichever is later. Any

subcontractors or other parties performing work on this Contract will be bound by the same

terms and responsibilities as the Contractor. All subcontracts or other agreements for work

performed on this Contract will include written notice that the subcontractors or other parties

understand and will comply with the terms and responsibilities. The Contractor, Lessee, or other

party to the contract, and any subcontractors understand and will abide by the requirements of

Chapter Section 34.09 (Audit) and Section 34.095 (Investigations concerning fraud, waste, and

abuse) of the Milwaukee County Code of General Ordinances.

8. AFFIRMATIVE ACTION.

The Contractor assures that it will undertake an affirmative action program as required by

Milwaukee County Code of General Ordinances (MCCGO) 56.17(1d), to insure that no person

shall, on the grounds of race, creed, color, national origin, or sex be excluded from participating

in any employment activities covered in MCCGO 56.17(1d). The Contractor assures that no

person shall be excluded, on these grounds, from participating in or receiving the services or

benefits of any program or activity covered by this subpart. The Contractor assures that it will

require that its covered organizations provide assurances to the Contractor that they similarly will

undertake affirmative action programs and that they will require assurances from their

suborganizations, as required by MCCGO 56.17(1d), to the same effect.

9. TARGETED BUSINESS ENTERPRISES.

Contractor shall comply with all provisions imposed by or pursuant to Milwaukee County Code

of General Ordinances Chapter 42 when and where applicable, and as said Ordinance may be

amended. The County shall notify Contractor in the event that new ordinances are issued.

10. NON-DISCRIMINATION, EQUAL EMPLOYMENT OPPORTUNITY AND AFFIRMATIVE

ACTION PROGRAMS.

In the performance of work or execution of this contract, the Contractor shall not discriminate

against any employee or applicant for employment because of race, color, national origin or

ancestry, age, sex, sexual orientation, gender identity and gender expression, disability, marital

status, family status, lawful source of income, or status as a victim of domestic abuse, sexual

assault or stalking, which shall include but not be limited to the following: employment,

upgrading, demotion or transfer; recruitment or recruitment advertising; layoff or termination;

rates of pay or other forms of compensation; and selection for training including apprenticeships.

A violation of this provision shall be sufficient cause for MTS to terminate the Contract without

liability for the uncompleted portion or for any materials or services purchased or paid for by the

Contractor for use in completing the contract.

The Contractor agrees that it will strive to implement the principles of equal employment

opportunities through an effective affirmative action program, and will so certify prior to the

award of the Contract, which program shall have as its objective to increase the utilization of

women, minorities and handicapped persons, and other protected groups, at all levels of

employment in all divisions of the contractor's workforce, where these groups may have been

previously under-utilized and under-represented. The Contractor also agrees that in the event of

any dispute as to compliance with the aforestated requirements, it shall be his/her responsibility

to show that he/she has met all such requirements.

The Contractor agrees that it will strive to implement the principles of active and aggressive

efforts to assist MTS in meeting or exceeding its overall annual goal of participation of target

enterprise firms.

When a violation of the non-discrimination, equal opportunity or Affirmative Action provisions

of this section has been determined by MTS. Contractor shall immediately be informed of the

violation and directed to take all action necessary to halt the violation, as well as such action as

may be necessary to correct, if possible, any injustice to any person adversely affected by the

violation, and immediately take steps to prevent further violations.

If, after notice of a violation to Contractor, further violations of the section are committed during

the term of the Contract, MTS may terminate the Contract without liability for the uncompleted

portion or any materials or services purchased or paid for by the Contractor for use in completing

the Contract, or it may permit Contractor to complete the Contract, but, in either event,

Contractor shall be ineligible to bid on any future contracts let by County.

11. INDEMNITY.

Contractor agrees to the fullest extent permitted by law, to indemnify, defend and hold harmless,

MTS and its agents, officers and employees, from and against all loss or expense including costs

and attorney’s fees by reason of statutory benefits under Workers’ Compensation Laws, or liability

for damages including suits at law or in equity, caused by any wrongful, intentional, or negligent

act or omission of Contractor, or its (their) agents which may arise out of or are connected with

the activities covered by this Contract.

Contractor shall indemnify and save MTS harmless from any award of damages and costs against

MTS for any action based on U.S. patent or copyright infringement regarding computers programs

involved in the performance of the tasks and services covered by this Agreement.

12. INSURANCE.

Contractor agrees to maintain policies of insurance and proof of financial responsibility to

cover costs as may arise from claims for damages to property of and/or claims which may

arise out of or result from Contractors activities, by whomever performed, in such coverage

and amounts as required and approved by MTS. Acceptable proof of such coverage shall be

furnished to MTS prior to commencement of activities under this agreement. A Certificate of

Insurance inc lud ing dec l a ra t ions page, shall be submitted for review for each

successive period of coverage for the duration of this agreement, unless otherwise specified by

MTS, in the minimum amounts specified below.

Contractor shall provide evidence of the following coverages and minimum amounts:

Type of Coverage Minimum Limits

Wisconsin Workers’ Compensation and

Employer’s Liability & Disease

Statutory/Waiver of Subrogation

$100,000/$500,000/$100,000

General Liability

Bodily Injury and Property Damage to

include: Personal Injury, Fire, Products

and Completed Operations

$1,000,000 Per Occurrence

$2,000,000 Aggregate

Automobile Liability

Bodily Injury and Property Damage

All Autos

$1,000,000 Per Accident

Professional Liability

Refer to Additional Provision A.1.



Umbrella Liability

Policy will follow form to underlying

Employer’s, General, and Automobile

Liability policies



Milwaukee Transport Services, Inc (MTS) and Milwaukee County shall be named as an

Additional Insured on the General and Automobile L iability policies as respects the services

provided in this agreement. A Waiver of Subrogation shall be afforded to MTS on the

Workers' Compensation policy. A thirty (30) day written notice of cancellation or non-renewal

shall be afforded to Milwaukee County.

The insurance specified above shall be placed with a Carrier approved to do business in the

State of Wisconsin. All carriers must be A rated or better per AM Best's Rating Guide. Any

requests for deviations from or waivers of required coverages or minimums shall be submitted

in writing and approved by MTS’s Risk Manager as a condition of this agreement.

A.1. Professional Liability – Additional Provision.

Contractor agrees to provide additional information on its professional liability coverage as

respects policy type, i.e. errors and omissions for consultants, architects, and/or engineers, etc.;

applicable retention levels; coverage form, i.e. claims made, occurrence; discover clause

conditions, and effective retroactive and expiration dates, to MTS’s Procurement Department as

may be requested to obtain approval of coverage as respects this section.

It is understood and agreed that coverage which applies to the services inherent in this agreement

will be extended for two (2) years after completion of all work contemplated on this project if

coverage is written on a claims-made basis.

13. PERMITS, TAXES, LICENSES.

Contractor is responsible for procuring, maintaining and paying for all necessary federal, state,

and local permits, licenses, fees and taxes required to carry out the provisions of this Contract.

14. TERMINATION BY CONTRACTOR.

Contractor may, at its option, terminate this Contract upon the failure of MTS to pay any amount

that may become due hereunder for a period of sixty (60) days following submission of appropriate

billing and supporting documentation. Upon said termination, Contractor shall be paid the

compensation due for all services rendered through the date of termination including any retainage.

15. TERMINATION BY MTS FOR VIOLATIONS BY CONTRACTOR.

If the Contractor fails to fulfill its obligations under this Contract in a timely or proper manner, or

violates any of its provisions, MTS shall there upon have the right to terminate it by giving thirty

(30) days written notice of termination of contract, specifying the alleged violations, and effective

date of termination. It shall not be terminated if, upon receipt of the notice, Contractor promptly

cures the alleged violation prior to the end of the thirty (30) day period. In the event of termination,

MTS will only be liable for services rendered through the date of termination and not for the

uncompleted portion, or for any materials or services purchased or paid for by Contractor for use

in completing the Contract.

16. UNRESTRICTED RIGHT OF TERMINATION BY MTS.

MTS further reserves the right to terminate the Contract at any time for any reason by giving

Contractor thirty (30) days written notice of such termination. In the event of said termination, the

Contractor shall reduce its activities hereunder as mutually agreed to, upon receipt of said notice,

and turn over all work product to MTS. Upon said termination, Contractor shall be paid for all

services rendered through the date of termination.

17. CONTINUITY OF SERVICE.

Contractor recognizes that the services under this contract are vital to MTS and must be continued

without interruption and that, upon contract expiration or termination, a successor, either MTS or

another contractor, may continue them. Contractor agrees to:

a. Furnish phase-in, phase-out services for up to 30 days after this contract expires or

terminates for any reason; and (ii) negotiate in good faith a plan with a successor to

determine the nature and extent of phase-in, phase-out services required. The plan shall

specify a training program and a date for transferring responsibilities for each division of

work described in the plan, and shall be subject to MTS approval. Contractor shall provide

sufficient experienced personnel during the phase-in, phase-out period to ensure that the

services called for by this contract are maintained at the required level of proficiency.

b. Contractor shall allow as many personnel as practicable to remain on the job to help the

successor maintain the continuity and consistency of the services required by this contract.

Contractor also shall disclose necessary personnel records and allow the successor to

conduct on-site interviews with these employees. If selected employees are agreeable to

the change, Contractor shall release them at a mutually agreeable date and negotiate transfer

of their earned fringe benefits to the successor.

18. INDEPENDENT CONTRACTOR.

Nothing contained in this Contract shall constitute or be construed to create a partnership or joint

venture between MTS or its successors or assigns and Contractor or its successors or assigns. In

entering into this Contract, and in acting in compliance herewith, Contractor is at all times acting

and performing as an independent contractor, duly authorized to perform the acts required of it

hereunder. Nothing contained in this Contract shall give Contractor any authority to supervise,

manage, and/or direct MTS employees.

19. SUBCONTRACTS.

Assignment of any portion of the work by subcontract must have the prior written approval of

County.

20. ASSIGNMENT LIMITATION.

This Contract shall be binding upon and inure to the benefit of the parties and their successors and

assigns; provided, however, that neither party shall assign its obligations hereunder without the

prior written consent of the other.

21. PROHIBITED PRACTICES.

The following practices are prohibited during the term of this contract:

a. Contractor during the period of this contract shall not hire, retain or utilize for

compensation any member, officer, or employee of MTS or any person who, to the

knowledge of Contractor, has a conflict of interest.

b. Contractor hereby attests that it is familiar with Milwaukee County’s Code of Ethics, which

applies to MTS employees, and which states, in part, “No person may offer to give to any

County officer or employee or his immediate family, and no County officer or employee

or his immediate family, may solicit or receive anything of value pursuant to an

understanding that such officer’s or employee’s vote, official actions or judgment would

be influenced thereby” and will not offer or give anything of value to any MTS employee.

22. PUBLIC RECORDS.

Both parties understand that MTS is bound by the public records law, and as such, all of the terms

of this agreement are subject to and conditioned on the provisions of Wis. Stat. § 19.21, et seq.

Contractor hereby agrees that it shall be obligated to assist MTS in retaining and timely producing

records that are subject to the Wisconsin Public Records Law upon any statutory request having

been made, and that any failure to do so shall constitute a material breach of this agreement,

whereupon the contractor shall then and in such event be obligated to indemnify, defend and hold

MTS harmless from liability under the Wisconsin Public Records Law occasioned by such breach.

Except as otherwise authorized by MTS in writing, records that are subject to the Wisconsin Public

Records Law shall be maintained for a period of three years after receipt of final payment under

this agreement.

23. TAXES.

MTS is exempt from Federal Excise Taxes and Wisconsin State Sales Taxes. Any billing

submitted by Contractor must be without such taxes. Including taxes on invoices will delay

payment.

24. NON-CONVICTION FOR BRIBERY.

Contractor hereby declares and affirms that, to the best of its knowledge, none of its officers,

directors, or partners or employees directly involved in obtaining contracts has been convicted of

bribery, attempted bribery, or conspiracy to bribe under the laws of any state or the federal

government.

25. CONFIDENTIALITY.

Contractor agrees that all work product and oral reporting shall be provided only to or as directed

by the individual who is signing this Contract on behalf of MTS, below, and not any other person

or entity, including any other MTS employee or official. Contractor further agrees that, aside from

obligations under the public records law as more fully described in Sec. 23 of this Contract and as

determined in cooperation with MTS Contractor shall maintain all materials and communications

developed under or relating to this Contract as confidential and shall disclose them only to or as

directed by the individual who is signing this Contract on behalf of MTS. Contractor understands

that breach of confidentiality, especially regarding information that is not subject to public records

law disclosure, may harm or create liability for MTS and may require Contractor to indemnify

MTS as provided in Sec. 12 of this Contract.

26. NOTICES.

All notices with respect to this Contract shall be in writing. Except as otherwise expressly provided

in this Agreement, a notice shall be deemed duly given and received upon delivery, if delivered by

hand, or three days after posting via US Mail, to the party addressed as follows:

To Contractor: To MTS:

Attn.: Attn.: Materials Management

Address: Address: 1942 N. 17th St

Milwaukee, WI 53205

Either party may designate a new address for purposes of this Contract by written notice to the

other party.

27. MISCELLANEOUS.

This Contract shall be interpreted and enforced under the laws and jurisdiction of the State of

Wisconsin.

This Contract constitutes the entire understanding between the parties and is not subject to

amendment unless agreed upon in writing by both parties.

28. LIQUIDATED DAMAGES

a. Contractor shall agree to reimburse MTS $115/hr. for any labor or charges incurred to repair

or address any quality defects in Contractor’s manufacturing that must be addressed

immediately. This rate includes towing costs for any buses that are unable to drive back to

MTS property due to Contractor’s poor manufacturing.

b. In the event that Contractor fails to comply with a request from MTS to repair, replace

materials, correct defective work, equipment, or accessories, MTS shall, upon written notice

to Contractor, have the authority to deduct the cost(s) incurred by MTS to address the request

from the next payment due under the contract.

29. FEDERAL LAWS, REGULATIONS, AND REQUIREMENTS.

Contractor acknowledges and agrees that it will perform its obligations hereunder in compliance

with all applicable state, local or federal law, rules and regulations and orders.

30. COUNTERPARTS.

This Agreement may be executed in counterparts, each of which is deemed an original, but all of

which together are deemed to be one and the same agreement. A signed copy of this Agreement

delivered by facsimile, e-mail, or other means of electronic transmission is deemed to have the

same legal effect as delivery of an original signed copy of this Agreement.

31. AUTHORIZATION.

IN WITNESS WHEREOF, this contract is effective on the date of the last acquired signature.

Signer for Contractor warrants they are authorized to sign on behalf of Contractor.

CONTRACTOR

By: _________________________________ Date: _________________________

Signed

__________________________________ __________________________

Name Printed Title

Milwaukee Transport Services, Inc

By: _________________________________ Date: __________________________

Signed

__________________________________ __________________________

Name Printed Title

EQUAL EMPLOYMENT OPPORTUNITY CERTIFICATE

FOR

MILWAUKEE COUNTY CONTRACTS

In accordance with Section 56.17 of the Milwaukee County General Ordinances and Title 41 of the

Code of Federal Regulations, Chapter 60, SELLER or SUCCESSFUL BIDDER or CONTRACTOR or

LESSEE or (other-specify) _______________________________________

(henceforth referred to as VENDOR), certifies to MILWAUKEE COUNTY as to the following and

agrees that the terms of this certificate are hereby incorporated by reference into any contract awarded.

Non-Discrimination

VENDOR certifies that it will not discriminate against any employee or applicant for employment

because of race, color, national origin, age, sex or disability, which includes, but is not limited to the

following: employment, upgrading, demotion or transfer, recruitment or recruitment advertising, layoff

or termination, rates of pay or other forms of compensation, and selection for training including

apprenticeship.

VENDOR will post, in conspicuous places available to its employees, notices to be provided by the

County setting forth the provisions of the non-discriminatory clause.

A violation of this provision shall be sufficient cause for the County to terminate the contract without

liability for the uncompleted portion or for any materials or services purchased or paid for by the

contractor for use in completing the contract.

Affirmative Action Program

VENDOR certifies that it will strive to implement the principles of equal employment opportunity

through an effective affirmative action program, which shall have as its objective to increase the

utilization of women, minorities, and persons with disabilities and other protected groups, at all levels of

employment in all divisions of the seller, successful respondent or contractor’s work force, where these

groups may have been previously under-utilized and under-represented.

Non-Segregated Facilities

VENDOR certifies that it does not and will not maintain or provide for its employees any segregated

facilities at any of its establishments, and that it does not permit its employees to perform their services

at any location under its control where segregated facilities are maintained.

Subcontractors

VENDOR certifies that it has obtained or will obtain certifications regarding non-discrimination,

affirmative action program and non-segregated facilities from proposed subcontractors that are directly

related to any contracts with Milwaukee County, if any, prior to the award of any sub-contracts, and that

it will retain such certifications in its files.

Reporting Requirements

Where applicable, VENDOR certifies that it will comply with all reporting requirements and procedures

in Title Code 41 Code of Federal Regulations, Chapter 60.

Affirmative Action Plan

VENDOR certifies that, if it has 50 or more employees, it has filed or will develop and submit (within

120 days of contract award) for each of its establishments a written affirmative action plan. Current

affirmative action plans, if required, must be filed with ANY one of the following: The Office of Federal

Contract Compliance Programs, or the State of Wisconsin, or the Milwaukee County Department of

Audit, Milwaukee County - City Campus, 9th Floor, 2711 W. Wells Street, Milwaukee, Wisconsin

53208. If a current plan has been filed, indicate where filed and the year

covered . Please provide proof of your AA Plan approval.

VENDOR will also require its lower-tier subcontractors who have 50 or more employees to establish

similar written affirmative action plans.

Employees

VENDOR certifies that it has employees in the Standard Metropolitan

(No. of Employees)

Statistical Area (Wisconsin Counties of Milwaukee, Waukesha, Ozaukee and Washington) and _______

employees in total. (Total No. of Employees)

Compliance

VENDOR certifies that it is not currently in receipt of any outstanding letters of deficiencies, show

cause, probable cause, or other notification of noncompliance with EEO regulations.

Executed this day of 20 by:

Name and Title:________________________________________________________________

Firm Name: ___________________________________________________________________

Address:______________________________________________________________________

City/State/Zip:__________________________________________________________________

Telephone:________________________________FAX: _______________________________

WARNING: An unsigned form shall be considered as a negative response.

By___________________________________________________________________________

(Signature)

______________________________________________________________________________

(Please Print Name Here)

CONFLICT OF INTEREST STATEMENT

________________________________________ hereby certifies that our Firm’s officers and/or

personnel assigned to this project or their immediate family members do not have a Conflict of Interest

performing the duties outlined in our contract(s) with Milwaukee County Transit System (MCTS). To the

best of our knowledge, no officer and/or personnel assigned or their immediate family members has a

material financial interest in any commercial entity which may provide products or services as part of this

MCTS project. If our Firm’s officers and/or personnel that are assigned to this MCTS project become

aware of any development that may create a conflict of interest and compromise the integrity of the project,

they shall notify MCTS immediately and take the necessary action to address the conflict.

Conflict of Interest: A situation in which professional judgment or behavior concerning a primary interest

of a MCTS project has been improperly influenced by a different interest (such as for financial gain).

Immediate family member: spouse/partner or son or daughter.

Material financial interest: ownership or beneficial ownership of more than $10,000 worth of equity or

one percent of the stock in a commercial entity.

(Name of Company)

(Authorized Name, Print) (Title)

(Name of Assigned Consultant, Print) (Signature of Consultant)

____________________________________

(Date)

BUY AMERICA REQUIREMENTS

49 U.S.C. 5323(j) 49 CFR Part 661

Applicability to Contracts The Buy America requirements apply to the following types of contracts: Construction Contracts and Acquisition of Goods or Rolling Stock (valued at more than $100,000).

Flow Down Requirements: The Buy America requirements flow down from FTA recipients and subrecipients to first tier contractors, who are responsible for ensuring that lower tier contractors and subcontractors are in compliance. The $100,000 threshold applies only to the grantee contract, subcontracts under that amount are subject to Buy America.

Mandatory Clause/Language: The Buy America regulation, at 49 CFR 661.13, requires notification of the Buy America requirements in FTA-funded contracts, but does not specify the language to be used. The following language has been developed by FTA.

Buy America - The contractor agrees to comply with 49 U.S.C. 5323(j) and 49 C.F.R. Part 661, which provide that Federal funds may not be obligated unless steel, iron, and manufactured products used in FTA-funded projects are produced in the United States, unless a waiver has been granted by FTA or the product is subject to a general waiver. General waivers are listed in 49 C.F.R. 661.7, and include final assembly in the United States for 15 passenger vans and 15 passenger wagons produced by Chrysler Corporation, and microcomputer equipment and software. Separate requirements for rolling stock are set out at 49 U.S.C. 5323(j)(2)(C) and 49 C.F.R. 661.11. Rolling stock must be assembled in the United States and have a 60 percent domestic content.

A bidder or offeror must submit to the FTA recipient the appropriate Buy America certification (below) with all bids or offers on FTA-funded contracts, except those subject to a general waiver. Bids or offers that are not accompanied by a completed Buy America certification must be rejected as nonresponsive. This requirement does not apply to lower tier subcontractors.

Certification requirement for procurement of steel, iron, or manufactured products.

Certificate of Compliance with 49 U.S.C. 5323(j)(1)

The bidder or offeror hereby certifies that it will meet the requirements of 49 U.S.C. 5323(j)(1) and the applicable regulations in 49 CFR Part 661.5.

Date ____________________________________________________________

Signature______________________________________________________

Company Name_______________________________________________________

Title _____________________________________________________________

Certificate of Non-Compliance with 49 U.S.C. 5323(j)(1)

The bidder or offeror hereby certifies that it cannot comply with the requirements of 49 U.S.C. 5323(j)(1) and 49 C.F.R. 661.5, but it may qualify for an exception pursuant to 49 U.S.C. 5323(j)(2)(A), 5323(j)(2)(B), or 5323(j)(2)(D), and 49 C.F.R. 661.7.

Date _________________________________________________________________

Signature ___________________________________________________________

Company Name _________________________________________________________

Title _______________________________________________________________

Certification requirement for procurement of buses, other rolling stock and associated equipment.

Certificate of Compliance with 49 U.S.C. 5323(j)(2)(C).

The bidder or offeror hereby certifies that it will comply with the requirements of 49 U.S.C. 5323(j)(2)(C) and the regulations at 49 C.F.R. Part 661.11.

Date _________________________________________________________________

Signature ____________________________________________________________

Company Name ____________________________________________________________

Title _________________________________________________________________

Certificate of Non-Compliance with 49 U.S.C. 5323(j)(2)(C)

The bidder or offeror hereby certifies that it cannot comply with the requirements of 49 U.S.C. 5323(j)(2)(C) and 49 C.F.R. 661.11, but may qualify for an exception pursuant to 49 U.S.C. 5323(j)(2)(A), 5323(j)(2)(B), or 5323(j)(2)(D), and 49 C.F.R. 661.7.

Date _______________________________________________________________

Signature ____________________________________________________________

Company Name ________________________________________________________

Title _______________________________________________________________

False Claims Act Form

A recent amendment to the Federal Acquisition Regulation requires contractors to disclose violations of

criminal law and the False Claims Act in connection with the award and performance of government

contracts and subcontracts.

By signing this form, it assures Milwaukee Transport Services, Inc., that Contractors are subject to

debarment and suspension from government contracting for knowingly failing to disclose such violations

and overpayments on government contracts in a timely manner.

Date: _____________

Submitted by: ________________________________________________________

Name of firm: _______________________________________________________

Address of firm: ______________________________________________________

Signed per: __________________________________________________________ (manual signature required)

Print name: __________________________________________________________

Title: __________________________________Email: ________________________

Telephone: ___________________________Fax: ____________________________

CERTIFICATION REGARDING

DEBARMENT, SUSPENSION, PROPOSED DEBARMENT, AND

OTHER RESPONSIBILITY MATTERS

A. The Proposer certifies to the best of its knowledge and belief that it and its principals:

1. Are not presently debarred, suspended, proposed for disbarment, declared ineligible, or voluntarily

excluded from covered transactions by any Federal department or agency;

2. Have not within a ten-year period preceding this application been convicted of or had a civil judgment

rendered against them for commission of fraud or a criminal offense in connection with obtaining,

attempting to obtain, or performing a public (Federal, State, or local) transaction or contract under a

public transaction; violation of Federal or State antitrust statutes or commission of embezzlement, theft,

forgery, bribery, falsification or destruction of records, making false statements, or receiving stolen

property;

3. Are not presently indicted for or otherwise criminally or civilly charged by a governmental entity

(Federal, State, or local) with commission of any of the offenses enumerated in paragraph (A)(2) of this

certification; and

4. Have not within a three-year period preceding this application had one or more public transactions

(Federal, State, or local) terminated for cause or default.

B. Where the prospective primary participant is unable to certify to any of the statements in this

certification, such prospective primary participant shall attach an explanation to this proposal.

Contractor Name: _________________________________________________________

Date: ___________________________________________________________________

By: _____________________________________________________________________

DUNS #: ________________________________________________

Name and Title of Authorized Representative: __________________________________

Signature of Authorized Representative: _______________________________________ Form 1220 12.19.2016

NON-COLLUSION AFFIDAVIT

The undersigned bidder or agent, being duly sworn on oath, says that he/she has not, nor has any other member, representative, or agent of the firm, company, corporation or partnership represented by him, entered into any combination, collusion or agreement with any person relative to the price to be bid by anyone at such letting nor to prevent any person from bidding nor to include anyone to refrain from bidding, and that this bid is made without reference to any other bid and without any agreement, understanding or combination with any other person in reference to such bidding. He/She further says that no person or persons, firms, or corporation has, have or will receive directly or indirectly, any rebate, fee gift, commission or thing of value on account of such sale.

OATH AND AFFIRMATION

I HEREBY AFFIRM UNDER THE PENALTIES FOR PERJURY THAT THE FACTS AND INFORMATION CONTAINED IN THE FOREGOING BID FOR PUBLIC WORKS ARE TRUE AND CORRECT. Dated this ___ day of ____________________, ________ _________________________________________________ (Name of Organization) (Title of Person Signing) (Signature)

ACKNOWLEDGEMENT

STATE OF _______________________) ) ss COUNTY OF_____________________) Before me, a Notary Public, personally appeared the above named and swore that the statements contained in the foregoing document are true and correct. Subscribed and sworn to me this _______ day of _____________, _______. ______________________________ Notary Public Signature My Commission Expires: __________________________________________________

September 2019

U.S. GOVERNMENT REQUIRED CLAUSES

Fly America Requirements – Applicability – all contracts involving transportation of persons

or property, by air between the U.S. and/or places outside the U.S. These requirements do not

apply to micro-purchases ($10,000 or less, except for construction contracts over $2,000).

Contractor shall comply with 49 USC 40118 (the “Fly America” Act) in accordance with

General Services Administration regulations 41 CFR 301-10, stating that recipients and

subrecipients of Federal funds and their contractors are required to use US Flag air carriers for

US Government-financed international air travel and transportation of their personal effects or

property, to the extent such service is available, unless travel by foreign air carrier is a matter of

necessity, as defined by the Fly America Act. Contractor shall submit, if a foreign air carrier was

used, an appropriate certification or memorandum adequately explaining why service by a US

flag air carrier was not available or why it was necessary to use a foreign air carrier and shall, in

any event, provide a certificate of compliance with the Fly America requirements. Contractor

shall include the requirements of this section in all subcontracts that may involve international air

transportation.

Buy America Requirements – Applicability – Construction Contracts and Acquisition of Goods

or Rolling Stock (valued at more than $150,000)

Contractor shall comply with 49 USC 5323(j) and 49 CFR 661, stating that Federal funds may

not be obligated unless steel, iron, and manufactured products used in FTA-funded projects are

produced in the United States, unless a waiver has been granted by FTA or the product is subject

to a general waiver. General waivers are listed in 49 CFR 661.7, and include software,

microcomputer equipment and small purchases (currently less than $150,000) made with capital,

operating, or planning funds. Separate requirements for rolling stock are stated at 5323(j)(2)(C)

and 49 CFR 661.11. Rolling stock must be manufactured in the US and have a minimum 60%

domestic content for FY2016 and FY2017, a minimum 65% domestic content for FY2018 and

FY2019 and a minimum 70% domestic content for FY2020 and beyond. A bidder or offeror

shall submit appropriate Buy America certification to the recipient with all bids on FTA-funded

contracts, except those subject to a general waiver. Proposals not accompanied by a completed

Buy America certification shall be rejected as nonresponsive. This requirement does not apply to

lower tier subcontractors.

Charter Bus Requirements – Applicability – Operational Service Contracts. These

requirements do not apply to micro-purchases ($10,000 or less, except for construction contracts

over $2,000).

Contractor shall comply with 49 USC 5323(d) and (g) and 49 CFR 604, which state that

recipients and subrecipients of FTA assistance may provide charter service for transportation

projects that uses equipment or facilities acquired with Federal assistance authorized under the

Federal transit laws (except as permitted by 49 CFR 604.2), or under 23 U.S.C. 133 or 142, only

in compliance with those laws and FTA regulations, “Charter Service,” 49 CFR part 604, the

terms and conditions of which are incorporated herein by reference.

School Bus Requirements – School Bus Requirements – Applicability – Operational Service

Contracts. These requirements do not apply to micro-purchases ($10,000 or less, except for

construction contracts over $2,000). Pursuant to 69 USC 5323(f) or (g) as amended by MAP-21,

23 USC 133, 23 USC 142, and 49 CFR 605, recipients and subrecipients of FTA assistance shall

September 2019

not engage in school bus operations exclusively for transportation of students and school

personnel in competition with private school bus operators unless qualified under specified

exemptions. When operating exclusive school bus service under an allowable exemption,

recipients and subrecipients shall not use federally funded equipment, vehicles, or facilities.

Violations. If a Recipient or any Third-Party Participant that has operated school bus service in

violation of FTA’s School Bus laws and regulations, FTA may: (1) Require the Recipient or

Third-Party Participant to take such remedial measures as FTA considers appropriate, or (2) Bar

the Recipient or Third Party Participant from receiving Federal transit funds.

Cargo Preference - Use of US-Flag Vessels – Applicability – Contracts involving equipment,

materials or commodities which may be transported by ocean vessels. These requirements do

not apply to micro-purchases ($10,000 or less, except for construction contracts over $2,000).

Contractor shall: a. use privately owned US-Flag commercial vessels to ship at least 50% of the

gross tonnage (computed separately for dry bulk carriers, dry cargo liners, and tankers) involved,

whenever shipping any equipment, material, or commodities pursuant to the underlying contract

to the extent such vessels are available at fair and reasonable rates for US flag commercial

vessels; b. furnish within 20 working days following the loading date of shipments originating

within the US or within 30 working days following the loading date of shipments originating

outside the US, a legible copy of a rated, "on-board" commercial bill-of-lading in English for

each shipment of cargo described herein to the Division of National Cargo, Office of Market

Development, Maritime Administration, Washington, DC 20590 and to the recipient (through

contractor in the case of a subcontractor's bill-of-lading.) c. include these requirements in all

subcontracts issued pursuant to this contract when the subcontract involves the transport of

equipment, material, or commodities by ocean vessel.

Seismic Safety – Applicability – Construction of new buildings or additions to existing

buildings. These requirements do not apply to micro-purchases ($10,000 or less, except for

construction contracts over $2,000). Contractor agrees that any new building or addition to an

existing building shall be designed and constructed in accordance with the standards required in

USDOT Seismic Safety Regulations 49 CFR 41 and shall certify compliance to the extent

required by the regulation. Contractor shall also ensure that all work performed under this

contract, including work performed by subcontractors, complies with the standards required by

49 CFR 41 and the certification of compliance issued on the project.

Energy Conservation – Applicability – All Contracts except micro-purchases ($10,000 or less,

except for construction contracts over $2,000) Contractor shall comply with mandatory standards

and policies relating to energy efficiency, stated in the state energy conservation plan issued in

compliance with the Energy Policy & Conservation Act.

Clean Water – Applicability – All Contracts and Subcontracts over $150,000. Contractor shall

comply with all applicable standards, orders or regulations issued pursuant to the Federal Water

Pollution Control Act, as amended, 33 USC 1251 et seq. Contractor shall report each violation to

the recipient and understands and agrees that the recipient shall, in turn, report each violation as

required to FTA and the appropriate EPA Regional Office. Contractor shall include these

requirements in each subcontract exceeding $150,000 financed in whole or in part with FTA

assistance.

September 2019

Bus Testing – Applicability – Rolling Stock/Turnkey

Contractor [manufacturer] shall comply with 49 USC A5323(c) and FTA's implementing

regulation 49 CFR 665 and shall perform the following:

1) A manufacturer of a new bus model or a bus produced with a major change in components or

configuration shall provide a copy of the final test report to the recipient prior to the recipient's

final acceptance of the first vehicle.

2) A manufacturer who releases a report under para. 1 above shall provide notice to the operator

of the testing facility that the report is available to the public.

3) If the manufacturer represents that the vehicle was previously tested, the vehicle being sold

should have the identical configuration and major components as the vehicle in the test report,

which must be provided to the recipient prior to the recipient's final acceptance of the first

vehicle. If configuration or components are not identical, the manufacturer shall provide a

description of the change and the manufacturer's basis for concluding that it is not a major

change requiring additional testing.

4) If the manufacturer represents that the vehicle is "grandfathered" (has been used in mass

transit service in the US before Oct. 1, 1988, and is currently being produced without a major

change in configuration or components), the manufacturer shall provide the name and address of

the recipient of such a vehicle and the details of that vehicle's configuration and major

components.

Pre-Award & Post-Delivery Audit Requirements - Applicability – Rolling Stock/Turnkey

Contractor shall comply with 49 USC 5323(l) and FTA's implementing regulation 49 CFR 663

and submit the following certifications:

1) Buy America Requirements: Contractor shall complete and submit a declaration

certifying either compliance or noncompliance with Buy America. If contractor certifies

compliance with Buy America, it shall submit documentation listing:

A. Component and subcomponent parts of the rolling stock to be purchased

identified by manufacturer of the parts, their country of origin and costs; and

B. The location of the final assembly point for the rolling stock, including a

description of the activities that will take place at the final assembly point and the

cost of final assembly.

C. Solicitation Specification Requirements: Contractor shall submit evidence that it

will be capable of meeting the bid specifications.

D. Federal Motor Vehicle Safety Standards (FMVSS): Contractor shall submit 1)

manufacturer's FMVSS self-certification sticker information that the vehicle

complies with relevant FMVSS or 2) manufacturer's certified statement that the

buses will not be subject to FMVSS regulations.

Lobbying – Applicability - Construction/Architectural and Engineering/Acquisition of Rolling

Stock/Professional Service Contract/Operational Service Contract/Turnkey contracts over

September 2019

$100,000

Byrd Anti-Lobbying Amendment, 31 U.S.C. 1352, as amended by the Lobbying Disclosure Act

of 1995, P.L. 104-65 [to be codified at 2 U.S.C. § 1601, et seq.] - Contractors who apply or bid

for an award of $100,000 or more shall file the certification required by 49 CFR part 20, "New

Restrictions on Lobbying." Each tier certifies to the tier above that it will not and has not used

Federal appropriated funds to pay any person or organization for influencing or attempting to

influence an officer or employee of any agency, a member of Congress, officer or employee of

Congress, or an employee of a member of Congress in connection with obtaining any Federal

contract, grant or any other award covered by 31 U.S.C. 1352. Each tier shall also disclose the

name of any registrant under the Lobbying Disclosure Act of 1995 who has made lobbying

contacts on its behalf with non-Federal funds with respect to that Federal contract, grant or award

covered by 31 U.S.C. 1352. Such disclosures are forwarded from tier to tier up to the recipient.

Access to Records and Reports– Applicability – As shown below. These requirements do not

apply to micro-purchases ($10,000 or less, except for construction contracts over $2,000)

The following access to records requirements apply to this Contract:

1. Where the purchaser is not a State but a local government and is an FTA recipient or a

subgrantee of FTA recipient in accordance with 49 CFR 18.36(i), contractor shall provide the

purchaser, the FTA, the US Comptroller General or their authorized representatives access to any

books, documents, papers and contractor records which are pertinent to this contract for the

purposes of making audits, examinations, excerpts and transcriptions. Contractor shall also,

pursuant to 49 CFR 633.17, provide authorized FTA representatives, including any PMO

contractor, access to contractor's records and construction sites pertaining to a capital project,

defined at 49 USC 5302(a)1, which is receiving FTA assistance through the programs described

at 49 USC 5307, 5309 or 5311.

2. Where the purchaser is a State and is an FTA recipient or a subgrantee of FTA recipient in

accordance with 49 CFR 633.17, contractor shall provide the purchaser, authorized FTA

representatives, including any PMO Contractor, access to contractor's records and construction

sites pertaining to a capital project, defined at 49 USC 5302(a)1, which receives FTA assistance

through the programs described at 49 USC 5307, 5309 or 5311. By definition, a capital project

excludes contracts of less than the simplified acquisition threshold currently set at $250,000.

3. Where the purchaser enters into a negotiated contract for other than a small purchase or under

the simplified acquisition threshold and is an institution of higher education, a hospital or other

non-profit organization and is an FTA recipient or a subgrantee of FTA recipient in accordance

with 49 CFR 19.48, contractor shall provide the purchaser, the FTA, the US Comptroller General

or their authorized representatives, access to any books, documents, papers and record of the

contractor which are directly pertinent to this contract for the purposes of making audits,

examinations, excerpts and transcriptions.

4. Where a purchaser which is an FTA recipient or a subgrantee of FTA recipient in accordance

with 49 USC 5325(a) enters into a contract for a capital project or improvement (defined at 49

USC 5302(a)1) through other than competitive bidding, contractor shall make available records

related to the contract to the purchaser, the Secretary of USDOT and the US Comptroller General

or any authorized officer or employee of any of them for the purposes of conducting an audit and

September 2019

inspection.

5. Contractor shall permit any of the foregoing parties to reproduce by any means whatsoever or

to copy excerpts and transcriptions as reasonably needed.

6. Contractor shall maintain all books, records, accounts and reports required under this contract

for a period of not less than three (3) years after the date of termination or expiration of this

contract, except in the event of litigation or settlement of claims arising from the performance of

this contract, in which case contractor agrees to maintain same until the recipient, FTA

Administrator, US Comptroller General, or any of their authorized representatives, have disposed

of all such litigation, appeals, claims or exceptions related thereto. Re: 49 CFR 18.39(i)(11).

FTA does not require the inclusion of these requirements in subcontracts.

Federal Changes – Applicability – All Contracts except micro-purchases ($10,000 or less,

except for construction contracts over $2,000)

Contractor shall comply with all applicable FTA regulations, policies, procedures and directives,

including without limitation those listed directly or by reference in the Master Agreement

between the recipient and FTA, as they may be amended or promulgated from time to time

during the term of the contract. Contractor's failure to comply shall constitute a material breach

of the contract.

Bonding Requirements – Applicability – For those construction or facility improvement

contracts or subcontracts exceeding $250,000, FTA may accept the bonding policy and

requirements of the recipient, provided that they meet the minimum requirements for

construction contracts as follows:

a. A bid guarantee from each bidder equivalent to five (5) percent of the bid price. The "bid

guarantees" shall consist of a firm commitment such as a bid bond, certifies check, or other

negotiable instrument accompanying a bid as assurance that the bidder will, upon acceptance of

his bid, execute such contractual documents as may be required within the time specified.

b. A performance bond on the part to the Contractor for 100 percent of the contract price. A

"performance bond" is one executed in connection with a contract to secure fulfillment of all the

contractor's obligations under such contract.

c. A payment bond on the part of the contractor for 100 percent of the contract price. A

"payment bond" is one executed in connection with a contract to assure payment, as required by

law, of all persons supplying labor and material in the execution of the work provided for in the

contract. Payment bond amounts required from Contractors are as follows:

(1) 50% of the contract price if the contract price is not more than $1 million;

(2) 40% of the contract price if the contract price is more than $1 million but not more than $5

million; or

(3) $2.5 million if the contract price is more than $5 million.

d. A cash deposit, certified check or other negotiable instrument may be accepted by a grantee in

lieu of performance and payment bonds, provided the grantee has established a procedure to

assure that the interest of FTA is adequately protected. An irrevocable letter of credit would also

September 2019

satisfy the requirement for a bond.

Bid Bond Requirements (Construction)

(a) Bid Security - A Bid Bond must be issued by a fully qualified surety company acceptable to

(Recipient) and listed as a company currently authorized under 31 CFR, Part 223 as possessing a

Certificate of Authority as described thereunder.

(b) Rights Reserved - In submitting this Bid, it is understood and agreed by bidder that the right

is reserved by (Recipient) to reject any and all bids, or part of any bid, and it is agreed that the

Bid may not be withdrawn for a period of [ninety (90)] days subsequent to the opening of bids,

without the written consent of (Recipient).

It is also understood and agreed that if the undersigned bidder should withdraw any part or all of

his bid within [ninety (90)] days after the bid opening without the written consent of (Recipient),

shall refuse or be unable to enter into this Contract, as provided above, or refuse or be unable to

furnish adequate and acceptable Performance Bonds and Labor and Material Payments Bonds, as

provided above, or refuse or be unable to furnish adequate and acceptable insurance, as provided

above, he shall forfeit his bid security to the extent of (Recipient's) damages occasioned by such

withdrawal, or refusal, or inability to enter into an agreement, or provide adequate security

therefor.

It is further understood and agreed that to the extent the defaulting bidder's Bid Bond, Certified

Check, Cashier's Check, Treasurer's Check, and/or Official Bank Check (excluding any income

generated thereby which has been retained by (Recipient) as provided in [Item x "Bid Security"

of the Instructions to Bidders]) shall prove inadequate to fully recompense (Recipient) for the

damages occasioned by default, then the undersigned bidder agrees to indemnify (Recipient) and

pay over to (Recipient) the difference between the bid security and (Recipient's) total damages,

so as to make (Recipient) whole.

The undersigned understands that any material alteration of any of the above or any of the

material contained on this form, other than that requested, will render the bid unresponsive.

Performance and Payment Bonding Requirements (Construction)

The Contractor shall be required to obtain performance and payment bonds as follows:

(a) Performance bonds

1. The penal amount of performance bonds shall be 100 percent of the original contract price,

unless the (Recipient) determines that a lesser amount would be adequate for the protection of

the (Recipient).

2. The (Recipient) may require additional performance bond protection when a contract price is

increased. The increase in protection shall generally equal 100 percent of the increase in contract

price. The (Recipient) may secure additional protection by directing the Contractor to increase

the penal amount of the existing bond or to obtain an additional bond.

(b) Payment bonds

1. The penal amount of the payment bonds shall equal:

(i) Fifty percent of the contract price if the contract price is not more than $1 million.

September 2019

(ii) Forty percent of the contract price if the contract price is more than $1 million but not more

than $5 million; or

(iii) Two and one half million if the contract price is more than $5 million.

2. If the original contract price is $5 million or less, the (Recipient) may require additional

protection as required by subparagraph 1 if the contract price is increased.

Performance and Payment Bonding Requirements (Non-Construction)

The Contractor may be required to obtain performance and payment bonds when necessary to

protect the (Recipient's) interest.

(a) The following situations may warrant a performance bond:

1. (Recipient) property or funds are to be provided to the contractor for use in performing the

contract or as partial compensation (as in retention of salvaged material).

2. A contractor sells assets to or merges with another concern, and the (Recipient), after

recognizing the latter concern as the successor in interest, desires assurance that it is financially

capable.

3. Substantial progress payments are made before delivery of end items starts.

4. Contracts are for dismantling, demolition, or removal of improvements.

(b) When it is determined that a performance bond is required, the Contractor shall be required to

obtain performance bonds as follows:

1. The penal amount of performance bonds shall be 100 percent of the original contract price,

unless the (Recipient) determines that a lesser amount would be adequate for the protection of

the (Recipient).

2. The (Recipient) may require additional performance bond protection when a contract price is

increased. The increase in protection shall generally equal 100 percent of the increase in contract

price.

The (Recipient) may secure additional protection by directing the Contractor to increase the

penal amount of the existing bond or to obtain an additional bond.

(c) A payment bond is required only when a performance bond is required, and if the use of

payment bond is in the (Recipient's) interest.

(d) When it is determined that a payment bond is required, the Contractor shall be required to

obtain payment bonds as follows:

1. The penal amount of payment bonds shall equal:

(i) Fifty percent of the contract price if the contract price is not more than $1 million;

(ii) Forty percent of the contract price if the contract price is more than $1 million but not more

than $5 million; or

September 2019

(iii) Two and one half million if the contract price is increased.

Advance Payment Bonding Requirements

The Contractor may be required to obtain an advance payment bond if the contract contains an

advance payment provision and a performance bond is not furnished. The (recipient) shall

determine the amount of the advance payment bond necessary to protect the (Recipient).

Patent Infringement Bonding Requirements (Patent Indemnity)

The Contractor may be required to obtain a patent indemnity bond if a performance bond is not

furnished and the financial responsibility of the Contractor is unknown or doubtful. The

(recipient) shall determine the amount of the patent indemnity to protect the (Recipient).

Warranty of the Work and Maintenance Bonds

1. The Contractor warrants to (Recipient), the Architect and/or Engineer that all materials and

equipment furnished under this Contract will be of highest quality and new unless otherwise

specified by (Recipient), free from faults and defects and in conformance with the Contract

Documents. All work not so conforming to these standards shall be considered defective. If

required by the [Project Manager], the Contractor shall furnish satisfactory evidence as to the

kind and quality of materials and equipment.

2. The Work furnished must be of first quality and the workmanship must be the best obtainable

in the various trades. The Work must be of safe, substantial and durable construction in all

respects. The Contractor hereby guarantees the Work against defective materials or faulty

workmanship for a minimum period of one (1) year after Final Payment by (Recipient) and shall

replace or repair any defective materials or equipment or faulty workmanship during the period

of the guarantee at no cost to (Recipient). As additional security for these guarantees, the

Contractor shall, prior to the release of Final Payment [as provided in Item X below], furnish

separate Maintenance (or Guarantee) Bonds in form acceptable to (Recipient) written by the

same corporate surety that provides the Performance Bond and Labor and Material Payment

Bond for this Contract. These bonds shall secure the Contractor's obligation to replace or repair

defective materials and faulty workmanship for a minimum period of one (1) year after Final

Payment and shall be written in an amount equal to ONE HUNDRED PERCENT (100%) of the

CONTRACT SUM, as adjusted (if at all).

Clean Air – Applicability – All contracts over $150,000. 1) Contractor shall comply with all

applicable standards, orders or regulations pursuant to the Clean Air Act, 42 USC 7401 et seq.

Contractor shall report each violation to the recipient and understands and agrees that the

recipient will, in turn, report each violation as required to FTA and the appropriate EPA

Regional Office. 2) Contractor shall include these requirements in each subcontract exceeding

$150,000 financed in whole or in part with FTA assistance.

Recycled Products – Applicability – All contracts for items designated by the EPA, when the

purchaser or contractor procures $10,000 or more of one of these items during the current or

previous fiscal year using Federal funds. The contractor agrees to comply with all the

requirements of Section 6002 of the Resource Conservation and Recovery Act (RCRA), as

amended (42 U.S.C. 6962), including but not limited to the regulatory provisions of 40 CFR Part

247, and Executive Order 12873, as they apply to the procurement of the items designated in

Subpart B of 40 CFR Part 247.

September 2019

Davis-Bacon and Copeland Anti-Kickback Acts – Applicability -Construction contracts and

subcontracts, including actual construction, alteration and/or repair, including decorating and

painting, over $2,000

(1) Minimum wages - (i) All laborers and mechanics employed or working upon the site of the

work (or under the United States Housing Act of 1937 or under the Housing Act of 1949 in the

construction or development of the project), will be paid unconditionally and not less often than

once a week, and without subsequent deduction or rebate on any account (except such payroll

deductions as are permitted by regulations issued by the Secretary of Labor under the Copeland

Act (29 CFR part 3)), the full amount of wages and bona fide fringe benefits (or cash equivalents

thereof) due at time of payment computed at rates not less than those contained in the wage

determination of the Secretary of Labor which is attached hereto and made a part hereof,

regardless of any contractual relationship which may be alleged to exist between the contractor

and such laborers and mechanics. Contributions made or costs reasonably anticipated for bona

fide fringe benefits under section 1(b)(2) of the Davis-Bacon Act on behalf of laborers or

mechanics are considered wages paid to such laborers or mechanics, subject to the provisions of

paragraph (1)(iv) of this section; also, regular contributions made or costs incurred for more than

a weekly period (but not less often than quarterly) under plans, funds, or programs which cover

the particular weekly period, are deemed to be constructively made or incurred during such

weekly period. Such laborers and mechanics shall be paid the appropriate wage rate and fringe

benefits on the wage determination for the classification of work actually performed, without

regard to skill, except as provided in 29 CFR Part 5.5(a)(4). Laborers or mechanics performing

work in more than one classification may be compensated at the rate specified for each

classification for the time actually worked therein: Provided, That the employer's payroll records

accurately set forth the time spent in each classification in which work is performed. The wage

determination (including any additional classifications and wage rates conformed under

paragraph (1)(ii) of this section) and the Davis-Bacon poster (WH-1321) shall be posted at all

times by the contractor and its subcontractors at the site of the work in a prominent and

accessible place where it can be easily seen by the workers. (ii)(A) The contracting officer shall

require that any class of laborers or mechanics, including helpers, which is not listed in the wage

determination and which is to be employed under the contract shall be classified in conformance

with the wage determination. The contracting officer shall approve an additional classification

and wage rate and fringe benefits therefore only when the following criteria have been met:

(1) Except with respect to helpers as defined as 29 CFR 5.2(n)(4), the work to be performed by

the classification requested is not performed by a classification in the wage determination; and

(2) The classification is utilized in the area by the construction industry; and (3) The proposed

wage rate, including any bona fide fringe benefits, bears a reasonable relationship to the wage

rates contained in the wage determination; and (4) With respect to helpers as defined in 29 CFR

5.2(n)(4), such a classification prevails in the area in which the work is performed. (B) If the

contractor and the laborers and mechanics to be employed in the classification (if known), or

their representatives, and the contracting officer agree on the classification and wage rate

(including the amount designated for fringe benefits where appropriate), a report of the action

taken shall be sent by the contracting officer to the Administrator of the Wage and Hour

Division, Employment Standards Administration, U.S. Department of Labor, Washington, DC

20210. The Administrator, or an authorized representative, will approve, modify, or disapprove

every additional classification action within 30 days of receipt and so advise the contracting

September 2019

officer or will notify the contracting officer within the 30-day period that additional time is

necessary. (C) In the event the contractor, the laborers or mechanics to be employed in the

classification or their representatives, and the contracting officer do not agree on the proposed

classification and wage rate (including the amount designated for fringe benefits, where

appropriate), the contracting officer shall refer the questions, including the views of all interested

parties and the recommendation of the contracting officer, to the Administrator for

determination. The Administrator, or an authorized representative, will issue a determination

within 30 days of receipt and so advise the contracting officer or will notify the contracting

officer within the 30-day period that additional time is necessary. (D) The wage rate (including

fringe benefits where appropriate) determined pursuant to paragraphs (a)(1)(ii) (B) or (C) of this

section, shall be paid to all workers performing work in the classification under this contract

from the first day on which work is performed in the classification.(iii) Whenever the minimum

wage rate prescribed in the contract for a class of laborers or mechanics includes a fringe benefit

which is not expressed as an hourly rate, the contractor shall either pay the benefit as stated in

the wage determination or shall pay another bona fide fringe benefit or an hourly cash equivalent

thereof. (iv) If the contractor does not make payments to a trustee or other third person, the

contractor may consider as part of the wages of any laborer or mechanic the amount of any costs

reasonably anticipated in providing bona fide fringe benefits under a plan or program, Provided,

That the Secretary of Labor has found, upon the written request of the contractor, that the

applicable standards of the Davis-Bacon Act have been met. The Secretary of Labor may require

the contractor to set aside in a separate account assets for the meeting of obligations under the

plan or program. (v)(A) The contracting officer shall require that any class of laborers or

mechanics which is not listed in the wage determination and which is to be employed under the

contract shall be classified in conformance with the wage determination. The contracting officer

shall approve an additional classification and wage rate and fringe benefits therefor only when

the following criteria have been met: (1) The work to be performed by the classification

requested is not performed by a classification in the wage determination; and (2) The

classification is utilized in the area by the construction industry; and (3) The proposed wage

rate, including any bona fide fringe benefits, bears a reasonable relationship to the wage rates

contained in the wage determination.

(B) If the contractor and the laborers and mechanics to be employed in the classification (if

known), or their representatives, and the contracting officer agree on the classification and wage

rate (including the amount designated for fringe benefits where appropriate), a report of the

action taken shall be sent by the contracting officer to the Administrator of the Wage and Hour

Division, Employment Standards Administration, Washington, DC 20210. The Administrator,

or an authorized representative, will approve, modify, or disapprove every additional

classification action within 30 days of receipt and so advise the contracting officer or will notify

the contracting officer within the 30-day period that additional time is necessary.(C) In the event

the contractor, the laborers or mechanics to be employed in the classification or their

representatives, and the contracting officer do not agree on the proposed classification and wage

rate (including the amount designated for fringe benefits, where appropriate), the contracting

officer shall refer the questions, including the views of all interested parties and the

recommendation of the contracting officer, to the Administrator for determination. The

Administrator, or an authorized representative, will issue a determination with 30 days of receipt

and so advise the contracting officer or will notify the contracting officer within the 30-day

period that additional time is necessary. (D) The wage rate (including fringe benefits where

appropriate) determined pursuant to paragraphs (a)(1)(v) (B) or (C) of this section, shall be paid

September 2019

to all workers performing work in the classification under this contract from the first day on

which work is performed in the classification.

(2) Withholding - The recipient shall upon its own action or upon written request of an

authorized representative of the Department of Labor withhold or cause to be withheld from the

contractor under this contract or any other Federal contract with the same prime contractor, or

any other federally-assisted contract subject to Davis-Bacon prevailing wage requirements,

which is held by the same prime contractor, so much of the accrued payments or advances as

may be considered necessary to pay laborers and mechanics, including apprentices, trainees, and

helpers, employed by the contractor or any subcontractor the full amount of wages required by

the contract. In the event of failure to pay any laborer or mechanic, including any apprentice,

trainee, or helper, employed or working on the site of the work (or under the United States

Housing Act of 1937 or under the Housing Act of 1949 in the construction or development of the

project), all or part of the wages required by the contract, the grantee may, after written notice to

the contractor, sponsor, applicant, or owner, take such action as may be necessary to cause the

suspension of any further payment, advance, or guarantee of funds until such violations have

ceased.

(3) Payrolls and basic records - (i) Payrolls and basic records relating thereto shall be maintained

by the contractor during the course of the work and preserved for a period of three years

thereafter for all laborers and mechanics working at the site of the work (or under the United

States Housing Act of 1937, or under the Housing Act of 1949, in the construction or

development of the project). Such records shall contain the name, address, and social security

number of each such worker, his or her correct classification, hourly rates of wages paid

(including rates of contributions or costs anticipated for bona fide fringe benefits or cash

equivalents thereof of the types described in section 1(b)(2)(B) of the Davis-Bacon Act), daily

and weekly number of hours worked, deductions made and actual wages paid. Whenever the

Secretary of Labor has found under 29 CFR 5.5(a)(1)(iv) that the wages of any laborer or

mechanic include the amount of any costs reasonably anticipated in providing benefits under a

plan or program described in section 1(b)(2)(B) of the Davis-Bacon Act, the contractor shall

maintain records which show that the commitment to provide such benefits is enforceable, that

the plan or program is financially responsible, and that the plan or program has been

communicated in writing to the laborers or mechanics affected, and records which show the costs

anticipated or the actual cost incurred in providing such benefits. Contractors employing

apprentices or trainees under approved programs shall maintain written evidence of the

registration of apprenticeship programs and certification of trainee programs, the registration of

the apprentices and trainees, and the ratios and wage rates prescribed in the applicable programs.

(ii)(A) The contractor shall submit weekly for each week in which any contract work is

performed a copy of all payrolls to the recipient for transmission to the Federal Transit

Administration. The payrolls submitted shall set out accurately and completely all of the

information required to be maintained under section 5.5(a)(3)(i) of Regulations, 29 CFR part 5.

This information may be submitted in any form desired. Optional Form WH-347 is available for

this purpose and may be purchased from the Superintendent of Documents (Federal Stock

Number 029-005-00014-1), U.S. Government Printing Office, Washington, DC 20402. The

prime contractor is responsible for the submission of copies of payrolls by all subcontractors. (B)

Each payroll submitted shall be accompanied by a "Statement of Compliance," signed by the

contractor or subcontractor or his or her agent who pays or supervises the payment of the persons

September 2019

employed under the contract and shall certify the following: (1) That the payroll for the payroll

period contains the information required to be maintained under section 5.5(a)(3)(i) of

Regulations, 29 CFR part 5 and that such information is correct and complete; (2) That each

laborer or mechanic (including each helper, apprentice, and trainee) employed on the contract

during the payroll period has been paid the full weekly wages earned, without rebate, either

directly or indirectly, and that no deductions have been made either directly or indirectly from

the full wages earned, other than permissible deductions as set forth in Regulations, 29 CFR part

3; (3) That each laborer or mechanic has been paid not less than the applicable wage rates and

fringe benefits or cash equivalents for the classification of work performed, as specified in the

applicable wage determination incorporated into the contract. (C) The weekly submission of a

properly executed certification set forth on the reverse side of Optional Form WH-347 shall

satisfy the requirement for submission of the "Statement of Compliance" required by paragraph

(a)(3)(ii)(B) of this section.

(D) The falsification of any of the above certifications may subject the contractor or

subcontractor to civil or criminal prosecution under section 1001 of title 18 and section 231 of

title 31 of the United States Code. (iii) The contractor or subcontractor shall make the records

required under paragraph (a)(3)(i) of this section available for inspection, copying, or

transcription by authorized representatives of the Federal Transit Administration or the

Department of Labor, and shall permit such representatives to interview employees during

working hours on the job. If the contractor or subcontractor fails to submit the required records

or to make them available, the Federal agency may, after written notice to the contractor,

sponsor, applicant, or owner, take such action as may be necessary to cause the suspension of

any further payment, advance, or guarantee of funds. Furthermore, failure to submit the required

records upon request or to make such records available may be grounds for debarment action

pursuant to 29 CFR 5.12.

(4) Apprentices and trainees - (i) Apprentices - Apprentices will be permitted to work at less than

the predetermined rate for the work they performed when they are employed pursuant to and

individually registered in a bona fide apprenticeship program registered with the U.S.

Department of Labor, Employment and Training Administration, Bureau of Apprenticeship and

Training, or with a State Apprenticeship Agency recognized by the Bureau, or if a person is

employed in his or her first 90 days of probationary employment as an apprentice in such an

apprenticeship program, who is not individually registered in the program, but who has been

certified by the Bureau of Apprenticeship and Training or a State Apprenticeship Agency (where

appropriate) to be eligible for probationary employment as an apprentice. The allowable ratio of

apprentices to journeymen on the job site in any craft classification shall not be greater than the

ratio permitted to the contractor as to the entire work force under the registered program. Any

worker listed on a payroll at an apprentice wage rate, who is not registered or otherwise

employed as stated above, shall be paid not less than the applicable wage rate on the wage

determination for the classification of work actually performed. In addition, any apprentice

performing work on the job site in excess of the ratio permitted under the registered program

shall be paid not less than the applicable wage rate on the wage determination for the work

actually performed. Where a contractor is performing construction on a project in a locality

other than that in which its program is registered, the ratios and wage rates (expressed in

percentages of the journeyman's hourly rate) specified in the contractor's or subcontractor's

registered program shall be observed. Every apprentice must be paid at not less than the rate

specified in the registered program for the apprentice's level of progress, expressed as a

September 2019

percentage of the journeymen hourly rate specified in the applicable wage determination.

Apprentices shall be paid fringe benefits in accordance with the provisions of the apprenticeship

program. If the apprenticeship program does not specify fringe benefits, apprentices must be

paid the full amount of fringe benefits listed on the wage determination for the applicable

classification. If the Administrator of the Wage and Hour Division of the U.S. Department of

Labor determines that a different practice prevails for the applicable apprentice classification,

fringes shall be paid in accordance with that determination. In the event the Bureau of

Apprenticeship and Training, or a State Apprenticeship Agency recognized by the Bureau,

withdraws approval of an apprenticeship program, the contractor will no longer be permitted to

utilize apprentices at less than the applicable predetermined rate for the work performed until an

acceptable program is approved.(ii) Trainees - Except as provided in 29 CFR 5.16, trainees will

not be permitted to work at less than the predetermined rate for the work performed unless they

are employed pursuant to and individually registered in a program which has received prior

approval, evidenced by formal certification by the U.S. Department of Labor, Employment and

Training Administration. The ratio of trainees to journeymen on the job site shall not be greater

than permitted under the plan approved by the Employment and Training Administration. Every

trainee must be paid at not less than the rate specified in the approved program for the trainee's

level of progress, expressed as a percentage of the journeyman hourly rate specified in the

applicable wage determination. Trainees shall be paid fringe benefits in accordance with the

provisions of the trainee program. If the trainee program does not mention fringe benefits,

trainees shall be paid the full amount of fringe benefits listed on the wage determination unless

the Administrator of the Wage and Hour Division determines that there is an apprenticeship

program associated with the corresponding journeyman wage rate on the wage determination

which provides for less than full fringe benefits for apprentices. Any employee listed on the

payroll at a trainee rate who is not registered and participating in a training plan approved by the

Employment and Training Administration shall be paid not less than the applicable wage rate on

the wage determination for the classification of work actually performed. In addition, any

trainee performing work on the job site in excess of the ratio permitted under the registered

program shall be paid not less than the applicable wage rate on the wage determination for the

work actually performed. In the event the Employment and Training Administration withdraws

approval of a training program, the contractor will no longer be permitted to utilize trainees at

less than the applicable predetermined rate for the work performed until an acceptable program is

approved.

(iii) Equal employment opportunity - The utilization of apprentices, trainees and journeymen

under this part shall be in conformity with the equal employment opportunity requirements of

Executive Order 11246, as amended, and 29 CFR part 30.

(5) Compliance with Copeland Act requirements - The contractor shall comply with the

requirements of 29 CFR part 3, which are incorporated by reference in this contract.

(6) Subcontracts - The contractor or subcontractor shall insert in any subcontracts the clauses

contained in 29 CFR 5.5(a)(1) through (10) and such other clauses as the Federal Transit

Administration may by appropriate instructions require, and also a clause requiring the

subcontractors to include these clauses in any lower tier subcontracts. The prime contractor shall

be responsible for the compliance by any subcontractor or lower tier subcontractor with all the

contract clauses in 29 CFR 5.5.

September 2019

(7) Contract termination: debarment - A breach of the contract clauses in 29 CFR 5.5 may be

grounds for termination of the contract, and for debarment as a contractor and a subcontractor as

provided in 29 CFR 5.12.

(8) Compliance with Davis-Bacon and Related Act requirements - All rulings and interpretations

of the Davis-Bacon and Related Acts contained in 29 CFR parts 1, 3, and 5 are herein

incorporated by reference in this contract.

(9) Disputes concerning labor standards - Disputes arising out of the labor standards provisions

of this contract shall not be subject to the general disputes clause of this contract. Such disputes

shall be resolved in accordance with the procedures of the Department of Labor set forth in 29

CFR parts 5, 6, and 7. Disputes within the meaning of this clause include disputes between the

contractor (or any of its subcontractors) and the contracting agency, the U.S. Department of

Labor, or the employees or their representatives.

(10) Certification of Eligibility - (i) By entering into this contract, contractor certifies that neither

it (nor he or she) nor any person or firm who has an interest in contractor's firm is a person or

firm ineligible to be awarded Government contracts by virtue of section 3(a) of the Davis-Bacon

Act or 29 CFR 5.12(a)(1). (ii) No part of this contract shall be subcontracted to any person or

firm ineligible for award of a Government contract by virtue of section 3(a) of the Davis-Bacon

Act or 29 CFR 5.12(a)(1). (iii) The penalty for making false statements is prescribed in 18 USC

1001.

Contract Work Hours & Safety Standards Act – Applicability – Contracts over $250,000

(1) Overtime requirements - No contractor or subcontractor contracting for any part of the

contract work which may require or involve the employment of laborers or mechanics shall

require or permit any such laborer or mechanic in any workweek in which he or she is employed

on such work to work in excess of 40 hours in such workweek unless such laborer or mechanic

receives compensation at a rate not less than one and one-half times the basic rate of pay for all

hours worked in excess of 40 hours in such workweek.

(2) Violation; liability for unpaid wages; liquidated damages - In the event of any violation of the

clause set forth in para. (1) of this section, contractor and any subcontractor responsible therefore

shall be liable for the unpaid wages. In addition, such contractor and subcontractor shall be liable

for liquidated damages. Such liquidated damages shall be computed with respect to each

individual laborer or mechanic, including watchmen and guards, employed in violation of the

clause set forth in para. (1) of this section, in the sum of $10 for each calendar day on which such

individual was required or permitted to work in excess of the standard workweek of 40 hours

without payment of the overtime wages required by the clause set forth in para. (1) of this

section.

(3) Withholding for unpaid wages and liquidated damages - the recipient shall upon its own

action or upon written request of USDOL withhold or cause to be withheld, from any moneys

payable on account of work performed by contractor or subcontractor under any such contract or

any other Federal contract with the same prime contractor, or any other federally-assisted

contract subject to the Contract Work Hours & Safety Standards Act, which is held by the same

September 2019

prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of

such contractor or subcontractor for unpaid wages and liquidated damages as provided in the

clause set forth in para. (2) of this section.

(4) Subcontracts - Contractor or subcontractor shall insert in any subcontracts the clauses set

forth in this section and also a clause requiring the subcontractors to include these clauses in any

lower tier subcontracts. Prime contractor shall be responsible for compliance by any

subcontractor or lower tier subcontractor with the clauses set forth in this section.

No Government Obligation to Third Parties - Applicability – All contracts except micro-

purchases ($10,000 or less, except for construction contracts over $2,000)

(1) The recipient and contractor acknowledge and agree that, notwithstanding any concurrence

by the US Government in or approval of the solicitation or award of the underlying contract,

absent the express written consent by the US Government, the US Government is not a party to

this contract and shall not be subject to any obligations or liabilities to the recipient, the

contractor, or any other party (whether or not a party to that contract) pertaining to any matter

resulting from the underlying contract.

(2) Contractor agrees to include the above clause in each subcontract financed in whole or in part

with FTA assistance. It is further agreed that the clause shall not be modified, except to identify

the subcontractor who will be subject to its provisions.

Program Fraud and False or Fraudulent Statements or Related Acts – Applicability – All

contracts except micro-purchases ($10,000 or less, except for construction contracts over $2,000)

(1) Contractor acknowledges that the provisions of the Program Fraud Civil Remedies Act of

1986, as amended, 31 USC 3801 et seq. and USDOT regulations, "Program Fraud Civil

Remedies," 49 CFR 31, apply to its actions pertaining to this project. Upon execution of the

underlying contract, contractor certifies or affirms the truthfulness and accuracy of any statement

it has made, it makes, it may make, or causes to be made, pertaining to the underlying contract or

FTA assisted project for which this contract work is being performed. In addition to other

penalties that may be applicable, contractor further acknowledges that if it makes, or causes to be

made, a false, fictitious, or fraudulent claim, statement, submittal, or certification, the US

Government reserves the right to impose the penalties of the Program Fraud Civil Remedies Act

(1986) on contractor to the extent the US Government deems appropriate.

(2) If contractor makes, or causes to be made, a false, fictitious, or fraudulent claim, statement,

submittal, or certification to the US Government under a contract connected with a project that is

financed in whole or in part with FTA assistance under the authority of 49 USC 5307, the

Government reserves the right to impose the penalties of 18 USC 1001 and 49 USC 5307(n)(1)

on contractor, to the extent the US Government deems appropriate.

(3) Contractor shall include the above two clauses in each subcontract financed in whole or in

part with FTA assistance. The clauses shall not be modified, except to identify the subcontractor

who will be subject to the provisions.

Termination – Applicability – All Contracts over $10,000, except contracts with nonprofit

organizations and institutions of higher learning, where the threshold is $250,000

September 2019

a. Termination for Convenience (General Provision) the recipient may terminate this contract, in

whole or in part, at any time by written notice to contractor when it is in the recipient's best

interest. Contractor shall be paid its costs, including contract close-out costs, and profit on work

performed up to the time of termination. Contractor shall promptly submit its termination claim

to the recipient. If contractor is in possession of any of the recipient’s property, contractor shall

account for same, and dispose of it as the recipient directs.

b. Termination for Default [Breach or Cause] (General Provision) If contractor does not deliver

items in accordance with the contract delivery schedule, or, if the contract is for services, and

contractor fails to perform in the manner called for in the contract, or if contractor fails to

comply with any other provisions of the contract, the recipient may terminate this contract for

default. Termination shall be effected by serving a notice of termination to contractor setting

forth the manner in which contractor is in default. Contractor shall only be paid the contract price

for supplies delivered and accepted, or for services performed in accordance with the manner of

performance set forth in the contract.

If it is later determined by the recipient that contractor had an excusable reason for not

performing, such as a strike, fire, or flood, events which are not the fault of or are beyond the

control of contractor, the recipient, after setting up a new delivery or performance schedule, may

allow contractor to continue work, or treat the termination as a termination for convenience.

c. Opportunity to Cure (General Provision) the recipient in its sole discretion may, in the case of

a termination for breach or default, allow contractor an appropriately short period of time in

which to cure the defect. In such case, the notice of termination shall state the time period in

which cure is permitted and other appropriate conditions

If contractor fails to remedy to the recipient's satisfaction the breach or default or any of the

terms, covenants, or conditions of this Contract within ten (10) days after receipt by contractor or

written notice from the recipient setting forth the nature of said breach or default, the recipient

shall have the right to terminate the Contract without any further obligation to contractor. Any

such termination for default shall not in any way operate to preclude the recipient from also

pursuing all available remedies against contractor and its sureties for said breach or default.

d. Waiver of Remedies for any Breach In the event that the recipient elects to waive its

remedies for any breach by contractor of any covenant, term or condition of this Contract, such

waiver by the recipient shall not limit its remedies for any succeeding breach of that or of any

other term, covenant, or condition of this Contract.

e. Termination for Convenience (Professional or Transit Service Contracts) the recipient, by

written notice, may terminate this contract, in whole or in part, when it is in the recipient's

interest. If the contract is terminated, the recipient shall be liable only for payment under the

payment provisions of this contract for services rendered before the effective date of termination.

f. Termination for Default (Supplies and Service) If contractor fails to deliver supplies or to

perform the services within the time specified in this contract or any extension or if the

contractor fails to comply with any other provisions of this contract, the recipient may terminate

this contract for default. The recipient shall terminate by delivering to contractor a notice of

termination specifying the nature of default. Contractor shall only be paid the contract price for

supplies delivered and accepted, or services performed in accordance with the manner or

September 2019

performance set forth in this contract.

If, after termination for failure to fulfill contract obligations, it is determined that contractor was

not in default, the rights and obligations of the parties shall be the same as if termination had

been issued for the recipient’s convenience.

g. Termination for Default (Transportation Services) If contractor fails to pick up the

commodities or to perform the services, including delivery services, within the time specified in

this contract or any extension or if contractor fails to comply with any other provisions of this

contract, the recipient may terminate this contract for default. The recipient shall terminate by

delivering to contractor a notice of termination specifying the nature of default. Contractor shall

only be paid the contract price for services performed in accordance with the manner of

performance set forth in this contract.

If this contract is terminated while contractor has possession of the recipient goods, contractor

shall, as directed by the recipient, protect and preserve the goods until surrendered to the

recipient or its agent. Contractor and the recipient shall agree on payment for the preservation

and protection of goods. Failure to agree on an amount shall be resolved under the Dispute

clause. If, after termination for failure to fulfill contract obligations, it is determined that

contractor was not in default, the rights and obligations of the parties shall be the same as if

termination had been issued for the recipient’s convenience.

h. Termination for Default (Construction) If contractor refuses or fails to prosecute the work or

any separable part, with the diligence that will insure its completion within the time specified, or

any extension, or fails to complete the work within this time, or if contractor fails to comply with

any other provisions of this contract, the recipient may terminate this contract for default. the

recipient shall terminate by delivering to contractor a notice of termination specifying the nature

of default. In this event, the recipient may take over the work and compete it by contract or

otherwise, and may take possession of and use any materials, appliances, and plant on the work

site necessary for completing the work. Contractor and its sureties shall be liable for any damage

to the recipient resulting from contractor's refusal or failure to complete the work within

specified time, whether or not contractor's right to proceed with the work is terminated. This

liability includes any increased costs incurred by the recipient in completing the work.

Contractor's right to proceed shall not be terminated nor shall contractor be charged with

damages under this clause if:

1. Delay in completing the work arises from unforeseeable causes beyond the control and

without the fault or negligence of contractor. Examples of such causes include: acts of God, acts

of the recipient, acts of another contractor in the performance of a contract with the recipient,

epidemics, quarantine restrictions, strikes, freight embargoes; and

2. Contractor, within 10 days from the beginning of any delay, notifies the recipient in writing of

the causes of delay. If in the recipient’s judgment, delay is excusable, the time for completing the

work shall be extended. The recipient’s judgment shall be final and conclusive on the parties, but

subject to appeal under the Disputes clauses.

If, after termination of contractor's right to proceed, it is determined that contractor was not in

default, or that the delay was excusable, the rights and obligations of the parties will be the same

September 2019

as if termination had been issued for the recipient’s convenience.

i. Termination for Convenience or Default (Architect & Engineering) the recipient may terminate

this contract in whole or in part, for the recipient's convenience or because of contractor’s failure

to fulfill contract obligations. The recipient shall terminate by delivering to contractor a notice of

termination specifying the nature, extent, and effective date of termination. Upon receipt of the

notice, contractor shall (1) immediately discontinue all services affected (unless the notice

directs otherwise), and (2) deliver to the recipient all data, drawings, specifications, reports,

estimates, summaries, and other information and materials accumulated in performing this

contract, whether completed or in process. If termination is for the recipient’s convenience, it

shall make an equitable adjustment in the contract price but shall allow no anticipated profit on

unperformed services. If termination is for contractor’s failure to fulfill contract obligations, the

recipient may complete the work by contact or otherwise and contractor shall be liable for any

additional cost incurred by the recipient.

If, after termination for failure to fulfill contract obligations, it is determined that contractor was

not in default, the rights and obligations of the parties shall be the same as if termination had

been issued for the recipient’s convenience.

j. Termination for Convenience or Default (Cost-Type Contracts) the recipient may terminate

this contract, or any portion of it, by serving a notice or termination on contractor. The notice

shall state whether termination is for convenience of the recipient or for default of contractor. If

termination is for default, the notice shall state the manner in which contractor has failed to

perform the requirements of the contract. Contractor shall account for any property in its

possession paid for from funds received from the recipient, or property supplied to contractor by

the recipient. If termination is for default, the recipient may fix the fee, if the contract provides

for a fee, to be paid to contractor in proportion to the value, if any, of work performed up to the

time of termination. Contractor shall promptly submit its termination claim to the recipient and

the parties shall negotiate the termination settlement to be paid to contractor. If termination is

for the recipient’s convenience, contractor shall be paid its contract close-out costs, and a fee, if

the contract provided for payment of a fee, in proportion to the work performed up to the time of

termination.

If, after serving a notice of termination for default, the recipient determines that contractor has an

excusable reason for not performing, such as strike, fire, flood, events which are not the fault of

and are beyond the control of contractor, the recipient, after setting up a new work schedule, may

allow contractor to continue work, or treat the termination as a termination for convenience.

Government-wide Debarment and Suspension (Nonprocurement) – Applicability –

Contracts over $25,000

The Recipient agrees to the following: (1) It will comply with the requirements of 2 C.F.R. part

180, subpart C, as adopted and supplemented by U.S. DOT regulations at 2 C.F.R. part 1200,

which include the following: (a) It will not enter into any arrangement to participate in the

development or implementation of the Project with any Third Party Participant that is debarred

or suspended except as authorized by: 1 U.S. DOT regulations, “Nonprocurement Suspension

and Debarment,” 2 C.F.R. part 1200, 2 U.S. OMB, “Guidelines to Agencies on Governmentwide

Debarment and Suspension (Nonprocurement),” 2 C.F.R. part 180, including any amendments

thereto, and 3 Executive Orders Nos. 12549 and 12689, “Debarment and Suspension,” 31 U.S.C.

§ 6101 note, (b) It will review the U.S. GSA “System for Award Management,”

September 2019

https://www.sam.gov, if required by U.S. DOT regulations, 2 C.F.R. part 1200, and (c) It will

include, and require each of its Third Party Participants to include, a similar provision in each

lower tier covered transaction, ensuring that each lower tier Third Party Participant: 1 Will

comply with Federal debarment and suspension requirements, and 2 Reviews the “System for

Award Management” at https://www.sam.gov, if necessary to comply with U.S. DOT

regulations, 2 C.F.R. part 1200, and (2) If the Recipient suspends, debars, or takes any similar

action against a Third Party Participant or individual, the Recipient will provide immediate

written notice to the: (a) FTA Regional Counsel for the Region in which the Recipient is located

or implements the Project, (b) FTA Project Manager if the Project is administered by an FTA

Headquarters Office, or (c) FTA Chief Counsel,

Contracts Involving Federal Privacy Act Requirements – Applicability - When a grantee

maintains files on drug and alcohol enforcement activities for FTA, and those files are organized

so that information could be retrieved by personal identifier, the Privacy Act requirements apply

to all contracts except micro-purchases ($10,000 or less, except for construction contracts over

$2,000)

The following requirements apply to the Contractor and its employees that administer any

system of records on behalf of the Federal Government under any contract:

(1) The Contractor agrees to comply with, and assures the compliance of its employees with, the

information restrictions and other applicable requirements of the Privacy Act of 1974, 5 U.S.C. §

552a. Among other things, the Contractor agrees to obtain the express consent of the Federal

Government before the Contractor or its employees operate a system of records on behalf of the

Federal Government. The Contractor understands that the requirements of the Privacy Act,

including the civil and criminal penalties for violation of that Act, apply to those individuals

involved, and that failure to comply with the terms of the Privacy Act may result in termination

of the underlying contract.

(2) The Contractor also agrees to include these requirements in each subcontract to administer

any system of records on behalf of the Federal Government financed in whole or in part with

Federal assistance provided by FTA.

Civil Rights Requirements– Applicability – All contracts except micro-purchases ($10,000 or

less, except for construction contracts over $2,000)

The following requirements apply to the underlying contract:

The Recipient understands and agrees that it must comply with applicable Federal civil rights

laws and regulations, and follow applicable Federal guidance, except as the Federal Government

determines otherwise in writing. Therefore, unless a Recipient or Program, including an Indian

Tribe or the Tribal Transit Program, is specifically exempted from a civil rights statute, FTA

requires compliance with that civil rights statute, including compliance with equity in service:

a. Nondiscrimination in Federal Public Transportation Programs. The Recipient agrees to, and

assures that each Third Party Participant will, comply with Federal transit law, 49 U.S.C. § 5332

(FTA’s “Nondiscrimination” statute): (1) FTA’s “Nondiscrimination” statute prohibits

September 2019

discrimination on the basis of: (a) Race, (b) Color, (c) Religion, (d) National origin, (e) Sex, (f)

Disability, (g) Age, or (h) Gender identity and (2) The FTA “Nondiscrimination” statute’s

prohibition against discrimination includes: (a) Exclusion from participation, (b) Denial of

program benefits, or (c) Discrimination, including discrimination in employment or business

opportunity, (3) Except as FTA determines otherwise in writing: (a) General. Follow: 1 The most

recent edition of FTA Circular 4702.1, “Title VI Requirements and Guidelines for Federal

Transit Administration Recipients,” to the extent consistent with applicable Federal laws,

regulations, and guidance, and

2 Other applicable Federal guidance that may be issued, but (b) Exception for the Tribal Transit

Program. FTA does not require an Indian Tribe to comply with FTA program-specific guidelines

for Title VI when administering its projects funded under the Tribal Transit Program,

b. Nondiscrimination – Title VI of the Civil Rights Act. The Recipient agrees to, and assures that

each Third Party Participant will: (1) Prohibit discrimination based on: (a) Race, (b) Color, or (c)

National origin, (2) Comply with: (a) Title VI of the Civil Rights Act of 1964, as amended, 42

U.S.C. § 2000d et seq., (b) U.S. DOT regulations, “Nondiscrimination in Federally-Assisted

Programs of the Department of Transportation – Effectuation of Title VI of the Civil Rights Act

of 1964,” 49 C.F.R. part 21, and (c) Federal transit law, specifically 49 U.S.C. § 5332, as stated

in the preceding section a, and (3) Except as FTA determines otherwise in writing, follow: (a)

The most recent edition of FTA Circular 4702.1, “Title VI and Title VI-Dependent Guidelines

for Federal Transit Administration Recipients,” to the extent consistent with applicable Federal

laws, regulations, and guidance. (b) U.S. DOJ, “Guidelines for the enforcement of Title VI, Civil

Rights Act of 1964,” 28 C.F.R. § 50.3, and (c) Other applicable Federal guidance that may be

issued,

c. Equal Employment Opportunity. (1) Federal Requirements and Guidance. The Recipient

agrees to, and assures that each Third Party Participant will, prohibit discrimination on the basis

of race, color, religion, sex, or national origin, and: (a) Comply with Title VII of the Civil Rights

Act of 1964, as amended, 42 U.S.C. § 2000e et seq., (b) Facilitate compliance with Executive

Order No. 11246, “Equal Employment Opportunity,” as amended by Executive Order No.

11375, “Amending Executive Order No. 11246, Relating to Equal Employment Opportunity,” 42

U.S.C. § 2000e note, (c) Comply with Federal transit law, specifically 49 U.S.C. § 5332, as

stated in section a, and (d) Comply with FTA Circular 4704.1other applicable EEO laws and

regulations, as provided in Federal guidance, including laws and regulations prohibiting

discrimination on the basis of disability, except as the Federal Government determines otherwise

in writing, (2) General. The Recipient agrees to: (a) Ensure that applicants for employment are

employed and employees are treated during employment without discrimination on the basis of

their: 1 Race, 2 Color, 3 Religion, 4 Sex, 5 Disability, 6 Age, or 7 National origin, (b) Take

affirmative action that includes, but is not limited to: 1 Recruitment advertising, 2 Recruitment, 3

Employment, 4 Rates of pay, 5 Other forms of compensation, 6 Selection for training, including

apprenticeship, 7 Upgrading, 8 Transfers, 9 Demotions, 10 Layoffs, and 11 Terminations, but (b)

Indian Tribe. Title VII of the Civil Rights Act of 1964, as amended, exempts Indian Tribes under

the definition of "Employer".

(3) Equal Employment Opportunity Requirements for Construction Activities. In addition to the

foregoing, when undertaking “construction” as recognized by the U.S. Department of Labor

(U.S. DOL), the Recipient agrees to comply, and assures the compliance of each Third Party

Participant, with: (a) U.S. DOL regulations, “Office of Federal Contract Compliance Programs,

September 2019

Equal Employment Opportunity, Department of Labor,” 41 C.F.R. chapter 60, and (b) Executive

Order No. 11246, “Equal Employment Opportunity,” as amended by Executive Order No.

11375, “Amending Executive Order No. 11246, Relating to Equal Employment Opportunity,” 42

U.S.C. § 2000e note,

d. Disadvantaged Business Enterprise. To the extent authorized by applicable Federal law, the

Recipient agrees to facilitate, and assures that each Third-Party Participant will facilitate,

participation by small business concerns owned and controlled by socially and economically

disadvantaged individuals, also referred to as “Disadvantaged Business Enterprises” (DBEs), in

the Project as follows: 1) Requirements. The Recipient agrees to comply with: (a) Section

1101(b) of Map-21, 23 U.S.C. § 101 note, (b) U.S. DOT regulations, “Participation by

Disadvantaged Business Enterprises in Department of Transportation Financial Assistance

Programs,” 49 C.F.R. part 26, and (c) Federal transit law, specifically 49 U.S.C. § 5332, as stated

in section a, (2) Assurance. As required by 49 C.F.R. § 26.13(a), (b) DBE Program

Requirements. Recipients receiving planning, capital and/or operating assistance that will award

prime third-party contracts exceeding $250,000 in a Federal fiscal year must: 1 Have a DBE

program meeting the requirements of 49 C.F.R. part 26, 2 Implement a DBE program approved

by FTA, and 3 Establish an annual DBE participation goal, (c) Special Requirements for a

Transit Vehicle Manufacturer. The Recipient understands and agrees that each transit vehicle

manufacturer, as a condition of being authorized to bid or propose on FTA-assisted transit

vehicle procurements, must certify that it has complied with the requirements of 49 C.F.R. part

26, (d) the Recipient provides assurance that: The Recipient shall not discriminate on the basis of

race, color, national origin, or sex in the award and performance of any DOT-assisted contract or

in the administration of its DBE program or the requirements of 49 C.F.R. part 26. The Recipient

shall take all necessary and reasonable steps under 49 C.F.R. part 26 to ensure nondiscrimination

in the award and administration of DOT-assisted contracts. The Recipient's DBE program, as

required by 49 C.F.R. part 26 and as approved by DOT, is incorporated by reference in this

agreement. Implementation of this program is a legal obligation and failure to carry out its terms

shall be treated as a violation of this agreement. Upon notification to the Recipient of its failure

to carry out its approved program, the Department may impose sanctions as provided for under

49 C.F.R. part 26 and may, in appropriate cases, refer the matter for enforcement under 18

U.S.C. § 1001 and/or the Program Fraud Civil Remedies Act of 1986, 31 U.S.C. § 3801 et seq.,

(2) Exception for the Tribal Transit Program. FTA exempts Indian tribes from the Disadvantaged

Business Enterprise regulations at 49 C.F.R. part 26 under Map-21and previous legislation,

e. Nondiscrimination on the Basis of Sex. The Recipient agrees to comply with Federal

prohibitions against discrimination on the basis of sex, including: (1) Title IX of the Education

Amendments of 1972, as amended, 20 U.S.C. § 1681 et seq., (2) U.S. DOT regulations,

“Nondiscrimination on the Basis of Sex in Education Programs or Activities Receiving Federal

Financial Assistance,” 49 C.F.R. part 25, and (3) Federal transit law, specifically 49 U.S.C. §

5332, as stated in section a,

f. Nondiscrimination on the Basis of Age. The Recipient agrees to comply with Federal

prohibitions against discrimination on the basis of age, including: (1) The Age Discrimination in

Employment Act (ADEA), 29 U.S.C. §§ 621 – 634, which prohibits discrimination on the basis

of age, (2) U.S. Equal Employment Opportunity Commission (U.S. EEOC) regulations, “Age

Discrimination in Employment Act,” 29 C.F.R. part 1625, which implements the ADEA, (3) The

September 2019

Age Discrimination Act of 1975, as amended, 42 U.S.C. § 6101 et seq., which prohibits

discrimination against individuals on the basis of age in the administration of programs or

activities receiving Federal funds, (4) U.S. Health and Human Services regulations,

“Nondiscrimination on the Basis of Age in Programs or Activities Receiving Federal Financial

Assistance,” 45 C.F.R. part 90, which implements the Age Discrimination Act of 1975, and

(5) Federal transit law, specifically 49 U.S.C. § 5332, as stated in section a,

g. Nondiscrimination on the Basis of Disability. The Recipient agrees to comply with the

following Federal prohibitions pertaining to discrimination against seniors or individuals with

disabilities: (1) Federal laws, including: (a) Section 504 of the Rehabilitation Act of 1973, as

amended, 29 U.S.C. § 794, which prohibits discrimination on the basis of disability in the

administration of federally funded programs or activities, (b) The Americans with Disabilities

Act of 1990 (ADA), as amended, 42 U.S.C. § 12101 et seq., which requires that accessible

facilities and services be made available to individuals with disabilities, 1 General. Titles I, II,

and III of the ADA apply to FTA Recipients, but 2 Indian Tribes. While Titles II and III of the

ADA apply to Indian Tribes, Title I of the ADA exempts Indian Tribes from the definition of

“employer,” (c) The Architectural Barriers Act of 1968, as amended, 42 U.S.C. § 4151 et seq.,

which requires that buildings and public accommodations be accessible to individuals with

disabilities, (d) Federal transit law, specifically 49 U.S.C. § 5332, which now includes disability

as a prohibited basis for discrimination, and (e) Other applicable laws and amendments

pertaining to access for elderly individuals or individuals with disabilities, (2) Federal

regulations, including: (a) U.S. DOT regulations, “Transportation Services for Individuals with

Disabilities (ADA),” 49 C.F.R. part 37, (b) U.S. DOT regulations, “Nondiscrimination on the

Basis of Disability in Programs and Activities Receiving or Benefiting from Federal Financial

Assistance,” 49 C.F.R. part 27, (c) U.S. DOT regulations, “Transportation for Individuals with

Disabilities: Passenger Vessels,” 49 C.F.R. part 39, (d) Joint U.S. Architectural and

Transportation Barriers Compliance Board (U.S. ATBCB) and U.S. DOT regulations,

“Americans With Disabilities (ADA) Accessibility Specifications for Transportation Vehicles,”

36 C.F.R. part 1192 and 49 C.F.R. part 38, (e) U.S. DOJ regulations, “Nondiscrimination on the

Basis of Disability in State and Local Government Services,” 28 C.F.R. part 35, (f) U.S. DOJ

regulations, “Nondiscrimination on the Basis of Disability by Public Accommodations and in

Commercial Facilities,” 28 C.F.R. part 36, (g) U.S. EEOC, “Regulations to Implement the Equal

Employment Provisions of the Americans with Disabilities Act,” 29 C.F.R. part 1630, (h) U.S.

Federal Communications Commission regulations, “Telecommunications Relay Services and

Related Customer Premises Equipment for Persons with Disabilities,” 47 C.F.R. part 64, Subpart

F, (i) U.S. ATBCB regulations, “Electronic and Information Technology Accessibility

Standards,” 36 C.F.R. part 1194, and (j) FTA regulations, “Transportation for Elderly and

Handicapped Persons,” 49 C.F.R. part 609, and (3) Other applicable Federal civil rights and

nondiscrimination guidance,

h. Drug or Alcohol Abuse - Confidentiality and Other Civil Rights Protections. The Recipient

agrees to comply with the confidentiality and civil rights protections of: (1) The Drug Abuse

Office and Treatment Act of 1972, as amended, 21 U.S.C. § 1101 et seq., (2) The

Comprehensive Alcohol Abuse and Alcoholism Prevention, Treatment and Rehabilitation Act of

1970, as amended, 42 U.S.C. § 4541 et seq., and (3) The Public Health Service Act, as amended,

42 U.S.C. §§ 290dd – 290dd-2,

September 2019

i. Access to Services for People with Limited English Proficiency. Except as the Federal

Government determines otherwise in writing, the Recipient agrees to promote accessibility of

public transportation services to people whose understanding of English is limited by following:

1) Executive Order No. 13166, “Improving Access to Services for Persons with Limited English

Proficiency,” August 11, 2000, 42 U.S.C. § 2000d-1 note, and (2) U.S. DOT Notice, “DOT

Policy Guidance Concerning Recipients’ Responsibilities to Limited English Proficiency (LEP)

Persons,” 70 Fed. Reg. 74087, December 14, 2005,

j. Other Nondiscrimination Laws. Except as the Federal Government determines otherwise in

writing, the Recipient agrees to: (1) Comply with other applicable Federal nondiscrimination

laws and regulations, and (2) Follow Federal guidance prohibiting discrimination.

k. Remedies. Remedies for failure to comply with applicable Federal Civil Rights laws and

Federal regulations may be enforced as provided in those Federal laws or Federal regulations.

Breaches and Dispute Resolution – Applicability – All contracts over $250,000

Disputes arising in the performance of this contract which are not resolved by agreement of the

parties shall be decided in writing by the recipient’s authorized representative. This decision

shall be final and conclusive unless within ten days from the date of receipt of its copy,

contractor mails or otherwise furnishes a written appeal to the recipient’s CEO. In connection

with such appeal, contractor shall be afforded an opportunity to be heard and to offer evidence in

support of its position. The decision of the recipient’s CEO shall be binding upon contractor and

contractor shall abide by the decision. FTA has a vested interest in the settlement of any

violation of Federal law including the False Claims Act, 31 U.S.C. § 3729.

Performance During Dispute - Unless otherwise directed by the recipient, contractor shall

continue performance under this contract while matters in dispute are being resolved.

Claims for Damages - Should either party to the contract suffer injury or damage to person or

property because of any act or omission of the party or of any of his employees, agents or others

for whose acts he is legally liable, a claim for damages therefore shall be made in writing to such

other party within ten days after the first observance of such injury or damage.

Remedies - Unless this contract provides otherwise, all claims, counterclaims, disputes and other

matters in question between the recipient and contractor arising out of or relating to this

agreement or its breach will be decided by arbitration if the parties mutually agree, or in a court

of competent jurisdiction within the residing State.

Rights and Remedies - Duties and obligations imposed by the contract documents and the rights

and remedies available thereunder shall be in addition to and not a limitation of any duties,

obligations, rights and remedies otherwise imposed or available by law. No action or failure to

act by the recipient or contractor shall constitute a waiver of any right or duty afforded any of

them under the contract, nor shall any such action or failure to act constitute an approval of or

acquiescence in any breach thereunder, except as may be specifically agreed in writing.

Patent and Rights Data –

Contracts involving experimental, developmental, or research work ($10,000 or less, except for

construction contracts over $2,000).

September 2019

Patent Rights

A. General. The Recipient agrees that:

(1) Depending on the nature of the Project, the Federal Government may acquire patent rights

when the Recipient or Third Party Participant produces a patented or patentable: (a) Invention,

(b) Improvement, or (c) Discovery, (2) The Federal Government’s rights arise when the patent or

patentable information is: (a) Conceived under the Project, or (b) Reduced to practice under the

Project, and (3) When a patent is issued or patented information becomes available as described

in Patent Rights section A(2), the Recipient agrees to: (a) Notify FTA immediately, and (b)

Provide a detailed report satisfactory to FTA,

B. Federal Rights. The Recipient agrees that:

(1) Its rights and responsibilities, and the rights and responsibilities of each Third Party

Participant, in that federally funded invention, improvement, or discovery will be determined as

provided by applicable Federal laws, regulations, and guidance, including any waiver thereof,

and (2) Unless the Federal Government determines otherwise in writing, irrespective of the

Recipient’s status or the status of any Third Party Participant as a large business, a small

business, a State government, a State instrumentality, a local government, an Indian tribe, a

nonprofit organization, an institution of higher education, or an individual, the Recipient agrees

to transmit the Federal Government’s patent rights to FTA as specified in: (a) 35 U.S.C. § 200 et

seq., and (b) U.S. Department of Commerce regulations, “Rights to Inventions Made by

Nonprofit Organizations and Small Business Firms Under Government Grants, Contracts and

Cooperative Agreements,” 37 C.F.R. part 401, and

C. License Fees and Royalties. As permitted by 49 C.F.R. parts 18 and 19:

(1) License fees and royalties for patents, patent applications, and inventions derived from the

Project are program income, and (2) The Recipient has no obligation to the Federal Government

with respect to those license fees or royalties, except: (a) For compliance with 35 U.S.C. § 200 et

seq., which applies to patent rights developed under a federally funded research-type project, and

(b) As FTA determines otherwise in writing.

Rights in Data and Copyrights

A. Definition of “Subject Data.” means recorded information: (1) Copyright. Whether or not

copyrighted, and (2) Delivery. That is delivered or specified to be delivered under the

Underlying Agreement,

B. Examples of “Subject Data.” Examples of “subject data”: (1) Include, but are not limited to:

(a) Computer software, (b) Standards, (c) Specifications, (d) Engineering drawings and

associated lists, (e) Process sheets, (f) Manuals, (g) Technical reports, (h) Catalog item

identifications, and (i) Related information, but (2) Do not include: (a) Financial reports,

(b) Cost analyses, or (c) Other similar information used for Project administration,

September 2019

C. General Federal Restrictions. The following restrictions apply to all subject data first

produced in the performance of the Recipient’s Project supported by the Underlying Agreement:

(1) Prohibitions. The Recipient may not: (a) Publish or reproduce any subject data in whole or in

part, or in any manner or form, or (b) Permit others to do so, but (2) Exceptions. The prohibitions

of Rights in Data and Copyrights C(1) do not apply to: (a) Publications or reproductions for the

Recipient’s own internal use, (b) An institution of higher learning, (c) The portion of subject data

that the Federal Government has previously released or approved for release to the public, or (d)

The portion of data that has the Federal Government’s prior written consent for release,

D. Federal Rights in Data and Copyrights. The Recipient agrees that: (1) License Rights. The

Recipient must provide a license to its “subject data” to the Federal Government, which license

is: (a) Royalty-free, (b) Non-exclusive, and (c) Irrevocable, (2) Uses. The Federal Government’s

license must permit the Federal Government to take the following actions provided those actions

are taken for Federal Government purposes: (a) Reproduce the subject data, (b) Publish the

subject data, (c) Otherwise use the subject data, and (d) Permit other entities or individuals to use

the subject data, and

E. Special Federal Rights in Data for Research, Development, Demonstration, Deployment, and

Special Studies Projects. In general, FTA’s purpose in providing Federal funds for a research,

development, demonstration, deployment, or special studies Project is to increase transportation

knowledge, rather than limit the benefits of the Project to the Recipient and its Third Party

Participants, therefore, the Recipient agrees that: (1) Publicly Available Report. When the

Project is completed, it must provide a Project report that FTA may publish or make available for

publication on the Internet, (2) Other Reports. It must provide other reports pertaining to the

Project that FTA may request, (3) Availability of Subject Data. FTA may make available to any

FTA Recipient or any of its Third Party Participants at any tier of the Project, either FTA’s

copyright license to the subject data or a copy of the subject data, except as the Federal

Government determines otherwise in writing, (4) Identification of Information. It must identify

clearly any specific confidential, privileged, or proprietary information submitted to FTA, (5)

Incomplete Project. If the Project is not completed for any reason whatsoever, all data developed

under the Project becomes “subject data” and must be delivered as the Federal Government may

direct, but (6) Exception. Rights in Data and Copyrights Section E does not apply to an

adaptation of automatic data processing equipment or program that is both: (a) For the

Recipient’s use, and (b) Acquired with FTA capital program funding,

F. License Fees and Royalties. As permitted by 49 C.F.R. parts 18 and 19: (1) License fees and

royalties for copyrighted material or trademarks derived from Project are program income, and

(2) The Recipient has no obligation to the Federal Government with respect to those license fees

or royalties, except: (a) For compliance with 35 U.S.C. § 200 et seq., which applies to patent

rights developed under a federally funded research-type project, and (b) As FTA determines

otherwise in writing,

G. Hold Harmless. Upon request by the Federal Government, the Recipient agrees that: (1)

Violation by Recipient. (a) If it willfully or intentionally violates any: 1 Proprietary rights, 2

Copyrights, or 3 Right of privacy, and (b) Its violation occurs from any of the following uses of

Project data: 1 Publication, 2 Translation, 3 Reproduction, 4 Delivery, 5 Use, or 6 Disposition,

then (c) It will indemnify, save, and hold harmless against any liability, including costs and

September 2019

expenses of: 1 The Federal Government’s officers acting within the scope of their official duties,

2 The Federal Government’s employees acting within the scope of their official duties, and 3

Federal Government’s agents acting within the scope of their official duties, but (2) Exceptions.

The Recipient will not be required to indemnify the Federal Government for any liability

described in Rights in Data and Copyrights section G(1) if: (a) Violation by Federal Officers,

Employees or Agents. The violation is caused by the wrongful acts of Federal employees or

agents, or (b) State law. If indemnification is prohibited or limited by applicable State law,

H. Restrictions on Access to Patent Rights. Nothing in this Rights in Data and Copyrights section

pertaining to rights in data either: (1) Implies a license to the Federal Government under any

patent, or (2) May be construed to affect the scope of any license or other right otherwise granted

to the Federal Government under any patent,

I. Data Developed Without Federal Funding or Support. The Recipient understands and agrees

that in certain circumstances it may need to provide data developed without any Federal funding

or support to FTA. Nevertheless: (1) Protections. Rights in Data and Copyrights Sections A, B,

C, and D generally do not apply to data developed without Federal funding, even though that

data may have been used in connection with the Project, and (2) Identification of Information.

The Recipient understands and agrees that the Federal Government will not be able to protect

data developed without Federal funding from unauthorized disclosure unless that data is clearly

marked “Proprietary” or “Confidential,” and

J. Requirements to Release Data. The Recipient understands and agrees that the Federal

Government may be required to release Project data and information the Recipient submits to the

Federal Government as required by: (1) The Freedom of Information Act, 5 U.S.C. § 552,

(2) Another applicable Federal law requiring access to Project records, (3) U.S. DOT regulations,

“Uniform Administrative Requirements for Grants and Agreements with Institutions of Higher

Education, Hospitals, and Other Non-Profit Organizations,” specifically 49 C.F.R. § 19.36(d), or

(4) Other applicable Federal regulations and guidance pertaining to access to Project records.

Transit Employee Protective Provisions – Applicability – Contracts for transit operations

except micro-purchases ($10,000 or less, except for construction contracts over $2,000)

Public Transportation Employee Protective Arrangements. The Recipient agrees that 49 U.S.C. §

5333(b) requires employee protective arrangements to be in place as a condition of award of

FTA assistance made available or appropriated for FTA programs involving public

transportation operations. U.S. DOL recognizes the following categories of arrangements:

(1) U.S. DOL Certification. When its Project involves public transportation operations and is

financed with funding made available or appropriated for 49 U.S.C. §§ 5307, 5309, 5312, 5337,

or 5339, as amended by Map-21, or former 49 U.S.C. §§ 5308, 5309, 5312, or other provisions

of law as required by the Federal Government, U.S. DOL must provide a Certification of

employee protective arrangements before FTA may provide financial assistance for the Project.

Therefore, the Recipient understands and agrees, and assures that any Third Party Participant

providing public transportation operations will agree, that: (a) It must carry out the Project as

provided in its U.S. DOL Certification, which contains the terms and conditions that U.S. DOL

has determined to be fair and equitable to protect the interests of any employees affected by the

Project, (b) It must comply with 49 U.S.C. § 5333(b), and any future amendments thereto, (c)

September 2019

It will follow the U.S. DOL guidelines, “Guidelines, Section 5333(b), Federal Transit Law,” 29

C.F.R. part 215, except as U.S. DOL determines otherwise in writing, (d) It must comply with

the terms and conditions of the U.S. DOL certification of public transportation employee

protective arrangements for the Project, which certification is dated as identified on the

Underlying Agreement, including: 1 Alternative comparable arrangements U.S. DOL has

specified for the Project, 2 Any revisions U.S. DOL has specified for the Project, or 3 Both, and

(e) It must comply with the following documents and provisions incorporated by reference in and

made part of the Underlying Agreement for the Project: 1 The U.S. DOL certification of public

transportation employee protective arrangements for the Project, which certification is dated as

identified on the Underlying Agreement, 2 The documents cited in that U.S. DOL certification

for the Project, 3 Any alternative comparable arrangements that U.S. DOL has specified for the

Project, and 4 Any revisions that U.S. DOL has specified for the Project, (2) Special Warranty.

When its Project involves public transportation operations, and is financed with funding made

available or appropriated for 49 U.S.C. § 5311, as amended by Map-21, for former 49 U.S.C. §

5311 in effect in FY 2012, or a previous fiscal year, or for section 3038 of TEA-21, as amended

by section 3039 of SAFETEA-LU, U.S. DOL will provide a Special Warranty for those projects,

including projects under the Tribal Transit Program. Therefore, the Recipient understands and

agrees, and assures that any Third Party Participant providing public transportation operations

will agree, that: (a) It must comply with Federal transit laws, specifically 49 U.S.C. § 5333(b),

(b) Follow the U.S. DOL guidelines, “Guidelines, Section 5333(b), Federal Transit Law,” 29

C.F.R. part 215, except as U.S. DOL determines otherwise in writing, (c) It will comply with the

U.S. DOL Special Warranty for its Project that is most current on the date when it executed the

Underlying Agreement, and documents cited therein, including: 1 Any alternative comparable

arrangements U.S. DOL has specified for the Project, 2 Any revisions U.S. DOL has specified

for the Project, or 3 Both, and (d) It will comply with the following documents and provisions

incorporated by reference in and made part of the Underlying Agreement: 1 The U.S. DOL

Special Warranty for its Project, 2 Documents cited in that Special Warranty, 3 Alternative

comparable arrangements U.S. DOL specifies for the Project, and 4 Any revisions that U.S. DOL

has specified for the Project, and (3) Special Arrangements for 49 U.S.C. § 5310 Projects. The

Recipient understands and agrees, and assures that any Third Party Participant providing public

transportation operations will agree, that although pursuant to 49 U.S.C. § 5310, and former 49

U.S.C. §§ 5310 or 5317, FTA has determined that it was not “necessary or appropriate” to apply

the conditions of 49 U.S.C. § 5333(b) to Subrecipients participating in the program to provide

public transportation for seniors (elderly individuals) and individuals with disabilities, FTA

reserves the right to make the following exceptions: (a) FTA will make case-by-case

determinations of the applicability of 49 U.S.C. § 5333(b) for all transfers of funding authorized

under title 23, United States Code (flex funds), and (b) FTA reserves the right to make other

exceptions as it deems appropriate.

Disadvantaged Business Enterprise (DBE) – Applicability – Contracts over $10,000 awarded

on the basis of a bid or proposal offering to use DBEs

a. This contract is subject to the requirements of Title 49, Code of Federal Regulations, Part 26,

Participation by Disadvantaged Business Enterprises in Department of Transportation Financial

Assistance Programs. The national goal for participation of Disadvantaged Business Enterprises

(DBE) is 10%. The recipient’s overall goal for DBE participation is listed elsewhere. If a

separate contract goal for DBE participation has been established for this procurement, it is listed

September 2019

elsewhere.

b. The contractor shall not discriminate on the basis of race, color, national origin, or sex in the

performance of this contract. The contractor shall carry out applicable requirements of 49 CFR

Part 26 in the award and administration of this contract. Failure by the contractor to carry out

these requirements is a material breach of this contract, which may result in the termination of

this contract or such other remedy as the municipal corporation deems appropriate. Each

subcontract the contractor signs with a subcontractor must include the assurance in this

paragraph (see 49 CFR 26.13(b)).

c. If a separate contract goal has been established, Bidders/offerors are required to document

sufficient DBE participation to meet these goals or, alternatively, document adequate good faith

efforts to do so, as provided for in 49 CFR 26.53.

d. If no separate contract goal has been established, the successful bidder/offeror will be required

to report its DBE participation obtained through race-neutral means throughout the period of

performance.

e. The contractor is required to pay its subcontractors performing work related to this contract for

satisfactory performance of that work no later than 30 days after the contractor’s receipt of

payment for that work from the recipient. In addition, the contractor may not hold retainage

from its subcontractors or must return any retainage payments to those subcontractors within 30

days after the subcontractor's work related to this contract is satisfactorily completed or must

return any retainage payments to those subcontractors within 30 days after incremental

acceptance of the subcontractor’s work by the recipient and contractor’s receipt of the partial

retainage payment related to the subcontractor’s work.

f. The contractor must promptly notify the recipient whenever a DBE subcontractor performing

work related to this contract is terminated or fails to complete its work, and must make good

faith efforts to engage another DBE subcontractor to perform at least the same amount of work.

The contractor may not terminate any DBE subcontractor and perform that work through its own

forces or those of an affiliate without prior written consent of the recipient.

Prompt Payment – Applicability – All contracts except micro-purchases ($10,000 or less,

except for construction contracts over $2,000)

The prime contractor agrees to pay each subcontractor under this prime contract for satisfactory

performance of its contract no later than 30 days from the receipt of each payment the prime

contract receives from the Recipient. The prime contractor agrees further to return retainage

payments to each subcontractor within 30 days after the subcontractors work is satisfactorily

completed. Any delay or postponement of payment from the above referenced time frame may

occur only for good cause following written approval of the Recipient. This clause applies to

both DBE and non-DBE subcontracts.

Incorporation of Federal Transit Administration (FTA) Terms – Applicability – All

contracts except micro-purchases ($10,000 or less, except for construction contracts over $2,000)

September 2019

The preceding provisions include, in part, certain Standard Terms & Conditions required by

USDOT, whether or not expressly stated in the preceding contract provisions. All USDOT-

required contractual provisions, as stated in FTA Circular 4220.1F, are hereby incorporated by

reference. Anything to the contrary herein notwithstanding, all FTA mandated terms shall be

deemed to control in the event of a conflict with other provisions contained in this Agreement.

The contractor shall not perform any act, fail to perform any act, or refuse to comply with any

request that would cause the recipient to be in violation of FTA terms and conditions.

Drug & Alcohol Abuse and Testing – Applicability – Operational service contracts except

micro-purchases ($10,000 or less, except for construction contracts over $2,000)

The Contractor agrees to comply with the following Federal substance abuse regulations: a.

Drug-Free Workplace. U.S. DOT regulations, "Drug-Free Workplace Requirements (Grants), "

49 C.F.R. Part 32, that implements the Drug-Free Workplace Act of 1988 as amended, 41

U.S.C. §§ 8103 et seq., and 2 CFR part 182, b. Alcohol Misuse and Prohibited Drug Use. FTA

Regulations, "Prevention of Alcohol Misuse and Prohibited Drug Use in Transit Operations," 49

USC 5331, as amended by Map-21, 49 CFR part 40, 49 USC chapter 53, 49 CFR Part 655, to the

extent applicable.

Other Federal Requirements:

Full and Open Competition – In accordance with 49 U.S.C. § 5325(h) all procurement

transactions shall be conducted in a manner that provides full and open competition.

Prohibition Against Exclusionary or Discriminatory Specifications – Apart from inconsistent

requirements imposed by Federal statute or regulations, the contractor shall comply with the

requirements of 49 USC 5323(h)(2) by refraining from using any FTA assistance to support

procurements using exclusionary or discriminatory specifications.

Conformance with ITS National Architecture – Contractor shall conform, to the extent

applicable, to the National Intelligent Transportation Standards architecture as required by

SAFETEA-LU Section 5307(c), 23 U.S.C. Section 512 note and follow the provisions of FTA

Notice, “FTA National Architecture Policy on Transit Projects,” 66 Fed. Reg.1455 etseq.,

January 8, 2001, and any other implementing directives FTA may issue at a later date, except to

the extent FTA determines otherwise in writing.

Access Requirements for Persons with Disabilities – Contractor shall comply with 49 USC

5301(d), stating Federal policy that the elderly and persons with disabilities have the same rights

as other persons to use mass transportation services and facilities and that special efforts shall be

made in planning and designing those services and facilities to implement that policy.

Contractor shall also comply with all applicable requirements of Sec. 504 of the Rehabilitation

Act (1973), as amended, 29 USC 794, which prohibits discrimination on the basis of handicaps,

and the Americans with Disabilities Act of 1990 (ADA), as amended, 42 USC 12101 et seq.,

which requires that accessible facilities and services be made available to persons with

disabilities, including any subsequent amendments thereto.

Notification of Federal Participation – To the extent required by law, in the announcement of

September 2019

any third party contract award for goods and services (including construction services) having an

aggregate value of $500,000 or more, contractor shall specify the amount of Federal assistance to

be used in financing that acquisition of goods and services and to express that amount of Federal

assistance as a percentage of the total cost of the third party contract.

Interest of Members or Delegates to Congress - No members of, or delegates to, the US

Congress shall be admitted to any share or part of this contract nor to any benefit arising

therefrom.

Ineligible Contractors and Subcontractors - Any name appearing upon the Comptroller

General’s list of ineligible contractors for federally-assisted contracts shall be ineligible to act as

a subcontractor for contractor pursuant to this contract. If contractor is on the Comptroller

General’s list of ineligible contractors for federally financed or assisted construction, the

recipient shall cancel, terminate or suspend this contract.

Other Contract Requirements - To the extent not inconsistent with the foregoing Federal

requirements, this contract shall also include those standard clauses attached hereto, and shall

comply with the recipient’s Procurement Guidelines, available upon request from the recipient.

Compliance With Federal Regulations - Any contract entered pursuant to this solicitation shall

contain the following provisions: All USDOT-required contractual provisions, as set forth in

FTA Circular 4220.1F, are incorporated by reference. Anything to the contrary herein

notwithstanding, FTA mandated terms shall control in the event of a conflict with other

provisions contained in this Agreement. Contractor shall not perform any act, fail to perform

any act, or refuse to comply with any grantee request that would cause the recipient to be in

violation of FTA terms and conditions. Contractor shall comply with all applicable FTA

regulations, policies, procedures and directives, including, without limitation, those listed

directly or incorporated by reference in the Master Agreement between the recipient and FTA, as

may be amended or promulgated from time to time during the term of this contract. Contractor’s

failure to so comply shall constitute a material breach of this contract.

Real Property - Any contract entered into shall contain the following provisions: Contractor

shall at all times comply with all applicable statutes and USDOT regulations, policies,

procedures and directives governing the acquisition, use and disposal of real property, including,

but not limited to, 49 CFR 18.31-18.34, 49 CFR 19.30-19.37, 49 CFR Part 24, 49 CFR 5326 as

amended by Map-21, 49 CFR part 18 or 19, 49 USC 5334, applicable FTA Circular 5010, and

FTA Master Agreement, as they may be amended or promulgated during the term of this

contract. Contractor’s failure to so comply shall constitute a material breach of this contract.

Access to Services for Persons with Limited English Proficiency - To the extent applicable

and except to the extent that FTA determines otherwise in writing, the Recipient agrees to

comply with the policies of Executive Order No. 13166, "Improving Access to Services for

Persons with Limited English Proficiency," 42 U.S.C. § 2000d 1 note, and with the provisions of

U.S. DOT Notice, “DOT Guidance to Recipients on Special Language Services to Limited

English Proficient (LEP) Beneficiaries,” 70 Fed. Reg. 74087, December 14, 2005.

Environmental Justice - Except as the Federal Government determines otherwise in writing, the

September 2019

Recipient agrees to promote environmental justice by following: (1) Executive Order No. 12898,

“Federal Actions to Address Environmental Justice in Minority Populations and Low-Income

Populations,” February 11, 1994, 42 U.S.C. § 4321 note, as well as facilitating compliance with

that Executive Order, and (2) DOT Order 5610.2, “Department of Transportation Actions To

Address Environmental Justice in Minority Populations and Low-Income Populations,” 62 Fed.

Reg. 18377, April 15, 1997, and (3) The most recent and applicable edition of FTA Circular

4703.1, “Environmental Justice Policy Guidance for Federal Transit Administration Recipients,”

August 15, 2012, to the extent consistent with applicable Federal laws, regulations, and

guidance,

Environmental Protections – Compliance is required with any applicable Federal laws

imposing environmental and resource conservation requirements for the project. Some, but not

all, of the major Federal laws that may affect the project include: the National Environmental

Policy Act of 1969; the Clean Air Act; the Resource Conservation and Recovery Act; the

comprehensive Environmental response, Compensation and Liability Act; as well as

environmental provisions with Title 23 U.S.C., and 49 U.C. chapter 53. The U.S. EPA, FHWA

and other federal agencies may issue other federal regulations and directives that may affect the

project. Compliance is required with any applicable Federal laws and regulations in effect now

or that become effective in the future.

Geographic Information and Related Spatial Data – Any project activities involving spatial

data or geographic information systems activities financed with Federal assistance are required to

be consistent with the National Spatial Data Infrastructure promulgated by the Federal

Geographic Data Committee, except to the extent that FTA determines otherwise in writing.

Geographic Preference

All project activities must be advertised without geographic preference, (except in A/E under

certain circumstances, preference for hiring veterans on transit construction projects and

geographic-based hiring preferences as proposes to be amended in 2 CFR Part 1201 ).

Organizational Conflicts of Interest

The Recipient agrees that it will not enter into a procurement that involves a real or apparent

organizational conflict of interest described as follows: (1) When It Occurs. An organizational

conflict of interest occurs when the Project work, without appropriate restrictions on certain

future activities, results in an unfair competitive advantage: (a) To that Third Party Participant or

another Third Party Participant performing the Project work, and (b) That impairs that Third

Party Participant’s objectivity in performing the Project work, or (2) Other. An organizational

conflict of interest may involve other situations resulting in fundamentally unfair competitive

conditions, (3) Disclosure Requirements. Consistent with FTA policies, the Recipient must

disclose to FTA, and each of its Subrecipients must disclose to the Recipient: (a) Any instances

of organizational conflict of interest, or (b) Violations of federal criminal law, involving fraud,

bribery, or gratuity violations potentially affecting the federal award, and (4) Failure to

Disclose. Failure to make required disclosures can result in remedies for noncompliance,

including debarment or suspension.

Federal Single Audit Requirements for State Administered Federally Aid Funded Projects

Non Federal entities that expend $750,000 or more in a year in Federal awards from all sources

September 2019

are required to comply with the Federal Single Audit Act provisions contained in U.S. Office of

Management and Budget (OMB) Circular No. A 133, “Audits of States, Local Governments, and

Non Profit Organizations” (replaced with 2 CFR Part 200,“Uniform Administrative

Requirements, Cost Principles, and Audit Requirements for Federal Awards” effective December

26, 2014 as applicable). Non Federal entities that expend Federal awards from a single source

may provide a program specific audit, as defined in the Circular. Non Federal entities that

expend less than the amount above in a year in Federal awards from all sources are exempt from

Federal audit requirements for that year, except as noted in Sec. 215 (a) of OMB Circular A-133

Subpart B--Audits, records must be available for review or audit by appropriate officials of the

cognizant Federal agency the New York State Department of Transportation, the New York State

Comptrollers Office and the U.S. Governmental Accountability Office (GAO).

Non Federal entities are required to submit a copy of all audits, as described above, within 30

days of issuance of audit report, but no later than 9 months after the end of the entity’s fiscal

year, to the New York State Department of Transportation, Contract Audit Bureau, 50 Wolf

Road, Albany, NY 12232. Unless a time extension has been granted by the cognizant Federal

Agency and has been filed with the New York State Department of Transportation’s Contract

Audit Bureau, failure to comply with the requirements of OMB Circular A-133 may result in

suspension or termination of Federal award payments.

Veterans Preference. As provided by 49 U.S.C. § 5325(k), to the extent practicable, the

Recipient agrees and assures that each of its Subrecipients:

(1) Will give a hiring preference to veterans, as defined in 5 U.S.C. § 2108, who have the skills

and abilities required to perform construction work required under a third party contract in

connection with a Capital Project supported with federal assistance appropriated or made

available for 49 U.S.C. chapter 53, and

(2) Will not require an employer to give a preference to any veteran over any equally qualified

applicant who is a member of any racial or ethnic minority, female, an individual with a

disability, or a former employee.

Safe Operation of Motor Vehicles.

a. Seat Belt Use. The Recipient agrees to implement Executive Order No. 13043, “Increasing

Seat Belt Use in the United States,” April 16, 1997, 23 U.S.C. § 402 note, (62 Fed. Reg.

19217), by:

(1) Adopting and promoting on-the-job seat belt use policies and programs for its

employees and other personnel that operate company-owned vehicles, company-rented

vehicles, or personally operated vehicles, and

(2) Including a “Seat Belt Use” provision in each third party agreement related to the

Award.

b. Distracted Driving, Including Text Messaging While Driving. The Recipient agrees to

comply with:

(1) Executive Order No. 13513, “Federal Leadership on Reducing Text Messaging While

Driving,” October 1, 2009, 23 U.S.C. § 402 note, (74 Fed. Reg. 51225),

(2) U.S. DOT Order 3902.10, “Text Messaging While Driving,” December 30, 2009, and

(3) The following U.S. DOT Special Provision pertaining to Distracted Driving:

(a) Safety. The Recipient agrees to adopt and enforce workplace safety policies to decrease

crashes caused by distracted drivers, including policies to ban text messaging while using an

electronic device supplied by an employer, and driving a vehicle the driver owns or rents, a

http://www.ecfr.gov/cgi-bin/text-idx?tpl=/ecfrbrowse/Title02/2cfr200_main_02.tpl


September 2019

vehicle Recipient owns, leases, or rents, or a privately-owned vehicle when on official business

in connection with the Award, or when performing any work for or on behalf of the Award,

(b) Recipient Size. The Recipient agrees to conduct workplace safety initiatives in a manner

commensurate with its size, such as establishing new rules and programs to prohibit text

messaging while driving, re-evaluating the existing programs to prohibit text messaging while

driving, and providing education, awareness, and other outreach to employees about the safety

risks associated with texting while driving, and

(c) Extension of Provision. The Recipient agrees to include the preceding Special Provision of

section 34.b(3)(a) – (b) of this Master Agreement in its third party agreements, and encourage its

Third Party Participants to comply with this Special Provision, and include this Special Provision

in each third party subagreement at each tier supported with federal assistance.

Catalog of Federal Domestic Assistance (CFDA) Identification Number

The municipal project sponsor is required to identify in its accounts all Federal awards received

and expended, and the Federal programs under which they were received. Federal program and

award identification shall include, as applicable, the CFDA title and number, award number and

year, name of the Federal agency, and name of the pass-through entity.

The CFDA number for the Federal Transit Administration. Nonurbanized Area Formula

(Section 5311) is 20.509. A Recipient covered by the Single Audit Act Amendments of 1996

and OMB Circular A-133, “Audits of States, Local Governments, and Non-Profit

Organizations,” (replaced with 2 CFR Part 200,“Uniform Administrative Requirements, Cost

Principles, and Audit Requirements for Federal Awards” effective December 26, 2014 as

applicable) agrees to separately identify the expenditures for Federal awards under the Recovery

Act on the Schedule of Expenditures of Federal Awards (SEFA) and the Data Collection Form

(SF-SAC) required by OMB Circular A-133. The Recipient agrees to accomplish this by

identifying expenditures for Federal awards made under Recovery Act separately on the SEFA,

and as separate rows under Item 9 of Part III on the SF-SAC by CFDA number, and inclusion of

the prefix “ARRA” in identifying the name of the Federal program on the SEFA and as the first

characters in Item 9d of Part III on the SF-SAC.

