maharashtra state electricity distribution …€¦ · · 2009-06-09[ bid submitted without d.d...
TRANSCRIPT
Signature and Seal of the Tenderer
1
CENZ / TECH/A-II /09-10 / T-04
………………………………………………………………………………………………
No.CENZ /TECH /A-II/Tender /09-10/ 2882 Date:- 08-06-2009
SHORT- TENDER-NOTICE
Super scribed and Sealed offers are invited from Manufacturers and Authorized
dealers For Supply Of L.T . Energy Metering Box For DTC Metering work made by Deep Drawn process by
using CRCA Sheet Steel metal ,as per drawing & specifications , in a two bid system tender . The Due date of
submission is on or before 18-06-09 up to 13=00 hrs . The offers will be opened on the same date i.e. on
dated 18-06-09 at 14=00 hrs if possible in the presence of Tenderers / Representative who ever choose to be
present at the time of opening.
Tender No. CE/NZ/Tech/A-II/ 09-10/ T- 04
Supply Of L.T . Energy Metering Box For DTC Metering work made by Deep Drawn process
by using CRCA Sheet Steel metal , as per drawing & specifications , shall Comply with the requirement of IP-53
Type as per IS- 13947 .
Estimated Cost ;- Rs. 30=00 Lakhs , EMD :- Rs. 30,000 /-
I) ENVELOPE-A. :- [ Contain qualifying documents only ]
Please note:- Eligible bidders should comply conditions as specified in tender document . Bidders who failed to
comply conditions mentioned in Tender document will not be entitled for opening price bid.
II) ENVELOPE-B.:- Price - Bid Should be quoted in the schedule – A format enclosed in Tender document. III) ENVELOPE-C. :- This Envelope will contain Envelope-A & Envelope - B only.
OTHER CONDITIONS. [ for detailed conditioned see Tender documents ]
1]The offer should reach this office on or before 18-06-09 up to 13=00 hrs
The Technical Bid & Price Bid will be opened on the same day if possible. 2) No documents will be sold by this office &,Tenders through Post will not be accepted.
The Tender document should be downloaded from our web-site . The cost of Tender document Rs 3000=00 should be submitted in the form of D.D payable at Nagpur, in the name of "Superintending Engineer , Civil Circle ,MSEDCL Nagpur." on any scheduled Bank at Nagpur. Please enclosed D.D in Envelope A along with qualifying documents. [ Bid Submitted without D.D shall be considered as NoN- responsive and shall be rejected ] .
3) The material is required urgently for the DTC metering work. The first lot is required within 30 days & II lot in next 30 days . [ Total delivery period 60 days. ] . Only Firm who are capable of supplying material with in 60 Days should submit their offer . Please Note.
4) Sample along with offer is must . Offer without Sample , Stand Rejected . 5) The Undersigned reserves the right to reject any or all offers without assigning any reasons thereof.
CHIEF ENGINEER (NZ)
MSEDCL,NAGPUR
MAHARASHTRA STATE ELECTRICITY DISTRIBUTION CO. LTD.
Office of The Chief Engineer, Nagpur Zone,
1st floor, Vidyut Bhavan, Katol Road ,Nagpur -13.
Ph:- .2591139 , 2591976 , FAX-0712-2591927,
Signature and Seal of the Tenderer
2
CENZ / TECH/A-II /09-10 / T-04
No. CENZ/TECH/A-II /09-10/T- 4 /
Issued to M/s -------------------------------
-------------------------------
------------------------------
Phone : Fax:
Tender Documents For Supply Of L.T . Energy Metering Box For
DTC Metering work made by Deep Drawn process by using CRCA Sheet Steel metal ,as
per drawing & specifications .
Returnable not later than l3.00 Hrs on 18/ 06 /09 in tender box only.
Tender will be opened at l4.00 Hrs. on 18/06 /09 if possible
Estimated cost Rs. 30 Lakhs (Rs. Thirty Lakhs only.)
Office of the CHIEF ENGINEER
Maharashtra State Electricity Distribution Company Ltd.
Nagpur Zone,Ist floor, Vidyut Bhavan,
Katol Road,Nagpur-440013.
Price : Rs. 3,000/- per tender. Receipt No.: ……………
Date : …………………..
I / We certify that this Tender offer consists of ____ duly numbered pages
EMD Rs. 30,000/- paid vide money receipt No.-------------- dt.----------------
Signature and Seal of the Tenderer
3
CENZ / TECH/A-II /09-10 / T-04
MAHARASHTRA STATE ELECTRICITY DISTRIBUTION COMPANY LTD.
NAGPUR ZONE NAGPUR
Tender No. CENZ/TECH/A-II /09-10/T-4
NAME OF WORK
Supply Of L.T . Energy Metering Box For DTC Metering work made by Deep Drawn
process by using CRCA Sheet Steel metal ,as per drawing & specifications .
INDEX
--------------------------------------------------------------------------------
Sr.No. Description Page No
------------------------------------------------------------------------------------
l. Letter to Tenderer 4
2. Annexure 'A' Instruction to the Tenderer. 5
3. Annexure 'B'- Conditions of Tender and Supply. 15
4. Letter to the Chief Engineer(NZ). 22
5. Schedule 'A' (Price Bid In Envelope II ) 23
6. Technical specification Annexure C 24
7. Drawings 28
Note : This Tender document issued to the tenderer comprises of duly
numbered pages and must be submitted intact and duly filled in, signed, affixing his
seal on each page (below) of Tender document by the Tenderer. All the Tender
documents properly stitched together shall be enclosed in a duly sealed envelope.
Signature and Seal of the Tenderer
4
CENZ / TECH/A-II /09-10 / T-04
MAHARASHTRA STATE ELECTRICITY DISTRIBUTION COMPANY LTD.
NAGPUR ZONE, NAGPUR.
Tender No. CENZ/TECH/A-II /09-10/T-04
LETTER TO THE TENDERER
M/s -------------------------------------
-------------------------------------
Dear Sir,
Please quote your lowest rates in two bid system for delivery at Store Center
Wardha, Tumsar, Chandrapur in Maharashtra State for the supply of materials as
mentioned in Annexure 'C' and as per technical specification and return the tender
documents duly filled in, signed on each page and stating the offered delivery schedule in
item No.11 of schedule 'A' enclosed . Rates should be offered in Schedule 'A' only (
and not on your letter head) duly signed and should bear your seal. You are also
requested to note the instructions to the tenderer (Annexure 'A') before submitting your
offer.
Yours faithfully
Chief Engineer
Nagpur Zone, Nagpur.
Nagpur
Date :
Signature and Seal of the Tenderer
5
CENZ / TECH/A-II /09-10 / T-04
ANNEXURE 'A'
INSTRUCTIONS TO THE TENDERER I. Two Bid System :
The Offer is to be submitted in two envelopes super scribed as 'Envelope A' and
'Envelope B ' in Tender Box in due time . The sample of the box is also to be
submitted along with each offer, Without sample the offer will not be
considered. Separate sample for each Tender & offer.
a) Envelope A : Envelope containing the qualifying documents / certificates should
properly sealed and super scribed as below :Tender for Supply Of L.T . Energy Metering
Box For DTC Metering work / Tender No : T- 04 The due date & time
EMD paid details, D.D. NO. , M.R. NO., DATE:- , Firms name & address.
The envelope I should contain following qualifying document.
DD/ Photo copy of money receipt paid against EMD.
1. Valid registration.(manufacturer / authorized dealer )
2. Sales Tax registration / VAT Registration.
3. Technical specification of the meter box offered and deviation from the prescribed
specification.
4. Type Test Certificate from laboratories as per IP -53 [ IS -13947 ] .
5. Testing facilities available as prescribed as per IP -53
6. Experience in supply of Box. copy of supply order, certificates, etc
Single Order copy of at least 50% value of present Tender cost will be
preferred.
7. Whether sample submitted. Yes / No.
8. Whether Documents submitted Yes/No
Regarding Guaranteed Technical Particulars.
9 copy of balance sheet of 2 years certified by C.A., to examine the
financial capacity of bidder ,along with I.T. return file copy of last 2 year.
The bidder should have a total turnover at least equal to the
tender value during the last Two financial years
[ i.e. 06-07 , 07-08 ] in any Two financial years ,
10 Whether agreed for Company 's terms for Liquidated Yes/No
damages for Late Delivery as specified under
clause no.9 of conditions of Tender and Supply.
11. Tender document duly signed without price offer.
Signature and Seal of the Tenderer
6
CENZ / TECH/A-II /09-10 / T-04
b. Envelope B
The envelope B should contain the price Bid offer in Schedule A [page -23] attached
and should be placed in envelope C with marking as Price bid for supply of CT Meter
boxes for DTC Metering Work. Tender No. The due date & time. Firms name &
address.
II. A: PRICES :
Prices are acceptable only on FOR destination basis inclusive of risk in transit and freight
paid basis showing the break-up as desired in the schedule "A". It shall be noted that
offers not confirming to FOR destination basis and to the unit as specified in Schedule
"A" of the tender documents may not be considered. Only firm price will be acceptable.
II. B: BASIS OF PRICES :
The tenderer shall quote the prices on firm price basis only, as has been specifically
brought out in the tender details. For any deviation in this regard, the offer shall be
summarily rejected.
III: EXCISE DUTY :
Excise Duty will be paid extra, if applicable and agreed to, in the contract, at the
rates applicable at the time of dispatch (within the contractual delivery period), on
Ex-works prices to be indicated by the tenderer, against copy of Excise Duty gate pass.
You must thereafter quote :-
a) The rate at which Excise Duty is applicable on different slabs.
b) The rate of Excise Duty applicable to the offer if contract is awarded.
c) Also you will give an undertaking that the Excise duty applicable
shall be firm and will not change during the contract, if awarded.
If the above details are not given, your offer is liable for rejection.
IV : SALES TAX / VAT:
i) This Company is registered under all sales tax Acts/Ordinance of the Maharashtra
State, so also under the Central Sales Tax Act l956.
ii) Declaration on Form "C" will be issued whenever and
wherever applicable.
iii) A copy of Sales Tax registration certificate, as applicable should
be attached alongwith the Tender, clearly quoting the sale tax
registration No. and date.
iv) Rates should be mentioned clearly inclusive/exclusive of sales TAX/VAT.
Signature and Seal of the Tenderer
7
CENZ / TECH/A-II /09-10 / T-04
V: OFFERING THE MATERIAL ON SLAB BASIS:
Tenderers are requested to quote only single price/rate for the quantity offered by
them. The offers with prices of the materials quoted on slab basis and/or with any
conditional discount on any account viz. Payment, quantity etc, shall be rejected. The
tenderers shall quote the delivery only in the unit of the item specified in Schedule "A" i.e.
quantity is in Sets or in Nos. etc.
VI : DISCLOSING THE NAME OF THE MANUFACTURER :
Whenever a material is described by name of the particular brand or being offered in
resale basis, the tenderer shall specifically disclose the name of the original supplier or
the manufacturer and the firm shall not be allowed to supply the material offered from
any other manufacturer unless the prior permission in writing is obtained from the
C.E.(NZ). Authorised dealership if any should be specified. Copy of certificate issued to
that effect should be enclosed.
VII : QUOTATION :
i) Tenderer shall quote his lowest reasonable rate per unit or set specified in Schedule
"A" only, and not on his letter head or in any other manner whatsoever, in figures
as well as in words. Any variation in the rates etc. will not be allowed on any ground
such as mistake, misunderstanding etc, after the tender has been submitted.
The tendered rate must include in general (a) all charges for container and
packing (b) all charges if any to effect F.O.R. delivery at the destination of the supplies.
ii) Supplier's printed terms and conditions will not be considered as forming part of
the tender.
iii) In case of difference between the rates in figures and in words and difference between
F.O.R. destination price and sum of its break-up in ex-works price, freight, transit
insurance etc, it will be considered to read the rates advantageous and economical to the
Company
VIII : AMBIGUITY IN QUOTATION:
Tenderers are requested to please make a note that in case of ambiguous terms in
respect of F.O.R. destination condition, Excise Duty, Sales Tax, Basis of Price (i.e.
firm/variable) or if the blanks are not filled in/answered, the offer/tender shall be rejected.
Signature and Seal of the Tenderer
8
CENZ / TECH/A-II /09-10 / T-04
IX: FILLING IN OF ANNEXURE" A"/ QUESTIONNAIRE :
Tenderers are requested to ensure that the comments against each and every
item/clause of Annexure/Questionnaire shall be clearly filled in and answered in
questionnaire to the tender, . Any item/clause shall not be left blank or unanswered.
If any item/clause is not applicable, the words "Not Applicable" shall be written against it.
No place in the offer should be left blank and no dashes are required.
X: MANDATORY REQUIREMENT OF SUBMISSION OF OFFER :
a) The tender documents are supplied in one copy per tender. The offer shall be
submitted in the prescribed form enclosed herewith duly filled in, signed and complete
in all respect (including all copies of reports etc). on or before due time and date of
submission, failing which the offer is likely to be rejected.
b) All the pages of the offer should be numbered and it should be mentioned on the
first page bottom "I/We certify that this tender offer consists of #___________
duly numbered pages "
(# Total nos. of pages to be mentioned by the Tenderer)
XI : ADDITIONS/ALTERATIONS PROHIBITED :
Tenderers shall not make any additions, alterations or changes in the tender form
and the conditions of tender and supply including the description of material mentioned in
Annexure "C".
XII : SIGNING OF THE TENDER DOCUMENTS :
Offers must be submitted alongwith the tender documents only and be clearly and
legibly filled in with all the Schedules and Annexures etc. complete in all respects and must
be either in ink or type written. Offer and all documents comprising of tender details.
Tender form, conditions of tender and Supply, Schedules "A", Questionnaire, drawings,
Annexures, test certificates and other documents should be duly signed on each page as
required and bear seal of the Tenderer.
On each page of the Tender offer and in correction, if any, to the information filled in,
should be initialed by the Tenderer with seal of his firm. There should be no over-writings.
Wherever required, the overwriting should be avoided and new details given only
initialed. Tenders not signed as above shall be liable to be rejected.
Signature and Seal of the Tenderer
9
CENZ / TECH/A-II /09-10 / T-04
XIII :QUANTITIES OFFERED:
Tenderers should, if not in a position to quote for the entire quantity and for delivery
as required, state specifically the quantities which they can deliver at the price quoted .
Silence on this point will entitle the responsibility for supply at quoted rate in full quantity
as per delivery offered.
XIV : TIMELY SUBMISSION OF OFFER :
a) Telegraphic offer or offers received in the form of Telex or Fax messages will not
be entertained and considered under any circumstances whatsoever.
b) Tender documents received after the due date and time of submission will not be
accepted.
c) Tender received in person or by post after the due date and time of submission shall
not be opened and no correspondence will be entertained. The Company shall not be
responsible for any loss arising out of such delay.
d) In case the date of opening the Tender happens to be holiday, the tender shall be
opened on the next working day at the same time.
e) The Company reserves the right to reject any or all offers without assigning any
reason whatsoever.
XV : DISREGARD OF TENDER CONDITIONS:
The Company reserves the right to reject any tender which does not confirm to any of
the conditions/instructions etc.
XVI : Tender containing any deviation/addition/alteration/change in the conditions of
tender and supply as stated in enclosed Scheduled and Annexures shall not be acceptable.
XVII: The tenderer should note that no correspondence shall be entertained or considered
after the due date and time of submission of tender unless otherwise sought by the
Company .
XVIII : To judge the capacity and capability of the tenderer or his manufacturer, the
tenderer shall furnish the list of orders executed by him or his manufactures /principals for
the last 3 years indicating the number and date of the order, name of the purchaser,
quantity ordered, value , the delivery quoted, the delivery executed and the
deviation/slippage in delivery. Copies of orders is required to be submitted alongwith
Tender. Performance certificate from appropriate authority may also be attached.
Signature and Seal of the Tenderer
10
CENZ / TECH/A-II /09-10 / T-04
XIX : ACCEPTANCE OF TENDER :
The Company does not bind to accept the lowest or any tender, neither will any
reasons be assigned for the rejection of any tender or part of tender,. It is also not binding
on the Company to disclose any analysis report on tender/samples. The tenderer on his
part binds himself to supply item or items selected from his offer in part or whole at the
option of the Company .
XX : The Company reserves the right to order out/procure only quantity in excess to
the extent of 50% or any less quantity, of the quantities offered by the tenderers. The
quantity so specified will be for dispatch to our stores as mentioned in Item No.24
consignees,
XXI : EARNEST MONEY DEPOSIT :
The tenderers should pay the Earnest Money 1 % of the estimated cost of Tender unless the
tenderer is exempted on account of statutory directives.
Earnest Money shall be paid either in cash in The Office of the Superintending Engineer, Nagpur Civil
Circle, Vidyut Bhavan, Second floor, Katol Road,Nagpur or by Demand Draft crossed "Payee's
account only" drawn in favour of "Superintending Engineer , Civil Circle ,MSEDCL Nagpur." on any
scheduled Bank at Nagpur. Reference to the tender No. should be given before the due date of the tender and
the relevant deposit amount and receipt No. should be mentioned in the tender. Interest shall not be allowed on
EMD. Earnest Money Deposit shall be forfeited : I) In case the tenderer withdraws the tender/offer during
the validity period or ii) In case the tenderer fails to pay the Security Deposit if the contract is award ed.
However, Tenderers from following categories are presently exempted from payment of earnest Money Deposit.
Any statutory changes in this respect will be binding upon the tenderer.
i) All Government and semi-Government institutions under Govt. of Maharashtra and Zilla Parishads in
Maharashtra and fully owned undertakings of any State Govt. and Govt. of India.
ii) Small Scale Industrial unit permanently registered with, Director of Industries, Maharashtra only for
the items mentioned in their permanent registration certificate,.
iii) Small scale Units registered with the National Small Scale Industries Corporation and Small Industries
Service Institute of Govt. of India. Only for items manufactured by them.
Signature and Seal of the Tenderer
11
CENZ / TECH/A-II /09-10 / T-04
XXII : EARNEST MONEY OF UNSUCCESSFUL TENDERER :
Earnest money deposited shall be returned to the unsuccessful tenderers as
soon as possible after the tender has been decided and on submission of original money
receipt of EMD payment to this office.
XXIII :OFFER OF SSI UNITS :
Offers of the SSI Units shall be considered for price preference applicable to them
only if they comply with provisions under G.R.No. SPO/l088/25l8/IND-6 dt. 2/l/92 and
Company's policy in implementation of same. The SSI Registration Certificate should
include the item for which the offer has been submitted.
A certified copy of the SSI Registration certificate for SSI Unit being in force at
present also should invariably be submitted with the offer. Every Tenderer will have to
produce original S.S.I. registration certificate (or equivalent) within 7 days of opening of
tender without fail for verification.
XXIV : DELIVERY :
The material will have to be delivered within the time period and destination as
specified .
XXV : SUBMISSION/SUPER SCRIBING OF THE TENDER DOCUMENTS :
The tenderers are requested to enclose their offers in an envelope of proper size,
duly sealed clothed envelope. This clothed envelope containing the complete offer(
Envelope I & II)shall be duly sealed and super scribed indicating the address,. tender No.
due time and date of submission and details as follows before posting or delivering the
same in Tender Box.
i)Tender No.
ii)Due date and time of submission.
iii) Due date and time of opening.
iv) Payment of E.M.D.
a) If paid give details; b) If not paid or exempted give details ;
Signature and Seal of the Tenderer
12
CENZ / TECH/A-II /09-10 / T-04
XXVI : ARBITRATION :
1) The matters to be determined by the Chief Engineer:
All disputes and differences of any kind whatsoever arising out of or in connection
with the contract, whether during the progress of the work or after its completion and
whether before or after the determination of the contract, shall be preferred by the
contractor to the C.E. and the C.E. shall (within 120 days after receipt of the contractor’s
representation make and notify decisions of all matters referred to by the contractor in
writing.
i) Demand for Arbitration :.
In the event of any disputes or difference between the parties hereto as to
the construction or operation of this contract or the respective rights and
liabilities of the parties on any matter in question, the disputes or difference
on any account or as to the withholding by MSEDCL of any certificate to which
the contractor may claim to be entitled to or if the C.E. fails to make a
decision (within 120 days) then and in any such case, the contractor( after
120 days) but within(180 days) of his presenting his final claim on disputed
matters, shall demand in writing that the dispute or difference to be referred
to arbitration.
ii) The demand for arbitration shall specify the matters which are in question, or
subject of the dispute or difference as also the amount of claim item wise.
Only such dispute(s) or difference(s) in respect of which the demand has
been made, together with counter claims or set off, shall be referred to
arbitration and other matters shall not be included in the reference.
a) The arbitration proceedings shall be assumed to have commenced
from the day, a written and valid demand for arbitration is received by
the Company.
b) The claimant shall submit his claim stating the facts supporting the
claims along with all relevant documents and the relief or remedy
sought against each claim within a period of 30 days from the date of
appointment of the Arbitral Tribunal
c) The Company shall submit its defense statement and counter claim(s),
if any, within a period of 60 days of receipt of copy of claims from the
Tribunal thereafter unless otherwise extension has been granted by
the Tribunal
iii) No new claim shall be added during the proceedings by either party.
However, a party may amend or supplement the original claims or defense
thereof during the course of arbitration proceedings subject to acceptance by
Tribunal having due regards to the delay in making it.
iv) If the contractor(s) does /do not prefer his /their specific and final claims in
writing , within a period of 90 days of receiving the intimation from the
Company, that the final bill is ready for payment, he / they will be deemed to
have waived his / their claim( s) and the Company shall be discharged and
released of all liabilities under the contract in respect of these claims.
Signature and Seal of the Tenderer
13
CENZ / TECH/A-II /09-10 / T-04
2) Obligation during pendency of Arbitration :
Work under the contract shall, unless otherwise directed by the Engineer,
continue during the arbitration proceedings, and no payment due or payable
by the Company shall be withheld on account of such proceedings, provided,
however, it shall be open for Arbitral Tribunal to consider and decide whether
or not such work should be continued during arbitration proceedings.
(i) In cases where the total value of all claims in question added together does not exceed Rs. 1,00,00,000/-(Rupees One Crore) the Arbitral Tribunal shall consist
of a Sole Arbitrator who shall be either the C.E. of the Company or serving or
retired Officer of the Company/Government not below the grade of C.E. or
equivalent nominated by the Chairman of the Company in that behalf. The Sole
Arbitrator shall be appointed within 60 days from the day when a written and
valid demand for arbitration is received by the Company.
(ii) In cases the value of the claim exceeds Rs. 1,00,00,000/-(Rupees One Crore) as above, the Arbitral Tribunal shall consist of panel of 3 serving or retired officers
of MSEDCL/Govt. not below the grade of CE/CAO as the Arbitrators. For this
purpose, the Company will send a panel of more than 3 names of arbitrators of
one or more department of the Company/Govt. to the contractor who will be
asked to suggest to the Chairman at least 2 names for appointment as
contractor’s nominee. The Chairman shall appoint at least one of them as the
contractor’s nominee and will also appoint the balance number of arbitrators
either from the panel or from outside the panel, duly indicating the presiding
arbitrator from amongst the three(3) arbitrators so appointed . While
nominating arbitrators, it will be necessary to ensure that one of them is or has
worked in Accounts department.
(iii) If one or more arbitrators appointed as above refuses to act as arbitrator, withdraws from his office as arbitrator or vacates his/their office/ offices or
is/are unable or unwilling to perform his functions as arbitrator for any reason
whatsoever or dies or in the opinion of the Chairman fails to act without undue
delay, the Chairman shall appoint new arbitrator/s to act in his/their place in the
same manner in which the earlier arbitrator/s had been appointed. Such
reconstituted Tribunal, may, as its discretion proceed with the reference from
the stage at which it was left by the previous arbitrator(s)
(iv) The Tribunal shall have powers to call for such evidence by way of affidavits or otherwise as the Arbitral Tribunal shall think proper, and it shall be the duty of
the parties hereto to do or cause to be done all such things as may be necessary
to enable the Arbitral Tribunal to make the award without any delay.
(v) While appointing arbitrator(s) as above, due care shall be taken that he/they is/are not the one/those who had an opportunity to deal with the matters to
which the contract relates or who in the course of his/their duties as Company’s
servant(s) expressed views on all or any of the matters under dispute or
differences. The proceedings or the Arbitral Tribunal or the award made by such
Tribunal will, however, not be invalid merely for the reason that one or more
arbitrator had, in the course of his service, opportunity to deal with the matters
to which the contract relates or who in the course of his/their duties expressed
views on all or any of the matters under disputes
(vi) Arbitral award shall state item wise, the sum and reasons upon which it is based.
(vii) A party may apply for corrections of any computational errors, any
typographical or clerical errors or any other error of similar nature
Signature and Seal of the Tenderer
14
CENZ / TECH/A-II /09-10 / T-04
(viii) occurring in the award and interpretation of specific point of award to tribunal within 30 days of receipt of the award.
(ix) A party may apply to Tribunal within 30 days of receipt of award to make an additional award as to claims presented in the arbitral proceedings, but omitted
from the arbitral award.
(x) In case of the Tribunal, comprising of three members any ruling or award shall be made by a majority of Members of Tribunal. In the absence of such a
majority, the views of the Presiding Arbitrator shall prevail.
(xi) Where the arbitral award is for payment of money, no interest shall be payable on whole or any part of the money for any period till the date on which the
award is made.
(xii) The cost of the arbitration shall be borne equally by the respective parties.
The cost shall inter-alia include fees of the arbitrators as per the rates fixed by
the Company from time to time. Provided that the fees payable per arbitrator
for claims up to Rs. One Crore, shall not exceed Rs. 2000/ per sitting subject to
a maximum of Rs. 25,000/- and the fees payable per arbitrator for claims over
Rs. One Crore, shall not exceed Rs. 2000/- per sitting subject to a maximum of
Rs. 50,000/- Provided further that the arbitrators who are in service of
Govt/MSEDCL shall draw fees at half of the rates mentioned above.
(xiii) Company shall maintain a list of arbitrators. The Chairman shall have full powers to delete or add the name of the arbitrators in the list or to make
amendments to the said list as per his discretion.
(xiv) The arbitral proceedings should be completed and the award be finalized within one year from the date of appointment of arbitrators.
(xv) Subject to the provisions as aforesaid, Arbitration and Conciliation Act, 1996
and the rules there under, any statutory notification thereof shall apply to the
arbitration proceedings under this clause.
In case the contractor(s) falls within the ambit of Small Scale and Ancillary Industrial
Undertakings Act, 1993, following clause regarding payment shall be incorporated :-
Payment of bills
“In case the contractor(s)/supplier(s) falls within the ambit of Small Scale and
Ancillary Industrial Undertakings Act 1993, the Company shall pay the price of the
goods received, as far as possible, within 60 days subject to a maximum of 120 days
from the date of acceptance or the date of deemed acceptance of goods as per
specifications. In case the Company fails to pay price of the goods within 120 days
from the date of acceptance or the date of deemed acceptance of the goods as per
specifications, the Company shall be liable to pay interest as per provisions of Small
Scale and Ancillary Industrial Undertakings Act, 1993.
Signature and Seal of the Tenderer
15
CENZ / TECH/A-II /09-10 / T-04
ANNEXURE -'B'
CONDITIONS OF TENDER AND SUPPLY
l. QUALITY OF SUPPLY:
All materials supplied shall be strictly as per the specification laid down and in strict
accordance with the details given in "ANNEXURE-C and Drawing". The supplier will keep
this office informed of the progress of fabrication and supply of the materials. The goods
shall be subject to the approval of the consignee after receipt of materials at our store
center.
2. VERIFICATION OF MATERIAL SUPPLIED :
a) The Company shall have option to test the samples selected at random from the
supplies effected to ensure that the supplies confirm in quality and workmanship to the
relevant specification and drawings if any.
b) The tendered material i.e. as per Annexure 'C' will have to be delivered by supplier
to the concerned store center.
4 . DESPATCH INTIMATION :
The supplier shall inform telegraphically to the consignee details of despatches giving
RR/LR No. wagon/truck No. type of wagon, cranable consignment or otherwise, total
value of consignment etc. to facilitate the consignee to arrange for clearance of
goods.
5. CLEAR RAILWAY RECEIPT :
Packing used shall be conforming to specifications/conditions laid down by Railway
and clear Railway Receipt shall be obtained by the
supplier from Railway without any ambiguity, so as to facilitate proper clearance of goods
at destination.
6. INSURANCE :
In all cases, Insurance shall be effected by the supplier with Govt. Insurance Fund or if
permitted by the Company . with his other Insurers for all risks for the total value of the
order plus l0% to cover freight, sales tax, and other incidental charges.
7. REPLACEMENT OF GOODS LOST, BROKEN OR DAMAGED. :
Not withstanding any thing herein contained, the supplier shall undertake to be
responsible for the safe arrival of the materials in good condition and without any loss or
damage at the final destination and until the same be delivered to and received by the
Company at the Stores or other places of final destination and,
Signature and Seal of the Tenderer
16
CENZ / TECH/A-II /09-10 / T-04
for this purpose materials carried by Railway or other carrier shall be deemed to be so
carried at the risk of the supplier, In case of transit damages /shortages, the payment
shall be made only for the quantity received in good and working condition. Consignee shall
lodge claim with carriers and transfer the same to the supplier with all necessary
documents for settlement of the same with carrier at supplier's end.
Transit damages/shortages/losses reported by the consignee shall be repaired/replaced
by the supplier duly inspected, free of cost within one month from the date of such
intimation of breakages /shortages without awaiting for settlement of his claim from
carrier or Insurance Co.etc.
8. LIFTING OF DAMAGED/REJECTED MATERIAL :
a) On failure to replace or repair the transit damages or rejected material within one
month from the date of intimation as required under tender specification, it shall be
deemed to have concluded that such material is finally rejected. The
damaged/rejected material shall be lifted by the supplier within 30(Thirty) days from the
date of receipt of notice to that effect from the concerned consignee on reimbursement to
the Company of the cost of the material/equipment, if any, already paid in terms of
payment clause in the contract and the actual expenses incurred
by the consignee towards, control, handling. demurrage/ pilferage /undercharges
freight, insurance, premium etc. The Company shall not be responsible in any case
for the loss, destruction, damage, deterioration of the material after expiry of the same
30(Thirty) days period.
b) If the supplier fails to lift the material within this period the material will remain with
Company at the cost and risk of the supplier. Supplier shall, therefore, be liable to pay
ground rent @ 0.l% (point one percent) per day of purchases cost will be recovered from
the date of intimation of rejection of materials till the actual date of lifting.
c) The Company will also be free to dispose of such materials, after the period of said
30 (Thirty) days by public Auction/Tender Notice/Destruction as may be deemed fit and
storage charges @ O.l% (point one percent) per day of purchase
cost will be recovered from the date of intimation of rejection of materials till the
date of realisation of the actual expenses incurred as referred to at (a) above.
d) Notwithstanding what is contended in the foregoing clauses, the supplier
shall be liable to pay the Company and cost and expenses incurred by the Company . if
any, including ground rent and the same shall be appropriated and recovered from the
sale proceeds.
Signature and Seal of the Tenderer
17
CENZ / TECH/A-II /09-10 / T-04
9. LIQUIDATED DAMAGES OR LATE DELIVERY:
In case the materials are not delivered within the period stipulated in the order,
supplier will be liable to pay, at the discretion of the competent authority of the Company ,
the liquidated damages to the Company upto half percent per week or part of week on
the price subject to a maximum of cumulative ceiling of l0% reckoned on the contract
value of such complete portion or section of plant, equipment or material, delayed and
also the portion supplied which could not be brought into commission due to any part
thereof not having been delivered in time. Due consideration may be given in the levy of
liquidated damages for reasons absolutely beyond the control of the supplier for which
documentary evidence shall be produced to the satisfaction of the competent authority of
the Company .
The Company shall be entitled to deduct/recover the amount of liquidated damages
from the current bills/ payable to the supplier or any other amount due or payable to him
against this or any other contract.
For computing the liquidated damages for delayed supplies, the date of railway receipt
or the date of receipt of materials at stores in case of road transport shall be the date of
delivery.
In case the Company does not arrange for inspection of material within 30 days,
from the date of receipt of inspection call in the office of the Chief Engineer, MSEDCL,
Nagpur Zone, Nagpur, the period of more than 30 days will not be considered for levy of
liquidated damages. For computing the period taken for inspection in such cases, the
relevant dates mentioned in the inspection certificate issued by Inspecting Officer would be
considered
l0. PERFORMANCE OF CONTRACT :
The Company will not be in any way liable for non-performance either in whole or in
part of any contract or for any delay in performance thereof in consequent of strikes,
shortages non availability of raw materials, combination of labor or workmen or lockout,
break down or accident to machinery or accidents of whatever nature, failure on the part
of the Railway to supply sufficient wagons to carry essential raw materials etc. and
finished products from the stores subject to the
provision and stipulation made in condition No.9 as stated above i.e. Liquidated Damages
for late delivery.
Signature and Seal of the Tenderer
18
CENZ / TECH/A-II /09-10 / T-04
11. SUBMISSION OF BILLS AND BILL OF MATERIAL :
The supplier shall furnish bill of material if applicable for each type of
equipment/material offered which should be consistent with the drawing, sample
specification and guaranteed technical particulars. The copies of this bill of material
should always be enclosed alongwith the bill submitted by the supplier for payment
wherein he should specifically mention the material/components despatched out of the bill
of materials if the equipment is not sent in totality. Where the equipments /materials to
be supplied consists of more than one component, the supplier claiming payment for
equipment/materials shall certify that all the components of the equipments /materials
have been supplied in full for the quantity indicated. Part payment shall not be allowed.
12. PACKING LIST : (wherever Necessary)
Each package shall contain in waterproof cover, the detail list indicating the order
reference, date list of contents and reference to the approved bill of material and enclosed
in the package. Each item contained in the package shall be described sufficiently to
enable to see identification of the quality, weight etc. There should not be any alteration
in the packing list incorporated in the order. Copy of the packing list should be sent to
(I) consignee(II) and it should be enclosed with the bills alongwith other documents.
13. MATERIAL DESPATCHED AND PROGRAMME:
A statement indicating despatches effected or otherwise during every month shall
be furnished along with programme of manufacturing/despatches should be submitted to
the office of the Chief Engineer, M.S.E.D.C.L. Nagpur Zone, Nagpur on or before seventh of
succeeding month.
14. PAYMENT OF BILLS :
100 % payment of the bill alongwith excise duty and taxes will be done by A/C payee
cheque within reasonable period from the date of receipt of specified material in good
condition. and on submission of bills to the respective Suptd. Engineer, in triplicate
along with valued S R note from Dy E E (Stores concerned ), duly certified. Date of issue
of cheque shall be the date of payment.
i) Bill/Invoice
ii) Certificate of proper despatch,
iii) Other documents like excise duty, gate pass, original receipt of payment of Octroi.
vi) Detailed packing list. (if applicable)
vii) Bill of material. if applicable..
viii) Valued Copy of S.R. Note
Signature and Seal of the Tenderer
19
CENZ / TECH/A-II /09-10 / T-04
Payment will be released by concerned Superintending Engineer, of that circle for which
material is ordered.
The supplier shall forward the original bill direct to the consignee alongwith 4th copy of
the bill and Xerox copy of approved drawing if any. The original bill should be marked
"ORIGINAL" The bill should indicate No. and date of sales Tax Registration Certificate
held by him under the Sales Tax Act. The Company shall not be responsible for delay in
payment of bills if the supplier fails to comply with any of the above requirements.
15. OCTROI AT DESTINATION :
Octroi charges, if applicable at destination shall be borne by the Company .
l6. SECURITY DEPOSIT ":
The supplier shall have to pay within 7 days from the date of receipt of order / letter
of intent, a security deposit @ l0% of the value of the order.
l7. Security deposit applicable to SSI Units in Maharashtra will be 3%(Three percent)
of the order value subject to a maximum of Rs. 50,000/- However , security deposit will not
be applicable in respect of following.
i) Registered suppliers on the list of Development Commissioner (Industries) and
stores Purchase Officer. For the order value upto Rs. 25,000/- no security deposit shall be
payable.
ii) Small scale Industries registered with the Directorate of Industries and Maharashtra
Khadi and Gramodyog Mandal shall be exempted from payment of security deposit for
value of order limited to Rs. 5 Lakhs.
The failure in making payment of security deposit as required herein above within
7 days will be viewed seriously and the contract awarded shall be liable to be
terminated.. The security deposit shall be paid in favor of The Superintending Engineer
(NRC) Maharashtra State Electricity Distribution Company Ltd., by way of:
i) Cash or
ii) Banker's cheque or Demand Draft or pay order on any
scheduled Bank in Nagpur.
This security deposit is for the performance of the material/contract and the same
shall be liable to be apportioned towards amount due or becoming due by the supplier on
his failure to execute the order or any other contract and in the event of non fulfillment
of the terms and conditions of the contract.
It will be refunded only on the fulfillment of condition of contract and complete
delivery of material up to the satisfaction of MSEDCL
Signature and Seal of the Tenderer
20
CENZ / TECH/A-II /09-10 / T-04
18 : AGREEMENTS :
Whenever agreement are to be executed, the supplier shall execute the same in the
form and manner as required by the Company on the required stamp papers at his cost.
19. DEDUCTION :
Any amount on damages or charges or expenses or any other amounts which become
payable by the supplier to the Company under the same or any other contract shall be
deducted by the Company from any amount/amounts due or becoming due to the
supplier under the same or any other contract and shall be adjusted against dues
of the Company without prejudice to the Company 's right to recover the same by
ordinary process of law.
20. ROAD TRANSPORT :
In case, supplier prefers to despatch the materials by Road Transport at his risk and
cost and without any extra cost to the Company , the materials shall be accepted only
during office hours on working days. Supplier should ensure that goods reach the stores
sufficiently in advance on any working day between 9=00 Hrs. to 15=00 Hrs. so as to
arrange their unloading during office hours, failing which the Company shall not be liable
for unloading and for inconvenience caused to the transport contractor in the form of
detention etc. Unloading at stores shall be arranged by the consignee.
21. WAGON LOAD/TRUCK LOAD :
Quantity to be dispatched to consignee may not necessarily be in full wagon load/truck
and may be part load as per requirement.
22. VALIDITY OF THE TENDER :
The tender shall remain open for acceptance by the Company for a period of 90
(Ninety) days from the date of opening of tender and the tender shall be bound to supply
at the same rate on acceptance by the Company during validity period of his offer.
23. TERMINATION OF CONTRACT :
In case the contract/supplier fails to deliver the stores/material or any
consignment thereof within the contracted period of delivery or in case the stores/materials
are found not in accordance with the prescribed specification and the approved
samples,/drawing (if any) the Company shall exercise its discretionary either,
a) to recover from the supplier the liquidated damaged as provided in the
condition No. 9 of "Condition of Tender And Supply".
b) to purchase from elsewhere, after giving due notice to the contractor on account of
his failure at the risk of contractor such stores/materials not so delivered or others of
similar description without canceling the contract in respect of consignment not yet due
for delivery.
Signature and Seal of the Tenderer
21
CENZ / TECH/A-II /09-10 / T-04
c) to cancel the contract reserving Company 's right to recover damages.
Notwithstanding that the powers under (a),(b) & (c) referred above are in addition to the
right and remedy available to the Company under the General Law of India relating to
contract.
NOTE :
l) In the event of risk purchase of stores of similar description, the option of the
Company shall be final. In the event of action taken under (a) or (b) above, the supplier
shall be liable for any loss which the Company may sustain on that account but the
supplier shall not be entitled to any saving on such purchases made against default.
2) The decision of the Company shall be final as regards the acceptability of the Stores
supplied by the supplier and the Company shall not be required to give any reason in
writing or otherwise at any time for the rejection of the stores/materials.
24. CONSIGNEE :
1. The Dy Executive Engineer(Stores)
MSEDCL Major Store A Kamptee
Kamptee- Dist. Nagpur.
2. The Dy Executive Engineer(Stores)
MSEDCL Tumsar Store Center,
Tumsar , Dist. – Bhandara –441907
3. The Dy Executive Engineer(Stores)
MSEDCL Chandrapur Store Center,
Chandrapur , Dist. – Chandrapur –442403
25. JURISDICTION :
Any disputes or differences, arising under, out of or in connection with this tender or
contract if concluded., shall be subject to the exclusive jurisdiction of local
courts/superior courts at Nagpur.
Signature and Seal of the Tenderer
22
CENZ / TECH/A-II /09-10 / T-04
MAHARASHATRA STATE ELECTRICITY DISTRIBUTION COMPANY LTD.
NAGPUR ZONE NAGPUR.
LETTER TO THE CHIEF ENGINEER
To
The Chief Engineer,
Nagpur Zone, MSEDCL
Katol Road, Vidyut Bhavan,
Nagpur-440013.
Dear Sirs,
I/We agree to supply the materials at the rates herein tendered by me/us subject
to the above conditions of tender and supply which I/We have carefully read and which
I/We have thoroughly understood and to which I/We agree.
I/We hereby agree to keep this offer open for 90 days from the date of opening of
tender and shall be bound by communication of acceptance despatched within the
prescribed validity period.
Yours faithfully,
Signature and Seal of Tenderer
Date :
Name and address of the
Tenderer,
l. with factory Phone No.
2. FAX No.
3. Permanent address with phone No.
Signature and Seal of the Tenderer
23
CENZ / TECH/A-II /09-10 / T-04
SCHEDULE "A"
The following rates are given for the standard materials specified in Annexure "C" and
as per drawings.(if applicable)
l. Rate for each box in Rs........................
(in words) .(Rupees .......................
[ Rates should be quoted F.O.R. at our Store centers at
Tumsar / Kamptee / Chandrapur. ]
2. Sales Tax / VAT.
3. Sales Tax Registration.
4. Central Excise Tax.
5. Excise duty.
6. Octroi.
7. Delivery period.
8. Validity.
9. Discount.
10. Delivery Schedule.
11. Guarantee/Warrantee.
12.Any other remarks.
Signature and Seal of the Tenderer
27
CENZ / TECH/A-II /09-10 / T-04
12. REJECTION :-
The Chief Engineer [ NZ] at his discretion , may select one Compete Metering Box
at random from a lot of each type or part thereof as may be supplied from time to time .
The metering Box so selected must pass any or all the Test mentioned above , other wise
the whole lot of metering boxes or part thereof from which one box was selected , will be
rejected.
The Testing under this clause will be done in any of Laboratory of MSEDCL Choice including
MSEDCL Laboratory. Notice of such tests will be given by the MSEDCL by ordinary post to
supplier and the date of Test may not be altered to the convenience or request of
Supplier. The supplier is at liberty to be present during testing.
13. Submission of Sample :-
The sample of Boxes as per specifications Shall be submitted along with tender.
14. All the deviations from the Specifications shall be brought out in the separates
attached Sheet . The discrepancies between the specification and the catalogs /
Literatures and indicative drawing which are subject to change ,submitted, as part
of the offer shall not be considered and representation in this regard shall not be
entertained.
15. The deviation brought by the Tenderer shall be supported by authentic documents
standard and clarification otherwise the offer may be liable for rejection.
16. The Tenderer shall submit the list of orders for similar type of equipments executed
or under execution during the last three years , with full details as a experience in
the field of supply and to enable the purchaser to evaluate the tender.
Signature and Seal of the Tenderer
31
CENZ / TECH/A-II /09-10 / T-04
Short Tender Notice
Super scribed and Sealed offers are invited from Manufacturers / authorized dealers For Supply Of L.T . Energy Metering
Box For DTC Metering work
The Tender details / documents No CE/NZ/Tech/A-II/ 09-10/ T- 04
is available at our web site WWW.mahadiscom.in.
Submit the tender – Offer on or before 18-06-2009 up to 13=00 hrs
Any changes in Tender Schedule , Corrigendum ,amendment , extension of due dates etc, if any , shall be available in our web site only and will not
be published in the News papers.
Contact Person Exe. Engineer ( ADM ) Tel No. 0712-2591976 , 2592341 ,2591023. Fax. No. 0712-2591927.
CHIEF ENGINEER [ Nagpur Zone ]
1 St Floor, Vidhut Bhavan , Katol Road , Nagpur:- 440013