infra projects and indian states
TRANSCRIPT
-
7/28/2019 Infra projects and Indian states
1/54
Mithun Karthikeyan
PGP Student
A study on the delay in the
construction of dams and canals
by NVDA
Indian Institute of Management
5/26/2011
Submitted to
-
7/28/2019 Infra projects and Indian states
2/54
2
DETAILS OF THE PROJECT
Organization Name: Narmada Valley Development Authority, Bhopal
Project Commencement Date: 1st April 2011
Project Duration: 2 months
Project Guide Details:
Mr. A.K.Srivastava (NVDA)
Secretary
NVDA
Name of Student Mithun Karthikeyan
Roll No: 2010 PGP 191Summer InternIndian Institute of Management, Indore
Email: [email protected]
-
7/28/2019 Infra projects and Indian states
3/54
3
CONTENTS
DETAILS OF THE PROJECT ............................................................................................................................................. 2CERTIFICATE.......................................................................................................................................................................... 5Executive Summary.................................................................................................................................................................. 9Background ............................................................................................................................................................................... 10
Brief history on NWDT and NVDA............................................................................................................................. 10Problem Definition.................................................................................................................................................................. 12
Statement of the problem ................................................................................................................................................. 12Details of projects being included as part of this study .......................................................................................... 13Past/Related Works ............................................................................................................................................................ 18
Research Design ...................................................................................................................................................................... 19Observations ............................................................................................................................................................................. 21Conclusion and Recommendations.................................................................................................................................... 23
Type of Contract ................................................................................................................................................................. 23Item rate or Turnkey ..................................................................................................................................................... 23Pros and Cons of Low bid contract .......................................................................................................................... 25
Issues with Project Scheduling....................................................................................................................................... 25Better Scheduling practices: ....................................................................................................................................... 26Department Engineers Competency in Scheduling Techniques ..................................................................... 26Types of Schedules to be provided by the contractor......................................................................................... 27Milestones ........................................................................................................................................................................ 29Qualifications of Scheduler and Contractor Staffing.......................................................................................... 29Allowable Software for Scheduling......................................................................................................................... 29
Partnering.............................................................................................................................................................................. 29Formal Risk Assessment process .................................................................................................................................. 30Monitoring the progress of work................................................................................................................................... 33
Intermittent Progress and Pacing for Delays......................................................................................................... 34Issues with Sub-Contacting............................................................................................................................................. 35Other issues .......................................................................................................................................................................... 36Conclusion ............................................................................................................................................................................ 39
Scope for future work............................................................................................................................................................ 40
-
7/28/2019 Infra projects and Indian states
4/54
4
Appendix:................................................................................................................................................................................... 41Details on Halon Project................................................................................................................................................... 41Details on Upper Beda Project ....................................................................................................................................... 42Details on Omkareswar Project...................................................................................................................................... 43Details on Lower Goi ........................................................................................................................................................ 45Details on ISP Project ....................................................................................................................................................... 47
Questionnaire............................................................................................................................................................................ 49Bibliography ............................................................................................................................................................................. 54
-
7/28/2019 Infra projects and Indian states
5/54
5
Narmada Valley Development Authority
CERTIFICATE
To whomsoever it may concern
This is to certify that Mr. Mithun Karthikeyan, an intern from MBA
Program of Indian Institute of Management, Indore was associated
with the Narmada Valley Development Authority, Bhopal under the
summer internship scheme of School of Good Governance and Policy
Analysis, Bhopal. He had undertaken a study on Delay in
construction of Dams and Canals by NVDA assigned to him by the
department. He was associated with the department for a period of
two months starting from 10th May, 2010 and has completed the
project successfully. We wish him all the very best for his future
endeavours.
(A.K.Srivastava )
Secretary
Govt. of MPNarmada Valley
Development Authority
-
7/28/2019 Infra projects and Indian states
6/54
6
ACKNOWLEDGEMENT
This study would not have been possible without the guidance and help of several individuals. First and
foremost I would like to thank Mr. O.P Rawat, VC, NVDA for his continued encouragement and support
in performing the study.
I would also like to thank the following for their contributions in successfully completing the project
Mr. A.K.Srivastava Secretary, NVDA For guiding me in completing the project
and helping me in mitigating any hurdle
in completing the project
Prof.H.P. Dikshit Director General SGPA For providing valuable suggestions and
insights on improving the research quality
Mr. A.K. Sukhla Member Engineering, NVDA For helping me in various stages of data
collection
Dr. S.M. Hyder Rizvi Director, Policy Analysis, SGPA For helping me resolve the various issues
that I faced during the initial phase of the
project.
Mr. Gaurav Khare KM, Project Officer, SGPA For his continuous support throughout the
project, and helping with any issue being
faced.
Mr. R.R. Bandari Advisor to Secretary, NVDA For reviewing my work and providing his
valuable suggestions.
Mr. G.P. Soni EE ND division -25, narmada
nagar
For taking out time from his busy
schedule and guiding me at various stages
of the project providing me with some
excellent suggestions and feedback
-
7/28/2019 Infra projects and Indian states
7/54
7
I would also like to thank the following for taking out time from their busy schedule and providing me
with the information that was required in completing the project.
Mr. P.K. Paharey
Mr. C.B.Srivastav EE, Region 25, NVDA
Mr. N.K. Brahme Director, E-Tendering Cell NVDA
Mr. S.K.G Pandit CE, CWC
Mr. V.C.Avasthi Consultant, R&R
Mr. Ajay Shah EE, ISP, NVDA
Mr. Dewada CE, ISP, NVDA
Mr. S.P. Tirkey EE, ISP, NVDA
Mr. Dhamendra Consultant, Cadd Systems and services
Mr. Chongad EE, Lower Goi
Mr. T.P. Anand SDO, Upper Beda
Mr. Sanjay Joshi AE, LNZ, Indore
Mr. S.K.Sharma SDO, Head Quarters, Jabalpur
Mr. G.B. Chanderia EE, Upper Narmada Project
Mr. P.K. Jain AE, Head Quarters, Jabalpur
Mr. V.K. Pandey EE, ND Div 2, Mandla
-
7/28/2019 Infra projects and Indian states
8/54
8
List of Abbreviations
NVDA Narmada Valley Development Authority NWDT Narmada Water Dispute Tribunal MoEF Ministry of Environment and Forest CE Chief Engineer EE Executive Engineer CPM Critical Path Method PERT Program Evaluation Review Technique CWC Central Water Commission NIT Notice Inviting Tender
-
7/28/2019 Infra projects and Indian states
9/54
9
EXECUTIVE SUMMARY
Almost all Dam and Canal construction projects under NVDA are suffering from huge delays in
completing the project. Delays in any infrastructure project leads to significant economic and political
implications. While the immediate effect is that the public needs to wait for the benefits being deliveredby the project, it also leads to many other secondary effects on the economy. For instance, delay in the
construction of canals leads to the benefit of irrigation being delayed to the farmers, which further leads to
decrease in the farm output, upsetting the economic growth in other sectors. Common Knowledge with in
NVDA dictates various reasons for this grave delay, one of the most prominent being issues with land
acquisition, followed by under staffing, delays on the part of CWC etc. This research concentrates on the
delays in post approval processes related to construction of dams and canals, and is based on in-depth
interviews with more than 15 Engineers from NVDA, a contractor and a consultant. Also 6 projects under
NVDA have been scrutinized for reasons that lead to the project being delayed and to explore the truth
behind the frequently stated reasons for delay.
The method being adopted by this study was to make a list of best practices in the industry which helps in
reducing the time delays in project execution, and then to check the existence of such practices during the
project execution at NVDA. In-depth interviews were conducted with Department Engineers, Contractor
and Consultant to study the practices being followed by NVDA in project execution. Also the project
document available at site has been evaluated to study the issues faced during the project execution. It has
been observed that NVDA lacks in almost all such best practices, some much grave than others. Lack of
formal scheduling techniques and failure in effectively monitoring the contractors performance with
respect to the schedule is one of the main reasons for non-performance of projects. Adding to these are
the issues of in-competence in the part of Engineers in scheduling techniques and lack of formal risk
assessment system etc.
It is recommended for NVDA to adopt detailed scheduling in its projects. A detailed approach to the
scheduling process has been provided as part of this study. In addition, there is necessity to train the
department engineers in the various scheduling techniques like CPM and PERT so that mistakes are not
made while preparing or reviewing the schedules. It will also help the engineers in close monitoring of the
progress of work by the contractors and to evaluate it on the basis of the schedule provided by them.
There is also a need to apply formal risk assessment processes in all the projects being undertaken by
NVDA. Since the projects are of similar nature, a generic risk assessment framework can be created and
can be extended for specific projects. The research also gives guidelines in preparing the risk assessment
processes.
-
7/28/2019 Infra projects and Indian states
10/54
10
BACKGROUND
BRIEF HISTORY ON NWDT AND NVDA
The Narmada Valley Development Authority is a multidisciplinary organization of the State of Madhya
Pradesh and its head office is at Bhopal. The NVDA has jurisdiction over the major water resources
development projects in the Narmada Basin. Formed in 1985, NVDA works for the all-round
development of the Narmada basin. Narmada is the 5th largest river in Indian Peninsula and flows
through the states of Madhya Pradesh, Gujarat and Maharashtra. The disputes related to utilization of
water from Narmada, between Madhya Pradesh and Gujarat led to the formation of Narmada Water
Disputes Tribunal (NWDT). NWDT suggested the following share of water for each state
State MAFMadhya Pradesh 18.25
Gujarat 9.00
Rajasthan 0.50
Maharashtra 0.25
Total - 28.00TABLE 1: NWDT ALLOCATION OF NARMADA WATER TO STATES
This allocation will be reviewed in the year 2025, and under utilization by any state will lead to re-
allocation of each states share appropriately. For Madhya Pradesh to make use of the 18.25 MAF of water
allotted, it is planned to complete 29 major projects by the year 2025. However the delays in construction
of such dams and canals have become a cause of worry for NVDA and if this issue is not addressed at the
earliest, it could even lead to failure in the part of NVDA in achieving its target of 18.25 MAF water
usage by the year 2025, leading to the un-tapped potential being allotted to other states. Moreover, the
delay in construction of dams and canals is also hurting the state in the form of higher financial
expenditure and losses in the form of delaying the revenue generation.
-
7/28/2019 Infra projects and Indian states
11/54
11
Table below provide details on the major dams and canals being planned on the Narmada Basin by
NVDA
S.No.
Name of Project Benefits Power Irrigation
(Lakh ha.) (MW) Mcum)Completed Projects
1 Tawa 2.469 13.50 2386.72
2 Barna 0.548 559.82
3 Kolar 0.451 435.90
4 Sukta 0.166 170.57
5 Matiari (Dhobatoria) 0.101 88.38
6 Man Project 0.15 140.00
7 Jobat Project 0.098 112.00
Ongoing Projects8 Rani Awanti Bai Sagar 1.57 100.00 1008.00
Bargi Diversion 2.45 1853.10
9 Indirasagar Project 1.23 1000.00 1674.00
Canal Power House of ISP 15.00
10 Omkareshwar Project 1.47 520.00 1300.00
11 Punasa lift 0.323 105.00
12 Upper Beda 0.099 90.00
Proposed Projects
13 Upper Narmada 0.185 178.93
14 Upper Burhner 0.098 82.72
15 Halon 0.117 134.00
16 Ataria 0.129 112.36
17 Chinki 0.708 1969.90
18 Sher 0.647 567.96
19 Machchrewa
20 Shakkar
21 Dudhi 0.506 444.49
22 Morand 0.522 465.48
23 Ganjal24 Lower Goi 0.137 133.00
25 Raghavpur 20
26 Rosara 25
27 Basaniyar 20
28 Sitareva 15
TABLE 2: MAJOR DAMS AND CANALS IN NARMADA BASIN
-
7/28/2019 Infra projects and Indian states
12/54
12
PROBLEM DEFINITION
STATEMENT OF THE PROBLEM
Decision Problem Research Problem Information Required Research Design
1. To study the
delay in
construction of
dams and canals
1.1 What are the major
factors affecting the
performance of project?
1.1.1 List of key attributes leading to
improvement in performance in the
execution of infrastructure projects
1.1.2 List of activities leading to
deterioration in the performance of
infrastructure project
implementation.
1. In-depth Interview
with Engineers and
senior officer in
NVDA
2. Literature review
and past research of
similar topics
1.2 What are the current
practices with in NVDA
during the execution of
the project?
1.2.1 Engineers knowledge about
the key attributes leading to the
success or failure of a project
1.2.2 Engineers competence in the
key attributes leading to the success
and failure of a project
1. In-depth interview
with the Engineers
1.3 What are the project
attributes missing in
NVDA leading to the
excessive delay in
completing the projects
1.3.1 How does the actual practices
in NVDA differ from the best
practices required for a speedy
construction of the project
1. Comparison of the
results obtained from
the two steps above
-
7/28/2019 Infra projects and Indian states
13/54
13
DETAILS OF PROJECTS BEING INCLUDED AS PART OF THIS STUDY1
1. Indira Sagar Project:The Indira Sagar Project is the key project on the Narmada River for irrigation and power
generation. The regulated releases from Indira Sagar Project will be utilized by Omkareshwar,Maheshwar and Sardar Sarovar Projects on the downstream of Indira Sagar Project. The Narmada
Tribunal has directed that regulated releases from ISP would be made available for use at Sardar
Sarovar to the extent 8.12 MAF per year, ex-Maheshwar. Indira Sagar Project envisages
construction of 92 m. high and 653 m. long concrete dam. Near village Punasa in district
Khandwa which is the highest dam of the State and on completion has formed a lake of gross
capacity of 12.220 Mcum (9.9 MAF) the biggest in South Asia. The project offers excellent
opportunity for power generation with an installed capacity of 1000 MW and will enable
irrigation with 249 km length of the main canal over 1.23 lakh hectares in Khandwa andKhargone districts. In Khandwa district 76 villages in Khargone district 345 villages and in
Barwani district 150 villages, in all 571 villages would be benefited In May 2000 It was decided
to implement the power portion of Indira Sagar Project through the joint venture of NHPC (GOI)
& GOMP. The joint venture is named as NHDC (Narmada Hydro Electric Development
Corporation Ltd.). The works of dam and power house were entrusted to NHDC Ltd. on
25.9.2000 and were completed by June 2005 and June 2007 respectively.
The works of canal of ISP are being executed by NVDA. The work of canal is being completed
by funds under Accelerated Irrigation Benefits Program (AIBP) of GOl and loan from NABARD.
The Indira Sager Project has been receiving assistance under AIBP since 1996-97. The works on
the canal system from 0 km to 248.00 kms is in progress. The canal system (cost about Rs. 2870
crore) is proposed to be completed in the 11th five year plan. Up to 2010 an Irrigation potential of
34010 ha. is created. The total expenditure of Rs.1222.45 Crore has been incurred up to
September 10, on the works of canal of ISP.
1 Vision 2015, Narmada Valley Development Authority
-
7/28/2019 Infra projects and Indian states
14/54
14
S. No Phase Reach Target for completion
1 Phase-I 0 to 71 km Dec-2011
2 Phase-II 71 to 142 km Jun-2012
3 Phase-III 142 to 206 km Jun-2013
4 Phase-IV 206 to 248 km Jun-2015
TABLE 3: PROGRAM FOR PHASE WISE CONSTRUCTION OF CANAL SYSTEM AND CREATION
OF IRRIGATION POTENTIAL
S.
No.Reach
Status of constructionTarget For
CompletionMain Canal Disnet
1 0 to 58 Km Completed All Distributaries Completed
except some Minors and missinglinks
Dec-11
2 58 to 67 Km Under Progress Only one distributary which hasbeen Completed
Dec-11
3 67 to 107 Km Completed 8 Nos of distributaries & Minors
Under Progress
Jun-12
4 107 to 130 Km Under Progress 13 Nos of distributaries & MinorsUnder Progress
Jun-12
5 130 to 155 Km Under Progress L.A. Under Progress Jun-13
6 155 to 206 Km Under Progress L.A. Under Progress Jun-13
7 206 to 248 Km Under Progress L.A. Under Progress Mar-14
8 Khargone Lift
Irrigation
Survey Under
Progress
- Mar-15
TABLE 4: REACH WISE STATUS OF CONSTRUCTION OF CANAL
S.
No.
Year Targeted
I.P.
I.P.
created
Cumulative
I.P created
Targeted
irrigation
Actual
irrigation
Cumulative
irrigation
1 2007-08 21100 22236 22236 - Nil Nil
2 2008-09 19900 9287 31523 25000 15485 15485
3 2009-10 10455 2487 34010 26500 1363 16848
4 2010-11 17518 - - 17162 - -
TABLE 5: DETAILS OF POTENTIAL CREATED AND ACTUAL IRRIGATION
-
7/28/2019 Infra projects and Indian states
15/54
15
2. HalonHalon irrigation project is proposed on the river Halon, a tributary of the river Narmada in the
block Bichiya, district Mandla. Total length of dam is 975 m. and maximum height is 31 m.
1938.50 ha., land will be affected due to submergence out of which 109.80 ha. of land is under
forest. Forest clearance in principle is received, 11,736 ha area is proposed for Irrigation by the
project. The hydrology of dam was approved by Central Water Commission in 1991. Detailed
Project Report (DPR) was submitted to Central Water Commission in 1999. The CWC has
approved the cost of the Halon project at Rs. 221.60 crore. The cost is revised now to Rs. 321.11
crore. The State Narmada Control Board has recommended granting of administrative approval to
the project at this cost in the 33rd meeting held on 31.08.2008. Proposal for environmental
clearance has been submitted to the Union Ministry of Environment and Forests after public
hearing for clearance. Forest clearance in principle has been received on 20.12.07. Environment
clearance was obtained on 4th Jan 2010 and Investment clearance from planning commission
obtained on 15 Apil 2011. The tender for the project has been prepared and send for approval to
Member Engineering NVDA.
3. Upper NarmadaThis project is proposed on the river Narmada at village Reenatola; district Dindori which is 72
km from Amarkantak (origin of the Narmada). Maximum height of dam is 31.80 M and length is
2112 M. Proposed irrigation is 18,616ha, 89 villages of Dindori district and 27 villages of
Shahdol district will be benefited from this project, 2952 ha. of land is coming under
submergence. There is no forest land in submergence. Hydrology of the project was approved in
1991 by Central Water Commission. The detailed project report was submitted to CWC In 1996.
For pre-construction work of the project, administrative approval of Rs. 41.0 Lakhs was given in
1980. The CWC has approved the cost of the project at Rs. 345.77 crore. The State Narmada
Control Board has recommended granting of administrative approval at this cost in the 24th
meeting held on 24.3.2003 with a proviso that work should be started only after getting funds
from outside. The cost of the project is now revised to Rs. 56959 Crore and got approved from
the Narmada Control Board in the 33rd meeting held on 31.08.2008. Proposal for environmental
clearance has been submitted to the Union Ministry of Environment and Forest for approval.
Approval from planning commission has been obtained on 5th
Dec 2010. The project is awaiting
design specifications from CWC. The tender has been prepared and has been submitted to
Member Engineering, NVDA for approval.
-
7/28/2019 Infra projects and Indian states
16/54
16
4. OmkareshwarThe Omkareshwar multipurpose project is proposed below the Indira Sagar Project. It is proposed
to construct the dam upstream of Mandhata Island across Narmada River for the utilization of
regulated releases from Indira Sagar Project for the production of 520 MW power and to provide
irrigation facilities to an area of 1.47 lakh ha. on both the banks of the Narmada river.
The project envisages construction of 949 M. long 73.12 m high dam with 8 units of 65 MW.
Total installed capacity for power generation is 520 MW. The dam and power house works are
entrusted to NHDC Ltd.
The canal system will be completed by the State by about 2014-15, with funds under AIBP and
NABARD; financial assistance under AIBP is being received since FY 2003-04, Grant of Rs.
220.53 crore has been received up to March 2008. The work of Narmada Aqueduct costing Rs.
31.5 crore has been taken up and completed before water is stored in the Maheshwar dam under
construction. Cost of canal system is Rs. 2175.59 crone. The work of the canal is in progress in a
total length of 218.40 km in 3 phases. The right bank lift canal is being taken up in the fourth
phase. The work is likely to be completed in the 11th plan. Target dates are as given below
S No Year Financial
target
Target
Achieved
Targeted
Irrigation
Actual
irrigation
1 2010&11 244-34 244-34 3940 3940
2 2011&12 426-77 671-11 27040 30980
3 2012&13 377-58 1048-69 23860 54840
4 2013&14 320-00 1368-69 49330 104170
5 2014&15 200-00 1568-69 18500 122670
6 2015&16 140-00 1708-69 24130 146800
TABLE 6: DETAILS OF FINANCIAL AND IRRIGATION TARGET AND ACTUAL ACHIEVEMENT
5. Upper BedaUpper Beda irrigation project is proposed on river Beda near village Nemit, Tehsil Jhiranya,
district Khargone of Madhya Pradesh. Project envisages the construction of 208 m. long and 37 m
high masonry dam and 2206 m long and 23.83 m. high earth dam. It is proposed to irrigate 9900
hectares land in Khargone district comprising 58% tribal population. The Planning Commission
has accorded investment clearance for the project on 10.9.1998. Administrative approval for the
Project amounting to Rs 87.86 crores has been accorded by Govt. of M. P. in May 2001. The
survey work of dam, command area survey, property survey and soil survey has been completed.
-
7/28/2019 Infra projects and Indian states
17/54
17
An expenditure of Rs. 104.95 Crores has been incurred on the project up to 3/2008. Work of the
dam is completed. R&R is also carried out pari passu. Canal work is in progress.
For the construction of the project NABARD sanctioned loan of Rs. 80.32 crores in March 03.
Agency has been fixed for main dam. The construction of the dam has been completed. The
project has been sanctioned under AIBP and grant started in FY 2008-09.
6. Lower GoiLower Goi Irrigation Project is proposed on Goi River near village Pachpula tehsil & district
Khargone (Badwani), 13760 ha. Area is proposed for irrigation through 5.71 km. long tunnel.
Estimated cost of the project is Rs. 360.37 crore. The survey work was completed and detailed
project report was submitted to Central Water Commission in 1992. There is no forest area in the
submergence due to the project. The tunnel for taking irrigation water, however, passes through
forest area for which clearance is obtained. The project is cleared by the Planning Commission on
12.8.2008. The work is taken up and is to be completed in the 11th plan. The project has been
accepted for AIBP grant during FY 2008-09, and grant of Rs. 499 crore received. The project has
been awarded to IVRCL on November 2008 and work is in progress
-
7/28/2019 Infra projects and Indian states
18/54
18
PAST/RELATED WORKS
Various studies have been conducted in the past to study the time delays in completion of infrastructure
projects. While some of them concentrated on delay aspects in execution of specific steps involved in the
project, others took a more comprehensive view of the project and studied the delay in the all-inclusive
conclusion of the project. Few of the past researches conducted to study the delay in completion of
infrastructure projects are
Risk Assessment and Best Practices in Schedulingby PinnelStudies the importance of a good scheduling practice in reducing the delays and claims associated
with an infrastructure project. The report comes up with a strong correlation between the presence
of an effective scheduling practice and the extent of delays being observed in infrastructure
projects. It continues to explore the role of various stake holders in developing the schedule and
brings out the importance of the partnership between the various parties involved in theimplementation of the project. Finally the report also identifies formal risk management
techniques, or rather uncertainty management, which is a better term for risk management of
infrastructure projects, in reducing the time delay in the implementation of infrastructure projects.
Delays and Cost Overruns in Infrastructure Projectsby Ram Singh, Department of EconomicsThis study was based on the time and cost over-runs of publicly funded infrastructure projects in
India. The research identifies contractual and institutional failures as two of the major reasons
behind time and cost overruns.
Factors effecting cost performance: evidence from Indian construction projects by K.C.Iyer andK.C. Jha
The research focuses on the critical success and failure factors in terms of cost performance of
Indian construction Industry. Few of the salient results that came out as part of the research was
the role of Project managers competence in the success of the project and also conflict among the
project participants being major reason for failure of a project.
Study for Expeditious Processing of Environment Clearances for Projects of Narmada ValleyDevelopment Authority (NVDA) by K V Gopakumar
The study focuses on the huge delay in getting environmental clearances for variousinfrastructure projects under NVDA. Further the recommendations from this study have helped in
reducing the time required to get environmental clearance for various projects under NVDA.
However the scope of this research was restricted to the Environmental clearance aspect of the
project. The current study has it focus on the post approval processes, beginning from the tender
preparation till the final commissioning of the project
-
7/28/2019 Infra projects and Indian states
19/54
19
RESEARCH DESIGN
Activities Deliverables
Phase 0
This phase will involve secondary research data analysis to understandthe reasons for delay in construction activities
Key reasons for delay
Helpful research tools
Phase 1
Discussion with key members of the department:This will help in identifying the processes specific to NVDA inimplementing a project and insights on delay factors
Project Implementation steps and
possible delay factors
Phase 2
Questionnaire formulation:
Questionnaire
Phase 3
Site Document Review and discussion with Engineer in Charge:This will be a primary data collection phase by reviewing the documents
at site and discussion with Engineer in Charge
Quantitative data on delays
Phase 4
Analysing data and arriving at critical bottle necksReport detailing critical bottle necksand implementable solutions.
PHASE 0
The main purpose of this phase is to understand the key attributes involved in the implementation of an
infrastructure project, which either leads to successful completion of the project on time, or which leads to
excessive delays in completion. A lot of research has already been conducted on this topic and detailed
surveys conducted to identify such key attributes. According to a study conducted by Pinnel, one of the
major reasons for delay in the construction of infrastructure projects is the improper or the lack of
scheduling techniques, and improper monitoring of the project. Based on extensive research and literature
review, the following aspects were arrived up on as the main attributes which make or break a project
1. Conflict among project Participants2. Ignorance and lack of knowledge of the Engineers3. Reluctance in Timely decision4. Improper or Lack of formal scheduling techniques5. Aggressive completion at tendering stage6. Short Bid preparation time7. Hostile Social and Economic Factors8. Dispute resolution practices
-
7/28/2019 Infra projects and Indian states
20/54
20
PHASE 1
Before visiting the construction sites to collect data, it was required to understand clearly the steps
involved in the project implementation at NVDA. It was also required to discuss the relevance of the
various attributes identified in Phase 0 with respect to the practices in NVDA. Detailed discussions were
held with Engineers in Narmada Bhavan and CWC. Based on the discussions the results obtained in
Phase 0 was further fine tuned and additions made.
PHASE 2
A questionnaire was prepared on the basis of the attributes that was finalized in Phase 1
PHASE 3
Field visits were made to Sanawad, Indore and Jabalpur and documents available at site was studied to
identify the reasons for delay in the specific projects. Also indepth interviews were conducted with the
Engineers at site on the factors leading to delay. The extent of delay caused by the various attributes
arrived in phase 1 was identified
PHASE 4
Analysis of the data collected during field visit and the outcome of the indepth interview with the
Engineers. The Method of analysis was to compare the best practices required for reducing the delay, and
compare it with the practices within NVDA. The study does not focus on in-depth analysis of any
particular project, but only identifies the practices in each of the 6 projects.
-
7/28/2019 Infra projects and Indian states
21/54
OBSERVATIONS
STAGES INVOLVED POST
FIGURE 1: V
No Schedule prepared by DDepartment engineers rely
involvement is leading to
delays. In the case of lowe
schedule. It took 1.5 years
falling behind on schedule
prepared by the contracto
schedules have details on
Tenderi
Tender
Preparation
Tender
Processing
Con
21
PPROVAL OF THE PROJECT BY PLANNING C
RIOUS ACTIVITIES FROM TENDERING STAGE
epartment Engineers during or after the Tender pre
on contractors to prepare the schedule for the pr
ailure in monitoring of the projects by the enginee
r Goi, the initial schedule provided by the contract
for the department to alert contactor and notifies t
and warn them on levying penalty. A monthly reco
, which was again approved by the department.
a weekly basis, nor did it specify the critical
ng Process
Tender Award Tender Signing
tractor activities
Survey
Alignment
Approvals
land Acquisition
cases
Work Execution
Departmen
Activities
Wor
Mon
All
suffi
A
S
Levyin
ca
c
MMISSION
aration
ject. This lack of
rs and causing the
or was a quarterly
em that they were
very schedule was
Neither did these
processes in the
t
k Order Issue
itoring Work
rogress
ocation of
cient funds
proval of
chedules
g of penalty in
ses of non
mpliance
-
7/28/2019 Infra projects and Indian states
22/54
22
construction nor did it have the sequencing details of specific events in each month on a day to
day, or atleast weekly basis.
Schedule prepared by the contractor only name sake, and no strict adherence followedThe schedule being prepared by the contractors are also not very uselful. These are mostly
Quarterly schedules with no detailed specification of work provided. It also fails in providing the
sequencing of activities nor does it provide information on the critical aspects of the project. The
schedule also does not identify the amount of labourers that are required to complete each aspect
of the project.
Department Engineers not very well versed in Scheduling Techniques like CPM or PERTDepartment Engineer needs to be competent in these techniques for them to be able to review the
schedules provided by the contactors, and also to be able to monitor the work. They will also
need to identify areas where the contactor will not be able to perform as per the schedule and
suggest changes in such cases.
Complete lack of risk assessment processes in all the projectsThere are no formal risk assessment processes being followed in any of the projects. Any issue is
taken up as and when it arises. Since NVDA only deals with the construction of dams and canals
it would be fairly possible to develop a risk assessment guideline for all the projects of NVDA.
The formation of such a guideline is out of the scope of this study due to time limitations.
However if the various risks like, land acquisition cases, risk due to adverse climatic conditions,
non-availability of raw materials etc are brought under a risk assessment framework, a better
management of such issues will be possible. Also it will help in having a formal issue resolution
guideline when such events occur.
-
7/28/2019 Infra projects and Indian states
23/54
23
CONCLUSION AND RECOMMENDATIONS
TYPE OF CONTRACT
ITEM RATE OR TURNKEY
Historically NVDA followed item rate type of contract in the construction of dams and canals. However
recently, they have started following floating contract on the turnkey basis. While contracts on turnkey
basis have its inherent advantages, it is not free of issues. Turn key based contracts shifts a lot of risks
from the NVDA side to the contractor side. But it is required to be analyzed if such a shift in risk is
beneficial for NVDA or detrimental to the project.
A study conducted by J.R. Turner and S.J. Simister indicates a relationship between the uncertainty in
projects deliverable and the best suited type of contract. An attempt is made to relate this study with the
current projects undertaken by NVDA, and to analyze if the move to turnkey projects were desirable. The
below graph indicates the relationship between the cost of managing different types of contract at
different levels of uncertainty2
2 Project contract management and a theory of organization, J R Turner, S J Simister
Costofadministeringtheproduct
Uncertainty of the product
Re-measurement Contract
Turnkey Contract Preferred
Cost of managing re-measurement
Cost of managing cost plus contract
Cost of managing fixed price contract
Cost-Plus Contract Preferred
-
7/28/2019 Infra projects and Indian states
24/54
24
The graph clearly indicates that as the uncertainty of the product increases it is desirable to go for cost-
plus type of contract, and turnkey or fixed price contract is best suited in cases when there is not much
uncertainty in the end product. The study was further extended to include the effect of Uncertainty of
process and Ability of client to contribute in the choice of contract. Below is a pictorial representation of
the selection of contract types with all variables included
Uncertainty of Product
Lo Hi
Uncertainty of
the process
Hi Fixed price/Turn KeyCost PlusDesign and Build
Hi
ComplexityLo Re-measurement No research done Lo
Lo Hi
Ability of Client to Contribute
Fig. 2. Selection of contract types.3
Extending this research to the construction activity undertaken by NVDA, dams and canals are
construction activities with very less uncertainty regarding the final product. The size, type and
dimensions of the final product is known before hand, and there is no scope for any confusion at that end.
However there is very high uncertainty in the process that needs to be followed in the construction
process. It will vary from project to project depending on the actual site conditions and an array of other
factors. The optimal process for one project might not turn out to be the best for another. Hence Fixed
Price/Turn Key contracts would be the best suited for the projects undertaken by NVDA, which is inline
with the current practice.
One of the main features that Turnkey contracts bring along is the contractors freedom in designing the
process best suited for delivering the product. Without providing this freedom to the contractor, turnkey
products will turn out to be quite detrimental, and could only further aggravate the delay aspects. The
contractor should be given the opportunity to gain from any innovative solutions that he comes up with.
3 Project contract management and a theory of organization, J R Turner, S J Simister
-
7/28/2019 Infra projects and Indian states
25/54
25
However this does not mean free hand for the contractor to do as he wish. The progress of the
construction still needs to be monitored constantly and verified to be in par with the schedule.
PROS AND CONS OF LOW BID CONTRACT
NVDA follows process of low bid contract for finalizing the agency for construction. The logic is quite
simple. To maximize the value of the project, it needs to be executed in the lowest possible price and for
this the owners tend to exploit the competition in the market to obtain the best price. However this
approach as its disadvantages associated with it. One of the main flaws with this line of thought is that, it
completely ignores the dependence of value of the project on the quality of work done, the timely delivery
of the project and the ability to meet the needs of the users.
Agencies in a struggle to win the contract, bid with the lowest possible amount to such an extent that, it
becomes impossible for them to effectively complete the work. The end result is bad quality work, lower
commitment levels and delayed works. This leads to increase in the amount of claims and legal actions
that eat up valuable project time and money.
One of the merits of the process being followed by NVDA is the pre-qualification process where strict
guidelines have been put forward in selecting the agencies eligible in bidding process. However the
process lacks in two aspects.
No guidelines on the extent of minimum bid (% below the initial estimate) No restrictions on the level of subcontracting
Every tender being invited needs to have a minimum bid amount which should be a % of the initial cost
estimate of the project. If there are bid with lower amount than this threshold amount, then the contractors
must be required to establish how they would be completing the project within the bid amount. The
Engineer in Charge for the project should have the authority to decide whether or not to award them the
contract. He will be liable to verify the facts provided by the contactor, and certify that the contractor will
be able to complete the project within the bid amount.
ISSUES WITH PROJECT SCHEDULING
There is failure in the part of Engineers in identifying the cause of delay in completing the project on
time. 11 out of the 15 engineers who were interviewed claimed land acquisition delays as the primary
reason or the delay of the project. However after analyzing the data available at site, it was clear that land
acquisition was not the major reason for delay. While land acquisition cases did account minor delays, it
-
7/28/2019 Infra projects and Indian states
26/54
26
was not the predominant factor. Moreover in most cases such delays could have been avoided by better
scheduling techniques and effective enforcement of such schedules.
BETTER SCHEDULING PRACTICES:
The first step in reducing the delay is to adopt an efficient and robust scheduling system. At present
Quarterly schedules are being prepared for project, and in almost all cases, the role of department
engineers in the preparation of such schedules are minimal. There needs to be a more active role by
department engineers in the preparing of project schedules. The schedule needs to be prepared for each
week. In case of lapse in the part of contractor in adhering to the schedule, for reasons attributable to
either department or the contracting agency, or external factors, a fresh schedule needs to be prepared,
detailing on how the lost time will be made up, or in case it cannot be made up, then what the new
scheduled completion time will be. Critical Path Method (CPM) or PERT are two very popular methods
that can be used for preparing such schedules. There are no guidelines from the department in the use of
scheduling techniques and its application.
DEPARTMENT ENGINEERS PROFICIENCY IN SCHEDULING TECHNIQUES
One of the main reasons for delays in the construction of dams and canals has been due to the lack of
adequate capacity in part of department engineers in various scheduling techniques. While almost
everyone knew the purpose of CPM or PERT, very few could effectively apply it for arriving at a
comprehensive schedule for the project. For effective monitoring of a project, scheduling to the least time
interval is the best. However NVDA follows quarterly or in few rare cases monthly schedules. This
clearly indicates an inadequate capacity in the part of engineers in the various scheduling techniques.
Department engineers need to be provided training on the various scheduling techniques. While it is not
essential to train them on the scheduling software, it will be useful if they are competent in such software.
None of the projects studied for this research had a schedule that was prepared by the Department. A few
recent projects had schedule prepared by the consultants, but those were also not up to the mark.
Preparation of schedule by the Department Engineer becomes all the more important when there are
various contractors involved in the completion of a project and coordination between such parties is
required. Listed below are few of the activities that needs to be included in the schedule created by the
department engineer
Obtaining permits, submittals for early procurement, and long lead time items. Mobilization and preliminary activities. Initial site work.
-
7/28/2019 Infra projects and Indian states
27/54
27
Specified work sequences, constraints, and milestones, including substantial completion. Major equipment design, fabrication, factory testing, and delivery. Delivery dates for department-furnished products. Site work, concrete, structural steel, architectural features, conveying systems, equipment
installation, mechanical, electrical, instrumentation and control, and interfaces with department
furnished equipment.
Equipment and system startup and testing. Final inspection and punch list. Project closeout and cleanup. Demobilization. Permitting and design activities. Procurement activities shall include: submittal and departmental review and approval
TYPES OF SCHEDULES TO BE PROVIDED BY THE CONTRACTOR
a. Preliminary SchedulePreliminary schedule is prepared by the contractor immediately after the issue of work order. This
would detail the schedule of activities to be performed for the first few months (2 months
normally). It will contain detail of work activities until the baseline schedule will get approved.
This is done so that the contactor will have sufficient time to come up with the baseline schedule
after finalizing the sub-contractors and planning the project in detail. The preliminary schedule
should detail on the machinery and labour mobilization details, Land acquisition case submission
schedules, site preparation schedules, contract mile stones, contract completion etc.
Once the Contractor is ready with the preliminary schedule, a pre construction meeting has to be
held with all the project stake holders, which includes contractors, department engineers,
consultants, revenue officials and the district collector. Before the meeting is conducted, the
schedules prepared by the contractor needs to be verified by the Engineer in Charge and any
corrections required needs to be communicated to the contractor. The following points need to be
verified while reviewing the schedule
All contract-specified milestones: notice to proceed, interim milestones, non-workwindows, substantial completion, and final completion.
Specified work sequences. Specified Owner-furnished equipment delivery dates or activity durations.
-
7/28/2019 Infra projects and Indian states
28/54
28
Specified submittal review times, except for early, critical materials that can be reviewedfaster.
A reasonable calendar for workdays, holidays, and expected non-work days for inclementweather.
The Schedule will then again be scrutinized during the pre-construction meeting and inputs from
all the stake holders will be sought for.
b. Baseline Schedule4The Baseline Schedule is created by adding the remaining activities through to completion of the
Preliminary Schedule. Upon acceptance, it is the official contract schedule, against which
progress is measured, until replaced by a revised baseline as part of a global settlement of all
changes up until that point. The Engineer in charge will have the final authority in accepting or
rejecting the Baseline Schedule.
The baseline schedule needs to be reviewed jointly by the Engineer and Charge and the
contractor, so that any issues can be ironed out.
c. Recovery Schedules and Narrative Reports5If the project falls behind schedule more than 14 days or 10% of the remaining duration,
whichever is less, for non-excusable delays or when requested by the Owner, the Contractor shall
prepare a Recovery Schedule and Narrative Report that demonstrates how the lost time will be
recovered. The Recovery Schedule will be subject to review and acceptance by the Engineer in
Charge.
Narrative reports should have a cover letter stating the name of the project, date submitted,
reporting period, and name of the report author. Narrative reports for updates need include only
new and revised activities and should include:
The Contractors plan for management of the site (laydown, etc.), use of equipment,buildup of trade labour, and potential change proposals.
A brief description of the more important critical and near-critical activities and how theywill be accomplished
Description of potential delays including their cause and steps to mitigate.
4 Pinnell/Busch Master Scheduling Specification5 Pinnell/Busch Master Scheduling Specification
-
7/28/2019 Infra projects and Indian states
29/54
29
MILESTONES
Milestones are major events with zero days duration and mark the beginning or end of an important
phase of the work. Except for contract-specified milestones the selection of milestones are up to the
contractor. A reasonable number of additional milestones are helpful in tracking progress and the
department should encourage the contractor to do so.
All project schedules should have milestones for work order issue, substantial completion and final
completion.
If a project has critical interfaces with other contracts, the Owner should specify interim milestones with
liquidated damages to avoid interfering with those other contracts and to inform the Contractor when
certain areas will be available. Interim milestones can also be used to ensure that progress is adequate.
QUALIFICATIONS OF SCHEDULER AND CONTRACTOR STAFFING
The tender document should specify the Qualification required by the Scheduler at contractor end. For a
medium sized project, the scheduler should have a minimum qualification of 3-4 years experience in
scheduling projects of this magnitude. Unless the scheduler has sufficient experience with such large
scale projects, he will not be able to come up with an efficient schedule for the project. Also care should
be taken so that the contractor doesnt under staff the Scheduler post.
ALLOWABLE SOFTWARE FOR SCHEDULING
There needs to be clear guideline on the type of software that can be used by contractor for scheduling
purpose. For the projects of magnitude undertaken by NVDA, MS Projects or Primavera would be a good
candidate. Care should also be taken to make use of the latest version of the software so as to avoid any
compatibility issues. Taking in to consideration the lack of competence in the part of department
engineers in the use of such software, it is highly recommended to hire a consultant who is well versed
with the use of such software.
PARTNERING
Partnering is a technique useful in reducing the time delays associated with almost all major construction
projects. Partnering can be termed as a commitment between the owner, the consulting engineer and the
contractors to avoid improve communication and avoid disputes by working together towards shared and
common goals and objectives on a project. However this does not include relaxing the contract terms or
circumventing the process to achieve quicker turnaround time. Past researches conducted on the use of
-
7/28/2019 Infra projects and Indian states
30/54
30
partnering in construction projects indicate an average increase in profitability by 25% and a reduction in
project completion time by 20%.
Typical workshop agenda for partnering workshop typically includes6
Overview of partnering Project overview Project organization and lines of communication Team communication flows Goals for the project Key expectations and needs of each stakeholder group Identification of potential project challenges Develop strategies and action plans to address key challenges Develop an issue resolution process Partnering follow-up tools and methods Identify celebrations throughout the life of the project Select partnering champions from each major stakeholder group Develop partnering charter
The typical time frame when a partnering workshop of this nature will bear the best result would be just
before the beginning of the project construction activities, or 1-3 weeks in to the beginning of the project.
Not only will such an activity give clarity on the deliverables expected from each party, but it will also
lead to better communication between the various stake holders, resulting in quicker problem resolutions
and faster turnaround times.
It is highly recommended for NVDA to adopt partnering technique in any one of its upcoming projects.
Upper Narmada would be a good candidate to be a pilot project given that the Tendering process is only
about to begin, and hence sufficient time would be available to finalize on the agency to conduct
partnering workshop.
FORMAL RISK ASSESSMENT PROCESS
Any major project should have a formal risk assessment exercise done before implementation of the
project. This is a process by which the critical areas and processes in the project are identified, the
possible issues and threats likely to develop during the course of the project is predicted and prioritizing
the available resources for uninterrupted operation of such critical functions. If a detailed schedule has
6 Source: http://www.allanlowe.com/partnering.htm
-
7/28/2019 Infra projects and Indian states
31/54
31
been prepared using CPM, then the critical processes in the project would already have been identified.
There could be additional processes with high level of uncertainty which can be formulated based on the
past experience of the engineers in the department.
Given below is a 6 step risk assessment process developed by Critical Incident Protocol Community
Facilitation ofMichigan State University School of Criminal Justice.
Identify Functions and ProcessesList the separate functions and processes involved in implementing the project
Determine CriticalityOf the processes listed in Step #1, which are the most critical to the continual operation. The
following definitions may be used as a general guide and should be modified to meet the
requirements of each specific process or function:
Critical necessary and/or vital. Will completely stop all work and delay the projectcompletion
Essential important but not critical. Disruption would cause difficulties and could leadto delays.
Non-Essential disruption is merely inconvenient. Determine Recovery Time
Determine the recovery time for each critical process listed in Step #2. In determining recovery
time, consider the following:
Time from loss or disruption of process to the point when continued disruption or loss isdetrimental to the mission of the project;
Special circumstances that may delay or prevent recovery actions, i.e., designation of anarea as a tribal area, or presence of NBA activists
Identify ThreatsIdentify threats that may halt or disrupt each of the critical functions identified in Step #3. In
identifying threats consider:
Natural disasters (tornados, floods, severe weather); Human-caused events (workplace violence, terrorist attack, sabotage, critical information
theft);
Facility-related emergencies (hazardous materials, loss of utilities, proximity to otherthreats);
Asset protection incidents (inadequate systems, untrained personnel); Machinery difficulties (lack of backup);
-
7/28/2019 Infra projects and Indian states
32/54
32
Employee-related problems (training, attitude, misconduct/grievances); Other events and incidents (nearby threats, political activities).
When assessing the various threats it is important to consider:
1. What can occur;2. The damage it is likely to cause.
Determine VulnerabilityDetermine which of the threats identified above have the greatest likelihood of disrupting or
attacking each critical function. When assessing how vulnerable a process or function is to the
various threats, it is important to consider:
1.How likely it is that a threat will occur;2.How often a threat is likely to occur.
The following descriptions are suggested as a guide:
Highly Vulnerable Functions that are most likely to experience threat. Vulnerable may experience the threat or threat. Not Vulnerable not likely to experience the threat or threat.
Select Action PlansDetermine if there are appropriate plans and resources to address the threats that are most
disruptive to the critical functions. It is imperative that these plans and capabilities are current and
adequate. If gaps or shortcomings are discovered, determine:
What do I have and what do I need? Solution areas include:o Planning. o Organization.
o Facilities o Equipment.
o Training. o Exercising.
Can the issues be addressed using available company personnel and resources or willoutside personnel and/or resources be required of other businesses and/or public
organizations?
If solutions require coordination with public agencies, do the businesses and publicagencies involved need to develop or enhance a public-private partnership?
Developing a risk assessment process for the projects under NVDA was outside the purview of this
research owing the lack of time. Hence only the lack of such a process is being pointed out here, and a
framework is being provided. It is strongly recommended to develop a Risk Assessment Process for the
construction of Dams and Canals being implemented by NVDA.
-
7/28/2019 Infra projects and Indian states
33/54
33
MONITORING THE PROGRESS OF WORK
Along with better scheduling practices, it is also required to have a better monitoring for the project. In
almost all cases, department waited a minimum of 2-3 months before intimating the contractor on the
delay on part of him in executing the project. However along with developing a weekly schedule, the
department should also monitor the progress of the project on a weekly basis confirming it to be in line
with schedule. In case it finds any deviations from the schedule, then the contractor needs to be intimated
immediately and recovery schedule for lost time need to be come up with. For department engineer to be
able to do this they need to be well competent in scheduling techniques and hence proper training is very
important.
Department Engineers should independently verify the actual start and finish dates. Contractors
sometimes fail to report the correct date, and sometimes misreport dates in order to hide their delays or set
up for a claim. Department Engineers also need to remember that the percent remaining times the originalduration is not necessarily the same as the days remaining. Therefore a mere comparison of the
percentage of work completed against the percentage of time elapsed is not an appropriate method to
evaluate whether the project is within schedule or not. However, in almost all projects in NVDA, this is
the method that is used to verify the delay of the project. The actual comparison has to be with respect to
the baseline schedule prepared during the commencement of the project.
The Contractor should also submit a daily field report. The report shall include, but not limited to:
Weather: rainfall, high and low temperatures during working day, wind or other environmentalfactor, and the impact.
List of the general contractors separate crews, the size of the crews, and activities performed. List of subcontractors on the site, their crew size, and activities performed Total number of personnel working on site. List of equipment on site and used. Start and finish dates of network activities and milestones. Extra work being performed. Delays, disruptions, and loss of efficiency with the reason. Meetings, conversations with owner, designer, or other party. Accidents and unusual events. Meetings
-
7/28/2019 Infra projects and Indian states
34/54
34
The daily field reports may be vital in analyzing time extension requests and claims for delay,
acceleration and impact. They should be reviewed at least weekly, to identify developing delays and other
problems, so that prompt corrective action can be taken.
There could be two possible kinds of delays that arise.
Minor delays of less than a week, which can be made up by the contractor in the course of work. Major Delays of more than 2 weeks
In the case of Major delays, the contractor will be required to submit a recovery schedule which needs to
be accepted by the Engineer in Charge. The recovery schedule should clearly specify how the contractor
will make up for the lost time, by means of increasing crew size and machineries. Care should be taken by
the contractor to ensure that he is not siphoning of labour from other critical processes to speed up the
work in this specific process.
INTERMITTENT PROGRESS AND PACING FOR DELAYS
Intermittent progress is when contractors reduce their crew size or pull a crew off of an activity, in order
to perform other work on this project or another. This isnt normally a problem on non-critical activities
but should not happen on the critical path. Owners need to record the crew size and note fluctuations in
the crew size, in case there is a later claim for impact, as a smaller crew size may be the reason for
activities taking longer than planned. Pacing occurs when there is an unavoidable delay to the critical path
and the contractor reduces the crew size or shifts workers off of previously critical activities in order to
avoid completing all available work for a specified trade and having to disband the crew. That would
result in later inefficiencies as the personnel may not be available later and a reconstituted crew would
start with a lower efficiency than the current crew.
Contractors need to notify Owners when they are pacing previously critical path activities, to avoid later
charges of concurrent delay. The contractor needs to strictly get the acceptance of the Engineer in Charge
before pacing reducing the crew size. The Department Engineer on the other hand should try and identify
other processes in the critical path where this extra crew can be accommodated. Once the cause of delay
in the original activity is rectified, then the crew can be pulled back to the original work.
This normally happens when there is obstruction to the construction by the inhabitants of the village, who
oppose the construction of dams and canals. In such instances, the contractor will be forced to reduce the
crew size so as to minimize the loss due to idling of crew.
-
7/28/2019 Infra projects and Indian states
35/54
35
ISSUES WITH SUB-CONTACTING
NVDA has detailed guidelines for pre-qualification of Contractors. However there is no such guideline
available when the contractor decides to let out the work to sub-contractors. While it is true that its the
contractors responsibility to adhere to the schedule and the quality aspects of the project, irrespective of
subcontracting the work, there is an inherent flaw in this logic. When strict pre-qualification has been
done during the tendering stage to make sure that only the capable contractors is awarded the contract, the
later subcontracting by the agency to below par agencies undermines this whole purpose. Even though the
main contractor requires the consent of the Engineer in charge before appointing any subcontractor, the
lack of any formal guidelines in evaluating such subcontracting agencies could lead to below par agencies
being part of the project. Also, the little guidelines available can be easily circumvented to the advantage
of the contractors. For instance, in-spite of clear guidelines that the work cannot be assigned to a different
agency but only subcontracted in specific cases where the subcontracting agency has competence in the
specific activity. However in case of Phase 3 of Omkareswar project, even though an initial attempt by
the Main contractor to assign part of the work to a different agency was rejected by the department,
however later on work was assigned to the same contractor but this time, rather than directly assigning the
section of work to the agency, all the different individual aspects of the construction activity was sub
contracted to them, and this was approved by the department. This is clearly assigning the work to the
agency, but under the pretext of subcontracting individual construction activities.
Few of the areas where crisp guidelines are required are
Limiting the number levels of sub-contracting Better qualification criterion for sub-contractors
Approve sub-contracting only if the agency is found to have superior expertise in the specific activity, and
only sub-contract the specific activity.
It is also important that the sub-contractors are aware of the schedule being committed by the Main
contractor, so that sub-contractors are not forced to accelerate owing to un-realistic schedule that they
were not aware of. It is a good practice to get the written agreement from the sub contractors regarding
the schedule that they are required to follow, so as to avoid any claims or cost over runs towards the later
stage.
-
7/28/2019 Infra projects and Indian states
36/54
36
OTHER ISSUES
1. Staffing IssuesFor effective monitoring of any project, it is required for adequate staffing of the project, and in
certain cases over staffing is desirable. However there is a shortage of engineers being staffed in a
project which is leading to in-effective monitoring of the project. A review of the staff position in
Upper Narmada project was performed and was found to be understaffed.
There is not only a need to fill these vacant posts for effective monitoring of the work, but the
recruitment should be done in a manner which attracts candidates who are proficient in the latest
construction management techniques.
2. Use of consulting agency and strict monitoring of workWhile NVDA has begun employing the use of consultants for monitoring the progress and quality
of work done by the contractors, but there is a need to better scrutinize and monitor the work
done by consultants. In the case of Lower Goi, it was observed that the schedule being prepared
was on quarterly basis, and only monthly review of the projects was being performed. There was
also no risk assessment process being done by the consultant. Though employing consultant is a
desirable aspect in effective monitoring and controlling the project and is helpful in reducing the
work load on the Department Engineers, strict guidelines needs to be enforced on the nature and
quality of work being done by the consultants and the department engineers should monitor the
work being done by the consultants.
There is also a need for stricter prequalification criteria while selecting the consultants, so as to
ensure prior experience of the consultants in work of similar nature, and also to make sure that
engineers being employed by the consultants are competent enough in construction management
and monitoring project of such large scale.
3. Proactive Decision making by the engineersAll the recommendations provided above rely heavily on the active participation of the
Department engineers. On the one hand, engineers should actively monitor the progress of the
work and at the same time they should be proactive in taking action against contractors who falter
in adhering to the schedule. Engineers should be able to identify delays early on, and take
corrective action to bring it back on schedule.
This would also require effective enforcement of authority endowed up on the engineers. For
instance, when an Engineer in Charge can take action for non compliance with the schedule, the
same need not be referred to Chief Engineer for action, and un-necessarily cause delays. The
Engineer in Charge needs to be proactive in taking such actions and enforcing his authorities.
-
7/28/2019 Infra projects and Indian states
37/54
37
4. Lack of motivation among EngineersContactors and consultants enjoy incentives for the early completion of the project. The
department gain in the form of overall cost savings and early revenue generation. But there is no
such motivation for the Department engineers. With the exception of few self-motivated
personals, there is a serious lack of motivation among the engineers in working towards
completing the project on time, if not ahead of schedule.
Exceptional work in a project by any engineers needs to be acknowledged and some form of
recognition needs to be awarded for the Engineer.
5. Short Bid preparation timeIn-order to gain time for execution, it is observed that bid preparation time is kept to the
minimum. Ideally reasonable time should be allowed for proper site investigation, and collection
of relevant details required for estimation purpose. The short bid preparation time leads to a
number of errors and omission on the part of the contractor which they try to settle through
claims, leading to disputes and schedule over runs. Almost during all the recent tenders that were
invited by NVDA, contractors had requested for time extension for extension of last submission
date. These requests were even made by construction giants like HCC, Gammon India, L&T etc.
However in almost all cases, such requests were denied forcing good companies to not submitting
the bid, thus reducing the competition during bidding.
Most of the recent tenders from NVDA are being invited based on turnkey basis. In any turnkey
project, the contractor shares a major portion of the construction risk. Hence it calls for a detailed
site investigation from the part of the contractor before he can arrive at a bid amount. However
except for Omkareswar, NVDA has refused to extend the Bid submission time, in-spite of
repeated request from multiple agencies including HCC and L&T. This has led to many such
agencies staying away from bidding and in turn leading to lesser competition in the bidding
process.
In addition, short bid preparation time could also lead to under bidding by the contractor, due to
improper site investigation. Once the contractor realizes that it will not be possible to complete
the project under the bid amount, the construction progress will begin to slack and will finally end
in huge delays and work with lower quality. So it is best in the interest of both NVDA and the
contractor that sufficient time is provided for them to perform site investigation. A period of 2
months would be appropriate for the contactor to perform site investigation and come up with a
competitive bid.
-
7/28/2019 Infra projects and Indian states
38/54
38
6. Huge Mobilization advance paid even before beginning the construction activityWhen there is provision to make payment in the form of Machinery advance for any expenditure
incurred by the contractor in procuring machineries there is no need for a separate provision for
an interest free Mobilization advance, which is 10% of the total project cost. Not only does this
practice encourage under qualified contractors to take part in the bidding, but it also aggravates
the issue of delay in the construction. Once the interest free payment is made to contractors, it is
pure business logic to extend the period of time till which they are able to hold on to such a
payment so as to maximize their profit. For this reason, they will come up with reasons for the
non-performance from their side, and try to get extension as much as possible. On the other hand,
if the initial interest free payment is not made, then the contractors have all the more reason to
complete the work as per schedule and claim the payment.
If it is required to make the payment to contractors then it is advisable to provide it to them at the
prevailing market interest rates, so that they do not make any
7. Delay in obtaining the design from CWCThis issue is being faced by Upper Narmada project, were CWC has not yet provided the design
for dams and canals. While the primary reason for this is due to the failure in part of department
in providing the soil investigation results, the base reason is that there is only one soil testing
institute being approved by CWC and they are not in a position to provide the results rapidly. So
the main bottle neck here is the lack in CWC approved soil testing institutes. It is recommended
to have a list of soil testing institutes across India approved by CWC so that the department can
allot the work to the institute which will be able to provide results in the lowest possible time
8. Land Acquisition issuesThis had been one of the most frequently cited reasons for delay by departmental engineers.
There had been instances where the construction was delayed due to the agitation by the local
population and the issues with land acquisition due to which the complete work came to a halt.
NVDAs move to turnkey contracts, under which the responsibility of preparing land acquisition
cases got transferred to the contractor, has relieved the department from the delay arising out of
this reason. However keeping in mind the greater good of the whole project, it would be advisable
for NVDA to acquire the land required for dam seat. This is make sure that once the construction
work starts, until the baseline survey is prepared, the contractors work does not get stopped
completely.
9. Detailed review and documentationAfter each phase of a project is completed, a review of the progress along with the issues faced
during the implementation is necessary. It will form as a basis for learning and innovations that
-
7/28/2019 Infra projects and Indian states
39/54
39
can help in better implementation of future projects. The fact that, it is required to go through
almost 300-400 pages of general correspondence , which is available only at a particular site
office, to get information on aspects of a project is a serious concern and a detrimental factor in
passing on the learning from implementing a project to the new projects. There is also a serious
need for better documentation from department engineers on the tacit knowledge and major
incidents during the course of implementing a project.
CONCLUSION
The main reason for the delay in projects being implemented by NVDA is due to the lack of a robust and
efficient scheduling technique. The inadequate capacity in the part of engineers in preparing and
reviewing such schedules, and in monitoring the progress of the work based on such schedule is a major
concern and needs to be addressed if any improvement in the project timelines needs to be obtained. Ashort training for the department engineers on the various scheduling techniques like CPM, PERT etc
needs to be taken up. The monitoring mechanism at NVDA also needs to be improved by monitoring the
progress every week, and in case the project falls behind schedule by more than 2 weeks, then a revised
schedule to be requested from the contractor detailing on how he plans to complete the project in
stipulated time. The quality of schedules provided by contactor also needs to be improved from a mere
formality document to an effective document detailing on each and every aspect of the project including
the sequencing of processes.
-
7/28/2019 Infra projects and Indian states
40/54
40
SCOPE FOR FUTURE WORK
A framework for the risk assessment process has been provided as part of this study.However the specific aspects of the process for NVDA were out of the scope of this study
due to lack of time. It is recommended to further study on the risk assessment processes for
projects undertaken by NVDA and in preparing a formal guideline for the same.
While there is certainly a need for improving the scheduling practices with in NVDA, at thesame time the same should not be overdone. This might lead to contractors staying away
from the bidding process resulting in lesser competition. A future survey among the major
bidding contractors for NVDA to determine their expectation on the scheduling processes
will help NVDA in arriving at an effective scheduling guideline.
-
7/28/2019 Infra projects and Indian states
41/54
41
APPENDIX:
DETAILS ON HALON PROJECT
Construction Schedule for Halon
S.No. Year % Proposed tobe completed
Cumulative %
1 up to 3/10 0.5 0.5
2 2010-11 21.72 22.22
3 2011-12 24.14 46.36
4 2012-13 24.14 70.5
5 2013-14 29.5 100
Activity Date
Clearance of R&R Plan 25/01/2007
In Principle Approval for diversion of forest land 20/12/2007
Environmental Clearance 04/01/2010
Approval from Ministry of Water Resources 12/05/2010
Investment Clearance 15/04/2011
-
7/28/2019 Infra projects and Indian states
42/54
42
DETAILS ON UPPER BEDA PROJECT
Activity Date
Investment Clearance 10/09/1998
Administrative Approval 01/05/2001
NIT 11/05/2003
Sale Begin 05/06/2003
Sale End 18/06/2003
Last date for submission 19/06/2003
Pre Tender Conference 12/06/2003
Bid Opening 18/08/2003
Work Order Issue 01/10/2003
Time Based incidents post issue of Work Order
Incident Date
Work Order Issued to Gurmeet Singh and Co 01/10/2003
GS complaints about no Department Engineer present at site 22/12/2003
GS Points out delay in payment to be made for acquired land 26/12/2003
Detailed land acquisition status prepared 29/12/2003
GS informs Department on the following issues
No Bench mark and boundary pillars erected nor pre-commencement joint levels taken
SE not visited the site even once EE visited only once Agitation issues
08/01/2004
2.5 Acre camp land provided 19/01/2004
Letter to collector for discussion on the issue of agitations 20/02/2004
Begin working of central line and boundary pillars 18/02/2004
Protestors obstruct the work and manhandle engineers 20/02/2004
Discussion with Collector 24/02/2004
Work still at stand still with no progress 15/03/2004
Letter from GS to SE, pointing out that, even if the demarcation work isstarted now, monsoon will delay the progress 29/03/2004
Entry to dam site made 23/05/2004
Center Line marked 30/05/2004
-
7/28/2019 Infra projects and Indian states
43/54
43
Following issues pointed to CE
No construction drawing issues Borrow area of land not yet available Land Acquisition of last 7 villages not complete Trial pits yet to complete
30/05/2004
Following Concerns raised by GS Scope of work revised Change in design Payments getting abnormally delayed First drawing of L.S.Regulator obtained on 24-04-2006, 31
months after issue of work order
30/03/2007
Issue of non availability of land pointed out by GS 06/04/2006
Notifies the following to CE
Increased the speed of construction Escalation provided by department not inline with increase in
cost or raw materials
03/06/2006
Following concerns raised by GS Land Acquisition, Rehabilitation, Settlement - 9 months to
possess few land
Drawingo Masonry Dam - 04/11/2004o Earth Dam - 01/01/2005o Under Sluice - 20/04/2006
Incumbency - Change of office in the last 36 monthso Chief Engineer - 6 timeso SE - 6 timeso EE - 5 times
Abnormal escalation
Consideration of request for time extension 31/10/2006
79% progress 31/03/2007
93% completed 20/10/2008
4th time extension till 30/06 2010 10/04/2009
Work Completed 25/05/2010
DETAILS ON OMKARESWAR PROJECT
-
7/28/2019 Infra projects and Indian states
44/54
44
Activities Date
Administrative Approval 20/08/1991
R & R Clearance 08/10/1993
Environmental Clearance 13/10/1993Forest Clearance 05/11/1993
Approval of CEA 11/11/1993
Clearance from CWC 18/11/1993
Clearance by NCA 01/09/1994
Revised Administrative Approval 17/06/1996
Investment Clearance from Planning Commission 15/05/2001
Clearance for revised cost by CWC 15/07/2009
Clearance by TAC, CWC, GoI 05/09/2009
-
7/28/2019 Infra projects and Indian states
45/54
45
DETAILS ON LOWER GOI
Activities Date
Environmental Clearnace 17/01/2008
R&R Clearance 05/03/2008
Investment Clearance 02/08/2008
TAC Clearance 28/07/2008
Administrative Approval 26/09/2008
NIT 22/08/2008
Sale Begin 15/09/2008
Sale End 25/09/2008
Bid Opening date 26/09/2008
Price Bid opening date 20/10/2008
WO issue 21/11/2008Completion Time 48 Months
Time Based incidents post Investment clearance
Incident Date
NIT 22/08/2008
Sale Begin 15/09/2008
Sale End 25/09/2008
Gammon India, HCC and 6 other contractors requested for extension
Bid Opening date 26/09/2008Price Bid opening date 20/10/2008
WO issue to IVRCL 21/11/2008
10% Mobilisation advance granted 18/02/2009
Letter from SE demanding immediate action 27/06/2009
Letter from CE as work not started yet 03/07/2009
Letter from SE requesting MIS every month 14/07/2009
Letter from CE requesting utilization certificate of paid mobilization 21/07/2009
Letter from SE requesting MIS 27/08/2009
Reply from IVRCL on activities done and mobilization advance utilization 28/08/2009
IVRCL points out land acquisition issues 20/12/2009
Letter from SE asking for balance land acquisition proposals 06/01/2010
-
7/28/2019 Infra projects and Indian states
46/54
46
Review done by consultancy in theprogress of the work
First six Months (30-03-09 to 30-09-09)
Target 434.45 Lacs
Achieved 147.31 Lacs
Short fall 288.14 Lacs
Second Six Months (30/09/09 to 31/03/10)
Target 2675.8 Lacs
Achieved 1231.18 Lacs
Short fall 1444.62 Lacs
Only 17% work completed till 31/03/11
-
7/28/2019 Infra projects and Indian states
47/54
47
DETAILS ON ISP PROJECT
Time Based incidents post Planning Commission approval
Incident Date
NIT 24/12/2007
Sale