![Page 1: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/1.jpg)
11
American Bar Association
Forum on the Construction Industry2013 Mid Winter Meeting
Contract Drafting To Reduce or Eliminate DamagesWhat Are The Limits?
Contract Drafting To Reduce or Eliminate DamagesWhat Are The Limits?
Linda Dickhaus AgnantThe Agnant Law Firm
Buck S. BeltzerHolland & Hart LLP
Jaimee L. NardielloZetlin & De Chiara LLP
Joseph D. WestGibson Dunn & Crutcher LLP
Plenary 2
![Page 2: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/2.jpg)
2
Fifty State Survey On Enforcement Of Limitation Of Liability Clauses
R. Thomas DunnLittle Medeiros Kinder Bulman & Whitney, PCProvidence, [email protected]
Michael KamprathThresher & Thresher P.A.Tampa, [email protected]
Kenneth H. HaneyQuarles & Brady LLP
Naples, [email protected]
239-659-5050
Bruce W. MerwinHaynes and Boone
Houston, [email protected]
713-547-2116
![Page 3: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/3.jpg)
SCENE 1
2006
Drafting Contract Documents for Trump’s New Naples Stadium
3
![Page 4: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/4.jpg)
The Donald
4
![Page 5: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/5.jpg)
5
![Page 6: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/6.jpg)
The Project
6
![Page 7: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/7.jpg)
The Stadium
7
![Page 8: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/8.jpg)
8
![Page 9: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/9.jpg)
99
Limitations of Liability
![Page 10: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/10.jpg)
Limitations of Liability
• Three most recognized contractual provisions to limit liability:
– (1) limit liability to certain claims;
– (2) limit liability to fees paid; and/or
– (3) limit liability to insurance recovery
10
![Page 11: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/11.jpg)
Limitations of Liability
• Limiting Liability to Certain Claims:
– Statute of limitations
– Differing site conditions
11
![Page 12: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/12.jpg)
Limitations of Liability
• Limiting Liability to Fees Paid
– Dollar Cap
– Don’t forget to include attorney’s fees!
12
![Page 13: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/13.jpg)
Limitations of Liability
• The liability of Consultant, and of Consultant’s employees and sub-consultants, to Client, including attorneys’ fees awarded under this Agreement, shall not exceed an aggregate limit of $50,000 or the amount of the fee, whichever is greater regardless of the legal theory under which such liability is imposed.
13
![Page 14: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/14.jpg)
Limitations of Liability
• Limitations to Insurance Recovery
– “insurance coverage available at the time of settlement or judgment”
14
![Page 15: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/15.jpg)
Limitations of Liability
• Will your limitation of liability clause be enforceable?– Upheld in 36 states
• Confirm the law governing your agreement permits a LOL clause
– Be clear and unambiguous
– Negotiate the terms
– Don’t be overzealous
– Confirm the contract provisions are not in conflict 15
![Page 16: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/16.jpg)
Limitations of Liability
• In a perfect world…
– No monetary caps
– All claims brought within one year
– No added protections for differing site conditions
16
![Page 17: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/17.jpg)
1717
Waiver of Consequential Damages
![Page 18: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/18.jpg)
Waiver of Consequential Damages
• Make the party whole, by placing in the position that party would have been had the contract been performed
– but must be reasonably foreseeable as a result of the breach
– but not including remote losses
18
![Page 19: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/19.jpg)
• Damages 101
– “the basic purpose of contract damages is to make a party whole by putting it in as good a position as the party would have been had the contract been performed…a party is not entitled to recover damages not the proximate result of the breach of contract and those which are remote, contingent, and speculative in character.”
• ABA Model Jury Instruction 10.02 19
Waiver of Consequential Damages
![Page 20: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/20.jpg)
• Consequential v. Direct
– Direct damages flow naturally and necessarily from the breach and compensate for foreseeable or contemplated loss
• Contract balance; cost to repair defective work
– Consequential damages do not flow directly and immediately from the breach, but only from some of the consequences or results of the breach
20
Waiver of Consequential Damages
![Page 21: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/21.jpg)
• Material Escalation
• Inefficiency
• Overtime/Cost of Acceleration
• Extended jobsite overhead
• Loss of early completion
bonus
• Lost Profits (this and other projects)
• Home Office overhead
• Loss of bonding capacity
• Loss of reputation
• Loss of financing
Examples - Contractor
21
Waiver of Consequential Damages
![Page 22: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/22.jpg)
• Rental income
• Diminution in value
• Financing
• Loss of use
• Loss of income
• Loss of profit
• Loss of business reputation
• Loss of management productivity
• Insolvency
Examples - Owner
22
Waiver of Consequential Damages
![Page 23: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/23.jpg)
• Contract Drafting Tips
– Generally enforceable if drafted correctly
– Spell out definitions for “consequential damages”
– One sided or neutral?
23
Waiver of Consequential Damages
![Page 24: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/24.jpg)
In no event shall Owner be liable to Contractor for any indirect, special, incidental or consequential damage including, but not limited to, material escalation, inefficiency, overtime, cost of acceleration, extended jobsite overhead, lost profits, home office overhead, or loss of bonding capacity.
24
Waiver of Consequential Damages
![Page 25: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/25.jpg)
2525
No Damages for Delay
![Page 26: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/26.jpg)
No Damages for Delay
• Basic Principal – Freedom of Contract
• Generally Enforceable
• Exception - Statutory
• Exception - Traditional Contract Law
26
![Page 27: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/27.jpg)
No Damages for Delay
• Exception – Extraordinary Circumstances
– fraud
– willful or malicious or grossly negligent conduct
– active interference
– abandonment
– uncontemplated delay27
![Page 28: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/28.jpg)
No Damages for Delay
• Consider
– Economic loss rule?
– Liquidated damages or incentives?
28
![Page 29: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/29.jpg)
No Damages for Delay
• Owner shall not be liable to Contractor and/or any Subcontractor for any claims or damages caused by or arising out of delays. Contractor’s sole remedy against Owner for delays shall be an allowance of additional Contract Time.
29
![Page 30: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/30.jpg)
3030
Liquidated Damages
![Page 31: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/31.jpg)
Liquidated Damages
• Basic Principal
– Compensation for Breach
• Two Requirements
– Actual damages are difficult to estimate
– Liquidated amount must be reasonable estimate of damages
• Key
– Cannot be a penalty
31
![Page 32: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/32.jpg)
Liquidated Damages
• The contractor’s failure to achieve substantial
completion by the contract completion date shall
require the contractor to pay liquidated damages
to the Owner in the amount of One Hundred
Thousand Dollars ($100,000) for each day that
substantial completion is delayed. …
32
![Page 33: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/33.jpg)
Liquidated Damages
• … Such liquidated damages are intended to
represent estimated actual damages and are not
intended as a penalty, and Contractor shall pay
them to Owner without limiting Owner’s right to
terminate this agreement for default as provided
elsewhere herein.
33
![Page 34: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/34.jpg)
Liquidated Damages
• Substantial Completion Occurs When:
– Stadium can be used for its intended purpose
– City of Naples issues a Certificate of Occupancy
– All systems are fully functional
– All claims are resolved
– All manuals and instructional materials have been delivered
– All punch list items must be resolved
34
![Page 35: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/35.jpg)
SCENE 2
35
2009
Construction is underway
What does the contract actually say?
![Page 36: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/36.jpg)
Limitations of Liability
• The liability of Architect, and of Architect’s employees and sub-consultants, to Client, including attorneys’ fees awarded under this Agreement, shall not exceed an aggregate limit of $550,000 or the amount of the fee paid to Architect, whichever is greater regardless of the legal theory under which such liability is imposed.
36
![Page 37: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/37.jpg)
Waiver of Consequential Damages
In no event shall Owner be liable to Contractor
either party be liable to the other for any
indirect, special, incidental or consequential
damage including, but not limited to, material
escalation, inefficiency, overtime, cost of
acceleration, extended jobsite overhead, lost
profits, home office overhead, or loss of
bonding capacity, rental expenses, lost use, lost
profit, lost financing, or lost profits.
37
![Page 38: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/38.jpg)
No Damages for Delay
• Owner shall not be liable to Contractor and/or
any Subcontractor for any claims or damages
caused by or arising out of delays, unless the
delay is caused by acts of the Owner
constituting active interference with the
Contractor’s performance of the work.
Contractor’s sole remedy against Owner for
delays shall be an allowance of additional
Contract Time.
38
![Page 39: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/39.jpg)
Liquidated Damages
• The contractor’s failure to achieve substantial
completion by the contract completion date shall
require the contractor to pay liquidated damages
to the Owner in the amount of One Hundred Fifty
Thousand Dollars ($100,000) ($50,000) for each
day that substantial completion is delayed. …
39
![Page 40: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/40.jpg)
Liquidated Damages
• … Such liquidated damages are intended to
represent estimated actual damages and are not
intended as a penalty, and Contractor shall pay
them to Owner without limiting Owner’s right to
terminate this agreement for default as provided
elsewhere herein.
40
![Page 41: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/41.jpg)
Liquidated Damages
• Substantial Completion Occurs When:– Stadium can be used for its intended purpose
– City of Naples issues a Certificate of Occupancy
– All systems are fully functional
– All claims are resolved
– All manuals and instructional materials have been delivered
– All punch list items must be resolved
41
![Page 42: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/42.jpg)
SCENE 3
42
2013
Things did not go well
In the boardroom with Trump
![Page 43: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/43.jpg)
Bruce Springsteen Concert
CANCELLED
43
![Page 44: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/44.jpg)
Trump’s Finances
44
![Page 45: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/45.jpg)
Trump’s Finances
45
![Page 46: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/46.jpg)
Trump’s Finances
46
![Page 47: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/47.jpg)
The Inefficient Contractor
47
![Page 48: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/48.jpg)
Gold Goal Posts
DELAYED
48
![Page 49: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/49.jpg)
The Hurricane
49
![Page 50: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/50.jpg)
The Missing Architect
50
![Page 51: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/51.jpg)
Limitations of Liability
• Professional Negligence
– Ignored site administration responsibilities
– Delayed approval of requisitions
– Delayed responding to RFIs
• Maximum liability is capped at his fee
51
![Page 52: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/52.jpg)
• Owner and Contractor breached
– Owner breaches: missing/inept architect; late gold goal posts
– Contractor breaches: inefficiency, late completion of punch list
– Acts of God: Hurricane
• Both parties suffered both direct and consequential damages
Waiver of Consequential Damages
52
![Page 53: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/53.jpg)
Waiver of Consequential Damages
53
• Mutual waiver means neither will recover their consequential losses from the other
– Trump will not owe the Contractor for material escalation, inefficiency, etc.
– But Trump will not recover the lost revenues associated with the Super Bowl relocation to New Orleans, or the cancelled Springsteen concert
![Page 54: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/54.jpg)
No Damages for Delay
• Uncontemplated Delay (the New York Approach)
– Hurricane
– OSHA Investigation for “Hair Hats”
• Active Interference
– Refusing to award change orders
– Forbidding work without signed change orders 54
![Page 55: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/55.jpg)
Liquidated Damages
• Stadium was ready for use 210 days after completion date.
• City issued C/O at that time
• But– TV service to “Million Dollar” suites not operative for
additional 200 days
– Manuals for overhead doors on loading dock were delivered 250 days beyond the ready for use date
– Punch list was not resolved until 300 days beyond the ready for use date
• Therefore, LD’s = (210 + 300) x 50,000 = $25,500,00055
![Page 56: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/56.jpg)
Liquidated Damages
• Many states are moving to a “Look Back” approach
• Concept is to prevent windfalls
• FORTUNATELY NEW YORK IS A SINGLE LOOK STATE
56
![Page 57: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/57.jpg)
57
![Page 58: American Bar Association Forum on the Construction Industry 2013 Mid Winter Meeting Contract Drafting To Reduce or Eliminate Damages What Are The Limits?](https://reader031.vdocuments.us/reader031/viewer/2022032802/56649e0a5503460f94af2615/html5/thumbnails/58.jpg)
You’re All Fired
58