Developing a Best Practice Framework for Implementing
Public Private Partnerships (PPP) in Hong Kong
Esther Cheung
BEng (Hons), MPhil
A thesis submitted for the degree of
Doctor of Philosophy
School of Urban Development
Faculty of Built Environment and Engineering
Queensland University of Technology
March 2009
Keywords
i
KEYWORDS
Public Private Partnership (PPP)
Build Operate Transfer (BOT)
Infrastructure
Procurement
Public Works
Public Sector
Private Sector
Researcher
Hong Kong
Australia
Abstract
ii
ABSTRACT
Public Private Partnership (PPP) is a well established methodology for procuring public
works projects. By incorporating the private sector’s expertise, efficiency, innovation,
business sense, risk sharing, financing etc. into public works projects, the quality of
public services and facilities can be uplifted. Like many jurisdictions, Hong Kong is also
keen to take aboard this methodology which is so familiar but yet so distant. Although
they have been one of the first jurisdictions to utilise the private sector in public works
projects, their comfortable financial reserves has meant that there has been no urge to
push the movement until recently. PPP has become increasingly popular amongst
governments. The Hong Kong Special Administrative Region (HKSAR) government is
no exception. Some of the more active works departments have commissioned studies to
investigate the best ways to deliver these projects, others have even trialed the method
themselves. The efficiency Unit of the HKSAR government has also become an active
arm in conducting research in this area. Although so, the information that is currently
available is still very broad. Building from their works there is a need to develop a best
practice framework for implementing PPP projects in Hong Kong by incorporating
international experiences.
To develop a best practice framework will require thorough investigation into the benefits,
Abstract
iii
difficulties and critical success factor of PPP. PPP should also be compared with other
procurement methods. In order to do so it is important to clearly understand the local
situation by an analysis of projects conducted to date. Lessons learnt can further be
derived from other countries and incorporated to those derived locally. Finally the best
conditions in terms of project nature, complexity, types, and scales for adopting PPP
should be derived.
The aim and objectives of this study were achieved via a comprehensive literature review,
in-depth case analyses, interview survey with experts from both Hong Kong and overseas,
and finally a large scale data collection was conducted via a questionnaire survey with
PPP practitioners. These findings were further triangulated before they were used as the
basis to form the best practice framework presented in this thesis. The framework was
then further validated by PPP experts to ensure it is comprehensive, objective, reliable
and practical.
This study has presented a methodology that can be adopted for future studies. It has also
updated our knowledge on the development trends of PPP as well as opened up the
experiences of other jurisdictions. The findings have shown that the local industry is
familiar with “what” should be done in PPP projects but they are unsure of “how” these
goals can be achieved. This framework has allowed this further knowledge to be
delivered to PPP practitioners. As a result, the development of this framework can help
to resolve the current economic crisis by encouraging more developments and business
opportunities for the private sector. In addition, the correct projects can be delivered by
Abstract
iv
PPP, the advantages of PPP can be maximised, and the general public can benefit from
the private sector’s participation.
List of Publications
v
LIST OF PUBLICATIONS
Journal Papers (published and accepted)
1. Esther Cheung and Albert P.C. Chan, Financing Model for Future Infrastructure
Projects in Hong Kong – A Case Study of the Hong Kong – Zhuhai – Macau
Bridge, Journal of Property Investment and Finance, Journal of Property
Investment and Finance, Paper accepted for publication.
2. Esther Cheung, Albert P.C. Chan and Stephen Kajewski (2008). Reasons for
Implementing Public Private Partnership Projects – Perspectives from Hong
Kong, Australian and British Practitioners. Journal of Property Investment and
Finance, Vol. 27, No. 1, 81 – 95.
3. Albert P.C. Chan, Patrick T.I. Lam, Daniel W.M. Chan and Esther Cheung (2008).
A Mechanism for Risk Sharing in PPP Projects – The Sydney Cross City Tunnel
Case Study, Surveying and Built Environment (Journal of the Hong Kong Institute
of Surveyors), 19, 1, December 2008.
List of Publications
vi
4. 陈炳泉,林俊业,陈炜明,张泳沁,柯永建 (2008). 香港基础设施融资模式
比较研究. 建築經濟, October 2008, 89-92. (English translation: Albert PC Chan,
Patrick TI Lam, Daniel WM Chan, Esther Cheung and Yongjian Ke (2008).
Comparative Study of Different Financial Modalities in Infrastructure
Development of Hong Kong. Construction Economy, October 2008, 89-92.)
Journal Papers (under review)
1. Esther Cheung, Albert P.C. Chan and Stephen Kajewski (2008). The Hong Kong
and Australian Private Sector’s Perspective on Procuring Public Works Projects,
Journal of Property Investment and Finance, Journal of Property Investment and
Finance, Paper under review.
2. Esther Cheung, Albert P.C. Chan and Stephen Kajewski (2008). The Public
Sector’s Perspective on Procuring Public Works Projects – Comparing the Views
of Practitioners in Hong Kong and Australia, Journal of Civil Engineering and
Management, Paper under review.
3. Esther Cheung, Albert P.C. Chan and Stephen Kajewski (2008). The Researcher’s
Perspective on Procuring Public Works Projects – Findings from Hong Kong and
Australian Interviewees, Australian Journal for Construction Economics and
Building, Paper under review.
List of Publications
vii
4. Esther Cheung, Albert P.C. Chan and Stephen Kajewski (2008). Suitability of
Procuring Large Public Works by Public Private Partnership - Comparing Hong
Kong Practitioners' Views against those in the United Kingdom and Australia.
Engineering, Construction and Architectural Management, Paper under review.
5. Esther Cheung, Albert P.C. Chan and Stephen Kajewski (2008). Factors
Contributing to Successful Public Private Partnership Projects – Comparing Hong
Kong with Australia and the United Kingdom. Canadian Journal of Civil
Engineering, Paper under review.
6. Esther Cheung, Albert P.C. Chan and Stephen Kajewski (2008). Enhancing Value
for Money in Public Private Partnership Projects - Findings from a Survey
Conducted in Hong Kong, Australia and the United Kingdom. Journal of
Financial Management of Property and Construction, Paper under review.
7. Albert PC Chan, Patrick TI Lam, Daniel WM Chan, Esther Cheung and Yongjian
Ke (2008). Critical Success Factors for Public Private Partnerships (PPP) in
Infrastructure Developments: A Chinese Perspective. Journal of Construction
Engineering and Management, ASCE, Paper under review.
8. Albert PC Chan, Patrick TI Lam, Daniel WM Chan, Esther Cheung and Yongjian
Ke (2008). A Comparative Study of Critical Success Factors for Public Private
Partnerships (PPP) between China and the Hong Kong Special Administrative
Region. Journal of Management in Engineering, ASCE, Paper under review.
List of Publications
viii
9. Albert PC Chan, Patrick TI Lam, Daniel WM Chan, Esther Cheung and Yongjian
Ke (2008). Driving Forces to Adopt Public Private Partnership (PPP) in China and
the Hong Kong Special Administrative Region. Engineering, Construction and
Architectural Management, Paper under review.
10. Albert PC Chan, Patrick TI Lam, Daniel WM Chan, Esther Cheung and Yongjian
Ke (2008). Potential Obstacles to Successful Implementation of Public Private
Partnerships (PPP) in China and the Hong Kong Special Administrative Region.
Journal of Management in Engineering, ASCE, Paper under review.
11. Albert PC Chan, Patrick TI Lam, Daniel WM Chan, Esther Cheung and Yongjian
Ke (2008). Drivers for Adopting PPP - A Comparison between China and Hong
Kong Special Administrative Region. Journal of Construction Engineering and
Management, ASCE, Paper under review.
12. Yongjian Ke, Shouqing Wang, Albert P.C. Chan and Esther Cheung (2008).
Research Trend of Public-Private Partnership (PPP) in Construction Journals,
Journal of Construction Engineering and Management, ASCE, Paper under
review.
Journal papers (pending submission)
1. Albert P.C. Chan, Patrick T.I. Lam, Daniel W.M. Chan, Esther Cheung, Yongjian
Ke, Yang Wen and Yelin Xu (2008) Understanding the Major Risks in Mainland
China's PPP Projects, Pending submission.
List of Publications
ix
2. Albert P.C. Chan, Patrick T.I. Lam, Daniel W.M. Chan, Esther Cheung, Yongjian
Ke, Yang Wen and Yelin Xu (2008) Critical risk groupings of public-private
partnerships in China, Pending submission.
Conference Papers (published and accepted)
1. Esther Cheung and Albert P.C. Chan. Suitability of Procuring Large Public Works
by Public Private Partnership (PPP) - A Case Study of the Kai Tak Cruise
Terminal Project in Hong Kong. The 34th Australasian Universities Building
Education Association (AUBEA) Annual Conference, 7 – 10 July 2009, Abstract
accepted.
2. Albert PC Chan, Patrick TI Lam, Daniel WM Lam, Esther Cheung and Yongjian
Ke (2009). Privileges and Attractions for Private Sector Involvement in PPP
Projects - A Comparison between China and the Hong Kong Special
Administrative Region. The Fifth International Structural Engineering and
Construction Conference, Las Vegas, Nevada, USA, 21 – 27 September 2009,
Abstract accepted.
3. Esther Cheung (2009). Common Problems Holding Back the Development of PPP
in Hong Kong, Public Private Partnerships (PPPs) Seminar Series, Hong Kong
Institute of Surveyors, 14 February 2009.
List of Publications
x
4. Albert P.C. Chan, Patrick T.I. Lam, Daniel W.M. Chan and Esther Cheung (2008).
Application of Public Private Partnership (PPP) Model in Procuring Infrastructure
Projects in Hong Kong, CIB W055 – W065 Joint International Symposium:
Transformation Through Construction, 190 – 191, 17 – 19 November 2008,
Dubai.
5. Albert P.C. Chan, Patrick T.I. Lam, Daniel W.M. Chan and Esther Cheung (2008).
Application of Public Private Partnership (PPP) in Hong Kong Special
Administrative Region – The Private Sector’s Perspective, The Chinese Research
Institute of Construction Management (CRIOCM) 2008 International Symposium
on “Advancement of Construction Management and Real Estate” , 31 October – 3
November 2008, Beijing, China.
6. Albert P.C. Chan, Patrick T.I. Lam, Daniel W.M. Lam, Esther Cheung and
Yongjian Ke (2008). Measures that Enhance the Achievement of Value-for-Money
in PPP Projects, Building Abroad - Procurement of construction and
reconstruction projects in the international context, IF Research Group, i-Rec and
CIB, University de Montreal, Canada, 23 – 25 October 2008.
7. Albert P.C. Chan, Patrick T.I. Lam, Daniel W.M. Chan and Esther Cheung (2008).
Application of Public Private Partnership (PPP) in Hong Kong Special
Administrative Region – the Critics’ Perspectives, International Conference on
Construction in Developing Countries - Advancing and Integrating Construction,
Education, Research & Practices (ICCIDC-I), Pakistan, 4 – 5 August 2008, 302-
311.
List of Publications
xi
8. Albert P.C. Chan, Tony Sidwell, Stephen Kajewski, Patrick T.I. Lam, Daniel W.M.
Chan and Esther Cheung (2007). From BOT to PPP - A Hong Kong Example,
2007 International Conference on Concession Public / Infrastructural Projects
(ICCPIP), Dalian University of Technology, China, 24 – 26 August 2007.
9. Albert P.C. Chan, Patrick T.I. Lam, Daniel W.M. Chan, Tony Sidwell, Stephen
Kajewski and Esther Cheung (2007). A Research Framework for Investigating
Public Private Partnerships (PPP) in Hong Kong, 4th International Conference on
Construction in the Twenty First Century (CITC-IV), Gold Coast, Australia, 11 –
13 July 2007.
Book Chapter (published)
1. Janardhan Rao N. and Singh Sisodiya A. (2009). Public-Private Partnership Model in
India: Concepts, Issues and Outlook. Albert P.C. Chan, Stephen Kajewski and Esther
Cheung. Obstacles in Adopting PPP – Lessons from Australia. Icfai University Press,
181-187.
Magazine Article (published)
1. Albert P.C. Chan, Stephen Kajewski and Esther Cheung (2008). Obstacles in
Adopting PPP – Lessons from Australia. Projects and Profits, Special Issue –
Managing Construction Projects, The Icfai University Press, 60, 28 – 31, May 2008.
Table of Contents
xii
TABLE OF CONTENTS
KEYWORDS i
ABSTRACT ii
LIST OF PUBLICATIONS v
TABLE OF CONTENTS xii
LIST OF TABLES xxi
LIST OF FIGURES xxv
LIST OF ABBREVIATIONS xxvii
STATEMENT OF ORIGINAL AUTHORSHIP xxx
ACKNOWLEDGEMENTS xxxi
CHAPTER 1 INTRODUCTION 1
1.1 Background 2
1.2 Research Aim and Objectives 4
1.2.1 Aim 4
1.2.2 Objectives 4
1.3 Research Methodology 5
1.4 Structure of the Thesis 7
Table of Contents
xiii
1.5 Research Significance and Value 9
1.6 Chapter 1 Summary 10
CHAPTER 2 RESEARCH METHODLOGY 11
2.1 Chapter 2 Introduction 12
2.2 Research Design 12
2.3 Research Process 13
2.3.1 Background study 13
2.3.2 Project experience 13
2.3.3 Extraction of expert knowledge 14
2.3.3.1 Interviews with the public sector 16
2.3.3.2 Interviews with the private sector 18
2.3.3.3 Interviews with researchers 21
2.3.4 Large scale data collection 23
2.4 Data Analysis Techniques 24
2.4.1 Qualitative data analysis 24
2.4.2 Quantitative data analysis 25
2.4.2.1 Mean score ranking technique 25
2.4.2.2 Kendall’s concordance analysis 26
2.5 Chapter 2 Summary 27
CHAPTER 3 LITERATURE REVIEW 28
3.1 Chapter 3 Introduction 29
Table of Contents
xiv
3.2 What is the Traditional Practice of Procuring Public Works Project? 31
3.2.1 Progression from traditional to PPP 31
3.2.2 Traditional vs PPP 36
3.3 Background of PPP 39
3.3.1 Background 39
3.3.2 Types of PPP 42
3.3.3 The PPP process 44
3.3.4 The parties involved in a PPP project 46
3.3.5 Research conducted in PPP 47
3.4 Attractive Factors of adopting PPP 49
3.5 Negative Factors of adopting PPP 55
3.6 Value for Money in PPP projects 59
3.7 Achieving Successful PPP projects 61
3.8 Chapter 3 Summary 63
CHAPTER 4 PROCURING INFRASTRUCTURE PROJECTS IN HONG KONG 64
4.1 Chapter 4 Introduction 65
4.2 BOT/PPP Experience in Hong Kong 65
4.3 BOT/PPP Case Studies 67
4.3.1 Cross Harbour Tunnel (CHT) 67
4.3.2 Western Harbour Crossing (WHC) 69
4.3.3 Asia World Expo (AWE) 71
4.3.4 West Kowloon Cultural District (WKCD) 74
Table of Contents
xv
4.3.5 Findings from the case studies 76
4.3.6 Section 4.3 summary 79
4.4 Is BOT the Best Financing Model to Procure Infrastructure Projects? 81
4.4.1 Background of the Hong Kong – Zhuhai – Macau Bridge 82
4.4.1.1 Background 82
4.4.1.2 The proposed design 84
4.4.1.3 The original BOT decision 86
4.4.1.4 Underlying problems of the project 87
4.4.2 Change from private financing to public financing 88
4.4.2.1 The Process of change 88
4.4.2.2 Government motives for not opting for the BOT model 91
4.4.2.3 Other underlying reasons for using public finance 92
4.4.3 Section 3.4 summary 97
4.5 Chapter 4 Summary 98
CHAPTER 5 THE AUSTRALIAN PPP EXPERIENCE 100
5.1 Chapter 5 Introduction 101
5.2 PPP in Australia 101
5.2.1 The Victoria practice 102
5.2.2 The Queensland practice 103
5.3 A New Era of PPP in Australia
– The Southbank Education and Training Precinct Case Study
106
5.3.1 Background 106
Table of Contents
xvi
5.3.2 The obstacles 109
5.3.3 Other projects in Queensland 110
5.3.4 Section 5.3 summary 111
5.4 Risk Sharing Mechanism for PPP Projects
– The Sydney Cross City Tunnel Case Study
112
5.4.1 Background 112
5.4.2 Underlying causes leading to failure 116
5.4.3 Appropriate risk allocation 121
5.4.4 Risk sharing mechanism 127
5.4.5 Section 5.4 summary 130
5.5 Chapter 5 Summary 131
CHAPTER 6 DIFFERENT PERSPECTIVES ON PROCURING PUBLIC
WORKS PROJECTS IN HONG KONG AND AUSTRALIA
132
6.1 Chapter 6 Introduction 133
6.2 The Public Sector’s Perspective 133
6.2.1 Selecting respondents 133
6.2.2 Interview findings 137
6.2.2.1 Research on local case studies 141
6.2.2.2 Comparing PPP with traditional procurement methods 142
6.2.2.3 Projects best suited to use PPP 144
6.2.2.4 Key performance indicators in PPP projects 146
Table of Contents
xvii
6.2.2.5 Critical success factors leading to successful PPP projects 148
6.2.2.6 In-house guidance/practice notes 150
6.2.3 Section 6.2 summary 151
6.3 The Private Sector’s Perspective 154
6.3.1 Selecting respondents 154
6.3.2 Interview findings 157
6.3.2.1 Local and international experience in conducting PPP
projects
161
6.3.2.2 Implementation process of PPP projects 162
6.3.2.3 Major reasons for adopting PPP projects 163
6.3.2.4 Comparing PPP with traditional procurement methods 164
6.3.2.5 Projects of interest to the private sector 166
6.3.2.6 Key performance indicators of PPP projects 167
6.3.2.7 Critical success factors leading to successful PPP projects 168
6.3.2.8 In-house guidance/practice notes 169
6.3.3 Section 6.3 summary 170
6.4 The Researcher’s Perspective 174
6.4.1 Selecting respondents 174
6.4.2 Interview findings 176
6.4.2.1 Research on local case studies 179
6.4.2.2 Comparing PPP with traditional procurement methods 179
6.4.2.3 Projects best suited to use PPP 181
6.4.2.4 Key performance indicators in PPP projects 182
Table of Contents
xviii
6.4.2.5 Critical success factors leading to successful PPP projects 182
6.4.3 Section 6.4 summary 184
6.5 Chapter 6 Summary 185
CHAPTER 7 SUITABILITY OF PROCURING LARGE PUBLIC WORKS BY
PPP
188
7.1 Chapter 7 Introduction 189
7.2 Collection of Research Data 189
7.3 Survey Results 194
7.3.1 Ranking of attractive factors for adopting PPP 194
7.3.2 Ranking of negative factors for adopting PPP 201
7.3.3 Agreement of the survey respondents 206
7.3.4 The suitability of adopting PPP 208
7.4 Chapter 7 Summary 213
CHAPTER 8 IMPLEMENTING PUBLIC PRIVATE PARTNERSHIP PROJECTS 215
8.1 Chapter 8 Introduction 216
8.2 Reasons for Implementing PPP Projects 216
8.2.1 Agreement of the survey respondents 218
8.2.2 Ranking of the reasons for implementing PPP projects 219
8.2.3 Section 8.2 summary 225
8.3 Factors Contributing to Successful PPP Projects 227
8.3.1 Agreement of the survey respondents 229
Table of Contents
xix
8.3.2 Ranking of factors that contribute to the success of PPP projects 230
8.3.3 Section 8.3 summary 237
8.4 Enhancing Value for Money in PPP Projects 238
8.4.1 Agreement of the survey respondents 240
8.4.2 Ranking of value for money measures in PPP 241
8.4.3 Section 8.4 summary 247
8.5 Chapter 8 Summary 248
CHAPTER 9 A BEST PRACTICE FRAMEWORK FOR IMPLEMENTING PPP
IN HONG KONG
251
9.1 Chapter 9 Introduction 252
9.2 The PPP Process 252
9.3 Incorporating the Research Findings into the PPP Process 257
9.4 Validation of the Framework 267
9.4.1 Design of the validation questionnaire survey 267
9.4.2 Respondents of the survey 268
9.4.3 Results of the validation 270
9.5 Chapter 9 Summary 272
CHAPTER 10 CONCLUSIONS AND RECOMMENDATIONS 273
10.1 Chapter 10 Introduction 274
10.2 Review of the Project Objectives 274
Table of Contents
xx
10.3 Major Findings 277
10.3.1 Benefits, difficulties and critical success factors of PPP 277
10.3.1.1 Benefits/attractive factors of PPP 277
10.3.1.2 Difficulties/negative factors of PPP 280
10.3.1.3 Critical success factors of PPP 284
10.3.2 PPP compared to other procurement methods 287
10.3.3 Representative case studies from Australia 289
10.3.4 PPP experiences in Hong Kong 290
10.3.5 Best conditions for using PPP 292
10.3.6 Recommendations for Developing a Best Practice Framework for
Public Private Partnerships in Hong Kong
294
10.4 Value and Significance of the Research 295
10.5 Limitations of the Research 297
10.6 Recommendations for Future Research 298
10.7 Chapter 10 Summary 299
REFERENCES 300
APPENDICES 327
Appendix 1 Questionnaire Survey Template for Research Study 328
Appendix 2 Questionnaire Survey Template for Validation Process 331
List of Tables
xxi
LIST OF TABLES
Table 2.1 Project objectives linking up with interview questions for public sector
interviewees
17
Table 2.2 Project objectives linking up with interview questions for private sector
interviewees
19
Table 2.3 Project objectives linking up with interview questions for researcher
interviewees
22
Table 4.1 Summary of the analysed case studies (Asia World Expo, 2007; Bouygues-
Asia, 2007; Hong Kong Engineers, 2006; Li, 2001; Nishimatsu, 2006)
78
Table 4.2 Summary of the HZMB details (Mak, 2008; Hong Kong Special
Administrative Region Government, 2008; Chen and Lee 2008; Hung,
2008; Transport and Housing Bureau, 2008a)
86
Table 4.3 Comparison of estimated toll fees to be charged under different financial
models (Ming Pao, 2008b)
95
Table 5.1 Risk allocation structure for CCT (Clifton and Duffield, 2006)
123
Table 5.2 Risk allocation framework for the annuity-based BOT model (Singh and
Kalidindi, 2006)
125
List of Tables
xxii
Table 6.1 List of interviewees from the public sector in Hong Kong 135
Table 6.2 List of interviewees from the public sector in Australia 136
Table 6.3 Summary of responses from public sector interviewees 138
Table 6.4 Question 1 - Have you conducted any research looking at local case
studies?
142
Table 6.5 Question 2 - How would you compare PPP with traditional procurement
methods?
144
Table 6.6 Question 3 - Which type of project do you feel is best suited to use PPP? 146
Table 6.7 Question 4 - What do you feel are the key performance indicators in a PPP
project?
148
Table 6.8 Question 5 - In general, what do you think are the critical success factors
leading to successful PPP projects?
150
Table 6.9 Question 6 - Does your organisation have any in-house guidance/practice
notes?
151
Table 6.10 List of Interviewees from the private sector in Hong Kong 155
Table 6.11 List of Interviewees from the private sector in Australia 156
Table 6.12 Summary of responses from private sector interviewees 158
Table 6.13 Question 1 - Which PPP projects has your company been involved in? 162
Table 6.14 Question 2 - Please describe the implementation process in these projects 162
Table 6.15 Question 3 - What were the major reasons for adopting PPP in these
projects?
164
Table 6.16 Question 4 - How do you think PPP compares with traditional procurement
methods?
165
List of Tables
xxiii
Table 6.17 Question 5 - Which type of project would your company be most interested
in applying PPP?
167
Table 6.18 Question 6 - What do you feel are the key performance indicators in a PPP
project?
168
Table 6.19 Question 7 - In general, what do you think are the critical success factors
leading to successful PPP projects?
169
Table 6.20 Question 8 - Does your company have any in-house guidance/practice notes
on PPP implementation?
170
Table 6.21 List of interviewees 175
Table 6.22 Summary of interview findings with researchers from Hong Kong and
Australia
177
Table 7.1 Mean scores and rankings for the attractive factors of PPP 200
Table 7.2 Mean scores and rankings for the negative factors of PPP 205
Table 7.3 Results of Kendall’s concordance analysis for the attractive factors of PPP 206
Table 7.4 Results of Kendall’s concordance analysis for the negative factors of PPP 207
Table 7.5 Checklist of attractive and negative factors for the Kai Tak cruise terminal
project
212
Table 8.1 Mean scores and rankings of the reasons for implementing PPP projects 217
Table 8.2 Results of Kendall’s concordance analysis of the reasons for implementing
PPP projects
218
Table 8.3 Mean scores and rankings for the factors that contribute to the success of
PPP projects
228
List of Tables
xxiv
Table 8.4 Results of Kendall’s concordance analysis for the factors that contribute to
the success of PPP projects
229
Table 8.5 Mean scores and rankings for the VFM measures in PPP projects 239
Table 8.6 Results of Kendall’s concordance analysis for the VFM measures in PPP
projects
240
Table 9.1 Guideline for conducting step 1 “Mobilisation and development of a
business case”
258
Table 9.2 Guideline for conducting step 2 “Funding” 260
Table 9.3 Guideline for conducting step 3 “Technical assessments, consultation and
land requirements”
261
Table 9.4 Guideline for conducting step 4 “Expression of interest exercise” 262
Table 9.5 Guideline for conducting step 5 “Policy and funding approvals” 263
Table 9.6 Guideline for conducting step 6 “Procurement and selection” 264
Table 9.7 Guideline for conducting step 7 “Service commencement” 265
Table 9.8 Guideline for conducting step 8 “Payment and contract management” 266
Table 9.9 Details of the survey respondents for the validation process 269
Table 9.10 Results of the validation questionnaire survey 271
Table 10.1 Tools used to achieve the research objectives 276
List of Figures
xxv
LIST OF FIGURES
Figure 1.1 Flow diagram of research process 6
Figure 3.1 Procurement selection process for typical public works project in Hong
Kong (adapted from Environment, Transport and Works Bureau, 2004)
32
Figure 3.2 The generic procurement categories with their respective sub-categories for
public works projects in Hong Kong (adapted from Environment, Transport
and Works Bureau, 2004)
34
Figure 3.3 Differences in procurement between the traditional and PPP approaches of
conducting public works projects in Hong Kong (adapted from Efficiency
Unit, 2008b)
38
Figure 3.4 Annual investment of infrastructure projects with private participation in
developing countries between 1990-2006 (World Bank, 2008)
41
Figure 3.5 Typical processes for delivering PPP projects in New South Wales, Australia
(adapted from Infrastructure Implementation Group, 2005)
45
Figure 4.1 Photograph of the Cross Harbour Tunnel entrance and exit on Kowloon
Peninsula (Kowloon Motor Bus 30X/230X, 2008)
68
Figure 4.2 Photograph of the Western Harbour Crossing entrance and exit on Kowloon
Peninsula (Forum Sara, 2008)
70
List of Figures
xxvi
Figure 4.3 Photograph of the Asia World Expo (Asia World Expo, 2008a) 72
Figure 4.4 Artist’s impression of the proposed West Kowloon Cultural District project
(Home Affairs Bureau, 2008)
75
Figure 4.5 Alignment of the HKZMB (Transport and Housing Bureau 2008a) 85
Figure 5.1 Ariel photograph of the Southbank Education and Training Precinct project
in October 2007 (Department of Education, Training and the Arts; 2008)
108
Figure 5.2 Photograph of the Cross City Tunnel (Traffman, 2008) 113
Figure 5.3 Examples of newspaper headlines relating to the CCT when it opened
(Infrastructure Implementation Group, 2005)
117
Figure 7.1 Histogram showing the number of years of working experience in
construction industry for the Hong Kong survey respondents
192
Figure 7.2 Histogram showing the number of years of working experience in
construction industry for the Australian survey respondents
192
Figure 7.3 Histogram showing the number of PPP projects the Hong Kong survey
respondents have been involved with
193
Figure 7.4 Histogram showing the number of PPP projects the Australian survey
respondents have been involved with
193
Figure 8.1 Rank relationship between Hong Kong, Australia and the United Kingdom
for success factors of PPP
236
Figure 8.2 Rank relationship between Hong Kong, Australia and the United Kingdom
for VFM measures of PPP
246
Figure 9.1 The process for implementing PPP projects in Hong Kong (adapted from
Efficiency Unit, 2008b)
255
List of Abbreviations
xxvii
LIST OF ABBREVIATIONS
AUD: Australian Dollar
AWCG: Advance Work Co-ordination Group
AWE: Asia World Expo
BOO: Build Own Operate
BOOR: Build Own Operate Remove
BOOT: Build Own Operate Transfer
BOT: Build Operate and Transfer
BTO: Build Transfer Operate
CCT: Cross City Tunnel
CHT: Cross Harbour Tunnel
DBFO: Design Build Finance Operate
DBFOM: Design Build Finance Operate Manage
Dr.: Doctor
e.g.: exempli gratia
et al.: et alii
etc.: et cetera
f: Frequency of each rating for each factor
HKSAR: Hong Kong Special Administrative Region
List of Abbreviations
xxviii
HM: Her Majesty
HPDI: China Highway Planning and Design Institute
HZMB: Hong Kong – Zhuhai – Macau Bridge
JV: Joint Ventures
km: Kilometre
KPI: Key Performance Indicator
LROT: Lease Renovate Operate Transfer
Mr.: Mister
MS: Mean Score
n: Number
N: Number
No: Number
NDRC: National Development and Reform Commission
NGO: Non Governmental Organisation
No.: Number
NSW: New South Wales
O&M: Operation and Maintenance
OM&M: Operate Maintain and Manage
PFI: Private Finance Initiative
PPP: Public Private Partnerships
R : Average of the ranks assigned across all factors
iR : Average of the ranks assigned to the ith factor
RMB: Renminbi
List of Abbreviations
xxix
s: Score given to each factor by the respondents
SETP: Southbank Education and Training Precinct
SPSS: Statistical Package for Social Science
TAFE: Technical and Further Education
U.K.: United Kingdom
VFM: Value for Money
W: Kendall’s Coefficient of Concordance
WHC: Western Harbour Crossing
WKCD: West Kowloon Cultural District
Statement of Original Authorship
xxx
STATEMENT OF ORIGINAL AUTHORSHIP
The work contained in this thesis has not been previously submitted to meet requirements
for an award at this or any other higher education institution. To the best of my
knowledge and belief, the thesis contains no material previously published or written by
another person except where due reference is made.
Signature:
Date: 23 March 2009
Acknowledgements
xxxi
ACKNOWLEDGEMENTS
I would like to take this opportunity to thank those who have supported me throughout
the course of my studies and contributed towards this thesis. Without them this thesis
would definitely not have been possible.
I would sincerely like to thank my PhD associate supervisor Professor Albert P.C. Chan.
Being an overseas student the majority of my time has been spent working under his
patient, professional and knowledgeable guidance. Not only has he taught me the skills
of becoming a researcher, he has also enlightened the world of research and consolidated
my decision to pursue a future career in this field.
I would also like to thank my PhD principal supervisor Professor Stephen Kajewski.
Stephen has always communicated with me regularly and responded to my needs
promptly. His advice and guidance has been vital towards completing this thesis.
I would also like to take this opportunity to thank my family for their continuous support
in whatever decisions I make in life.
Acknowledgements
xxxii
Sincere thanks goes to Dr. Bing Li and Professor Akintola Akintoye for permitting to
adapt their survey questionnaire template. Special gratitude is also extended to those
industrial practitioners from both Hong Kong and Australia, who have kindly participated
in the interviews and questionnaire survey of this study.
Finally, this study would not have been possible without the financial support from the
Research Grants Council of the Hong Kong Special Administrative Region, China (RGC
Project No. PolyU 5114/05E), and the QUT International Doctoral Scholarship offered by
Queensland University of Technology. Their financial support has allowed me to
concentrate solely on my research work.
Chapter 1 Introduction
1
CHAPTER 1
INTRODUCTION
1.1 Background
1.2 Research Aim and Objectives
1.3 Research Methodology
1.4 Structure of the Thesis
1.5 Research Significance and Value
1.6 Chapter 1 Summary
Chapter 1 Introduction
2
1.1 Background
The success of implementing Public Private Partnership (PPP) projects in places such as
Western Europe, the United States and Australia has been an attractive alternative for
procuring public works projects instead of the usual traditional methods. With benefits
such as risk transfer, increased efficiency and innovation, and private financing
governments around the world are keen to encourage PPP projects.
Hong Kong is not completely new to the PPP idea. Back in the late sixties several Build
Operate Transfer (BOT) projects were conducted. These were mainly transportation type
projects. Unfortunately, not all of these were equally successful hence the
implementation of PPP projects have decelerated since. Another reason for the slow
adoption of PPP is that the Hong Kong Special Administration Region (HKSAR)
government has been able to enjoy a budget surplus for many years running. Hence,
providing for their own public projects has not been a problem. In other jurisdictions that
first adopted PPP, often their motives have been finance driven. But with the matured
development seen across the world and the in-depth research conducted, the other
advantages of PPP are even more obvious. The public sector is also aware that in many
cases they cannot deliver projects as efficiently and effectively as the private sector. The
private sector is able to introduce efficiency, skills, innovation, technology, motivation,
finance and most importantly a share of the project risks. On the other hand, the public
sector is best dealing with administrative matters. Similarly, the private sector is also
interested in public works projects as they tend to be large. And as business persons they
Chapter 1 Introduction
3
are keen to become players within this circle.
Unfortunately, a string of recent projects in Hong Kong linked with PPP have received
much opposition. Debates have been going on for many years for certain projects to
whether they should be procured by the PPP model. In other cases, projects have been
heavily criticised for over benefiting the private consortium. Some cases have even
changed from originally being procured by PPP to opting for more traditional methods.
These obstacles have heavily discouraged both the public and private sectors from
considering the PPP model. Although so, the Efficiency Unit of the HKSAR has been
continuously working on PPP related research. Some of the local government
departments have also continued to use different forms of PPP such as Design Build
Operate (DBO). Obviously this shows that there are still many in Hong Kong who has
faith in the PPP model.
Although Hong Kong has not rejected PPP, undoubtedly the local practitioners lack
knowledge on how to procure PPP projects hence they have become reluctant to do so.
Therefore, a best practice framework should be put in place. Being aware of this need,
this research has looked into developing such a framework for PPP projects in Hong
Kong. The derived framework combines international and local experience in order to
appropriately fit in with the local culture, practice and unique features, as well as
incorporate the lessons learnt from overseas. This framework acts as a guideline for the
user, enabling them to build on the existing PPP process adopted in Hong Kong. Both the
public and private sectors can adopt this framework. The users are provided clear
Chapter 1 Introduction
4
instructions to what they should and should not be doing within the PPP process.
Currently, no such framework exists and this development is believed to benefit the
construction industry at large, as well as introduce new opportunities.
1.2 Research Aim and Objectives
1.2.1 Aim
This research study aims to develop a best practice framework for implementing PPP in
Hong Kong by looking at international experience.
1.2.2 Objectives
In order to achieve the aim the following objectives were identified for this research:
(a) Identify the benefits, difficulties and critical success factors of PPP.
(b) Measure the effectiveness of PPP against other procurement methods.
(c) Identify representative case studies from other countries for analysis to identify
their approach to success/failure.
(d) Identify previous projects in Hong Kong that utilised a similar approach to PPP
and to analyse their implementation successfulness.
Chapter 1 Introduction
5
(e) Investigate the best conditions in terms of project nature, project complexity,
project types and project scales under which the use of PPP is the most
appropriate.
(f) Evaluate the findings collected to determine a best practice framework for
implementing PPP in Hong Kong.
1.3 Research Methodology
Figure 1.1 shows a flow diagram of the research process that was adopted for this study.
The research consisted of mainly four stages. The first stage focused on the identification
of research objectives, design of research methodology and gaining background
knowledge on the topic. These activities were achieved by conducting a comprehensive
literature review, holding informal discussions with experts and running brainstorming
sessions with supervisors and colleagues. The second stage focused on the data
acquisition. This stage was conducted by the collection of case study information,
interviews with experts and an empirical questionnaire survey. The third stage was the
data interpretation and analysis phase. This was achieved by a selection of methods such
as comparative analysis, content analysis, statistical analysis and triangulation of the
results. The final stage presented the conclusions and recommendations. These were
achieved by drawing conclusions from the analysed data, deriving recommendations for
the research scope and also suggesting recommendations for future research.
Chapter 1 Introduction
6
Figure 1.1 Flow diagram of research process
Research Stages Methodology Adopted
Stage 1 Identification of research
objectives Design of research
methodology Background knowledge
Comprehensive literature review
Informal discussions with experts
Brainstorming sessions with supervisors and colleagues
Collection of case study information
Interviews with experts Empirical questionnaire
survey
Stage 2 Data acquisition
Comparative analysis Content analysis Statistical analysis Triangulation of results
Stage 3 Data Interpretation and
analysis
Draw conclusions Derive recommendations for
research scope Validation Suggest recommendations for
future research
Stage 4 Conclusions Recommendations
Chapter 1 Introduction
7
1.4 Structure of the Thesis
The structure of this research report is as follows:
Chapter 1 gives the introduction of the research study. It covers the background,
research aim and objectives, scope and significance of the research. The research
approach and the structure of the research report are also outlined.
Chapter 2 presents the methodology of this research study. The chapter explains the
research design, process and data analysis techniques used.
Chapter 3 provides an insight into the existing literature of the research topic. The
literature studies the traditional practice of procuring public works projects and also
looks into the option of using PPP. Specific features of PPP have also been covered
including the attractive factors, the negative factors, the value for money measures
and the factors leading to success.
Chapter 4 studies the BOT and PPP experience in Hong Kong. BOT is a more
common form of PPP adopted in Hong Kong. Several cases from different eras are
analysed to observe the development of PPP in Hong Kong. Lastly this chapter
considers whether BOT/PPP is the best financing model for conducting public
infrastructure in Hong Kong.
Chapter 1 Introduction
8
Chapter 5 studies Australia’s experience in conducting PPP projects by looking at
the problems encountered in two highly profiled cases. Lessons learnt from these
cases were derived.
Chapter 6 presents the findings from interviews conducted in both Hong Kong and
Australia with PPP experts. The chapter considers the views of these experts from
three different perspectives: the public sector’s angle, the private sector’s angle and
the researcher’s angle. Each perspective has been analysed for commonalities and
unique features between the two jurisdictions.
Chapter 7 looks at the suitability of procuring large public works by PPP from the
findings of a questionnaire survey conducted in both Hong Kong and Australia. The
attractive and negative factors for adopting PPP have been analysed to help provide
solutions on whether the PPP model is more ideal than traditional methods.
Chapter 8 continues to present the findings of the same questionnaire survey. This
chapter specifically considers the reasons for implementing PPP projects, the factors
contributing to successful PPP projects and the ways to enhance value for money in
PPP projects. Again the findings present a comparative analysis for the two survey
jurisdictions.
Chapter 9 presents a best practice framework for implementing PPP in Hong Kong.
The framework is presented according to the project steps as defined by local
Chapter 1 Introduction
9
governmental guidelines. The results obtained in this study are drawn together to
illustrate how each stage can be carried out more efficiently. As a result both the
public and private sectors can better conduct future PPP projects by referring to this
framework. Also, the findings from the validation process are presented.
Chapter 10 concludes this research study. A review of the research objectives, a
presentation of the major findings, the limitations have been highlighted and finally
potential future research areas have been suggested.
1.5 Research Significance and Value
The Hong Kong Special Administrative Region (HKSAR) government has realised the
benefits of using PPP in Hong Kong as well as the success achieved overseas. But a
more thorough research is needed to develop the most suitable practice of PPP in terms of
project nature, project complexity, project type and project scale under which PPP is most
appropriate for Hong Kong. The lessons learnt from other countries are also useful.
Hence this study has opted to consider the experience of PPP in Australia: one of the
leading countries in implementing this model. From their experiences and a study of the
local situation in Hong Kong a best practice framework has been developed. The
findings of this study are believed to be valuable to the government and construction
industry at large. The opportunities for infrastructure development in Hong Kong will be
broadened. In addition this project also forms a comparative study for the use of PPP in
Australia and Hong Kong.
Chapter 1 Introduction
10
1.6 Chapter 1 Summary
This chapter outlines the framework of this research study by considering the background,
research aim and objectives, research methodology, and research significance and value.
The structure of the thesis has also been introduced.
Chapter 2 Research Methodology
11
CHAPTER 2
RESEARCH METHODLOGY
2.1 Chapter 2 Introduction
2.2 Research Design
2.3 Research Process
2.4 Data Analysis Techniques
2.5 Chapter 2 Summary
Chapter 2 Research Methodology
12
2.1 Chapter 2 Introduction
This chapter describes the research methodology used to achieve the study objectives.
Data was collected utilising a combination of different methods. And both qualitative
and quantitative techniques were used to analyse the data.
2.2 Research Design
Construction management research is commonly carried out using four standard methods,
these include: (1) Literature review; (2) Case study; (3) Interview; and (4) Questionnaire
survey (Chow, 2005). Therefore this research study combines these methods to collect
information and data on Public Private Partnership (PPP) both locally and internationally.
The techniques and design of the data collection process were arranged so that the
research objectives would be achieved (as described in later sections of this chapter). The
research data and analyses were triangulated from multiple sources to help improve the
credibility of the findings. And finally the results contributed to the development of a
best practice framework for PPP projects in Hong Kong.
Chapter 2 Research Methodology
13
2.3 Research Process
2.3.1 Background study
Literature on the current practice of PPP both locally and internationally were extensively
reviewed via books, journals, magazines, newsletters, conference proceedings,
workshops, seminars and other sources. Past and current practices of PPP were
documented. The review exercise also included the development of an instrument to
conduct the interviews and questionnaires. The information collected from these
interviews and questionnaires were fully documented individually but analysed
collectively to firstly verify the literature study conducted and secondly achieve the
proposed research objectives. In addition as a result of the literature review appropriate
case studies were identified for analyses.
2.3.2 Project experience
From the literature review representative case studies were selected. The selected cases
included ones with unique features such as having particular success or failure. These
cases consist of ones both locally and internationally. The findings from the case studies
enable us to verify and triangulate the findings from the other sources of data collection
used in this study.
This part of the data collection mainly aimed to collect information for the objectives
Chapter 2 Research Methodology
14
“Identify representative case studies from other countries for analysis to identify their
approach to success/failure” and “Identify previous projects in Hong Kong that utilised a
similar approach to PPP and to analyse their implementation successfulness”. Through
this process some of the other objectives were also achieved including: “Identify the
benefits, difficulties and critical success factors of PPP”; “Investigate the best conditions
in terms of project nature, project complexity, project types and project scales under
which the use of PPP is the most appropriate”; and “Evaluate the findings collected to
determine a best practice framework for implementing PPP in Hong Kong”.
In addition, a comparison of the experiences was performed to identify whether the PPP
approach is appropriate to be used in Hong Kong. Also, the best way to avoid risks and
maximise the benefits of PPP was studied.
2.3.3 Extraction of expert knowledge
The interviews which were carried out in this research study adopted the “Grounded
Theory” approach. This approach is an iterative process by which the analyst becomes
more and more “grounded” in the data and develops increasingly richer concepts and
models of how the phenomenon being studied really works (Denzin and Lincoln, 2005).
This approach involves the interviewer to collect word for word transcripts from the
interviewees. These transcripts can then be further analysed by identifying themes which
are common and meaningful by an “open coding” technique. Therefore the findings will
be solely based on the responses given by the interviewees.
Chapter 2 Research Methodology
15
Dainty et al. (2000) also adopted the Grounded Theory approach for construction
management research. In their methodology they collected unstructured data and coded
meaning information. This method allows the researcher to relate categories in complex
ways and ensuring density and precision to the developed theory. They also believed that
too much structuring would mean that the interviewees’ responses would be defined by
the researcher. Hence, they used a semi-structured interview format. Their aim was not
to promote consistency in terms of response, but to uncover as many relevant responses
as possible. Consistencies would therefore emerge from the subsequent Grounded
Theory analysis.
Raiden et al. (2008) agreed that structured questions would not allow interviewees to
fully expand on their knowledge. This does not mean that the theory from literature
should not be tested but its generalization should be tested with a population first.
Based on these concepts, interviews were conducted with experts from the public sector,
private sector and with researchers. The experts were selected based on two main criteria,
these included:
1) The experts must possess adequate knowledge in the area of PPP; and
2) The experts have hands-on experience with PPP projects, experience in conducting
PPP research or have followed very closely with the development of PPP.
Chapter 2 Research Methodology
16
2.3.3.1 Interviews with the public sector
Based on the Grounded Theory approach, six interview questions linking up to the
project objectives were derived for the interviews with the public sector interviewees
(please refer to Chapter 1 for the project objectives). Table 2.1 shows how these
objectives are linked to the interview questions. In the first question the interviewees
were asked “Have you conducted any research looking at local case studies?” This
question aimed to collect information for objectives 3 – 6. Question 2 “How would you
compare PPP with traditional procurement methods?” targeted to achieve objectives 2,
4 – 6. Objectives 5 and 6 were covered again in Question 3 “Which type of project do
you feel is best suited to use PPP?” and Question 4 “What do you feel are the key
performance indicators in a PPP project?” In Question 5, interviewees were asked to
answer “In general, what do you think are the critical success factors leading to
successful PPP projects?” This question sought information for objectives 1, and 6. The
final question was “Does your organisation have any in-house guidance/practice notes?”
This question aimed to collect information for objectives 1, 5 – 6.
Chapter 2 Research Methodology
17
Table 2.1 Project objectives linking up with interview questions for public sector interviewees
Question Objective 1 2 3 4 5 6
Identify the benefits,
difficulties and critical
success factors of
PPP
Measure the effectiveness
of PPP against other procurement
methods
Identify representative case studies from other
countries for analysis to
identify their approach to
success/failure
Identify previous
projects in Hong Kong
that utilised a similar
approach to PPP and to
analyse their implementation successfulness
Investigate the best
conditions in terms of project nature, project
complexity, project types and project scales under
which the use of PPP is the
most appropriate
Evaluate the findings
collected to determine a best practice framework
for implementing PPP in Hong
Kong
1. Have you conducted any research looking at local case studies?
2. How would you compare PPP with traditional procurement methods?
3. Which type of project do you feel is best suited to use PPP?
4. What do you feel are the key performance indicators in a PPP project?
5. In general, what do you think are the critical success factors leading to successful PPP projects?
6. Does your organisation have any in-house guidance/practice notes?
Chapter 2 Research Methodology
18
2.3.3.2 Interviews with the private sector
Eight interview questions linking up to the project objectives were derived. Table 2.2
shows how these objectives are linked to the interview questions. In the first question the
interviewees were asked “Which PPP projects have your company been involved in?”
This question aimed to collect information for objectives 3 – 6. Question 2 “Please
describe the implementation process in these projects.” targeted to achieve objectives 3, 4
and 6. Objectives 1, 2, 5 and 6 were covered in Question 3 “What were the major reasons
for adopting PPP in these projects?” Question 4 “How do you think PPP compares with
traditional procurement methods?” and Question 5 “Which type of project would your
company be most interested in applying PPP?” collected information for objectives 2, 5
and 6. Question 6 “What do you feel are the key performance indicators in a PPP
project?” sought information for objectives 5 and 6 only. Question 7 “In general, what do
you think are the factors leading to successful PPP projects?” collected information for
objectives 1, 5 and 6. The final question was “Does your company have any in-house
guidance/practice notes on PPP implementation?” This question aimed to collect
information for objectives 5 and 6 only.
Chapter 2 Research Methodology
19
Table 2.2 Project objectives linking up with interview questions for private sector interviewees
Question Objective 1 2 3 4 5 6
Identify the benefits,
difficulties and critical
success factors of
PPP
Measure the effectiveness
of PPP against other procurement
methods
Identify representative case studies from other
countries for analysis to
identify their approach to
success/failure
Identify previous
projects in Hong Kong
that utilised a similar
approach to PPP and to
analyse their implementation successfulness
Investigate the best
conditions in terms of project nature, project
complexity, project types and project scales under which the
use of PPP is the most
appropriate
Evaluate the findings
collected to determine a best practice framework
for implementing PPP in Hong
Kong
1. Which PPP projects has your company been involved in?
2. Please describe the implementation process in these projects.
3. What were the major reasons for adopting PPP in these projects?
4. How do you think PPP compares with traditional procurement methods?
Chapter 2 Research Methodology
20
5. Which type of project would your company be most interested in applying PPP?
6. What do you feel are the key performance indicators in a PPP project?
7. In general, what do you think are the factors leading to successful PPP projects?
8. Does your company have any in-house guidance/practice notes on PPP implementation?
Chapter 2 Research Methodology
21
2.3.3.3 Interviews with researchers
Five interview questions linking up to the project objectives were derived. Table 2.3
shows how these objectives are linked to the interview questions. In the first question the
interviewees were asked “Have you conducted any research looking at local case
studies?” This question aimed to collect information for objectives 3 – 6. Question 2
“How would you compare PPP with traditional procurement methods?” targeted to
achieve objectives 2, 4 – 6. Objectives 5- 6 were covered again in Question 3 “Which
type of project do you feel is best suited to use PPP?” and Question 4 “What do you feel
are the key performance indicators in a PPP project?” In Question 5, interviewees were
asked to answer “In general, what do you think are the critical success factors leading to
successful PPP projects?” This question sought information for objectives 1, and 6.
Chapter 2 Research Methodology
22
Table 2.3 Project objectives linking up with interview questions for researcher interviewees
Question Objective 1 2 3 4 5 6
Identify the benefits,
difficulties and critical
success factors of
PPP
Measure the effectiveness
of PPP against other procurement
methods
Identify representative case studies from other
countries for analysis to
identify their approach to
success/failure
Identify previous
projects in Hong Kong
that utilised a similar
approach to PPP and to
analyse their implementation successfulness
Investigate the best
conditions in terms of project nature, project
complexity, project types and project scales under which the
use of PPP is the most
appropriate
Evaluate the findings
collected to determine a best practice framework
for implementing PPP in Hong
Kong
1. Have you conducted any research looking at local case studies?
2. How would you compare PPP with traditional procurement methods?
3. Which type of project do you feel is best suited to use PPP?
4. What do you feel are the key performance indicators in a PPP project?
5. In general, what do you think are the critical success factors leading to successful PPP projects?
Chapter 2 Research Methodology
23
2.3.4 Large scale data collection
Questionnaire survey is an effective method to seek a large sample size for quantitative
data analysis. Representative practitioners with in-depth experience in PPP were targeted.
The selection criteria for suitable respondents were similar to those for the interviewees
mentioned in Section 2.3.3 “Extraction of expert knowledge”. The questionnaire aimed
to achieve several key features of PPP projects including: the attractive and negative
factors, reasons for implementation, value for money measures and also factors
contributing to success (please refer to Appendix 1 for questionnaire template). Using the
questionnaire survey the following objectives were achieved: “Identify the benefits,
difficulties and critical success factors of PPP”; “Investigate the best conditions in terms
of project nature, project complexity, project types and project scales under which the use
of PPP is the most appropriate”; and “Evaluate the findings collected to determine a best
practice framework for implementing PPP in Hong Kong”.
The questionnaire template designed by Li (2003) was adopted for this study. Although a
new research questionnaire could be developed based on the literature and interview
findings, there were several advantages foreseeable to adopt Li’s (2003) survey
questionnaire rather than designing a new template. Firstly, the value of Li’s (2003)
questionnaire has already been recognised by the industry at large. His publications as a
result of the research findings derived from the questionnaire are evidence of its
worthiness. Secondly, there would be no added advantage to reinvent the work that has
previously been done by other researchers. And thirdly by administering Li’s (2003)
Chapter 2 Research Methodology
24
questionnaire in different administrative systems, it would be of interest for comparison
purposes in the future. In addition, Hong Kong is traditionally influenced by the British,
so the construction practice is very close hence no problems in adopting this
questionnaire could be observed. Therefore, Li’s (2003) questionnaire was adopted for
the survey as presented in Chapters 7 and 8 with prior permission obtained from the
author Dr. Bing Li and his doctoral research supervisor, Professor Akintola Akintoye who
is currently the Head of the School of Built and Natural Environment, University of
Central Lancashire, United Kingdom.
2.4 Data Analysis Techniques
2.4.1 Qualitative data analysis
The literature review and case studies were analysed by content analysis. Literature from
different sources were summarised (as shown in Chapter 3). Content analysis is often
used to determine the main facets of a set of data, by simply counting the number of
times an activity occurs (Fellows and Liu, 1997). The initial step in content analysis is
for the researcher to identify the material to be analysed. The next step is to determine
the form of content analysis to be employed: qualitative, quantitative or structural. The
choice is dependent on, if not determined by, the nature of the research project. The
choice of categories will also depend upon the issues to be addressed in the research.
Using this approach the case studies were analysed both individually and collectively.
The process of each case was mapped out, and each stage was analysed and compared.
Chapter 2 Research Methodology
25
The analysis of the case studies drew answers behind successful implementation of PPP
projects and also highlighted the common obstacles and problems which could be
encountered (as shown in Chapters 4 and 5).
2.4.2 Quantitative data analysis
The quantitative data collected was analysed using the Statistical Package for Social
Science (SPSS). The techniques that were used in this research study, in respect of
quantitative analysis include the mean score ranking technique and Kendall’s
concordance analysis.
2.4.2.1 Mean score ranking technique
Chan and Kumaraswamy (1996) adopted the “mean score” method to establish the
relative importance of causes of delay in building construction projects in Hong Kong as
suggested by the clients, consultants and contractors. The data collected from the current
questionnaire survey was also analysed using the same technique, within various groups
being categorised according to the origins of the respondents (i.e. Hong Kong and
Australia). The five-point Likert scale (1 = Least Important and 5 = Most Important) as
described previously was used to calculate the mean score for each factor, which was
then used to determine its relative ranking in descending order of importance. These
rankings made it possible to triangulate the relative importance of the factors to the
respondents from Hong Kong, Australia and the United Kingdom as presented in Li’s
Chapter 2 Research Methodology
26
(2003) survey 2003. The mean score (MS) for each factor was computed by the following
formula:
5)MS(1 , N
s)(fMS ≤≤
×= ∑
Where s = Score given to each factor by the respondents, ranging from 1 to 5 (1 = Least
Important and 5 = Most Important);
f = Frequency of each rating (1-5) for each factor; and
N = Total number of responses concerning that factor.
2.4.2.2 Kendall’s concordance analysis
The survey respondents in this study were based on two groups: Hong Kong and
Australia. Kendall’s concordance analysis was conducted to measure the agreement of
different respondents on their rankings of factors based on mean values within a
particular group. If the Kendall’s coefficient of concordance (W) is significant at a pre-
defined allowable significance level of, say 0.05, a reasonable degree of consensus
amongst the respondents within the group on the rankings of factors was indicated. The
W for the factors was calculated by the following formula (Siegel and Castellan, 1988):
Chapter 2 Research Methodology
27
( )12/)1( 2
1
2
−
−=∑=
nn
RRW
n
ii
Where n = Number of factors being ranked;
iR = Average of the ranks assigned to the ith factor; and
R = Average of the ranks assigned across all factors.
According to Siegel and Castellan (1988), W is only suitable when the number of
attributes is less than or equal to 7. If the number of attributes is greater than 7, chi-
square is used as a near approximation instead. The critical value of chi-square is
obtained by referring to the table of critical values of chi-square distribution, which can
be found in Siegel and Castellan (1988).
2.5 Chapter 2 Summary
This chapter provides a detailed account of the research framework for this study. The
methods used to achieve the research objectives are described. The overall research
design and process were first introduced, followed by the explanation of qualitative and
quantitative data analysis techniques.
Chapter 3 Literature Review
28
CHAPTER 3
LITERATURE REVIEW
3.1 Chapter 3 Introduction
3.2 What is the Traditional Practice of
Procuring Public Works Project?
3.3 Background of PPP
3.4 Attractive Factors of Adopting PPP
3.5 Negative Factors of Adopting PPP
3.6 Value for Money in PPP Projects
3.7 Achieving Successful PPP Projects
3.8 Chapter 3 Summary
Chapter 3 Literature Review
29
3.1 Chapter 3 Introduction
Public Private Partnership (PPP) is a procurement approach where the public and private
sector join forces to deliver a public service or facility. In this arrangement normally both
the public and private sector will contribute their expertise and resources to the project
and share the risks involved. The definition of PPP may differ slightly between different
jurisdictions, depending on which part of the arrangement the importance is focused on.
For example, PPP is defined by the Efficiency Unit of the Hong Kong Special
Administrative Region (HKSAR) government as any agreement where the public and
private sectors work together to deliver a public project:
“Arrangements where the public and private sectors both bring their complementary
skills to a project, with varying levels of involvement and responsibility, for the purpose
of providing public services or projects.” (Efficiency Unit 2008a)
Whereas, according to the New South Wales Government the term PPP is used to mean:
“An arrangement for the provision of assets or services, often in combination and usually
for a substantial or complex ‘package’, in which both private sector supplier and public
sector client share the significant risks in provision and/or operation.”
(Infrastructure Implementation Group, 2005)
Chapter 3 Literature Review
30
In this definition there is an emphasis that both the public and private parties share a large
proportion of the risks in a PPP project. In reality it is not always that an equal split of
risks is experienced. Naturally, each party will want to pass on more risks to the other
party. It is noticed that this occurrence is more common in developing countries or
jurisdictions where the government has less experience in this alternative procurement
method. The New South Wales (NSW) government further describes the importance in
the financing of PPP projects and how passing on financial risks is appealing to
governments:
“Privately financed projects involve provision by investors of equity capital and debt
capital to fund what might otherwise be wholly publicly funded projects financed from
NSW Government borrowings and/or budget revenue.”
(Infrastructure Implementation Group, 2005)
Chapter 3 Literature Review
31
3.2 What is the Traditional Practice of Procuring Public Works
Project?
3.2.1 Progression from traditional to PPP
According to a technical circular prepared by the Environment, Transport and Works
Bureau (2004) of the HKSAR government, in a typical public works project the selection
process will consist of three stages (Figure 3.1). In the first stage the generic
procurement category will be selected. In the second stage a sub-category will be
selected. And in the third and final stage the major areas requiring improvement in
performance will be identified. Also, the optimal project delivery techniques to address
these identified improvement areas will be selected. In an ideal case a project manager
from the government will be assigned to follow up the selection process as early as
possible.
Chapter 3 Literature Review
32
Figure 3.1 Procurement selection process for typical public works project in Hong
Kong (adapted from Environment, Transport and Works Bureau, 2004)
Four generic procurement categories are identified (Figure 3.2). These include: I -
Designer Led; II – Design and Construct; III – Design, Construct and Operate; and IV –
Finance Design Construct and Operate. The four categories show different levels of
private sector participation. The first category is where the private sector has the least
involvement, whereas the fourth category shows the private sector having the most
involvement. The most extreme form of these categories is category IV. In this category
the private sector’s involvement is the maximum. This model can be regarded as
equivalent to the PPP arrangement. Typically PPP projects have a strong emphasis on the
private financing aspect. Also, the private consortium is required to maintain and operate
the product/facility for an agreed concession period. For the other procurement
categories identified these could be regarded as the traditional approaches for delivering
public works projects in Hong Kong.
Stage 1
Select generic procurement category
Stage 2
Select sub-category
Stage 3
Select optimal project delivery technique
Chapter 3 Literature Review
33
Under each procurement category, there are also a number of sub-categories. Under the
first category “Designer Led” the sub-categories include:
Lump Sum Contract (with bills of quantities or with drawings and
specifications);
Remeasurement Contract;
Term Contract; and
Prime Cost Contract.
The second category “Design and Construct” includes the sub-categories:
Employer’s Designer Novated;
Independent Designers; and
Contract Designer.
The third category “Design, Construct and Operate” includes the sub-categories:
Design Build Operate (DBO); and
Prime Contracting.
And the final category “Finance, Design, Construct and Operate” includes the sub-
categories:
Private Finance Initiative (PFI);
PPP; and
Build Operate Transfer (BOT).
Chapter 3 Literature Review
34
Figure 3.2 The generic procurement categories with their respective sub-categories
for public works projects in Hong Kong (adapted from Environment,
Transport and Works Bureau, 2004)
Category I Designer Led
Lump Sum Contract (with bills of quantities or
with drawings and specifications)
Remeasurement Contract
Term Contract
Prime Cost Contract
Category II Design and Construct
Employer’s Designer Novated
Independent Designers
Contract Designer
Category III Design, Construct and Operate
Design Build Operate (DBO)
Prime Contracting
Category IV Finance, Design, Construct and Operate
Private Finance Initiative (PFI)
PPP
Build Operate Transfer (BOT)
Lev
el o
f par
ticip
atio
n
Public sector
Private sector
Chapter 3 Literature Review
35
In the third and final stage of the project selection process the delivery technique is
identified. These have been broadly categorised into six groups that include:
Non-contractual Project Delivery Techniques – Partnering;
Contractual Project Delivery Techniques - Guaranteed Maximum Price, Target
Cost, Construction Management, Incentivisation, Revenue Sharing and
Contractor Designed Portions;
Project Design Improvement Techniques – Life Cycle Costing, Environmental
Assessments and Buildability Rating System;
Supplier/Contractor Management - Supply Chain Management, Supplier
Benchmarking and Performance Assessment Scheme;
Techniques for General Application - Value Management and Risk
Management; and
Dispute Resolution Mechanisms - Dispute Resolution Advisor, Dispute
Resolution Panel, Expert Determination, Mediation, Adjudication, Local
Arbitration and International Arbitration.
Chapter 3 Literature Review
36
3.2.2 Traditional vs PPP
The Efficiency Unit (2008b) of the HKSAR government conducted a thorough
comparison to look at the differences between procuring public works projects in Hong
Kong traditionally and by PPP (Figure 3.3).
In both approaches the client department takes the lead. Traditionally the client
department will request the relevant works department to design their desired facility.
Via the PPP approach the client department would define their desired facility in terms of
the service required. Next, for both approaches the client department together with
external experts would form a group to monitor the project.
In the traditional approach, after planning and approvals are obtained, the works
department would call for tenders from private contractors to construct or to design and
build the facility. On the other hand, in a PPP approach the client group would prepare an
output-based performance specification to request proposals for a private sector
consortium to design, build, finance, operate and maintain the facility for a specified
period.
For both approaches the client department would then conduct a consultation with the
general public and Legislative Council Panels before obtaining financial endorsement.
The successful bidder in a traditional approach would be the one that satisfies the
minimum requirements specified by the client department with respect to quality of
Chapter 3 Literature Review
37
service or product, and also scores the highest mark in the tender evaluation which
weighs both the technical and cost aspects. In a PPP approach, the successful consortium
bidder would be the one that satisfies the mandatory requirements specified with respect
to the ability of the facility to deliver the service required, the quality of design,
construction and operation and on terms which provide best value for money.
Once the contract has been awarded the works department would monitor the
construction process under a traditional approach. In a PPP approach, the client
department advisors would deal solely with the consortium only. The consortium would
also manage the specialist contractors involved.
After completion of a traditional project the works department would inspect the works,
and upon satisfaction payment would be made to the contractor. On the other hand, in a
PPP approach the client department or a third party would verify the facility to be fit for
the purpose before payment is made to the consortium.
Chapter 3 Literature Review
38
Figure 3.3 Differences in procurement between the traditional and PPP approaches of
conducting public works projects in Hong Kong (adapted from Efficiency Unit, 2008b)
Traditional approach PPP approach
Client department requests works department to design
Client department defines facility in terms of service required
Client department and external experts form group to monitor project
Client department and external experts form group to monitor project
After planning and approvals are obtained, works department would call for tenders
from private contractors to construct or to design and build
The group would prepare output-based performance specification to request
proposals for a private sector consortium to design, build, finance, operate and maintain the facility for a specified
period
Client department would conduct consultation with general public and
Legislative Council Panels before obtaining financial endorsement
Client department would conduct consultation with general public and
Legislative Council Panels before obtaining financial endorsement
Successful bidder would be the one that satisfies the minimum requirements
specified by the client department with respect to quality of service or product and
scores the highest mark in the tender evaluation which weighs both the
technical and cost aspects
Successful consortium bidder would be the one that satisfies the mandatory
requirements specified with respect to the ability of the facility to deliver the service required, the quality of design,
construction and operation and on terms which provide best value for money
Works department monitors construction process
Client department advisors deal solely with consortium. Consortium will manage the specialist contractors
After completion works department would inspect the works, upon satisfaction
payment will be made to the contractor
Client department or third party would verify the facility to be fit for the purpose
before payment to the consortium
Chapter 3 Literature Review
39
3.3 Background of PPP
3.3.1 Background
PPP projects can be dated as far back as the 1600s during the railway construction boom
in the United Kingdom (Grimsey and Lewis, 2004). PPP is a relatively modern term for
this arrangement used only more commonly in the last decade. Previously different
variations of the arrangement included Private Finance Initiative (PFI), which is a more
familiar term to many people due to its popular development in the United Kingdom
during the early nineties (Tieman, 2003).
It would not be incorrect to say that the PFI practice developed in the United Kingdom
raised the world’s attention to this alternative option for delivering public infrastructure
and services. PPP projects now account for about 15 and 8 percent of infrastructure spent
in the United Kingdom and Australia respectively (Ernst and Young, 2005). Up to 2006,
794 PPP/PFI deals had already been signed. The combined capital value was
approximately £55 billion (National Audit Office, 2008). Amongst these projects almost
70% were in the health sector, and over 40% costing below £10 million (Akintoye, 2007).
However, Maltby (2003) asserted that PPP/PFI should be abolished for smaller projects
and for information technology schemes.
Partnership UK was set up in 2000 to succeed the Treasury Taskforce. The Taskforce
was set up in 1997 to oversee the implementation of PPP/PFI projects. One observation
Chapter 3 Literature Review
40
is that Partnerships UK was initiated by the local Treasury. The team is generally
responsible for providing project advice and support, developing government policies,
providing co-sponsorship and participating in investment of PPP/PFI projects.
Due to the long history of PPP/PFI projects in the United Kingdom, Partnerships UK has
a very comprehensive collection of guidelines and policies on implementing PPP projects
for all sectors in many aspects. Case study reports can also be found on the public
domain. Amongst the projects conducted by Partnerships UK it was noticed that the
majority included projects for schools, hospitals and transportation. Other projects which
have also been conducted include environment ones, leisure facilities, prisons and
detention centers, housing etc. (Partnerships UK, 2008). The extent to which PFI could
be used and the advantages created were the main drivers attracting other countries to
start adopting or improve their practice in PPP.
A more specific term used more commonly decades ago in Hong Kong is Build Operate
and Transfer (BOT). This arrangement was commonly adopted for transportation
projects. This is because transportation projects tend to be larger in size and also because
their long physical lives fit well into the procurement model. Early types of public
infrastructure projects that involved the private sector include the turnpikes built in the
United Kingdom and The United States, and also the water facilities that the French
delivered through the concession approach (Grimsey and Lewis, 2004). Although water
projects tend not to be particularly large in project sum, it was noticed early on the
advantages of introducing private expertise to deal with tasks that the public sector was
Chapter 3 Literature Review
41
probably not as efficient or experienced in carrying out the works. On the other hand,
PPP also plays a significant role in the infrastructure development of developing
countries. Figure 3.4 presents the annual private investment between 1990 and 2006 in
the public services of developing countries (World Bank, 2008).
Figure 3.4 Annual investment of infrastructure projects with private participation in
developing countries between 1990-2006 (World Bank, 2008)
Chapter 3 Literature Review
42
3.3.2 Types of PPP
There are many types of PPP used around the world. Most of them operate in similar
ways and the name is differed depending on the country it is used in, whereas in some
cases there are major differences to the approach. Some of the commonly mentioned
different types of PPP have been listed as follows.
Design Build Finance Operate (DBFO) – similar to BTO, the government will
retain title of the land and lease it to the private consortium over the life of the
concessionary agreement (Levy 1996).
Operation and Maintenance (O&M) – the private company operates and
maintains a publicly owned asset. This is especially common in Mainland
China as traditionally the majority of assets are state owned. The large number
of state owned facilities and services have meant that the Chinese government
has held a heavy burden, and by adopting PPP this financial commitment can
be released. This type of PPP is sometimes not as favourable compared to ones
that start from scratch. For new projects the benefits of employment are
obvious, but on the other hand for existing facilities and services a consortium
taking over can cause change to the existing employees.
Private Finance Initiative (PFI) – commonly used in the United Kingdom, there
is a large emphasis on private financing.
Build Operate Transfer (BOT) – one of the most traditional types of PPP used
in the early days mainly for transport economic infrastructure projects. This
Chapter 3 Literature Review
43
has also been the traditional option used in Hong Kong. BOT involves the
construction of the facility as well as the operation of it. At the end of the
contract period it will be transferred back into the hands of the government.
Build Own Operate (BOO) – commonly used in Australia at the beginning.
Build Own Operate Transfer (BOOT) - commonly used in Australia at the
beginning. Similar to BOT but a larger emphasis on the ownership.
Build Transfer Operate (BTO) – a method of relieving the consortium of
furnishing high cost insurance required by the project during operation of the
facility (Levy, 1996).
Joint Ventures (JV) – public and private sector jointly finance, own and operate
the facility (Grimsey and Lewis, 2004).
Leasing – where all or a substantial part of all risks associated with funding,
developing and operating the facility are assumed by the private sector, with the
public sector entity taking the facility on lease (Sapte, 1997).
Chapter 3 Literature Review
44
3.3.3 The PPP process
Section 3.2.2 in this chapter has already mentioned the process of conducting PPP
projects in Hong Kong, but this section takes a further look at the process adopted in
general. In a typical PPP project the government will invite private consortia to bid by
submitting a project proposal. The successful bidder will need to design, construct and
manage the facility/service for the agreed concessionary period which is typically 10 to
30 years. Over the concessionary period the private consortium will need to maintain and
operate the facility/service according to the contract terms defined by the government.
Normally certain quality standards or performance targets must be achieved. Part of the
profit made from the project will be used to repay the loan that the consortium took out to
cover the design and construction costs. The remaining proportion becomes their profit,
so obviously it is to their benefit to manage the project well. At the end of the
concessionary period the private consortium will normally hand back the facility/service
into the hands of the government.
In general, the typical processes for delivering PPP projects in New South Wales (NSW)
include five major steps (Figure 3.2): (1) Project identification; (2) Project approval; (3)
Planning assessment; (4) Project delivery; and (5) Project implementation (Infrastructure
Implementation Group, 2005). Before a project is even considered going through the
PPP path it will go through a series of governmental in-house procedures to decide
whether it is a public facility or service that is needed. If decided to be necessary the
project will have to be approved via the Gateway review process and to see which
Chapter 3 Literature Review
45
procurement option it should adopt. Planning assessment via a number of different line
agencies would be necessary. Finally the project will be offered to the market, consortia
will bid for it and the government will select the most suitable candidate after a long
series of negotiations. The project will be designed and constructed over typically 3-5
years. It will then be operated and maintained for a further 25-30 years as the concession
period. Thereafter, the project will normally be returned to the government, completely
ending its life as a PPP project.
Figure 3.5 Typical processes for delivering PPP projects in New South Wales,
Australia (adapted from Infrastructure Implementation Group, 2005)
Project identification and early consideration
Project approval
Planning assessment
Project delivery
Project implementation
Chapter 3 Literature Review
46
3.3.4 The parties involved in a PPP project∗
In a PPP project there are usually four key parties involved: the local government
department / public sector, the consortium / the private sector, the employees of the
project and also the public and end-users of the facility or service.
In traditional PPP projects the government is usually more concerned with transferring
their risks associated with design, construction, management, operation etc. on to the
private sector and satisfying the needs of the general public. On the other hand, the
consortium is usually willing to accept some risk but in return expect a more satisfactory
financial profit. In the traditional practice the government and the consortium are more
self-centered focusing on their own benefits rather than trying to achieve a win-win
scenario. Recent years has shown a change to this practice, the parties are more willing
to share responsibility, communication is increased and the partnership apart from being
based on finance is also concerned with maximising the benefits that can be adopted from
the private sector and bringing in skills and innovations that the public sector do not
possess.
The employees of a PPP project benefit through employment. For this group of people a
successful PPP project often indicates job security. The general public end-users have
been known to have a large effect towards the success of a PPP project. Often it is not
whether a PPP project is finished ahead of time or is making a huge profit that determines
∗ Information contained in this section is according to the author’s own interpretation, analysis and observation of existing theory and cases studies
Chapter 3 Literature Review
47
it to be successful. In many cases it is often its image perceived by the general public
from the media that is its key to success. Public opinion is important hence a successful
PPP project must consider its overall image. For example, a project that needs to cut
down forestry for construction maybe perceived to fail at the beginning due to its lack of
environmental awareness. Therefore a strategic plan must be considered at the start even
before possibly the drawing board.
3.3.5 Research conducted in PPP
With the increasing popularity of adopting PPP projects around the world, research in this
field has also become more important to both researchers and practitioners (Al-Sharif and
Kaka, 2004). A comprehensive literature review of PPP research was previously
conducted by Ke et al. (2008). A total of 148 recent publications from renowned journals
were studied. The findings showed that the researchers from the United Kingdom were
found to be the originators of most PPP papers, followed by the United States, Singapore,
Hong Kong, China, Australia and Germany. It was assumed that construction education,
national economics and mother language were all factors affecting which countries
published more PPP papers.
In academic institutions, Nanyang Technological University in Singapore, The University
of Hong Kong, National University of Singapore, and Glasgow Caledonian University
were all identified as active in pursuing PPP research. It was also found that various
Chapter 3 Literature Review
48
modes of PPP have been applied in different parts of the world, and the diverse concept
of PPP has been publicly accepted instead of the more traditional BOT scheme alone.
PPP topics that were found to be of particular interest to the researchers included “Risk”,
“Procurement” and “Finance”. In which seven more specific categories were derived
from these topics including (a) Investment environment; (b) Procurement; (c) Economics
viability; (d) Financial package; (e) Risk management; (f) Governance issue; and (g)
Integration research. For these research studies, the techniques adopted vary from
qualitative to quantitative analyses, some of which have included more vigorous
techniques / theories in researching.
Chapter 3 Literature Review
49
3.4 Attractive Factors of Adopting PPP
The attractive factors of PPP have been discussed by many previous researchers. This
section looks briefly at some of these. So why are governments across the world
favouring the approach of PPP to provide for their public services and facilities? The
very first PPP projects that opted for this approach were simply to bring in private
investment for public services and facilities. These services and facilities were often
essential for the public but to provide for them using the government’s capital would put
pressure on the government’s financial status. Therefore, it was an ideal situation that the
public had what they want provided for without the government having to pay, and also
business opportunities were widened for the private sector.
As PPP has developed over the years the advantages associated have become more
obvious. Walker and Smith (1995) suggested three main reasons for using the PPP
approach:
In general, the private sector possesses better mobility than the public sector.
For example, the private sector is not only able to save the costs of project in
planning, design, construction and operation, but also avoid the bureaucracy
and to relieve the administrative burden.
The private sector can provide better service to the public sector and establish a
good partnership so that a balanced risk-return structure can be maintained.
The government lacks the ability of raising massive funds for the large-scale
infrastructure projects, but private participation can mitigate the government’s
Chapter 3 Literature Review
50
financial burden.
In addition, Walker et al. (1995) supported that PPP is a win-win solution and a number
of benefits to the general public and government are recognised:
Relief of financial burden;
Relief of administrative burden;
Reduction in size of (inefficient) bureaucracy;
Better services to the public;
Encouragement of growth; and
Government can better focus and fund social issues such as health, education,
pensions and arts.
It is anticipated that there will be more PPP projects due to two main reasons according to
Ghobadian et al. (2004). Firstly, the private sector will get to know the needs of the
public sector client over time. Secondly, the private sector has more to give than the
public sector in terms of skills, technology and knowledge therefore providing better
quality facilities.
Askar and Gab-Allah (2002) summarised eight advantages of PPP in their paper:
The use of private sector financing to provide new sources of capital, thus
reducing public borrowing and improving the host government’s credit rating;
The ability to accelerate the development of projects that would otherwise have
to wait for scarce sovereign resources;
Chapter 3 Literature Review
51
The use of private-sector capital, initiative, and know-how to reduce project
construction costs and schedules and to improve operating efficiency;
The allocation of project risk and burden to the private sector that would
otherwise have to be undertaken by the public sector;
The involvement of private sponsors and experienced commercial lenders,
providing an in-depth review and additional assurance of project feasibility;
Technology transfer, training of local personal, and development of national
capital markets;
In contrast to full privatisation, the government’s retention of strategic control
over the project, which is transferred back at the end of the contractual period;
and
The opportunity to establish a private benchmark to measure the efficiency of
similar public sector projects and thereby offer opportunities for the
enhancement of public management of infrastructure facilities.
Risk transfer is one of the main reasons for adopting the PPP approach. The private
sector is in general more efficient in asset procurement and service delivery and as a
result it is to the government’s advantage to share the associated risks with the private
sector. In line with widely accepted principles, Hong Kong government’s Efficiency Unit
(2003a) advocated that the most ideal situation is to allocate the risk to the party most
able to manage/control that risk. For example, the contractor would take up the
construction risk, the designer would take up the design risk, the government would take
up environmental approval risks, land acquisition risks etc. (Corbett and Smith, 2006;
Chapter 3 Literature Review
52
Chan et al., 2006; Grimsey and Lewis, 2004; Boussabaine, 2007; Akintoye et al., 2003;
Li et al., 2005a; So et al., 2007; Li, 2003; Efficiency Unit, 2003a; Ingall, 1997; New
South Wales Government, 2006; European Commission Directorate, 2003; Efficiency
Unit, 2002; United Nations Economic Commission for Europe, 2004; British Columbia,
1999).
Cost certainty is more easily achieved in PPP projects as financial terms are identified
and included within the contract. Since the private consortium will normally be
responsible for financing, designing, constructing and operating the facility over an
extended period, any cost saving can naturally result in a better chance of securing profit.
Hence they are keen to control their spending tightly (Corbett and Smith, 2006; Chan et
al., 2006; Environment, Transport and Works Bureau, 2004; Boussabaine, 2007).
Innovation is another important advantage that the private sector can bring to public
services. Generally speaking, the public sector may not be as innovative as the private
sector. The private sector on the other hand is continuously searching for new products
and services to increase their competitive edge and to save costs (Chan et al., 2006;
Environment, Transport and Works Bureau, 2004; Akintoye et al., 2003; Li et al., 2005b;
Li, 2003; Efficiency Unit, 2003a; New South Wales Government, 2006; Efficiency Unit,
2002; British Columbia, 1999).
The private sector is made responsible for ensuring that the asset and service delivered
meet pre-agreed quality benchmarks/standards throughout the life of the contract.
Chapter 3 Literature Review
53
Sometimes, the private consortium would only receive payment upon meeting certain
requirements of the project; or it is motivated by the incentive payments to reward the
high quality of service to be provided.
In a PPP project the consortium is also responsible for the long-term maintenance of the
facility/service. The concession period may range from a few years to decades.
Therefore the consortium is keen to design and construct the service/facility to ensure
better maintainability (Chan et al., 2006; Environment, Transport and Works Bureau,
2004; Grimsey and Lewis, 2004; Boussabaine, 2007; So et al., 2007; Li, 2003; Efficiency
Unit, 2003a), at least within the concession period if not beyond.
Public sector projects delivered by the PPP model can often be completed on time and
even with time savings because the consortium would start receiving revenue once the
facilities/services are up and running. Therefore, the project team is keen to complete
design and construct as quickly as possible. Once it starts to accrue revenue it can begin
to pay off the initial costs and build up profits, whereas in a traditionally procured project
there are no extra financial incentives for public servants to deliver projects faster. As a
result, projects can best be proceeded along as scheduled (Environment, Transport and
Works Bureau, 2004; Grimsey and Lewis, 2004; Akintoye et al., 2003; Li, 2003;
Efficiency Unit, 2003a).
Time certainty is found to be more easily achieved in PPP projects. The consortium is
often paid according to milestones of the project schedule and any delay might be subject
Chapter 3 Literature Review
54
to liquidated damages. Therefore the consortium is often motivated to reach these
milestones on time, if not earlier. This is a common behavior observed in the private
sector but it may not be the case in the public sector (Chan et al., 2006).
To the government, PPP frees up fiscal funds for other areas of public service, and
improves cash flow management as high upfront capital expenditure is replaced by
periodic service payments and provides cost certainty in place of uncertain calls for asset
maintenance and replacement. Public sector projects delivered via the private sector
normally involve private sector funding. Consequently, the public funding required for
public services can be reduced and redirected to support sectors of higher priority, e.g.
education, healthcare, community services, etc. (Li et al., 2005b; Efficiency Unit, 2002).
To the private sector participants, PPP provides access to public sector markets. If priced
accurately and costs managed effectively, the projects can provide reasonable profits and
investment returns on a long-term basis. Also, these projects tend to be large and
therefore expertise from many areas is required. Hence co-operation among different
collaborating parties is encouraged (Environment, Transport and Works Bureau, 2004;
Grimsey and Lewis, 2004; Boussabaine, 2007; European Commission Directorate, 2003;
United Nations Economic Commission for Europe, 2004).
Business opportunities are also created, due to the large scope of works that can benefit
different sectors (So et al., 2007; Li, 2003; Efficiency Unit, 2003a; United Nations
Economic Commission for Europe, 2004; British Columbia, 1999).
Chapter 3 Literature Review
55
3.5 Negative Factors of Adopting PPP
Similarly the negative factors for PPP were also reviewed and a summary has been given
in this section. Berg et al. (2002) also summarised some disadvantages of PPP projects:
Lengthy bidding process – from initial phase of public sector assessment to
signing of contract takes up to two years. The process of inviting, preparing,
assessing and refining bids and negotiating contracts is complex and procedural.
High bidding costs – the detailed and lengthy nature of the bidding process
implies increased transaction costs.
Small number of bidders
Cost overruns – considerable scope for cost inflation through the bidding
process.
Excessive risks – not clear to what extent the government can shift risk.
The impact of risks to project objectives in completing a PPP project is usually
significant, and these risks arise from multiple sources including the political, social,
technical, economic and environmental factors, due mainly to the complexity and nature
of the disciplines, public agencies and stakeholders involved. Both the private and public
sectors need to have a better understanding of these risks in order to achieve an equitable
risk allocation and enable the project to generate better outcomes (Chan et al., 2006;
Environment Transport and Works Bureau, 2004; Gunnigan and Eaton, 2006; Koppenjan,
2005; Li, 2003; Merna and Owen, 1998; Mustafa, 1999; Ng and Wong, 2006; Satpathy
and Das, 2007; Xenidis and Angelides, 2005; Zhang, 2001; Zhang and AbouRisk, 2006).
Chapter 3 Literature Review
56
In fact, a fair and reasonable allocation of various risks is vital to PPP success. If risks
are inequitably or wrongly allocated beyond the capacity of the parties concerned, PPP
projects would fail (e.g. demand risk resulting from town planning falling on private
consortium).
PPP projects may fall apart due to failure on the part of the private sector participants. In
contracting out the PPP projects, the government should ensure that the parties in the
private sector consortium are sufficiently competent and financially capable of taking up
the projects. Due to a lack of relevant skills and experience of project partners, PPP
projects are more complex to procure and implement (e.g. London Underground).
One common problem encountered in PPP projects is the high bidding costs, which is
owing to increasing project complexity and protracted procurement process. The private
sector incurs high bidding costs partly due to the consideration of the client’s and their
financiers’ objectives. Lengthy negotiations and especially the cost of professional
services may increase the bidding costs further (Chan et al., 2006; Corbett and Smith,
2006; Environment Transport and Works Bureau, 2004; Li, 2003; Li et al., 2005b;
Mustafa, 1999; Xenidis and Angelides, 2005; Zhang, 2001).
The PPP bidding process is also regarded as lengthy and complicated. For example,
bidders are required to prepare tender proposals attached with a bundle of additional
materials. Such a process may take three to four months. Besides, another several
lengthy negotiations will be required for the formation of the contract. Clearly, setting up
Chapter 3 Literature Review
57
a complicated agreement framework for successful PPP implementation can slow down
the bidding process (Chan et al., 2006; Environment Transport and Works Bureau, 2004;
Grimsey and Lewis, 2004; Li, 2003; Li et al., 2005b; Merna and Owen, 1998; Mustafa,
1999; Zhang, 2001).
One other reason for failure is the stakeholders’ opposition and general public opposition.
Whether the proposed project is consonant with the interest of the public is important as
public opposition can adversely affect the funding for the project from the public sector
(El-Gohary et al., 2006; Grimsey and Lewis, 2004; Zhang and AbouRisk, 2006). PPP in
public projects typically incur political and social issues like land resumption, town
planning, employment, heritage and environmental protection. These could result in
public opposition, over-blown costs and delays to the projects.
Another common complaint by the public is the high tariff charged for the services
provided. More often, the private sector would face political uphill in raising tariff to a
level sufficient to cover its costs and earn reasonable profits and returns on investment.
The participation of the private sector to provide public service will undoubtedly bring
innovations and efficiencies in the operation, but may produce a fear of downsizing in the
public sector. To a certain extent, there would be fewer employment opportunities if no
regulatory measures were implemented (Li, 2003; Li et al., 2005b; Zhang and AbouRisk,
2006).
The introduction of PPP exerts unprecedented pressure on the legal framework as it plays
Chapter 3 Literature Review
58
an important role in economic development, regeneration and mechanism for developing
infrastructure. Still, some countries do not have a well established legal framework for
PPP projects and the current legal framework is only supposed to deal with the traditional
command and control model. Although PPP involves a great deal of legal structuring and
documentation to deal with potential disputes amongst PPP parties, a “water-tight” legal
framework is still lacking (e.g. protection of public interests versus legitimate rights of
private sector). Without a well-established legal framework, disputes are inevitable
(Grimsey and Lewis, 2004; Li et al., 2005b; Satpathy and Das, 2007).
Private sector investors bear financial risks in funding of the investment. Seeking
financially strong partners in a PPP project is regarded as difficult. In most PPP
arrangements, the debt is limited-recourse or non-recourse, where financiers need to bear
risks. In fact, most stakeholders are not willing to accept excessive risks. The lack of
mature financial engineering techniques on the part of the host countries can also be
another problem (Grimsey and Lewis, 2004; Zhang, 2001). Unattractive financial market
(e.g. politically unstable or high interest rate) is often a negative factor to PPP success.
Therefore, a conducive financial market is important for the private parties to drive PPP
projects.
Chapter 3 Literature Review
59
3.6 Value for Money in PPP Projects
One of the main reasons that projects are procured by PPP is to enhance Value for Money
(VFM) by inviting the private sector to handle public works projects. As a result there
has been much literature on how VFM in PPP projects can be achieved. This section
reports only a few examples of how VFM can be achieved in PPP projects.
VFM, defined by Grimsey and Lewis (2004) as the optimum combination of whole life
cycle costs, risks, completion time and quality in order to meet public requirements, is
another important consideration when deciding whether to proceed with the PPP option,
especially for the public sector (Chan et al. 2006; Boussabaine 2007; Li et al. 2005b; Li
2003; Efficiency Unit 2003a; Ingall 1997; New South Wales Government 2006;
European Commission Directorate 2003; Efficiency Unit 2002). "Public Sector
Comparator" is the most common tool used by the public sector to show how much it
would cost the Government to build the asset through public funding, which is then used
to compare with how much it would cost to build it as a PPP (Farrah 2007). In the case
of the University College London Hospital Redevelopment in the United Kingdom, the
PPP option cost 6.7% less than the Public Sector Comparator, while maintaining the same
output and user requirements as demanded (Efficiency Unit 2003b).
Cost savings refer to the reduction in price as a result of delivering a project by PPP
instead of traditional methods. The saving could be a result of the private sector’s
innovation and efficiency which the public sector may not be able to achieve (Corbett and
Chapter 3 Literature Review
60
Smith 2006; Environment, Transport and Works Bureau 2004; Grimsey and Lewis 2004;
Akintoye et al. 2003; Li et al. 2005b; So et al. 2007, Li 2003; Efficiency Unit 2003a;
European Commission Directorate 2003; United Nations Economic Commission for
Europe 2004; British Columbia 1999). Private sector generally achieves higher
operational efficiency in asset procurement and service delivery by applying their
expertise, experience, innovative ideas/technology (e.g. using durable materials to reduce
future maintenance cost) and continuous improvements. Overall cost savings to the
project can be achieved by striving for the lowest possible total life cycle costs while
maximising profits.
PPP project arrangements are complex and involve many parties with conflicting
objectives and interests. Hence, PPP projects often require extensive expertise input and
high costs and take lengthy time in deal negotiation. The high transaction costs and
lengthy time may not represent good value to all parties and as a result the deal may not
materialise in the beginning or may falter in the end. PPP projects may incur higher
transaction costs than those under the conventional public sector procurement. The legal
and other advisory fees would be included as lawyers are involved in all stages of a PPP
project, as well as the cost of private sector finance, and the price premium for single
point responsibility arrangement. The potential high transaction costs may have a
negative impact on the objective of securing the best value (Corbett and Smith 2006;
Environment, Transport and Works Bureau 2004; Grimsey and Lewis 2004; Li 2003; Li
et al. 2005b; Merna and Owen 1998; Zhang 2001; Zhang and AbouRisk 2006). Complex
PPP projects require inputs from many parties of different expertise. Therefore, the
Chapter 3 Literature Review
61
projects should be economically viable to cover such costs.
3.7 Achieving Successful PPP Projects
In order to achieve successful PPP projects, some suggestions have previously been
reported in literature. This section reports only a few examples of how successful PPP
projects can be achieved.
Under PPP contracts the government should be concerned that the assets are procured and
services are delivered on-time with good quality and meet the pre-agreed service
benchmarks or requirements throughout the life of the contract. However, the
government should be less concerned with “how” these are achieved and should not
impose undue restrictions and constraints on the private sector participants. The
government should be relegated to the primary role of industry and service regulation;
should be flexible in adopting innovations and new technology; should provide strong
support and make incentive payments to the private sector where appropriate. On the
other hand, the government should retain controls in case of default and be prepared to
step in and re-provide the service if necessary (Abdul-Rashid et al. 2006; Corbett and
Smith 2006; El-Gohary et al. 2006; Jamali 2004; Kanter 1999; Li et al. 2005c; Tam et al.
1994; Tiong 1999; Zhang 2005).
A transparent and efficient procurement process is essential in lowering the transaction
costs and shortening the time in negotiation and completing the deal. Clear project brief
Chapter 3 Literature Review
62
and client requirements should help to achieve these in the bidding process. In most
cases, competitive bidding solely on price may not help to secure a strong private
consortium and obtain value for money for the public. The government should take a
long-term view in seeking the right partner (Corbett and Smith 2006; Gentry and
Fernandez 1997; Jefferies et al. 2002; Jefferies 2006; Li et al. 2005c; Qiao et al. 2001;
Zhang 2005a).
Successful PPP implementation requires a stable political and social environment, which
in turn relies on the stability and capability of the host government (Wong 2007).
Political and social issues that go beyond private sector’s domain should be handled by
the government. If unduly victimised, it is legitimate that the private sector participants
should be adequately compensated. Unstable political and social environments have
resulted in some failed rail projects (e.g. frequent change in government premiers in
Bangkok leading to the cancellation of many new public infrastructure projects originally
procured under the PPP approach (Khang 1998; Cobb 2005)).
Many researchers (Akintoye et al. 2001; Corbett and Smith 2006; Jefferies et al. 2002; Li
et al. 2005c, Zhang 2005a) have found that project financing is a key success factor for
private sector investment in public infrastructure projects. The availability of an efficient
and mature financial market with the benefits of low financing costs and diversified range
of financial products would be an incentive for private sector taking up PPP projects.
Chapter 3 Literature Review
63
3.8 Chapter 3 Summary
This chapter has provided the results of a comprehensive literature review conducted to
provide background knowledge on the research topic. The traditional practice of
procuring public works projects was reviewed to highlight the difference compared to the
PPP method. It was found that there are some clear procedures prepared by the local
government explaining the process of implementing PPP projects. Although the
procedures were explained clearly and illustrated by a step by step process, there are no
exact instructions on how to carry out these activities. Furthermore a comprehensive
review was conducted to study the attractive factors, negative factors, value for money
measures and success factors of PPP. These findings should be further verified with a
population before generalization can be reached.
Chapter 4 Procuring Infrastructure Projects in Hong Kong
64
CHAPTER 4
PROCURING INFRASTRUCTURE
PROJECTS IN HONG KONG
4.1 Chapter 4 Introduction
4.2 BOT/PPP Experience in Hong Kong
4.3 BOT/PPP Case Studies
4.4 Is BOT the Best Financing Model to
Procure Infrastructure Projects?
4.5 Chapter 4 Summary
Chapter 4 Procuring Infrastructure Projects in Hong Kong
65
4.1 Chapter 4 Introduction
Hong Kong has seen a long history of adopting the Build Operate Transfer (BOT)
arrangement for its public works projects. The famous channel tunnel projects have been
amongst some of the earliest projects in the world to adopt this arrangement.
Unfortunately, the development of this procurement arrangement was not continued until
more recently. Overseas experience demonstrating the benefits of PPP has re-initiated
the interest of some local governmental departments, to develop the traditional BOT
arrangement into a more appropriate, refined and internationally recognised successful
approach. This paper examines the development of PPP projects in Hong Kong by
looking at a number of cases which have contributed to this change.
4.2 BOT/PPP Experience in Hong Kong
Hong Kong is not completely new to the idea of PPP. In actual fact the city was probably
one of the first to utilise resources from the private sector. The term PPP may sound
revolutionary to Hong Kong, whereas a more familiar term is BOT. The concept of BOT
has been used since the late sixties. Although Hong Kong has had experience in adopting
quite a number of BOT projects, the approach of PPP has never really been studied
extensively in the local context. The traditional practice of these projects was for the
government to directly award a concession to the potential bidder. This practice of
awarding concessions is common in Hong Kong, but the gestation period spent in
formulating the enabling legislation is lengthy (Zhang 2001).
Chapter 4 Procuring Infrastructure Projects in Hong Kong
66
Hong Kong being the international gateway to China and possibly even Asia represents a
huge business market filled with opportunities and attractions. As a result of the profits
foreseeable Hong Kong has the potential to draw companies from across the world.
Money coming in from outside is beneficial to the local government. The local
government having seen the success stories experienced by others is keen to bring
innovation and efficiency into their public works projects.
In recent years the Efficiency Unit of the Hong Kong Special Administrative Region
(HKSAR) government has been heavily involved in PPP research. The local
government’s interest in utilising PPP is obvious. The approaches that they have taken
mainly involve gaining international experience from particularly Europe and Australia.
One of the early documents produced by the Efficiency Unit on private sector
involvement was a guideline to help governmental bureaus and departments to familiarise
with private sector engagement (Efficiency Unit, 2001). These guidelines were published
in 2001 and showed the government’s interest in adopting the idea of PPP. Only two
years later they also produced a comprehensive introductory guide to PPP (Efficiency
Unit, 2003a). This guide was aimed for the use of the civil servants but is also made
available for the public’s interest to understand the government’s approach. After the
publication of this report much interest was drawn from the construction industry due to
the possibility of the increased business opportunities available.
More recently, the Efficiency Unit published two more guidelines on PPP (Efficiency
Unit, 2007; 2008b). The first of these publications shows how more knowledge on the
Chapter 4 Procuring Infrastructure Projects in Hong Kong
67
issues of PPP have been learnt, it also identifies areas of concern to local practitioners as
well as civil servants, and it tries to provide some insights into these areas. The second
publication is much more specific on how to establish a PPP project. The guideline is
aimed at coaching civil servants on how to conduct a PPP project by looking at the
business case, dealing with the private sector, managing the risks, funding and payment
issues, managing performance etc.
4.3 BOT/PPP Case Studies
4.3.1 Cross Harbour Tunnel (CHT)
In September 1969 the construction for the first BOT project in Hong Kong commenced
(Mak and Mo, 2005). The Cross Harbour Tunnel (CHT) is a two lane tunnel in each
direction (Figure 4.1 shows a photograph of the CHT (Kowloon Motor Bus 30X/230X,
2008)). It took only 36 months to complete and was eleven months ahead of schedule.
The CHT was an instant success when it came in operation in August 1972. It was the
first tunnel linking Hong Kong Island to Kowloon Peninsula. Before the tunnel was
constructed traveling between the two places was by ferry for passengers and vehicles.
There were more reasons for its success, it was well situated in the centre and provided
the shortest route across the harbour of only 1,852 m. More importantly it was
constructed at the right time. During the late sixties and seventies, Hong Kong’s
economy was developing at a high speed, and with good economy the number of vehicles
on the street had also increased dramatically. Within three and a half years of operation
Chapter 4 Procuring Infrastructure Projects in Hong Kong
68
the tunnel had already collected enough tolls to pay back for the construction cost. The
franchise period for the project was thirty years the tunnel was therefore handed back to
the local Government on 31 August 1999. The tunnel is probably the most successful
BOT project in Hong Kong. The tunnel is still one of the most important and profitable
pieces of infrastructure locally.
Figure 4.1 Photograph of the Cross Harbour Tunnel entrance and exit on Kowloon
Peninsula (Kowloon Motor Bus 30X/230X, 2008)
Tam (1999) documented some lessons learnt in Asian projects through a selection of case
studies. From his analysis on the CHT project he concluded that BOT would be a good
solution to overcome the shortage in public money and the lack of technology. The BOT
model allows the government to transfer technical and financial risks to the project
Chapter 4 Procuring Infrastructure Projects in Hong Kong
69
concessionaire. He further suggested that to ensure the commitments from the
government and the concessionaire, the government should hold a stake in the project as
in the CHT case. The result meant that the parties cooperated to limit competing projects
and the construction process was faster.
4.3.2 Western Harbour Crossing (WHC)
The success of the CHT introduced around a dozen more BOT projects in Hong Kong.
Other examples of local BOT projects include the Chemical Waste Treatment Plant on
Tsing Yi Island, the Tate’s Cairn Tunnel, and the Route 3 Country Park Section. But not
all these projects were equally as successful. A typical example is the Western Harbour
Crossing (WHC) opened in 1993 (Figure 4.2 shows a photograph of the WHC (Forum
Sara, 2008)).
This project was the third underwater roadway tunnel to connect Hong Kong Island with
the Kowloon Peninsula. This project was constructed as part of a giant infrastructure
improvement project reaching HK$160 billion in scale, centered on Hong Kong’s new
airport (Nishimatsu, 2006). Under the contract agreement of a 30 year period, the
consortium can adjust the toll depending on the performance of the revenue. If the
revenue is underestimated the toll can be increased to meet targets, on the other hand the
toll can also be lowered if the toll exceeds the expected revenue. When the tunnel came
into operation in April 1997 (Mak and Mo, 2005), Hong Kong was experiencing an
economic downturn which in turn reduced the traffic volume. Another problem was that
Chapter 4 Procuring Infrastructure Projects in Hong Kong
70
the WHC was very expensive to build. It cost approximately HK$7,500 million, which
was over 23 times more than that for the CHT (Li, 2003). Therefore, in order to reach
target revenue the WHC increased the toll causing drivers to use the other two cross
harbour tunnels linking Hong Kong Island to Kowloon (Kwan, 2005).
WHC can therefore be discussed as a less successful project. The project investors have
not made their target revenue, the general public has a negative perception of the project
due to some adverse media reporting and the local government has had to take up critique
from the general public.
Figure 4.2 Photograph of the Western Harbour Crossing entrance and exit on
Kowloon Peninsula (Forum Sara, 2008)
Chapter 4 Procuring Infrastructure Projects in Hong Kong
71
Analysis conducted by Tam (1999) showed that although the WHC was also completed
earlier and effectively managed, the project performance was destroyed by the delay in
toll rise applications. The applications were held up by the elected members of the
Legislative Council of the HKSAR when the government introduced more democracies
into the political system from 1990 onwards. The importance of a well defined toll rise
mechanism was crucial in this case. Political influence was also a major factor towards
the end performance. As a result an arbitration clause and a legal system were
established to resolve the dispute. Another possible factor affecting the difference in
performance between the CHT and the WHC could be due to the lower government stake
in the WHC. As mentioned previously government stake in projects could further ensure
the commitment from all parties.
4.3.3 Asia World Expo (AWE)
A recently completed project is the Asia World Expo (AWE) opened in December 2005
(Figure 4.3 shows an aerial photograph of the exhibition centre (Asia World Expo,
2008a)). The project has been touted as a model PPP scheme by the HKSAR government
(Tam, 2006). Some may consider AWE to even be the first proper PPP project in Hong
Kong. The project was initiated to increase competition in the exhibition sector, and as a
result to make Hong Kong more attractive to the outside world. Therefore, PPP seemed
to be the innovative way to tackle the project. The exhibition centre is located right next
to the Hong Kong International Airport and provides 70,000 square meters of rentable
Chapter 4 Procuring Infrastructure Projects in Hong Kong
72
space, including 10 exhibition halls and meeting rooms. The exhibition hall also claims
to be capable of holding a 13,500 seat entertainment arena (Asia World Expo, 2008b).
Figure 4.3 Photograph of the Asia World Expo (Asia World Expo, 2008a)
An obvious difference between this project and other previous projects delivered by this
approach was that AWE was highly driven by the Financial Secretary’s Office. One of
the problems that Hong Kong has experienced in the development of PPP is the lack of
driving force or champion at senior level of the government. In other countries it has
often been seen that in jurisdictions where PPP have developed well and rapidly are those
where someone in government with authority has been behind the driving force. AWE
has therefore been fortunate enough to have this driving force.
Chapter 4 Procuring Infrastructure Projects in Hong Kong
73
During the collection of case study information an interview was conducted with a
member of the AWE project, who described that:
“An existing convention and exhibition centre in Hong Kong has 62,000 square metres of
usable space and 900 permanent staff recruited. In comparison, the AWE is a lot larger
providing 70,000 square metres of usable space but only recruits 50 permanent staff.
Temporary services are called upon when needed. This shows that AWE is a cost
effective model. In addition, AWE cost HK$2.5 billion to deliver the asset which included
a railway station and the infrastructure. On the other hand, the quasi-public operator of
the existing convention facilities is reacting to the new competition and expanding its
premises, creating 15,000 square metres of additional space at a cost of over HK$1
billion. If the job was left to the concessionaire it would be much cheaper. If AWE was
delivered the traditional way it would have cost a lot more and would have taken a lot
longer. The speed of the project was down to the drive of the people behind it and their
desire to make it happen. By making the operator and contractor stakeholders they
ensure that the cost is kept in track as they do not want to create cost overruns. This
project was delivered without any significant overruns since the private sector has to
bear the excess over the government’s injection. It was the desire of the operator to have
the facility designed to be readily manageable and easily maintained.”
Chapter 4 Procuring Infrastructure Projects in Hong Kong
74
4.3.4 West Kowloon Cultural District (WKCD)
The proposed West Kowloon Cultural District (WKCD) project is located West of Yau
Ma Tei on the Kowloon Peninsula of Hong Kong (Figure 4.4 shows an artist’s
impression of the project (Home Affairs Bureau, 2008)). The project had been long
awaited due to repeated delays and controversies (South Morning China Post, 2008).
Back in April 2001, the HKSAR government invited the private sector to submit
conceptual plans for the 40 hectare waterfront site at the southern tip of the Western
Kowloon reclamation into an integrated arts, cultural and entertainment district under the
mode of PPP (Mok, 2005). Since, there has been continuous debate over the best suitable
financing modality which should be adopted. A number of uncertainties in this project
doomed it to be highly criticised. These problems included:
Initially the government was unclear of what they wanted and their objectives
were unknown;
Government did not notify or seek advice from relevant parties at the beginning
e.g. art and culture groups;
There is no timeframe or schedule to be met and no milestones to be achieved;
The private sector has been kept in the process for too long causing loss in
terms of time and resources; and
The project may not be able to proceed if private financing is not involved.
Media reports have also highly publicised the dissatisfaction heard from local Legislative
Councilors towards the government’s indecisiveness and delay in delivering this project
Chapter 4 Procuring Infrastructure Projects in Hong Kong
75
(Leong, 2008). Due to the large number of uncertainties involved, the local government
has needed to handle the project more cautiously. As a result a decision to the project
design, timeframe and the delivery method took a long time to be decided. A number of
public consultations were conducted. And a special task force was established to monitor
the progress of this project.
The debate over the financing modalities finally came to a halt when the Legislative
Council of the HKSAR government approved HK$21.6 billion to fund this project (Wu,
2008). The agreement was reached after thirty-two Legislative Councilors agreed to this
arrangement against ten that opposed.
Figure 4.4 Artist’s impression of the proposed West Kowloon Cultural District
project (Home Affairs Bureau, 2008)
Chapter 4 Procuring Infrastructure Projects in Hong Kong
76
4.3.5 Findings from the case studies
This section has looked into four case studies in Hong Kong. Two of these appear to be a
failure or less successful and the other two are seen to be highly successful or at least
most of the project stakeholders are happy with their performance.
The CHT and the WHC were delivered by the more traditional BOT approach which
Hong Kong has gained abundant experience in. Although experience has been developed
for these types of projects, WHC has still been regarded as relatively unsuccessful,
especially when compared to the CHT which is one of the most profitable public services
that the local Government now owns.
AWE and WKCD are two more recent projects. AWE is classified by some as the first
proper PPP project to be delivered in Hong Kong. The satisfied stakeholders involved in
this project have reflected its success. On the other hand, the WKCD took a long while
to decide on the delivery approach of whether or not using the PPP route; and finally the
government decided that they should fund the project out of their own money. The
lengthy decision process and the uncertainty of the local government, has doomed it to
become an unsuccessful PPP venture. Its consideration to go down the PPP path has
given PPP a highly bad profile in Hong Kong.
The cases discussed in this section have shown both successful and unsuccessful
experiences of the more traditional BOT projects and the more recent PPP projects in
Chapter 4 Procuring Infrastructure Projects in Hong Kong
77
Hong Kong. Table 4.1 shows a summary of some of the project information for the cases
presented.
Chapter 4 Procuring Infrastructure Projects in Hong Kong
78
Table 4.1 Summary of the analysed case studies (Asia World Expo, 2008; Bouygues-Asia, 2008; Hong Kong Engineers, 2006; Li,
2003; Nishimatsu, 2006)
Project Name Abbreviation Delivery
Approach
Concession
Period
(years)
Construction
Start Date
Opening
Date
Approximate
Project Cost
(HK$ million
)
Planned
Construction
Period
(months)
Actual
Construction
Period
(months)
Cross Harbour Tunnel CHT BOT 30 Sep 1969 Aug 1972 320 47 36
Western Harbour Crossing WHC BOT 30 2 Aug 1993 1 Apr 1997 7,500 48 44
Asia World Expo AWE PPP 25 Sep 2003 21 Dec 2005 2,350 28 27
West Kowloon Cultural District WKCD Traditional On-going: to be confirmed
Chapter 4 Procuring Infrastructure Projects in Hong Kong
79
4.3.6 Section 4.3 summary
Although Hong Kong has had experience in adopting quite a number of BOT projects,
the approach of PPP has yet to be studied extensively on a local scale. Often the
traditional practice of these projects was to directly form a contract agreement with the
potential bidder. By doing so it was possible that essential items for success were
neglected and risks were not avoided. Some of the BOT projects conducted in Hong
Kong have often jumped straight into the project agreement neglecting important
foundation work. This practice of securing contracts quickly is common in Hong Kong,
but the risks which maybe associated are unpredictable. Therefore, it is important to
adopt the experiences of others and to develop a suitable model to fit Hong Kong bearing
in mind the differences in location, culture, experiences and practices.
Some of the lessons learnt which can be derived from the Hong Kong case studies
include:
Timing of the project is important, this will effect whether there is a demand;
The PPP method can help to resolve technical and financial problems by
bringing in more able parties to work with/for the government;
Ensure that value for money is achievable by adopting PPP;
Ensure a reasonable toll adjustment mechanism;
Keep the general public satisfied by sufficient consultations and transparency in
the process;
Projects that attract a lot of political debates are less likely to be successful;
Chapter 4 Procuring Infrastructure Projects in Hong Kong
80
A project champion is necessary;
PPP projects can also be delivered via public funding;
Set clear objectives and timeline; and
Streamline the procurement process.
Presently, PPP projects are conducted without thorough investigation into the feasibility
of using the model in Hong Kong. The only information available is the experiences that
Hong Kong has derived. Some recent projects have been adopted appropriately by
integrating international best practice. It is anticipated that future PPP projects in Hong
Kong will be adopted well if the local Government can integrate the lessons learnt from
other jurisdictions and integrate these with Hong Kong’s own experiences to overcome
the differences in practice and location.
Chapter 4 Procuring Infrastructure Projects in Hong Kong
81
4.4 Is BOT the Best Financing Model to Procure Infrastructure
Projects?
This section aims to study the feasibility of implementing BOT projects in Hong Kong by
looking at the recent highly profiled Hong Kong – Macau – Zhuhai Bridge (HMZB)
project. The three governments that are going to deliver the HMZB, have decided to
finance the project themselves rather than to seek private financing as previously planned.
Additionally, the objectives of this analysis will include:
Study the background of the HMZB to discover the reasons why it will not be
delivered by the BOT model;
Analyse the process in which the HMZB changed from being delivered by
BOT to being funded solely by the host governments;
Study the underlying problems of the HMZB and why the BOT model could
not be applied; and
Analyse the government’s motives for not opting for the BOT model in the
case of the HMZB.
The aim and objectives of this study were achieved by conducting an in-depth analysis of
the HZMB case via published materials such as newspapers, magazine articles, websites,
journal papers, government releases etc. A large range of materials were firstly collected.
Then materials that were believed to show a true reflection of the HZMB situation were
retrieved and analysed thoroughly. This process was conducted using the “WiseNews”
search engine. WiseNews is a database of news and magazine articles that are published
Chapter 4 Procuring Infrastructure Projects in Hong Kong
82
in more than 500 sources including all major newspapers in Hong Kong, press release
from the Information Services Department of the HKSAR government, ATV Internet
news, Xinhua News Agency and many magazines from Hong Kong, Macau, China and
Taiwan (The Hong Kong Polytechnic University, 2009).
4.4.1 Background of the Hong Kong – Zhuhai – Macau Bridge
4.4.1.1 Background
The idea for the HZMB was first proposed by Mr. Gordon Wu of the Hong Kong listed
Hopewell Holdings Limited in the eighties (Kwok, 2009). Mr. Wu had observed the
added advantages towards industry with improved infrastructure network in the Pearl
River Delta Region. But no further actions were taken by the HKSAR government hence
the project was put on hold for over two decades (Oriental Newspaper, 2008).
It was not until September 2002 that the project was rethought. At the “Third Meeting of
the Mainland / Hong Kong Conference on the Co-ordination of Major Infrastructure
Projects” it was agreed that a study would be conducted on the transportation between
Hong Kong and Pearl River West. This was the first proper study conducted to analyse
the feasibility of the HZMB. Furthermore, in January 2003, the National Development
and Reform Commission (NDRC) and the HKSAR government commissioned the
Institute of Comprehensive Transportation to conduct this study. The study was
completed in July 2003. The report entitled “Transport Linkage between Hong Kong and
Chapter 4 Procuring Infrastructure Projects in Hong Kong
83
Pearl River West” highlights that transportation between Hong Kong and the Pearl River
West is insufficient. A point which was mentioned over twenty years ago but only
verified till now. The current transport between theses jurisdictions via the Humen
Bridge is costly and time consuming. Therefore, the report concluded that the HZMB
would be advantageous to overcome the problems (Transport and Housing Bureau 2008a).
With the project back on track the Advance Work Co-ordination Group (AWCG) was
setup in August 2003 for the bridge. The AWCG is comprised of representatives from
each of the governments. In February 2004, the AWCG commissioned the China
Highway Planning and Design Institute (HPDI) to conduct a feasibility study for the
HZMB. In doing so the HPDI also set up an office in Guangzhou to specifically monitor
the works conducted by HPDI. The study looked at all aspects of the project including
hydrology, environment, landscape, marine, ship impact protection, traffic, wind speed
assessment and financial viability (Transport and Housing Bureau, 2008a). The report
proposed several alignment options which were presented at a meeting organised by the
NDRC in April 2005. It was approved by the AWCG that the Northern bridge-cum-
tunnel alignment would be adopted (Transport and Housing Bureau, 2008a). The HPDI
were further commissioned to conduct studies on the locations of boundary crossing
facilities of the bridge after the “Ninth Plenary of the Hong Kong-Guangdong
Cooperation Joint Conference” held in August 2006 (Transport and Housing Bureau,
2008a).
Chapter 4 Procuring Infrastructure Projects in Hong Kong
84
With the technical side of the project underway, the financial arrangement and
responsibilities needed to be confirmed. These details are discussed in later sections of
this chapter.
4.4.1.2 The proposed design
The three governments have claimed that the HZMB will further enhance the economy
development of Hong Kong, Macau and the Western Pearl River Delta region (Hong
Kong Special Administrative Region Government, 2008). The new bridge is expected to
significantly reduce the cost and time for both people and goods transportation between
the regions. At the same time it is hoped that the project will increase the region’s
competitiveness. The construction of the bridge is expected to commence no later than
2010 (Hong Kong Special Administrative Region Government, 2008). And the estimated
completion date is set for year 2015 to 2016 (Chen and Lee, 2008).
The initial estimated time of travel is believed to be within 15 to 20 minutes and the total
cost of the bridge will be approximately RMB37.4 billion (Mak, 2008). The main bridge
will be a 29.6 kilometres dual 3-lane carriageway in the form of bridge tunnel structure
comprising an immersed tunnel of about 6.7 kilometres. Vehicle speeds are anticipated
to be 100 kilometres per hour. A traffic flow of approximately 12000 – 16000 vehicles
are expected per day (Hung, 2008). The bridge will land on an artificial island off
Gongbei on the west side, and another artificial island on the east which would be west of
the HKSAR boundary. According to the current proposed construction option, the
Chapter 4 Procuring Infrastructure Projects in Hong Kong
85
connecting roads are about 12.6 kilometres on the Hong Kong side and 13.9 kilometres
on the Mainland side. As shown in Figure 4.5 the bridge will run across the Lingding
Channel, the Tonggu Channel, the Qingzhou Channel, the Jiuzhou Port Channel, and the
Jianghai Channel etc. (Transport and Housing Bureau, 2008a). A summary of the project
details is also shown in Table 4.2.
Figure 4.5. Alignment of the HKZMB (Transport and Housing Bureau, 2008a)
Chapter 4 Procuring Infrastructure Projects in Hong Kong
86
Table 4.2 Summary of the HZMB Details (Mak, 2008; Hong Kong Special
Administrative Region Government, 2008; Chen and Lee 2008; Hung,
2008; Transport and Housing Bureau, 2008a)
Route Joining Lantau Island in Hong Kong to Perola
in Macau and Gongbei in Xhuhai
Length 29.6 kilometres (main body)
Vehicle speed limit 100 kilometres per hour
Journey duration 15 to 20 minutes
Toll fee $HK150 per vehicle
Construction cost RMB37.4 billion
Traffic Flow (Hung, 2008) 12000 – 16000 vehicles per day
Estimated Date of Construction
Commencement
2010
Estimated Date of Completion 2015/ 2016
4.4.1.3 The original BOT decision
The HZMB project was originally suggested by the private sector hence BOT was the
assumed delivery method from the very beginning. A BOT plan was originally drawn up
in early 2008 for the bridge. This plan was officially initiated by the three governments
from Guangdong, Hong Kong and Macau in 2002. Under the BOT scheme, the three
governments would be only responsible for construction of ports and connective parts of
the bridge within the three sides and its main part will be constructed by bids (Qiu, 2008).
Chapter 4 Procuring Infrastructure Projects in Hong Kong
87
Under the BOT arrangement the bridge was to have a 50 year concession period
(Legislative Council, 2008).
Another reason for the HZMB to be delivered by the BOT model was the high project
costs. By involving the private sector the governments would not need to take up the
financial risks involved (Apple Daily, 2008). Although this was appealing the extended
duration of the tendering and negotiation process due to the project being a BOT was
foreseeable. Also the differences in legislation between the three jurisdictions, made it
even more difficult to come up with a unique agreement on aspects such as vehicle flow
and sharing of risks between the public and private sectors. As a result to continue with
the BOT plan would mean that the timeframe for the project would be more
unpredictable and a lot further away (Apple Daily, 2008).
4.4.1.4 Underlying problems of the project
Originally calculations showed that if the bridge was procured by the BOT model the toll
fares would be approximately $150 for each vehicle crossing the bridge (Mak, 2008), but
whether this price will be lowered due to public financing is still unknown (Hong Kong
Special Administrative Region Government, 2008). Chairman of the Container
Transportation Employees General Union, Mr. Chiu spoke publicly that the toll fees
should be lowered between the range HK$80 to HK$100 to be reasonable for the general
public (Mak, 2008). Another local Hong Kong car rental enterpriser believed that for
such a short journey the fare should not be beyond HK$100 to HK$120. The responses
Chapter 4 Procuring Infrastructure Projects in Hong Kong
88
show that the proposed toll prices would be far too high for the general public to benefit
from the project.
Also as mentioned previously a major reason why the WHC was so unsuccessful
compared to the CHT was because it was built 30 years later and at a cost of twenty-three
times more. Similarly it has been 25 years since the idea for the HZMB was first
mentioned, the cost of construction and the necessity for the bridge has definitely
changed. The lack of interest from the private sector maybe an indication that the bridge
is not as important as it once was. The original intention was that the bridge could serve
the industrial development of the area rather than the general public. But since the idea
was first proposed undoubtedly there has been a large change and movement to the
industries in the region.
4.4.2 Change from private financing to public financing
4.4.2.1 The process of change
Mr. Wu’s original initiation of the project led minds to think that Hopewell Holdings
would definitely be interested to participate in this mega infrastructure project but it has
been reported that over twenty years after the idea was first proposed, the company no
longer saw a business opportunity in the plan (Lam and Chan, 2008). Similarly, other
private sector companies felt the same. The private sector was no longer interested in this
project as the business potential for them was not attractive.
Chapter 4 Procuring Infrastructure Projects in Hong Kong
89
Therefore, the decision for the financing model of the bridge was changed dramatically.
In the “8th AWCG Meeting” held in February 2008 it was still assumed that the project
would be procured by BOT. The three governments agreed to take up the responsibility
for construction and operation of the boundary crossing facilities and the link roads to the
bridge within their own territory. It was discussed that private investment would be
invited for the main body of the bridge with the funding gap shared by the three
governments according to construction needed in their own territories. In this
arrangement Hong Kong would have covered 50% of the difference, Guangdong 35%
and Macau 15%. The decision showed that the governments were in favour of the PPP
arrangement at the time (Transport and Housing Bureau, 2008b).
But in an interview conducted with the Secretary for Transport and Housing Bureau also
in February 2008, she was asked by reporters whether the BOT method would be adopted
for the HZMB. The Secretary responded that the project would be considered as a whole
amongst the governments. Her response did not directly answer whether the project
would be financed by the private sector or not (Transport and Housing Bureau, 2008c).
Under some discussion and reviews of the studies that have been carried out such as on
the traffic flow and bid price, it was realised that the governments would not be able to
come up with an attractive economic package for the private sector to be interested (Ming
Pao Newspaper, 2008a). Finally a decision was made at the “11th Plenary of Hong
Kong-Guangdong Co-operation Joint Conference” in August 2008. It was announced
that the HZMB would be funded jointly by the governments (Hong Kong Special
Chapter 4 Procuring Infrastructure Projects in Hong Kong
90
Administrative Region Government, 2008). It was confirmed that the bridge would be
conducted using public money rather than private sector resources.
The preliminary proposed contribution from each government will be RMB6.75 billion
from the HKSAR government, RMB7 billion from the Guangdong-Central government,
and RMB1.98 billion from the Macau Special Administrative Region government. The
total contribution from the three governments will be RMB15.73 billion, which will be
equal to 43% of the bridge's construction cost. The remainder will be financed by bank
loans (Information Services Department, 2008a).
The new arrangement has meant that the Guangdong government has become the largest
stakeholder of the project (Hong Kong, Guangdong and central government and Macau
government will take up approximately 43%, 45% and 13% respectively of the upfront
payments (Lam and Lai, 2008)). In the original proposal the HKSAR government would
have taken this role. The move for this change can be an indication that the Chinese
government has high desire to push the project ahead. But there has been no
comprehensive answer from the governments why the BOT arrangement was not opted
for the bridge. (Chen and Lee 2008)
Chapter 4 Procuring Infrastructure Projects in Hong Kong
91
4.4.2.2 Government motives for not opting for the BOT model
Faster project delivery
Undoubtedly there are benefits to paying for the HZMB with public money otherwise the
governments would not have come to this conclusion. The Chief Executive of Hong
Kong, Donald Tsang spoke publicly at the “11th Plenary of Hong Kong-Guangdong Co-
operation Joint Conference” in Guangzhou during August 2008 on the advantages for the
HZMB to be funded jointly by the governments. He explained that for the governments
to take up the financing responsibility would speed up the construction works of the
bridge. This argument was also agreed by Chen (2008) who claimed that the project
would be delivered two years earlier than the BOT approach which normally would
require a lengthy consultation period and complicated legislative requirements.
Government control in tolls
Furthermore, Mr. Tsang added that the governments would be left with more allowance
to adjust the toll fee of the bridge without economic pressure (Information Services
Department, 2008a). Ng (2008) also agreed that paying for the bridge with public money
would mean that the governments would have more authority to adjust the tolls. Also,
the governments being willing to undertake the project’s financial risk gives certainty that
they are committed to the project (Hong Kong Special Administrative Region
Government, 2008).
Chapter 4 Procuring Infrastructure Projects in Hong Kong
92
4.4.2.3 Other underlying reasons for using public finance
Time and cost certainty
The governments’ decision in this project has also been supported by some of the media.
If the project continued as a BOT, the private sector would need to prepare a bid based on
their financial benefits in which they will take in to account their expenditure for the
project, the traffic forecast and the toll price. Bid preparation is a lengthy and costly
process in BOT type projects (Zhang, 2001). If the governments are to find that their
proposals are unsuitable, the process for the project would be further extended. Similar
situations as the Kai Tak Cruise Terminal could arise.
In this case the package offered by the HKSAR government was not attractive enough to
seek private investors hence the government has had to repackage the project and re-
invite the private sector for bids. The HKSAR government believed that the private
sector would be interested in this project but reality has shown that this was not the
situation (Oriental Newspaper, 2008) (More information on the Kai Tak cruise terminal
project is given in Section 7.3.4 of Chapter 7).
Cheaper tolls
Another problem foreseeable if the project was to be delivered by the BOT model would
be the high toll fees that may be imposed. The private sector are profit making
Chapter 4 Procuring Infrastructure Projects in Hong Kong
93
organisations, hence they would adjust the toll fees so that they can cover their
expenditure acquired during the delivery and maintenance of the project. In addition,
they will hope to seek reasonable financial rewards. In doing so there is a risk that the
project would follow in the footsteps of the East and West Harbour Crossings in Hong
Kong (Apple Daily, 2008). These projects were procured under the BOT model,
controversy to the CHT (Hong Kong’s first and probably most successful BOT project)
they suffered much bad publicity due to the high and continuously increasing toll prices.
As a result, the general public has tended to use the cheaper CHT more frequently than
the other two tunnels for the crossing between Hong Kong Island and Kowloon Peninsula.
In the case of the HZMB, the general public could also choose to travel on cheaper routes
if the prices were to be too high. Studies showed that the HZMB would not be
commercially viable hence that would mean that the governments would have to cover
the financial costs if the bridge was to be delivered by BOT (Brown, 2008). If the
private sector was to be involved they would be left with no choice but to raise the toll
process incredibly to compensate for their expenses acquired as in the case of the East
and West Harbour Crossings (Apple Daily, 2008).
So (cited in Ming Pao, 2008b) conducted an analysis on the probable toll fees under
different financing models. As shown in Table 4.3, three different scenarios are
considered. The first and second scenarios estimates the toll fee for crossing the HZMB,
with the project financed by the host governments according to a 120 year and 60 year
investment return period respectively. Other factors considered in the estimation include
Chapter 4 Procuring Infrastructure Projects in Hong Kong
94
the savings from the private investor’s profits if the project was to be financed by the
BOT model, and also the estimated annual usage of the bridge. The toll fees estimated
per trip were RMB$193 and RMB$387 for the first and second scenarios respectively.
The third scenario considers the project under the BOT model. The investment return
period was set at 30 years which is also a typical concession period for BOT type projects
(Howes and Robinson, 2005). Other factors considered in the estimation also included
the estimated annual usage of the bridge. Under this scenario the toll fee was calculated
to peak RMB$830 per trip. Analyses of these scenarios have illustrated that the use of
the BOT financial model (Scenario 3) may be 2 (Scenario 2) to 4 times (Scenario 1) more
expensive than if it is funded primarily by the government.
Chapter 4 Procuring Infrastructure Projects in Hong Kong
95
Table 4.3 Comparison of estimated toll fees to be charged under different financial models (Ming Pao, 2008b)
Scenario 1: Funded by the host governments with an investment return period equal to the bridge life of 120 years Total Investment RMB72.7 billion Savings from private investor’s profits RMB4.95 billion (under the BOT model, with a private investment of RMB30
billion calculated at a 16.5% return rate) Usage per year 292 0000 (8000 per day) Investment return period 120 years Estimated cost per trip (daily maintenance cost not included) (RMB72.7 billion – RMB4.95 billion) / RMB2.92 billion / 120 years = RMB$193 Scenario 2: Funded by the host governments with an investment return period of 60 years Total Investment RMB72.7 billion Savings from private investor’s profits RMB4.95 billion (under the BOT model, with a private investment of RMB30
billion calculated at a 16.5% return rate) Usage per year 292 0000 (8000 per day) Investment return period 60 years Estimated cost per trip (daily maintenance cost not included) (RMB72.7 billion – RMB4.95 billion) / RMB2.92 billion / 60 years = RMB$387 Scenario 3: Adopting the BOT model (financed, constructed and operated by private investors) with a return period of 30 years (typical BOT concession period in transportation projects) Total Investment RMB72.7 billion Usage per year 292 0000 (8000 per day) Investment return period 30 years Estimated cost per trip (daily maintenance cost not included) RMB72.7 billion / RMB2.92 billion / 30 years = RMB$830 Note: 1 RMB = 0.1464 US$ (Yahoo, 2008)
Chapter 4 Procuring Infrastructure Projects in Hong Kong
96
User satisfaction
A similar problem was also observed in the Cross City Tunnel project of Sydney which
was delivered by the PPP model. Due to the inaccurate traffic forecasts and the high toll
prices which were applied to overcome the low traffic volume, both the consortium and
the New South Wales Government were highly criticised for this project (Jean, 2006)
(Refer to Chapter 4 Section 4.4 for more details). Similarly if high tolls and low usage
are experienced by the HZMB, the situation would in turn limit the cooperation between
the three jurisdictions and also demean the objective of the bridge. As a result the
governments may be reluctant to deliver large infrastructures jointly again.
Lack of private sector interest
The governments were also aware that the private sector lacked motivation for this
project. As the bridge was found to be highly costly and uneconomic, the appeal to the
private sector even with compensation would be difficult to attract (Van der Kamp, 2008).
With the comfortable reserve from all three governments there has been less drive to
force the project as a BOT. Although the project may not be economically feasible when
all costs are considered, experts believe that the collected tolls would sufficiently cover
the expenses of maintenance and operation hence the financial risks involved for the
government would be minimal.
Chapter 4 Procuring Infrastructure Projects in Hong Kong
97
Reduce allegation of collusion between the public and private sectors
There are also other advantages that have been perceived of the new arrangement. Chen
and Lee (2008) quoted from a Hong Kong academic that the new arrangement will
minimise the chance of negotiation between developers and the governments; hence will
reduce allegation of collusion between business and the government. Hong Kong has
previously been criticised for favouring certain developers and giving developers high
financial returns through delivering public projects. An example is the Cyberport project
a technological centre and the West Kowloon Cultural District a proposed cultural hub
(Wong, 2005).
4.4.3 Section 4.4 summary
This section has studied the much speculated case of the HZMB from Hong Kong’s angle.
The findings showed that there were several reasons that led to the case being financed by
the governments rather than involving the private sector as originally planned. Firstly,
Hong Kong had previously experienced a lack of interest from the private sector in the
bid of the Kai Tak Cruise Terminal hence causing the project to be delayed for
repackaging. Therefore, the governments did not want the HZMB to experience a similar
situation causing it to be further delayed. Also, the project was first proposed twenty-five
years ago, hence to proceed with the BOT model would mean that the project would be
further delayed due to the long tendering and negotiation processes that would be
involved if it was to go along with the BOT model.
Chapter 4 Procuring Infrastructure Projects in Hong Kong
98
Secondly, the legal differences between the three jurisdictions would mean that an
agreement unifying and compromising all legal systems would be difficult. Thirdly, with
private sector involvement there would be a lack of government control over the toll
prices. Again the HKSAR government has had some bad experiences in the West and
East Harbour Tunnels where the private consortia have charged tolls much higher than
the government owned tunnels. Fourthly, the private sector was no longer as interested in
the project as they were when the idea was first proposed due to changes and movements
in industries over time. Also, studies carried out by the governments showed that the
business model would not be economically attractive enough for the private sector to be
interested. The fifth reason for financing the project with public money is to avoid the
public perception of collusion between business and the government. And finally the
most important reason of all is that the three governments have comfortable financial
reserves, meaning they could deliver the project themselves with ease.
4.5 Chapter 4 Summary
This chapter has studied Hong Kong’s experience in BOT/PPP projects by looking at
different cases. Projects conducted by the BOT and the PPP approach have been studied
to compare the differences. Both dated and recent projects have been considered to
analyse the development trend. As a result some lessons learnt were derived from this
analysis. It was found that timing can be a very important aspect affecting the success of
projects as the demand will differ over time. Also, the PPP method can help to resolve
technical and financial problems by bringing in more able parties to work with/for the
Chapter 4 Procuring Infrastructure Projects in Hong Kong
99
government. Value for money should be achievable by adopting PPP. For transportation
projects a reasonable toll adjustment mechanism should be in place. Often the success of
a project can affect the satisfaction level of the general public hence there should be
sufficient consultations and transparency in the process. Projects that have complicated
political issues should be avoided. Successful projects are those that have had a project
champion. PPP projects do not necessarily have to be funded by the private sector. PPP
projects should have clear objectives and a timeline. Lastly the procurement process
should be streamlined to avoid unnecessary delays and expenses.
This chapter has also considered whether BOT is the best option for public works
projects in Hong Kong by analyzing the HZMB. There were six main reasons leading to
the governments’ decision to fund the project themselves. These include: 1) To avoid
delay due to the foreseeable long procurement process; 2) Complicated legal differences
between the three jurisdictions; 3) Private sector involvement would mean less control
over the toll prices for the governments; 4) Lack of interest from the private sector; 5)
Avoid perception of collusion between public and private sectors; and 6) The
governments all have a comfortable financial reserve.
Chapter 5 The Australian PPP Experience
100
CHAPTER 5
THE AUSTRALIAN PPP EXPERIENCE
5.1 Chapter 5 Introduction
5.2 PPP in Australia
5.3 A New Era of PPP in Australia – The Southbank
Education and Training Precinct Case Study
5.4. Risk Sharing Mechanism for PPP Projects
– The Sydney Cross City Tunnel Case Study
5.5 Chapter 5 Summary
Chapter 5 The Australian PPP Experience
101
5.1 Chapter 5 Introduction
Public Private Partnership (PPP) has been an increasingly popular choice for delivering
public works projects in Australia. Although for decades there have been known to be
public works projects delivered in Australia by similar partnership arrangements, it has
only been since the early nineties that PPP was first properly introduced. PPP has been a
growing alternative to procuring public projects across the world. Especially with the
success seen from the Victoria state, the other Australian states are eager to get a taste.
This chapter looks at two highly profiled case studies: The Southbank Education and
Training Precinct in Brisbane and the Cross City Tunnel in Sydney. From these
experiences it is hoped that some lessons learnt can be drawn for future PPP projects.
5.2 PPP in Australia
The practice for delivering public works projects across Australia is quite different
depending on the state. Each state government will have its own set of guidelines, rules,
preference and practice to go by. Political decisions are crucial in deciding procurement
processes.
Chapter 5 The Australian PPP Experience
102
5.2.1 The Victoria practice
The Victoria government released the Partnerships Victoria policy in June 2000
providing a framework for developing contractual partnerships between the public and
the private sector for public infrastructure and services (Partnerships Victoria, 2000).
This bought about the change to the traditional practice of using Build Own Operate
(BOO) and Build Own Operate Transfer (BOOT). The traditional practice focused more
on bringing in the private sector’s financial input and also having the risk transferred
from the public sector to the private sector. But since the Partnerships Victoria policy the
focus moved more towards delivering better projects as a result of bringing in the private
sector expertise and also the government would regain direct control over the service or
facility after the concession period.
The Partnerships Victoria team is part of the Commercial Division in the Department of
Treasury and Finance of the Victoria state. The team is mainly responsible for
overseeing projects implemented via the PPP practice and also developing guidelines and
policies for PPP projects. Up to present, seventeen projects have already been
implemented under Partnerships Victoria totaling AUD$5.5 billion (Partnerships Victoria
2008a). The team has also produced four policies, four guidelines, three technical notes
and four advisory notes for the implementation of PPP projects in Victoria. These
publications are targeted for the use of both the private and public sectors, and cover
areas including the public sector comparator, risk allocation, standard commercial
principles, tender process, interest rates etc. (Partnerships Victoria, 2008b).
Chapter 5 The Australian PPP Experience
103
5.2.2 The Queensland practice
In the past, Queensland has always been historically a conservative state (Townsend,
2004). The conservativeness of the Queensland government has meant that alternative
procurement methods have not been considered until recently. Queensland is a very
unique state, for example it is the only state that has elected a communist member into its
parliament. Another example more relevant to procuring projects is that unlike other
states such as New South Wales and Victoria, Queensland has its own public works
department to deal with their projects. In other states those services tend to be outsourced
to the private sector. The Queensland government still runs their own toll roads and
some of the electricity. This may also be one of the reasons that other states have been
more comfortable and quicker in adopting PPP.
Another major factor is that Queensland has never had a huge budgetary crisis. The
traditional practice of how the state has operated has meant that it is a state which has the
ability to control almost every function within itself, such as marketing functions,
agricultural functions etc. The approach in general is therefore a very socialist one.
Queensland has therefore adopted PPP much slower than other states in Australia.
Taking Victoria for example, PPP projects were introduced over a decade beforehand.
PPP although not called by this term 20 years ago was first utilised in Queensland even
before other states. The project was a toll way built in Sunshine Coast. The short lived
procurement alternative came to a hold after the Queensland government changed from
Chapter 5 The Australian PPP Experience
104
being conservative to labour. As a result public infrastructure was basically nationalised.
This was a typical intervention. The new Queensland government was not keen with
adopting PPP. In other jurisdictions PPP projects have been driven by either the Premier
or the Treasurer. And the previous Queensland Treasurer did not take any actions to
encourage PPP projects.
Another major reason that the Queensland government has not been keen to jump into
using PPP at first, is because it does not see the delivery method as value for money when
compared to conventional options. The Queensland government’s state budget is in a
much more robust situation compared to Victoria when they first adopted PPP. Therefore
there has never been any economic pressure for them to try out alternatives. Similar to
other governments around the world, PPP was often first adopted due to budgetary crisis
for delivering public infrastructure and services.
Queensland government’s recent interest in PPP has also been due to changes in their
economic situation. The state is required to pay approximately AUD50 billion over the
next four years to uplift their infrastructure. Therefore, there has been a lot more pressure
in the state to turn up the cash with ease. PPP has therefore become an attractive option
to draw in cash from the private sector. Obviously, with the amount of experience and
research done on PPP in other parts of Australia the Queensland government are clearly
aware that PPP should be driven by value for money. The reason there have not been
many PPP projects in Queensland is because some people in the state government believe
that they may not be value for money. They see no reason for the private sector to
Chapter 5 The Australian PPP Experience
105
finance and build public projects when they can borrow the money themselves at a lower
financial cost.
The Queensland government has also been careful to ensure that they do not follow in the
same footsteps as the Sydney government. Although the Sydney government has
delivered many successful PPP projects in the past, a very high profile project has caused
negative views on PPP. The Cross City Tunnel faced problems associated to traffic
forecasts and toll fare (Chan et al, 2008). The result was that the private consortium
made a total loss. The risks associated with PPP projects were therefore highly profiled
at the time causing the government unwanted attention from the media. Governments in
general are concerned about similar criticism. Therefore the Queensland government has
been careful with every step they take on the PPP path in order to avoid the trap holes
(The Cross City Tunnel case is discussed further in later sections of this chapter).
Many of the Queensland government’s PPP guidelines have been based on those of
neighboring states, especially Victoria. Victoria’s PPP process published by Partnerships
Victoria (Partnership Victoria, 2000) has been undoubtedly the most advance in Australia.
The Victoria government has handled the most PPP projects in Australia in terms of
number and variation. The publications produced are renowned worldwide and
compared to those of Partnerships UK. Many players in the private sector have also
tended to follow the rules in these publications, as often what is written by the Victorian
government on PPP is believed to be the “Bible of PPP” across Australia. Undoubtedly,
the private sector may not even challenge the appropriateness of the guidelines, but often
Chapter 5 The Australian PPP Experience
106
the governments will expect the private sector to go by these “rules”, as it has become the
expected. The Queensland government has moved one step forward by producing their
own guidelines for PPP projects. Although based on the Victorian model, they have
added some further steps in the process to suit Queensland’s situation and needs.
5.3 A New Era of PPP - The Southbank Education and Training
Precinct Case Study
5.3.1 Background
Queensland is no exception and together with the demand for public infrastructure, the
private sector’s economic support is much more welcome. This section looks at the
obstacles faced by the Queensland government, from the case of the South Bank
Education and Training Precinct (SETP) in Brisbane, Australia. From the obstacles
highlighted by this case study it is hoped that jurisdictions elsewhere in the world can
learn from these and avoid them, in order to deliver successful PPP projects.
The first proper PPP project conducted by the Queensland government was the SETP. In
September 2002 the development of the SETP was announced. The goal was to develop
a multi-sectoral campus that built on developing greater links between schools, Technical
and Further Education (TAFE), universities, community groups and industry.
Chapter 5 The Australian PPP Experience
107
The private sector was invited for expression of interest from February 2003 to 11 April
2003. Three consortia were shortlisted by August 2003. In the end only two bids were
received and Axiom Education Queensland Proprietary Limited was selected as the more
favourable consortium in December 2004. The parties within the consortium consisted of
ABN Amro, John Holland Proprietary Limited and Spotless Services Australia Limited.
After further rounds of reviews especially on the value for money aspect the consortium
was announced successful on 19 April 2005, to plan, design, construct, finance and
maintain the AUD550 million facility. The construction of this four hectare site is
currently still undergoing and aims to be completed by the end of year 2008 (Figure 5.1
shows an aerial photograph of the project under construction). The concession period
will be for 34 years (Queensland Government, 2008).
The SETP was initiated by the then Department of Employment and Training in
consultation and collaboration with the Department of Education and central agencies,
including the Premiers and Treasury. As the SETP represented the Queensland
government’s first project to be commenced under PPP guidelines, there were no state-
based or local examples to go by. Therefore in order to aid the concessionaire, they were
given access to policy material form the Department of State Development and
Innovation and also the opportunity to interview interstate government agencies which
had direct experience on the development and procurement of PPP projects. It was by
this way the concessionaire of SETP learnt to conduct PPP projects. On top the selected
consortium already had experience in PPP projects elsewhere beforehand.
Chapter 5 The Australian PPP Experience
108
Figure 5.1 Ariel photograph of the Southbank Education and Training Precinct
project in October 2007 (Department of Education, Training and the Arts;
2008)
Chapter 5 The Australian PPP Experience
109
5.3.2 The obstacles
Being the first PPP project in Queensland, SETP faced a number of problems early on.
Firstly the government’s design of the project was very conceptual. Therefore the actual
validity of the public sector comparator was highly questionable and hence so was the
debate of value for money. Although so the public sector comparator was still conducted
just as a governmental process to justify the project for being a PPP. Another worry for
the private consortium was the Queensland government’s commitment to proceeding
with the project. It is known that some organisations and companies in the private sector
were reluctant to participate in this project as the state government has had a previous
track record of pulling out a proposed PPP project. With the large project sum and the
complexity of PPP projects, the risks that they bear are immensely high. Therefore, the
private sector needs to be sure that they have the government’s full support throughout
the project to overcome potential obstacles.
In addition, many experts in the field believed that the Queensland government should
not have chosen such a complex project for its first PPP project. Social projects are often
considered more difficult to handle compared to economic ones where income is obvious.
In addition, partnership projects between the public and private sectors have always
traditionally been economic ones hence the experience and knowledge in this field is
much more advanced. This was another reason that drew away potential bidders due to
their lack of confidence that the project would succeed. In the end there were only two
bidders for this project. The lack of potential bidders is another issue thought to limit the
Chapter 5 The Australian PPP Experience
110
competition in a PPP project. The lack of competition can be linked to the lack of quality,
innovation and price delivered. In order to boost up the number of potential bidders in
future, not only does the first project need to be a success, the Queensland government
has also proposed a small amount of compensation to the losing bidder. In the SETP case
the losing bidder was compensated AUD3 - 4 million. Although this is not the full
amount that they would have spent during the tendering stage it was more comforting to
get a partial return of the investment.
For the SETP project many of the protocols were already set out in the project deed
issued by the Queensland government. In terms of management practice there was little
difference to conventional methods. But a more rigorous risk management practice and a
better management practice overall was incorporated. Being a PPP project the other
issues that the consortium needed to deal with was the management of publicity and
media issues. In addition, the initial phase of this project took a long time. Much longer
than it should have, the government also noticed this and has stated that for future
projects they would definitely need to streamline the timeframe.
5.3.3 Other projects in Queensland
Following SETP, the Queensland government has already announced a further eight more
public projects which will be conducted by PPP also. These projects include: Airport
Link/Northern Busway; Gold Coast Rapid Transit; Gold Coast University Hospital; New
Queensland Driver Licence; Project Vista; South East Queensland Schools Project;
Chapter 5 The Australian PPP Experience
111
Sunshine Coast Hospital and Toowoomba Bypass. The projects selected are all relatively
large projects of both social and economic nature.
5.3.4 Section 5.3 summary
Similar to other large projects, PPP projects also have specific obstacles to overcome. It
is hoped that the obstacles highlighted for the SETP case have informed practitioners of
the things that should be avoided and how PPP projects can be conducted better. Apart
from financing the private sector obviously has other added advantages to offer such as
efficiency, skills, innovation, expertise, risk sharing etc. But at the end of the day
governments opt to utilise PPP because it provides value for money in the long run for
them. Therefore before adopting PPP, governments should consider their drive for
utilising this approach. Public projects should be conducted by the method that is best
suited for their needs.
Chapter 5 The Australian PPP Experience
112
5.4 Risk Sharing Mechanism for PPP Projects – The Sydney Cross
City Tunnel Case Study
5.4.1 Background
The Cross City Tunnel (CCT) in Sydney, Australia is a good example of how improper
allocation of risks could affect the success of a PPP project (Figure 5.2 shows a
photograph of the CCT). It is not incorrect for risks to be passed on to the private sector,
especially when they are capable to. But maybe there should be a “partnership” in place
when the private sector is unable to manage all the risks themselves. Some critiques
considered this project as an unsuccessful PPP as the local state government has had to
cope with handling many public opinions and criticisms for their inaccurate traffic
forecasts, leading to the investor making a financial loss.
The primary objectives of the CCT project were to reduce “through” traffic in central
Sydney, and as a result easing traffic congestion and improving environmental amenity in
the central business district and on streets approaching the central business district, and to
improve the east to west traffic flows (Roads Traffic Authority, 2003).
Chapter 5 The Australian PPP Experience
113
Figure 5.2 Photograph of the Cross City Tunnel (Traffman, 2008)
Chapter 5 The Australian PPP Experience
114
The CCT is a 2.1 kilometre twin two-lane motorway that runs east and west underneath
the busy central business district of Sydney. It opted for a Design Build Operate (DBO)
arrangement under a 30-year concession agreement. The project was part of a network of
new transportation infrastructure plan of the Roads and Traffic Authority of the New
South Wales Government. Its large project sum of AUD680 million meant that PPP was
an attractive option to the New South Wales Government.
The initial concept of the tunnel was mooted in 1998 (Cross City Tunnel Proprietary
Limited, 2007). After a series of complex consultations, exhibitions, modification and
approvals the private sector was finally asked for an expression of interest on 15
September 2000 (Roads Traffic Tunnel, 2003). In response, a total of eight consortia
expressed interest by 23 October 2000. Three consortia were shortlisted and asked to
submit detailed proposals for the project on 8 June 2001. All three consortia submitted
their proposals by the closing date of 24 October 2001. It was announced on 27 February
2002 that Cross City Motorway Proprietary Limited was selected as the winning
consortium.
The project commenced construction on 28 January 2003. It was delivered ahead of
schedule and took only 31 months to construct (typical for PPP projects). The tunnel was
officially opened for service on 28 August 2005 to the public. Unsurprisingly the project
attracted private sector from within Australia and abroad. The selected consortium
included strong financiers, Cheung Kong Infrastructure of China, Bilfinger Berger of
Germany and RREEF Infrastructure of Australia. They would bring in equity and
Chapter 5 The Australian PPP Experience
115
recover the cost of design, construction, operation and maintenance via the tolls collected.
Therefore the project company Cross City Motorway Proprietary Limited was allocated
all the demand risk for the project. Innovation was introduced by the contractor. The
tunnel was the first motorway in Sydney to have full electronic tolling. There were high
levels of expectations for all the parties, the traffic forecast for the project was predicted
to be 90,000 vehicles per day.
A number of benefits were sourced from materials published and released from the
project company Cross City Motorway Proprietary Limited (Cross City Tunnel, 2007)
and the government agency client the Roads and Traffic Authority of New South Wales
(Government Roads Traffic Authority, 2007). These parties claimed that as a result of
the Cross City Tunnel project the following benefits would be experienced:
34 traffic signals avoided (16 sets westbound and 18 sets eastbound);
Major reduction of traffic across the central business district;
Improved quality of life for pedestrians and cyclists in the central business
district;
Higher reliability of bus services in the central business district;
Cut trips across the city to approximately 2 minutes, from up to 20 minutes by
avoiding traffic lights;
Improved access and movement within the city for taxis, delivery vehicles,
cyclists and pedestrians;
Chapter 5 The Australian PPP Experience
116
Make city streets safer and more pleasant for pedestrians, residents and
business people by removing intrusive through traffic and providing more
footpath space in some streets;
Reduced traffic noise levels; and
Better air quality by taking cars off surface streets.
Despite the benefits of PPP which have been highly publicised, some may consider that
there are also many “failures” from the project. The next sub-section takes a closer look
into these “failures”.
5.4.2 Underlying causes leading to failure
CCT has been perceived as an unsuccessful case by the general public and as a result the
government’s image has suffered (Jean, 2006). To illustrate some of the negative
portrayals of the project, some headlines related to the project were sought and shown in
Figure 5.3. Amongst these seven headlines, three are related to the toll. This can show
that the toll is probably one of the key factors affecting the satisfaction level of the
general public towards CCT, and also one of the issues that is highly sensitive amongst
them.
Chapter 5 The Australian PPP Experience
117
Figure 5.3 Examples of newspaper headlines relating to the CCT when it opened
(Infrastructure Implementation Group, 2005)
Chapter 5 The Australian PPP Experience
118
PPP has been given a bad name and investors have been driven away from New South
Wales, at least temporarily (AAP General News Wire, 2006a). CCT encountered severe
difficulties in reaching the predicted traffic volume. Motorists have expressed their
unhappiness towards the high toll levels (AAP General News Wire, 2006b) and the
government closing off the surface roads to direct the traffic into CCT (AAP General
News Wire, 2006c). These sufferings have been the result of inaccurate traffic forecast
and flawed concession agreement. Currently, CCT has entered into receivership and the
concessionaire has written off their equity (Project Finance, 2007).
In this project it has been unfortunate that the public client and the private consortium
have openly argued in public. Newspapers have reported them criticising each other for
their faults (Field, 2006a). The Premier publicly spoke out expressing his frustration that
motorists were able to use the toll road without paying. He criticised the operators for
not enforcing the charge and how it was unfair for the motorists who did pay (AAP
General News Wire, 2006d; Field, 2006b). On the other hand the consortium also
criticised the Premier for failing to demonstrate leadership (AAP General News Wire,
2006e). It can be seen how the media has portrayed a tense battle between the public and
private sectors. This is an image that nobody wants to create for any project whether it is
delivered by PPP or not. But being a PPP project creates an even higher sensitivity, as
tax payers will query whether they are actually getting value for money from the
government’s decision.
Chapter 5 The Australian PPP Experience
119
Following the unfortunate events experienced, the private consortium requested the local
state government to pay them a toll subsidy and compensation for the road changes.
Unfortunately the two parties were unable to come to a satisfactory agreement (AAP
General News Wire, 2006f). But in order for the CCT case not to be repeated the local
state government considered to pay the consortium compensation for the Lane Cove
Tunnel, which is also in Sydney, if unfortunately traffic forecasts are also predicted
inaccurately (Cratchley and Jean, 2006a; 2006b). This action from the government was
positive as it showed that they were aware that there were problems in the CCT project,
and that they should share the responsibilities by undertaking more of the risks rather
than passing the pressure solely to the private consortium.
In 2005 the New South Wales government produced a report titled “Review of Future
Provision of Motorways in NSW” (Infrastructure Implementation Group, 2005). The
report reviews recent road projects including the CCT in order to improve future similar
projects. It is unfortunate to see that more barricades are set up to protect the government,
as a result of which risks are further passed on to the private sector. For example, in the
document they expressed their preference to bidders with the “lowest” toll. This line of
thinking is similar to selecting the lowest cost bidder, which should not be the only way
to select the consortium. Instead, value for money for the project overall should be their
main concern. By focusing on the toll only, other important features adding to value may
be neglected such as innovative techniques and skills used in the project to make it more
efficient and as a result creating value for money. Quality of the works may also suffer.
Chapter 5 The Australian PPP Experience
120
In the report it was also mentioned that in Victoria all the main variables which would
affect the commercial outcome of the project for all parties would be negotiated at the
bidding stage. But in New South Wales the toll level or the possibility of government
contribution would not be open to negotiation. Therefore whether value for money for
the taxpayers is achieved is questionable. The report has indicated that the New South
Wales government is clearly aware of their faults, but whether they actually rectify the
situation is to be observed.
To consolidate the findings reported by the press discussed previously, the underlying
causes leading to the “failure” of the CCT project include:
Inaccurate traffic forecast;
High toll levels;
Government closing off the surface roads to direct the traffic into CCT;
Flawed concession agreement;
The public client and the private consortium arguing openly in public;
No toll subsidy and / or compensation from the government;
The toll level or the possibility of government contribution was not open to
negotiation.
Chapter 5 The Australian PPP Experience
121
5.4.3 Appropriate risk allocation
Grimsey and Lewis (2002) identified nine main risks affecting all types of infrastructure
projects. These included technical risk, construction risk, operating risk, revenue risk,
financial risk, force majeure risk, regulatory/political risk, environmental risk, and project
default. On the other hand (Lam et al., 2007) identified seven key risk allocation criteria:
Whether the party is able to foresee the risk;
Whether the party is able to assess the possible magnitude of consequences for
the risk;
Whether the party is able to control the chance of the risk occurring;
Whether the party is able to manage the risk in case of occurring;
Whether the party is able to sustain the consequences if the risk occurs;
Whether the party will benefit from bearing the risk; and
Whether the premium charged by the risk receiving party is considered
reasonable and acceptable for the owner.
According to the terms and conditions set out in the Project Deed of CCT, the private
consortium accepted more or less all the risks associated with the project. The private
sector is often willing to take up large proportions of risk to gamble for their desired
returns. The government is also concerned about the consortium's readiness to accept
risk (Ahadzi and Bowles, 2004). But it is a surprise that the government is willing to
allow the private sector to take up such a large proportion of the risks. However in the
arrangement the social responsibility will always be the public sector’s. Therefore the
Chapter 5 The Australian PPP Experience
122
government should consider whether the consortium is able to handle the risk effectively.
In an ideal situation the risks should be shared equitably so that the party best able to
manage that risk will take up the role. The risks that the consortium agreed to take on
board in the Project Deed included (Roads Traffic Authority, 2003):
All risks associated with the financing, design, construction, operation,
maintenance and repair costs of the project;
The risks that traffic volumes or project revenues may be less than expected;
Income tax risks; and
The risks that their works or operational and maintenance activities might be
disrupted by the lawful actions of other government and local government
authorities or a court or tribunal.
Clifton and Duffield (2006) undertook a study where they looked into the risk allocation
structure for several recent PPP projects in Australia. One of these cases included the
CCT and realised that the risks for each party were quite evenly spread. But further study
showed that the intensity of the risks allocated to the private sector were actually much
more intense compared to those allocated to the local state government, as shown in
Table 5.1.
Chapter 5 The Australian PPP Experience
123
Table 5.1 Risk allocation structure for CCT (Clifton and Duffield, 2006)
Risk Allocated to Government Risk Allocated to Consortium
Native title risks Design, construction and commissioning
risks
Force majeure Delay and completion risks
Uninsurable risks Ground/geotechnical conditions risks
Legislative and Government Policy Operation and maintenance/facility
management risks
Shen et al. (2006) studied the risk allocation for public sector projects in Hong Kong.
From literature they identified a number of major risks affecting public sector projects.
In their analysis they selected the Hong Kong Disneyland as a case study. This case
study demonstrated which risks would be most suitably allocated to each party. The
study concluded that the public sector should be allocated the site acquisition risks,
inexperienced private partner risk and legal and policy risks. On the other hand, the
private party should be allocated the design and construction risks, operation risks and
industrial action risks. Lastly, Shen et al. (2006) advocated the importance that there are
some risks which both parties should share, these include development risks, market risks,
financial risks and force majeure. Although Shen et al.’s (2006) study was conducted for
a project in another country and of a different nature; it is believed that these shared risks
as mentioned could also apply to other PPP projects such as the CCT. CCT suffered
immensely due to the market and financial risks. If these were shared risks as suggested
Chapter 5 The Australian PPP Experience
124
by Shen et al. (2006), the intensity of the damage to the consortium could have been
minimised.
Traffic revenue risk has been identified as one of the most critical risks impacting the
commercial success of road projects delivered by PPP (Singh and Kalidindi, 2006). In
order to overcome traffic revenue risk, the annuity-based Build Operate Transfer (BOT)
model1 has been presented as a good solution. Unlike the traditional BOT type road
economic projects, the concessionaire will be paid by the governmental client a fixed
semi-annual annuity. This approach is similar to that used for the social infrastructure
PPP projects such as hospitals and schools which are paid by a regular fixed payment.
Similarly the annuity-based BOT model will require the concessionaire to achieve certain
milestones and standards. The payment will be used to cover the design, construction,
maintenance and operation of the road and its facilities. As a result the concessionaire
does not undertake any of the traffic revenue risk. This approach ensures that the
governmental client must also undertake their fair share of risks.
The risk allocation framework shown in Table 5.2 shows the appropriate risk allocation
for each party under the annuity-based BOT model. Amongst the sixteen risks listed,
over half or nine are undertaken by governmental clients. In general the concessionaire is
responsible for the risks related to the construction and operational performance of the
facility. Other risks which are less predictable and controllable are taken by
governmental clients. By adopting this approach the business case may not be as
1 Annuity-based BOT model – a fixed amount of payment is made by the public sector to the private sector for running the project.
Chapter 5 The Australian PPP Experience
125
attractive to the private sector. The private sector is often willing to take up more risks in
return for the possibility of financial benefits. The private sector should not be solely
responsible for taking these decisions. Instead the government should also consider
whether they should allow the private sector to take up large risk.
Table 5.2 Risk allocation framework for the annuity-based BOT model (Singh and
Kalidindi, 2006)
Risk Allocated to Government Risk Allocated to Consortium
Pre-investment Delay in financial closure
Resettlement and rehabilitation Time and cost overrun during construction
Permit/approval Time and cost overrun during operation
and maintenance
Delay in land acquisition Non-political force majeure
Delay in payment of annuity Performance standards
Change of scope Lane availability
Traffic revenue risk Interest rate risk
Change in law
Political risk
Another payment mechanism similar to the annuity-based BOT model was proposed, in
that the patronage risk stays with the government (Aziz, 2007). The shadow-toll Design
Chapter 5 The Australian PPP Experience
126
Build Finance Operate (DBFO) system2 is similar to the BOT system except shadow tolls
are used instead of real tolls. The government will pay a toll per vehicle per road
kilometre instead of the end users paying the toll. Another option is the performance-
based DBFO system3. For this payment mechanism the services and the operational
performance of the contractor are emphasised rather than the usage of the facility.
From the experience of several road projects including the CCT, the New South Wales
government identified some lessons learnt (Infrastructure Implementation Group, 2005):
Need for consultation and communication over the life of project procurement;
Need for improved community consultations and messages;
Responsibility of government client over procurement life of project; and
Greater onus on the consortium to accept full responsibility over the whole life
of the concession period.
The fourth lesson learnt indicates that the Government feels they have accepted too much
of the project risks. Therefore they appear to be keen to ensure that the consortium will
take a larger responsibility for risks in future.
2 Shadow-toll DBFO system - payment is made by the public sector to the private sector based on the number of vehicles using the road. 3 Performance-based DBFO system - payment is based on the service and operational performance rather than the usage.
Chapter 5 The Australian PPP Experience
127
5.4.4 Risk sharing mechanism
PPP should be adopted primarily based on value for money. Obviously the package is
accompanied by various other advantages which are attractive to the government such as
private financing and transfer of risks. But the decision to adopt PPP should not be solely
based on these additional advantages.
As discussed previously risks should always be allocated to the party best able to handle
them. The party allocated the risk should be the one most able to prevent it from
occurring. And if the risk does occur the allocated party should be the one most able to
minimise the consequences.
The inaccurate traffic forecast was the main reason that led to the collapse of the project
company. As a result of this fault other actions were taken by the concessionaire to
overcome the reduced traffic flow. These actions led to further complications which in
turn ruined the partnership agreement between the public and private sectors.
In the case of CCT the inappropriate allocation of risks was believed to be the root cause.
In some cases the government may subsidise or compensate the concessionaire if the
project revenue is less than expectation or if the contract is terminated. But often there is
much argument as to the amount which this subsidy or compensation should be. For
example, railways in Hong Kong have been implemented very successfully by MTR
Corporation using the “Railway plus Property Model” (Asian Development Bank, 2009).
Chapter 5 The Australian PPP Experience
128
The cost of constructing and operating railways is often very high. The R+P model uses
the surrounding development rights to compensate for the losses encountered for
delivering the railway. Public transport is particularly important to the development of a
city but as they are often expensive to deliver, private parties will not be interested unless
there are other means they can profit or there is subsidy available, like in the case of the
R+P model.
To prevent similar cases from occurring, an optimal risk sharing mechanism is presented.
The risk sharing mechanism can be adopted in projects of high risk nature. CCT was a
project of high risk due to its scale and significance. In this risk sharing mechanism,
projects which are traditionally economic infrastructure projects such as transportation
projects can adopt a regular fee payment from the government instead of bearing the
revenue risk. This approach is similar to social infrastructure projects. As mentioned
previously in this paper other researchers have also reported the possibility and feasibility
of this arrangement for economic infrastructure projects.
Under this mechanism, the consortium of high risk economic infrastructure projects will
be paid via a regular fee payment. In this way the payment will be based on project
performance rather than usage. As in social infrastructure projects certain risks are still
taken by the concessionaire, such as those associated with the design, construction,
operation and maintenance. But the other risks should be dealt with by the government
including revenue risk.
Chapter 5 The Australian PPP Experience
129
Although the economic package for projects paid by a regular fee may not be as attractive
to the private sector, this type of mechanism for high risk projects can help to protect the
private sector. By protecting the private sector the government will also benefit, since as
always the ultimate responsibility lies with them. The government may be able to pass
on most of the financial risks but for social responsibility they cannot avoid. Hence this
proposed mechanism is believed to benefit all parties involved.
The details of the proposed risk allocation mechanism will vary depending on the project
itself. But it is likely that the payment will be a regular fee paid to the concessionaire
based on performance and activity milestones. Under the agreed payment the
concessionaire will deliver a service to the public according to standards as agreed to in
the contract. If the concessionaire under performs then they will be penalised by a
deduction of their fees. In this way the concessionaire is monitored by the project’s
performance rather than usage of the facility. In the CCT project the concessionaire had
to bear the revenue risk, hence their main priority was to generate revenue. They used
toll prices and redirecting traffic to bring in revenue which just caused public frustration.
Although the local state government could have prevented these actions, they did not step
in. If the consortium had not needed to worry about the revenue, the public would have
been more satisfied. As a result the public perception of the facility, the project company
and the local state government would have been very different!
Chapter 5 The Australian PPP Experience
130
5.4.5 Section 5.4 summary
CCT was designed as part of a large infrastructure network plan for New South Wales,
Australia. Due to its complexity and size, PPP appeared to be an attractive delivery
method. Under PPP procurement the financing would be provided by the private sector.
Also expertise and innovation which would otherwise be unavailable within the local
state government could be sought. As a result the local state government managed to
pass on many of the project risks to the private sector. Obviously for a project of this size
there would be abundant financial opportunities for the private sector, hence they were
readily willing to take up the associated risks for the chance to be involved. The situation
could have been a win-win case but unfortunately this was not actually what happened.
Media reports have reflected CCT as an unsuccessful PPP project. For the consortium
this may have been the case. For the local state government, although they have received
some negative critiques, at the end of the day they have still constructed a world class
infrastructure facility. For the general public, the scandal may have been more amusing
to them rather than affecting! It is not easy and probably impossible to distinguish
whether any case is either solely successful or a failure. Instead it is believed that lessons
learnt from each case can be sought.
This section has looked into a highly profiled case and tried to recommend solutions to
overcome the potential obstacles. As a result a more suitable risk sharing mechanism for
projects similar to the CCT has been presented to achieve win-win service outcomes.
Chapter 5 The Australian PPP Experience
131
5.5 Chapter 5 Summary
This chapter has studied the development of PPP in Australia by analysing two highly
profiled cases: The Southbank Education and Training Precinct in Brisbane and the Cross
City Tunnel in Sydney. The obstacles encountered in these cases have been highlighted,
and measures have been suggested for future projects that may encounter similar
problems. It was found that projects should be delivered by the most suitable
procurement method. And value for money should be a key reason for delivering
projects by PPP. It was also found that risk is sometimes unfairly allocated amongst
parties. Instead equitable risk allocation should be achieved. In theory, the risk should
go to the party best able to handle it. It is believed that through valuable previous
experiences, PPP projects can be better implemented in future.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
132
CHAPTER 6
DIFFERENT PERSPECTIVES ON PROCURING PUBLIC
WORKS PROJECTS IN HONG KONG AND AUSTRALIA
6.1 Chapter 6 Introduction
6.2 The Public Sector’s Perspective
6.3 The Private Sector’s Perspective
6.4 The Researcher’s Perspective
6.5 Chapter 6 Summary
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
133
6.1 Chapter 6 Introduction
This chapter presents the findings from thirty-five interviews conducted in Hong Kong
and Australia with experts involved with Public Private Partnership (PPP) projects. The
findings from these interviews were analysed according to the perspectives of the public
sector, private sector and researchers. Within each of these categories, the findings from
Hong Kong and Australian interviewees were further compared.
6.2 The Public Sector’s Perspective
6.2.1 Selecting respondents
The target public sector respondents of the interviews were practitioners with experience
in PPP of senior level and authority who have had experience. A total of fourteen
interviews were conducted with experts from the public sector. Seven interviews were
conducted in each jurisdiction. Amongst the seven interviews conducted in Hong Kong,
two were from Administration Departments (one of the interviewees previously
represented a Works Department), three were from Works Departments (one of which
previously represented an Administration Department and the other also holds a position
at a local institute), two of the interviewees were from Non Governmental Organisations
(NGO) (both had previously acted for different Works Departments).
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
134
The Australian interviewees consisted of three government officials and four specialist
advisers from the private sector. The government officials interviewed are from local
state education and treasury departments. When arranging the interviews in Australia, it
was found that the state governments tended to employ advisers from the private sector to
act on their behalf in providing advice and expertise for selecting and monitoring the PPP
project consortia. Therefore four advisers from the private sector were also selected for
interview. Their roles were solely on behalf of the public sector hence their responses can
also be regarded as the public sector’s view. Background details of these experts are
shown in Tables 6.1 and 6.2 for Hong Kong and Australian interviewees respectively.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
135
Table 6.1 List of interviewees from the public sector in Hong Kong
No. Position of Interviewee Organisation of Interviewee Experience of Interviewee
PU1 Assistant Director Administration Department Produced many PPP guidelines and conducted research.
PU2 Permanent Secretary
Administration Bureau
(previously Works Department)
Involved with initiating PPP projects in a works
department he previously worked for.
PU3 Director
Works Department
(previously Administration Bureau)
Involved with on-going PPP projects.
PU4 Assistant Director Works Department
Involved with on-going PPP projects.
PU5 Senior Quantity Surveyor Works Department / Local
Professional Institute
Founder of a PPP research working group for his
institute.
PU6 Executive Board Member NGO (previously Works
Department)
Involved with initiating PPP projects in a works
department he previously worked for.
PU7 Executive Director NGO (previously Works
Department)
Involved with initiating PPP projects in a works
department he previously worked for.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
136
Table 6.2 List of interviewees from the public sector in Australia
No. Position of Interviewee Organisation of Interviewee Experience of Interviewee
PU8 Executive Director
Education Department His department initiated a social PPP project of which he
was responsible for the overall delivery.
PU9 Director
Treasury Department Involved with delivering many PPP projects, producing
guidelines, training, courses and research.
PU10 Executive Manager
Treasury Department Involved with delivering many PPP projects, producing
guidelines, training, courses and research.
PU11 Executive Director
Transaction Adviser Acted as governments’ adviser for many PPP projects,
managing the tender, evaluation, negotiation and award.
PU12 Partner
Legal Adviser Acted as the governments’ legal adviser for many PPP
projects.
PU13 Head
Finance Adviser Acted as the governments’ financial adviser for many
PPP projects.
PU14 Director
Finance Adviser Acted as the governments’ financial adviser for many
PPP projects.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
137
6.2.2 Interview findings
Table 6.3 shows a summary of the responses to each question given by the fourteen
interviewees. The number of times that each response was given was tallied. Where the
response was only given once it was believed to be insignificant for further analysis. For
the responses given more than once, these were tabulated and further analysed as shown
in Tables 6.4 to 6.9. The numbers in brackets represent the number of times the response
was mentioned by interviewees.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
138
Table 6.3 Summary of responses from public sector interviewees
Hong Kong Interviewees Australian Interviewees PU1 PU2 PU3 PU4 PU5 PU6 PU7 Total PU8 PU9 PU10 PU11 PU12 PU13 PU14 Total 1. Have you conducted any research looking at local case studies? And if so, could you share your insights? Local case studies 1 4 International case studies 3 2 Other research conducted 5 5 Not mentioned 2 2 2. How would you compare PPP with traditional procurement methods? Using a Public Sector Comparator 2 0 Longer tendering/negotiation for PPP 1 1 Government act as supervisor in PPP 1 0 Traditional method accepted as norm 1 0 Each project is unique 2 0 Difference in payment mechanism 1 0 PPP projects gain private sector’s added efficiency/expertise/management skills
2 2
PPP projects delivered faster 1 0 PPP utilises private sector finance/difference in finance structure
1 4
PPP tend to be large project sums 1 0 Difference in risk profile 0 1 Operational differences 0 1 Management differences 0 1 PPP projects have a more transparent process
0 1
PPP considers whole life cycle cost 0 1
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
139
More parties involved in PPP 0 1
3. Which type of project do you feel is best suited to use PPP? Link between performance and payment 1 0 Each project unique 1 0 Economically viable 3 3 Value for Money 1 0 Large operating element/cost 2 0 Performance easily measured 1 2 Mutual benefits for all parties 1 0 Economic infrastructure 0 1 Scope for innovation 0 3 High project costs 0 2 Any nature 0 2 Sufficient risk transfer 0 2 4. What do you feel are the key performance indicators in a PPP project? Project performance 1 2 Resources saved 2 0 Contractor’s performance 2 2 Traditional KPIs: Cost, time, quality 3 1 Risk Management 1 2 Public acceptance 1 0 Value for money achieved 0 1 Service outcomes 0 1 Contract terms 0 4 Client satisfaction 0 1 Payment mechanism performed 0 1
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
140
5. In general, what do you think are the critical success factors leading to successful PPP projects? Champion 1 3 Large project capital value 1 0 Well prepared contract/document 2 1 Partnership spirit/commitment/trust 2 2 Transparent process 2 1 Project objectives well defined 3 3 Public consultation 3 1 Appropriate risk allocation 4 1 Large operating element 1 0 Development potential 1 0 Economically viable 1 2 Effective negotiations between parties 0 1 Competitive procurement process 0 5 Government support 0 2 Skilled and experienced parties 0 4 Clear milestones 0 3 Initiate project 0 1 Value for money 0 2 6. Does your organisation have any in-house guidance/practice notes? Yes 3 6 No 4 0 Refer to others 2 1
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
141
6.2.2.1 Research on local case studies
Table 6.4 shows the responses of Question 1 “Have you conducted any research looking
at local case studies?” that were given more than once. The findings show that three
different responses were given by Hong Kong interviewees and four were given by the
Australians. Amongst the four responses given by the Australian interviewees, three were
the same as those given by the Hong Kong interviewees. The response which was given
most by both groups of interviewees was “Other research conducted”, mentioned five
times for each. This finding showed that irrespective of geographical locations the
interviewees tended to conduct other research besides case studies on PPP.
The response “Local case studies” was mentioned four times by the Australians. It is
possible that because Australia has had much experience in conducting PPP projects, they
do not need to look else where to learn from the experience of others, instead they can
refer to their own projects as reference material. As mentioned previously the Victoria
state in Australia for example has a large range of guidance materials on the public
domain which other states can refer to when conducting PPP projects (Partnerships
Victoria, 2008b).
On the other hand the Hong Kong interviewees mentioned “International case studies”
three times showing there need to learn from the experience of others. The Efficiency
Unit of the Hong Kong Special Administrative Region (HKSAR) government has also
been known to be interested in international case studies. They have also published a
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
142
number of case study reports for PPP projects in the United Kingdom and Australia
(Efficiency Unit, 2008c). The Australians also mentioned this response two times. From
the interviews it was found that the involvement in research was “Not mentioned” twice
by each group of interviewees.
Table 6.4 Question 1 - Have you conducted any research looking at local case
studies?
Hong Kong Interviewees Australian Interviewees
Other research conducted (5) Other research conducted (5)
International case studies (3) Local case studies (4)
Not mentioned (2) Not mentioned (2)
International case studies (2)
6.2.2.2 Comparing PPP with traditional procurement methods
Table 6.5 shows the responses mentioned more than once by both groups of interviewees
for Question 2 “How would you compare PPP with traditional procurement methods?”
Three and two different responses were mentioned more than once by the Hong Kong
and Australian interviewees respectively. For all three responses mentioned by the Hong
Kong interviewees each was mentioned twice.
Mentioned the most by Australian interviewees was “PPP utilises private sector
finance/difference in finance structure” which was mentioned four times. This finding
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
143
shows the importance of the different financing structure provided by PPP projects.
Although finance should not be the main reason for adopting PPP projects, undoubtedly,
financial drive is still an attractive factor to governments, hence this response was
unsurprising.
Mentioned by both groups of interviewees was the response “PPP projects gain private
sector’s added efficiency/expertise/management skills”. This response was also
mentioned twice by the Australian interviewees. From previous literature it has also been
recorded that one of the main advantages of involving the private sector is to add value to
public projects in terms of their efficiency, expertise and management skills when
compared to those of the public sector (Yescombe, 2008; Carrillo et al., 2007; Leiringer,
2006).
Other response mentioned by the Hong Kong interviewees included “Using a Public
Sector Comparator”, which was also mentioned by the Efficiency Unit (2003a) of the
HKSAR government as necessary whenever public money is involved. Also “Each
project is unique” was mentioned by the Hong Kong interviewees too.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
144
Table 6.5 Question 2 - How would you compare PPP with traditional procurement
methods?
Hong Kong Interviewees Australian Interviewees
Using a Public Sector Comparator (2)
PPP utilises private sector
finance/difference in finance structure
(4)
PPP projects gain private sector’s
added efficiency/expertise/
management skills (2)
PPP projects gain private sector’s
added efficiency/expertise/
management skills (2)
Each project is unique (2)
6.2.2.3 Projects best suited to use PPP
The Interviewees were asked to answer “Which type of project do you feel is best suited
to use PPP?” in Question 3. Table 6.6 shows their responses that were mentioned more
than once. The results showed that only one similar response was mentioned by both
groups of interviewees. This was “Economically vaible” which was mentioned three
times by both groups of interviewees and also mentioned the most. The private sector
parties are businessmen, so for them to participate in PPP projects there must be
reasonable financial benefits foreseeable for them. Partnerships Victoria (2001) explains
how developing a business case is a key step in the decision-making process. This is
where the project is fully scoped and the risks and costs are identified to develop a cost-
benefit analysis, as well as to test the net benefit of the proposal.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
145
The Hong Kong interviewees suggested only one more criteria for PPP projects, which
was “Large operating element/cost” mentioned twice. One typical feature of PPP projects
is that the consortium is normally responsible for the operation and maintenance of the
project. Without this element PPP projects would be similar to projects procured
traditionally. Therefore the operation part must constitute a reasonable proportion of the
project. Grimsey and Lewis (2004) listed a number of public private business models
prior to the more general term PPP, many of these emphasised the operation element of
the structure within its name, showing the highly important role in these arrangements
including: Operate and Maintain (O&M); Operate Maintain and Manage (OM&M); Build
Transfer Operate (BTO); Build Operate Transfer (BOT); Build Own Operate Remove
(BOOR); Build Own Operate Transfer (BOOT); Lease Renovate Operate Transfer
(LROT); Design Build Finance Operate (DBFO); Design Build Finance Operate Manage
(DBFOM); Build Own Operate (BOO) etc.
Other response given by the Australian interviewees included “Scope for innovation”
(Eaton et al. 2006) which was mentioned three times. Also, mentioned twice each by the
Australians included “Performance easily measured” (Partnerships Victoria 2001), “High
project value” (HM Treasury 2003), “Any nature” and “Sufficient risk transfer” (Jin and
Doloi 2008). These features forming suitable PPP projects have been previously recorded
by other researchers as well.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
146
Table 6.6 Question 3 - Which type of project do you feel is best to use PPP?
Hong Kong Interviewees Australian Interviewees
Economically viable (3) Economically viable (3)
Large operating element/cost (2) Scope for innovation (3)
Performance easily measured (2)
High project value (2)
Any nature (2)
Sufficient risk transfer (2)
6.2.2.4 Key performance indicators in PPP projects
The interviewees were also asked to answer Question 4 “What do you feel are the key
performance indicators in a PPP project?” (Table 6.7). Amongst the responses received,
three were mentioned more than once by the Hong Kong interviewees and four by the
Australian interviewees.
The response “Contract terms” was mentioned the most at four times by the Australian
interviewees. In Australia high priority is given to the contract component of projects
procured by PPP. Guidelines have also been published on this aspect (Partnerships
Victoria 2008c). The response mentioned the most by Hong Kong interviewees was
“Traditional KPIs: Cost, time, quality”. Probably due to the lack of experience in PPP
projects (not including BOT type projects), the Hong Kong interviewees did not
commonly come up with any responses that were specifically related to PPP projects
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
147
solely. Only one response was raised by both groups of interviewees, this was
“Contractor’s performance” which was mentioned twice by each group of the
interviewees.
Also mentioned twice by the Australian interviewees were the responses “Project
performance” and “Risk Management”. The performance of the contractor and project
are items which would definitely be mentioned in the contract documents, these again
confirm the importance of the contract to the Australian interviewees. Many studies have
been conducted on the importance of risks in PPP projects (Akbiyikli and Eaton, 2004; Li
et al., 2004; Li et al., 2005a; Shen and Wu, 2005). One of the main reasons for
implementing public projects by PPP is also for risk transfer, therefore to classify the risk
management as a performance indicator is also reasonable.
Another response mentioned by Hong Kong interviewees was “Resources saved”. PPP
projects are normally only conducted after they have been proved to be a cheaper
alternative to traditionally procured projects. This is normally conducted via the Public
Sector Comparator (Efficiency Unit, 2003a; Partnerships Victoria, 2008b).
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
148
Table 6.7 Question 4 - What do you feel are the key performance indicators in a PPP
project?
Hong Kong Interviewees Australian Interviewees
Traditional KPIs: Cost, time, quality
(3)
Contract terms (4)
Contractor’s performance (2) Contractor’s performance (2)
Resources saved (2) Project performance (2)
Risk Management (2)
6.2.2.5 Critical success factors leading to successful PPP projects
Question 5 “In general, what do you think are the critical success factors leading to
successful PPP projects?” received the most variation of responses from the interviewees
(Table 6.8). This probably indicated that there are many ways for PPP projects to achieve
success.
For responses that were mentioned more than once, there were six from the Hong Kong
interviewees and nine for the Australian interviewees. Amongst these only two were
similar for both groups of interviewees, these included “Project objectives well defined”
which was mentioned three times by each group of respondents and “Partnership
spirit/commitment/trust” mentioned twice by each group of interviewees. As mentioned
by the Efficiency Unit (2008d) and the Queensland Government (2008b) the
objectives/output specification of a PPP project must be well defined. The importance of
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
149
partnership spirit was also identified by Gunnigan and Eaton (2006).
Mentioned the most frequently by Australian interviewees was “Competitive procurement
process” (Jefferies et al., 2002) at five times, followed by “Skilled and experienced
parties” (Drew, 2005) at four times, “Champion” (Efficiency Unit, 2008b) and “Clear
milestones” (Civic Exchange et al., 2005) both three times and “Economically viable”
(Chege, 2001), “Government support” (Qiao et al., 2001) and “Value for money” (Heald,
2003) all twice.
Mentioned the most by Hong Kong interviewees was “Appropriate risk allocation” (Li et
al., 2005a) at four times, “Public consultation” (Kanakoudis et al., 2007) at three times
and “Well prepared contract/document” (Partnerships Victoria, 2008c) and “Transparent
process” (United Nations Economic Commission for Europe, 2004) both at two times.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
150
Table 6.8 Question 5 - In general, what do you think are the critical success factors
leading to successful PPP projects?
Hong Kong Interviewees Australian Interviewees
Appropriate risk allocation (4) Competitive procurement process (5)
Public consultation (3) Skilled and experienced parties (4)
Project objectives well defined (3) Project objectives well defined (3)
Well prepared contract/document (2) Champion (3)
Transparent process (2) Clear milestones (3)
Partnership spirit/commitment/trust
(2)
Partnership spirit/commitment/trust
(2)
Economically viable (2)
Government support (2)
Value for money (2)
6.2.2.6 In-house guidance/practice notes
For Question 6 “Does your organisation have any in-house guidance/practice notes?” it
was found that the majority of the interviewees (six out of seven) in Australia responded
“Yes”, whereas only three interviewees in Hong Kong agreed (Table 6.9).
Four Hong Kong interviewees responded “No” and two responded “Refer to others”.
This finding has shown that the Australians were much more likely to have their own
guidance materials, whereas for the Hong Kong interviewees the responses varied.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
151
Australia has implemented many more PPP projects compared to Hong Kong; hence they
can also be regarded as much more experienced. The Victoria state in Australia alone has
implemented seventeen projects under the Partnerships Victoria arrangement
(Partnerships Victoria, 2008a) as mentioned previously. On the other hand, not
considering the previous projects conducted by BOT, Hong Kong has only completed a
couple of PPP projects.
Table 6.9 Question 6 - Does your organisation have any in-house guidance/practice
notes?
Hong Kong Interviewees Australian Interviewees
No (4) Yes (6)
Yes (3)
Refer to others (2)
6.2.3 Section 6.2 summary
This section has studied the public sector’s perspective on procuring public works
projects via findings from fourteen interviews conducted in Hong Kong and Australia.
Government officials and advisers with experience in PPP projects and research were
invited to answer six questions related to the implementation.
The results found that interviewees from both jurisdictions had conducted some kind of
research in the area and had looked at international cases. This finding has shown that
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
152
governments in both jurisdictions have shown an interest in other sources of information
besides real cases and also both are keen to learn from international experiences.
Therefore other governments can also consider using a similar approach if they have not
already done so.
Both groups of interviewees also found that the main difference between PPP and
traditional projects is that in a PPP project there is the added advantage of the private
sector’s efficiency/expertise/management skills involved. Therefore other governments
could consider whether this added advantage is required from the private sector when
they consider whether or not to opt for the PPP model in their public work projects. The
interviewees from Hong Kong also suggested using the Public Sector Comparator as an
indicator to determine the preference between the methods. Other criteria recommended
by the Australian interviewees were the private sector financing and finance structure of
the project. Again these could be used as indications to which method to opt for.
The interviewees were asked which projects would be suitable to use PPP; both groups
suggested that an economically viable project would be crucial. Another important
feature according to the Australian interviewees is scope for innovation.
It was suggested by both groups of interviewees that the contractor’s performance would
be the key performance indicator in a PPP project. The Hong Kong interviewees also
suggested that the traditional key performance indicators such as cost, time and quality
are also important. The Australian interviewees suggested that the contract terms should
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
153
be considered. These findings are valuable for measuring the performance of a PPP
project for both the public and private sectors.
Common critical success factors mentioned by both groups of interviewees included the
project objectives being well defined and a partnering spirit/commitment/trust. These
factors should be considered by all parties before the project begins to ensure that they
are achieved. The Hong Kong interviewees also felt strongly that an appropriate risk
allocation would achieve success in the project. For the Australian interviewees a
competitive procurement process was the most important success factor.
Lastly it was found that all the interviewees from Australia and some of the ones from
Hong Kong had a practice of having their own organisation guidance/practice notes. This
practice is highly recommended and especially useful for individuals and companies that
are inexperienced with the PPP practice.
A large number of differences were observed between the findings from the two
jurisdictions. This result is logical as each jurisdiction will differ in practice, culture,
geographical location, experience, tradition, politically, economically, socially etc.
Hence it is of interest to compare these differences.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
154
6.3 The Private Sector’s Perspective
6.3.1 Selecting respondents
The target private sector respondents of the interviews were practitioners with experience
in PPP of senior level and authority within the private sector. A total of fourteen
interviews were conducted, with seven interviews conducted in each jurisdiction.
Interviewees of different backgrounds were purposely selected to compare the similarities
and differences within the private sector. This would make the findings even more
representable if common findings are derived even though their backgrounds are so
diverse.
Amongst the seven interviews conducted in Hong Kong, four of the interviewees work
for local companies whereas the other interviewees each work for a Japanese, French and
Australian company respectively. These companies comprise of a property developer,
three construction companies, an exhibition company, a law firm and a service provider.
Most of the Australian interviewees work for companies of their own country. Again the
majority (four out of seven) of these are construction companies. The other three
companies include a project management company, a bank and a credit rating company.
Details of these experts are shown in Tables 6.10 and 6.11 for Hong Kong and Australian
interviewees respectively.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
155
Table 6.10 List of Interviewees from the private sector in Hong Kong
No. Position of Interviewee Organisation of Interviewee Experience of Interviewee
PR1 Project Advisor Local Property Developer
Strong interest in PPP, previously bid for several PPP
projects but unsuccessful.
PR2 Deputy General Manager Japanese Construction Company
working in Hong Kong
Involved with the design and construction of several PPP
projects.
PR3 General Manager Local Exhibition Company
Previously a general manager for a social PPP project.
PR4 Engineering Director French Construction Company
working in Hong Kong
Involved with the design and construction of several PPP
projects.
PR5 Executive Director Local Construction Company
Conducted PPP projects in other countries.
PR6 Managing Partner Australian Law Firm working in
Hong Kong
Acted as legal adviser for PPP projects in other countries.
PR7 Commercial Manager Local Service Provider
Involved with an on-going PPP project.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
156
Table 6.11 List of Interviewees from the private sector in Australia
No. Position of Interviewee Organisation of Interviewee Experience of Interviewee
PR8 Executive Manager
Local Construction Company Involved with the design and construction of many PPP
projects.
PR9 Manager
Local Construction Company Involved with the design and construction of many PPP
projects.
PR10 Manager
Local Construction Company Involved with the design and construction of many PPP
projects.
PR11 Manager
Local Construction Company Involved with the design and construction of many PPP
projects.
PR12 Director Local Project Management
Company
Acted as the project director for many PPP projects.
PR13 Head
Local Bank One of the main financiers of PPP projects globally.
PR14 Managing Director
American Credit Rating Company Advised bidders on PPP projects.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
157
6.3.2 Interview findings
Table 6.12 shows a summary of the responses to each question given by the fourteen
interviewees. The number of times that each response was given was tallied. Where the
response was only given once it was believed to be insignificant for further analysis. For
the responses given more than once, these were tabulated and further analysed as shown
in Tables 6.13 to 6.14. The numbers in brackets represent the number of times the
response was mentioned by interviewees.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
158
Table 6.12 Summary of responses from private sector interviewees
Hong Kong Interviewees
Australian Interviewees
PR1 PR2 PR3 PR4 PR5 PR6 PR7 Total PR8 PR9 PR10 PR11 PR12 PR13 PR14 Total
1. Which PPP projects has your company been involved in? Local projects 3 5 Local and international projects 4 2
2. Please describe the implementation process in these projects. Increase competition 1 0 Reduce competition 0 2
Refer to Efficiency Unit Guidelines 1 0 Government and authority co-promoted 1 0 Consultations before project start 1 0 Not initiated by Treasury Department 1 0 Pre-qualification exercise 1 0 Government focus on administration 1 0 Based on Victoria Partnerships projects 0 1 Costly bidding process 0 1 Banks take lead in project transaction 0 1 Same as traditional 0 1 Consist of specialists 0 1
3. What were the major reasons for adopting PPP in these projects? Private sector expertise 5 1 Developing countries 1 0 Private sector’s cost and time certainty 1 1 Win-win situation 1 0 Value for money 3 0 Private sector efficiency 2 1 Transfer of risks 1 2 Large projects 0 1 Government need 2 4
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
159
4. How do you think PPP compares with traditional procurement methods? Better integration 2 0 Private sector involvement 1 0 Benefits for early completion 1 0 Better value for money 2 1 Performance based 2 0 Consider project life 1 0 Differentiated product 1 1 Larger projects 0 3 Increased efficiency and speed 2 2
More rigorous tendering process 1 2
Paid according to schedule 0 1
Different risk profiles 0 3
Large emphasis on relationships 0 1
No difference in terms of rating 0 1
More complex 0 1
More politically challenging 0 1
5. Which type of project would your company be most interested in applying PPP? All 5 1 Any except transportation 1 0 Projects with subsidy 1 0 Projects with appropriate risk allocation 1 1 Projects with prospect of success 2 1 Where land is not issue 1 0 No staffing issues 1 0 Recurrent expenditure already budgeted 1 0 Projects with business case 1 1
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
160
Economic infrastructure 0 3 Projects with clear objectives 0 1 Social infrastructure 0 3
6. What do you feel are the key performance indicators in a PPP project? Economics 4 5 Risk 1 3 Control 1 0 Refer to Efficiency Unit guide 1 0 Contract terms (operating parameters) 2 1 Traditional KPIs (time, cost and quality) 1 0 Public sector comparator 1 0 Service 1 0 Time 0 2
7. In general, what do you think are the critical success factors leading to successful PPP projects? Economically viable 2 2 No Legislative Council interference 1 0 Good relationships / partnering spirit 2 2 Clear project objectives / timeline 3 2 Private party possess expertise 1 1 Appropriate allocation of risks 2 1 Government support (champion) 2 1 Transparent process 1 0
Flexibility for innovation 0 1
Robust contract 0 1
Positive media 0 2
8. Does your company have any in-house guidance/practice notes on PPP implementation?
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
161
Yes 0 1 Other materials available 4 4 No 3 2
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
162
6.3.2.1 Local and international experience in conducting PPP projects
Table 6.13 presents the findings that were mentioned more than once by the interviewees
for Question 1 “Which PPP projects has your company been involved in?” The results
showed that interviewees from both jurisdictions mentioned two responses more than once.
Four interviewees from Hong Kong and two interviewees from Australia mentioned that
they had participated in both “Local and international projects”. On the other hand five
and two interviewees in Australia and Hong Kong respectively mentioned that they had
been involved with “Local projects” only.
The findings showed that the majority of Hong Kong interviewees had participated in
projects both locally and abroad, whereas most of the Australian interviewees had
participated in local projects only. Another observation is that none of the interviewees
had participated in international projects only. Although Hong Kong has had a long
history in BOT projects it has still conducted far fewer of these types of projects compared
to Australia. Therefore most of the PPP expertise utilised in Hong Kong today has been
sourced from overseas rather than trained locally. On the other hand in Australia, their
extensive use of PPP has meant that they have built up resources of their own to cater for
these projects (Infranews, 2006).
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
163
Table 6.13 Question 1 - Which PPP projects has your company been involved in?
Hong Kong Interviewees Australian Interviewees
Local and international projects (4) Local projects (5)
Local projects (3) Local and international projects (2)
6.3.2.2 Implementation process of PPP projects
Thirteen aspects related to the implementation of PPP projects were mentioned by the
interviewees. Only one of these was mentioned twice by the Australian interviewees:
“Reduce competition” (Table 6.14). The two Australian interviewees described that there
has been too much competition in the procurement process of PPP projects. They further
suggested that the number of competitors involved in the process should be reduced. The
transaction process for PPP projects can be a costly and lengthy process. Hence the
competitors need certainty that they have a high chance of winning the bid before they
enter the process. Fewer competitors will assure them of their chances of success.
Publications have also reported the problems related to the transaction process of PPP
projects causing the private sector to become reluctant to continue participating in them
(Ahadzi and Bowles, 2004).
Table 6.14 Question 2 - Please describe the implementation process in these projects.
Hong Kong Interviewees Australian Interviewees
Reduce competition (2)
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
164
6.3.2.3 Major reasons for adopting PPP projects
As shown in Table 6.15 four and two reasons were mentioned more than once by the
Hong Kong and Australian interviewees respectively. Amongst these reasons one was
mentioned by both groups of interviewees: “Government need”. This reason was
mentioned the most at four times by the Australian interviewees, whereas only twice by
the Hong Kong interviewees. PPP in Australia were originally initiated due to financial
shortages for the state governments to deliver public infrastructure and services (English
and Guthrie, 2003). The findings from the interviews have shown that many of the
experts still regard this as an important reason to adopt PPP.
Mentioned the most by Hong Kong interviewees was “Private sector expertise” at five
times. The Hong Kong government has been able to enjoy a comfortable financial
reserve. Hence other advantages such as the added benefits of the private sector’s
expertise and efficiency have been motivators to adopt PPP projects (Borzel and Risse,
2005). Therefore “Private sector efficiency” was also mentioned by the Hong Kong
interviewees twice. Other reasons mentioned by the Hong Kong interviewees include
“Value for money”, which has also been studied by previous researchers (Grimsey and
Lewis, 2005; Heald, 2003).
In Australia “Transfer of risks” was also mentioned twice by the interviewees. Risk is
probably the most extensively studied aspect of the PPP method. Numerous studies have
already been conducted on risk identification, allocation, treatment etc. (Akbiyikli and
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
165
Eaton, 2004; Chan et al., 2008; Hodge, 2004; Jin and Doloi, 2008; Li et al., 2004; Li et al.,
2005b; Ng and Loosemore, 2007; Shen et al., 2006; Shen and Wu, 2005; Sun et al., 2008;
Thomas et al., 2003; Thomas et al., 2006; Wibowo and Kochendörfer, 2005)
Table 6.15 Question 3 - What were the major reasons for adopting PPP in these
projects?
Hong Kong Interviewees Australian Interviewees
Private sector expertise (5) Government need (4)
Value for money (3) Transfer of risks (2)
Private sector efficiency (2)
Government need (2)
6.3.2.4 Comparing PPP with traditional procurement methods
Four differences mentioned more than once between PPP and traditional procurement
methods were suggested by each group of interviewees (Table 6.16). Only one of these
was similar for both groups of interviewees: “Increased efficiency and speed”. Efficiency
and speed have been known as reasons for implementing public works projects by PPP
(Borzel and Risse, 2005; Bovaird, 2004). The public sector tends to be more laid back
compared to the private sector that tends to be more motivated due to commercial reasons
(Sharma, 2007).
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
166
Other differences mentioned more than once by the Hong Kong interviewees include
“Better integration”, “Better value for money” and “Performance based”. Again these
features have been highlighted by previous researchers. Nisar (2007) also agreed that a
key aspect of PPP is the integration between partners. Many studies have also been
conducted in the topic of value for money, as technically public projects are procured by
the PPP model only when value for money can be achieved (Grimsey and Lewis, 2005;
Heald, 2003; Nisar, 2007). A key feature of PPP projects is that there is a heavy emphasis
on project and private sector performance (Dhaene, 2008).
The Australian interviewees also mentioned three other differences. Mentioned three
times include “Larger projects” and “Different risk profiles”. Shen et al. (2006)
mentioned that the best PPP projects should be ones that are mega-scale. As mentioned
previously in this paper, risks are an important part of PPP projects throughout the
lifecycle. The last difference mentioned twice was a “More rigorous tendering process”,
which is another key feature of PPP projects (Ahadzi and Bowles, 2004).
Table 6.16 Question 4 - How do you think PPP compares with traditional procurement
methods?
Hong Kong Interviewees Australian Interviewees
Better integration (2) Larger projects (3)
Better value for money (2) Different risk profiles (3)
Performance based (2) More rigorous tendering process (2)
Increased efficiency and speed (2) Increased efficiency and speed (2)
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
167
6.3.2.5 Projects of interest to the private sector
Table 6.17 shows the types of PPP projects that the interviewees would be most interested
in. Five of the Hong Kong interviewees mentioned “All”. And two suggested “Projects
with prospect of success”. The private sector participates in PPP projects not because
they have to but for commercial benefits hence it is logical that they expect the project to
be successful.
Three Australian interviewees mentioned that they would be interested in “Transportation
projects” and “Social infrastructure”. Public works projects normally comprise of either
economic or social infrastructure. Economic projects are normally those where the
income is collected directly from the end-user, for example toll roads, railways etc. On
the other hand social infrastructure projects are normally supported by a regular fee paid
by the government, for example schools, hospitals etc. Both of these were mentioned by
the Australian interviewees indicating that most types of public works projects are
supported by the private sector.
Similarly the findings found that the Hong Kong interviewees were interested in all PPP
projects. The main difference is probably that Hong Kong’s experience in PPP projects
has mainly been in economic infrastructure (Mak and Mo, 2005), hence they did not
further break public works projects up into categories. Whereas, Australia has conducted
a larger range of different natured PPP projects hence they tend to split them to into
categories.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
168
Table 6.17 Question 5 - Which type of project would your company be most interested
in applying PPP?
Hong Kong Interviewees Australian Interviewees
All (5) Economic infrastructure (3)
Projects with prospect of success (2) Social infrastructure (3)
6.3.2.6 Key performance indicators of PPP projects
Table 6.18 shows the key performance indicators mentioned by the interviewees. The top
key performance indicator identified by both groups of interviewees was “Economics”.
This key performance indicator was mentioned four times by the Hong Kong
interviewees and five times by the Australian interviewees. Money has often been used
as a measure to quantify performance. Especially for the private sector their motives for
participating in PPP projects are related often to commercial aspects (Sharma, 2007).
Other key performance indicators mentioned by the Hong Kong interviewees include
“Contract terms (operating parameters)” which was mentioned twice. Contracts can be
used to measure the outputs of a project (Entwistle and Martin, 2005).
The Australian interviewees mentioned “Risk” three times and “Time” twice. Again as
mentioned before risk is an important aspect of the PPP arrangement. On the other hand
time is also a key performance indicator for traditional projects and highly related to the
commercial aspects of the project.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
169
Table 6.18 Question 6 - What do you feel are the key performance indicators in a PPP
project?
Hong Kong Interviewees Australian Interviewees
Economics (4) Economics (5)
Contract terms (operating parameters) (2) Risk (3)
Time (2)
6.3.2.7 Critical success factors leading to successful PPP projects
Table 6.19 shows that the Hong Kong interviewees mentioned five critical success factors
more than once whereas the Australian interviewees mentioned four. Three of these
critical success factors were similar, including “Clear project objectives / timeline”
mentioned three times by the Hong Kong interviewees and twice by the Australian
interviewees, “Economically viable” and “Good relationships / partnering spirit”
mentioned twice by both groups of interviewees. The importance of clear project
objectives and timeline has also been incorporated in to governmental guidance notes
(Efficiency Unit, 2003a). In Zhang’s (2005a) study he looked at several groups of
potential critical success factors, one of these was identified as economic viability.
Partnering spirit between the parties is a vital aspect of PPP projects (Gunnigan and Eaton,
2006).
Other critical success factors also mentioned twice by the Hong Kong interviewees
include “Appropriate allocation of risks” and “Government support (champion)”. Again
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
170
risks are mentioned as being highly important in the PPP arrangement. In addition,
Zhang (2005a) derived from his study that government support is the second most
significant critical success factor under the group of “Favourable investment
environment”.
The Australian interviewees also mentioned “Positive media” twice. The effect of
positive media is incredibly important for the success of a PPP project. In the case of the
Cross City Tunnel in Sydney, Australia the negative portrayal of the media caused the
effects of its faults to intensify (Chan et al., 2008).
Table 6.19 Question 7 - In general, what do you think are the critical success factors
leading to successful PPP projects?
Hong Kong Interviewees Australian Interviewees
Clear project objectives / timeline (3) Clear project objectives / timeline (2)
Economically viable (2) Economically viable (2)
Good relationships / partnering spirit (2) Good relationships / partnering spirit (2)
Appropriate allocation of risks (2) Positive media (2)
Government support (champion) (2)
6.3.2.8 In-house guidance/practice notes
Table 6.20 shows that both groups of interviewees had mentioned “Other materials
available” instead of in-house guidelines/practice notes for PPP implementation. This
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
171
finding is probably because the private sector tends to follow the guidelines of their client
the public sector hence there is no need for them to derive their own guidance materials.
Governmental guidance notes are readily available for the general public’s use
(Efficiency Unit, 2008e; Partnerships Victoria, 2008d). Although so it was found that the
organisations of most of the interviewees had conducted some kind of research in the
topic of PPP to broaden their knowledge on the process. Some of the interviewees
mentioned “No” to this final question (three in Hong Kong and two in Australia) showing
the lack of need for in-house guidance/practice notes.
Table 6.20 Question 8 - Does your company have any in-house guidance/practice
notes on PPP implementation?
Hong Kong Interviewees Australian Interviewees
Other materials available (4) Other materials available (4)
No (3) No (2)
6.3.3 Section 6.3 summary
This section has studied the private sector’s perspective on procuring public works
projects via findings from fourteen interviews conducted in Hong Kong and Australia.
Experts with experience in PPP projects and research were invited to answer eight
questions related to the implementation. The results found that interviewees from Hong
Kong had participated in projects both locally and internationally, whereas the Australian
interviewees had participated in local projects mainly. Australia has conducted many
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
172
more PPP projects compared to Hong Kong hence they have built up and trained their
own resources and expertise of time. Hong Kong, on the other hand, may not have the
necessary talents hence it is important for them to either gain overseas experience or
import their expertise. With the increasing number of PPP projects conducted in Hong
Kong there is a need to start training their own people.
The implementation process of PPP projects can vary depending on the project itself,
hence a large range of descriptions were given by the interviewees. Only reduce
competition was repeatedly mentioned. Reducing competition in the tendering process
would mean that the chance of winning would be greater for the bidding party. Hence in
future projects the government should consider a suitable number of competitors in the
tendering process to avoid the private sector’s loss in terms of time, money and especially
lack of confidence in conducting future PPP projects.
Only one reason for adopting PPP projects was mentioned by both groups of interviewees
which was government need. Other reasons mentioned by the Hong Kong respondents
included private sector expertise, value for money and private sector efficiency. All these
reasons have been mentioned in many literature pieces for being typical features and
attractions of the PPP model hence the findings have further verified previous studies.
Another major reason for adopting PPP is for risk transfer as mentioned by the Australian
interviewees; this topic is probably the most discussed. It is likely that Hong Kong is
familiar with delivering public works projects themselves hence are comfortable with the
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
173
practice. Therefore they did not highlight risk transfer as a reason for adopting PPP
projects as they are less aware of the risks. But according to previous cases around the
word, the HKSAR government should consider an appropriate risk allocation in order for
public projects to be delivered more effectively.
The common difference between PPP and traditional methods highlighted by both groups
of interviewees was the increased efficiency and speed in PPP projects. Added value has
become the foremost reason to apply PPP projects these days. Governments have
realised that the private sector tends to be more motivated and driven due to commercial
reasons. Other differences highlighted by the Hong Kong interviewees include: better
integration; better value for money; and performance based. Mentioned by the Australian
interviewees include: larger projects; different risk profiles; and more rigorous tendering
process.
The findings also showed that the interviewees were interested in all sorts of projects. In
Hong Kong the interviewees did not further categorise PPP projects, probably because
there have been few PPP projects in Hong Kong and they have tended to be
transportation related hence the variation has not been large. In Australia, on the other
hand there have been various types of PPP projects conducted; hence the interviewees
categorised them into social or economic types of projects. The preference for
conducting these two groups of projects was similar.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
174
Both groups of interviewees agreed that economic performance indicators were the most
appropriate. The Hong Kong interviewees also recommended that the contract terms
could be used to measure performance. The Australian interviewees also mentioned risk
and time as key performance indicators. Therefore the key performance indicators for
PPP projects should focus heavily on the economics.
Five critical success factors were mentioned more than once by Hong Kong interviewees
and four by the Australian interviewees. Amongst these three were mentioned by both
groups of interviewees: clear project objectives/timeline; economically viable; and good
relationship / partnering spirit. Clear objectives and timeline allows the private sector to
keep on track over such a long project period. In PPP projects typically the consortium’s
responsibility is over 30 years instead of a normal design and construct contract which
will span over maybe just 5 years. Hence clear objectives and timeline are particularly
important. These should be well defined before the project commences. An
economically viable project is also vital as the private sector is driven by commercial
motives. In order to sustain such a long term relationship over the project period good
relations / partnering spirit is also vital. The parties involved could consider utilising
tools such as partnering workshops to increase their communication and understanding.
Other critical success factors mentioned by Hong Kong interviewees include appropriate
allocation of risks and government support (champion). The Australian interviewees also
mentioned positive media as a critical success factor. Finally, it was realised that the
interviewees all had access to some kind of PPP guidance materials.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
175
6.4 The Researcher’s Perspective
6.4.1 Selecting respondents
The target respondents of the interviews were researchers with experience in PPP who
neither belonged to nor acted for the public or private sectors. A total of seven interviews
were conducted, with three in Hong Kong and four in Australia.
Amongst the three interviewees from Hong Kong, two were members of the Legislative
Council in Hong Kong (one with a law background and the other with an engineering
background). The third interviewee was an academic and researcher in PPP from a local
university. Similarly the Australian interviewees were all active researchers of the PPP
topic from local universities. Due to the limited number of PPP projects conducted in
Hong Kong (not including BOT type), fewer academics are involved with PPP related
research, hence two legislative councilors were selected, both have been known to
publicly mention their interests in PPP. As their role tends to represent the general public
rather than the public or private sector, it was believed that their position would be similar
to the academics interviewed. Background details of these experts are shown in Tables
6.21.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
176
Table 6.21 List of researcher interviewees
No. Jurisdiction Position of Interviewee Organisation of Interviewee Experience of Interviewee
R1 Hong Kong Member of Legislative Council
(Legal background)
Legislative Council of the
HKSAR Government
Commissioned a working group to
analyse the feasibility of PPP.
R2 Hong Kong Member of Legislative Council
(Engineering background)
Legislative Council of the
HKSAR Government
Supporter of PPP and included in his
campaign to push the development.
R3 Hong Kong Professor
Local University Conducted his own PhD in the area of
PPP and active researcher.
R4 Australia Professor
Local University Active researcher.
R5 Australia Professor
Local University Involved with producing
governmental guidelines, training,
courses and research for PPP.
R6 Australia Professor
Local University Active researcher.
R7 Australia Professor
Local University Involved with producing
governmental guidelines, training,
courses and research for PPP.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
177
6.4.2 Interview findings
Table 6.22 shows a summary of the responses to each question given by the seven
interviewees. The number of times that each response was given was tallied. Where the
response was only given once it was believed to be insignificant for further analysis. For
the responses given more than once, these were tabulated and further analysed.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
178
Table 6.22 Summary of interview findings with researchers from Hong Kong and Australia
Hong Kong Interviewees
Australian Interviewees
R1 R2 R3 R4 R5 R6 R7 Total 1. Have you conducted any research looking at local case studies? Yes 7 2. How would you compare PPP with traditional procurement methods? Clear project objectives 1 PPP utilises public resources 1 PPP is a partnership arrangement 2 PPP projects have high tendering / transaction costs 2 PPP projects tend to be completed on-time 1 Income of PPP projects can be dependent on market 1 Construction costs of PPP projects are more expensive 1 PPP considers maintenance 1 Different risk profiles 2 More expensive for private sector to borrow money 1 Private sector more innovative / efficient 2 PPP focuses on service delivery 1 PPP improves public procurement 1
3. Which type of project do you feel is best suited to use PPP? Government lacks funding 2 Project dependent 2 Projects with few competitors 1 Large projects 2 Expensive projects 1 Quantifiable income stream 1 Scope for innovation 1
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
179
Toll ways 1 4. What do you feel are the key performance indicators in a PPP project? Profits 1 Project dependant 2 Traditional KPIs: Quality, time and cost 1 Should be defined by private sector 1 Service outcomes 1 Contract compliance 1 Proactive managers 1 5. In general, what do you think are the critical success factors leading to successful PPP projects? Clear project objectives 2 Timeline and milestones foreseeable 1 Transparent process 2 Public consultation 1 Project dependent 2 Clear legal structure and regulation mechanism 1 Market need 2 Technical and financial capability of concessionaire 1 Champion with authority 1 Roles clearly defined and related to each other 1 Need to budget money for project amount 1 Right timing 1 Strong and robust contract 1 Commitment of partners 1
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
180
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
181
6.4.2.1 Research on local case studies
The first question that the interviewees were asked to answer was “Have you conducted
any research looking at local case studies?” All interviewees responded that they had
conducted PPP case studies and research both locally and overseas. In general, it can be
summarised that the interviewees are active experienced researchers in the field of PPP.
6.4.2.2 Comparing PPP with traditional procurement methods
The interviewees were further asked “How would you compare PPP with traditional
procurement methods?” Thirteen different responses were given, but only four of these
were mentioned more than once. These responses which were each mentioned twice
included: “PPP is a partnership arrangement”; “PPP projects have high tendering /
transaction costs”; “Different risk profiles”; and “Private sector more innovative /
efficient”.
Mentioned by the Hong Kong interviewees only was “PPP is a partnership arrangement”
and “PPP projects have high tendering / transaction costs”. The Efficiency Unit of the
HKSAR government has been actively involved in pushing the movement of PPP in
Hong Kong. In one of their latest guidelines they mention the importance of the
partnership arrangement “A PPP is a contractual arrangement involving the private sector
in the delivery of public services. As the name suggests, this is based on a partnership
approach, where the responsibility for the delivery of services is shared between the
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
182
public and private sectors, both of which bring their complementary skills to the
enterprise” (Efficiency Unit, 2008a).
A common feature which is found in PPP projects is the high costs of tendering and
transaction (Zhang, 2005). Hughes et al. (2001) reported that the costs associated with
tendering are seen by the construction industry in the United Kingdom to be significant,
typically quoted as ½ – 1% of turnover; and 2 – 3% of bid price for PPP bids.
Furthermore results from their study showed that building services contractors had
calculated that up to 15% of their turnover could be accounted for by “unnecessary”
tendering processes.
For the other two responses which were mentioned more than once (“Different risk
profiles” and “Private sector more innovative / efficient”), these were mentioned by
interviewees from both jurisdictions. As mentioned previously in this section one of the
main reasons for implementing public projects by PPP is also for risk transfer. The
National Stadium for the Beijing 2008 Olympic Games in China is an example of how
key risk factors were appropriately passed to the private sector via the PPP model (Liu et
al., 2007). Without doubt this project has been highly profiled hence the pressure to
perform well increased the risks associated. The four most critical risks of this project
included 1) The irrational construction schedule for a project of this size and complexity;
2) Possible cost overruns due to inexperience in delivering similar previous projects in
China; 3) Small and limited market for large scale sporting events in China; and 4) Lack
of operational experience in similar previous projects in China. These factors were all
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
183
related to the management, design, construction and operation of the project, which are
also aspects that are considered to be best handled by the private sector; whereas the
public sector’s expertise lies in the area of public administration.
Another major difference observed between traditionally procured projects and PPP
projects is the added innovation and efficiency from the private sector in PPP projects.
The private sector in general tends to be more motivated due to financial drive, whereas
the public sector parties are experts in policy making rather than innovation and
efficiency. Studies have shown that by adopting PPP in public works projects, innovation
and efficiency is achieved due to the private sector’s contribution (Leiringer, 2006)
6.4.2.3 Projects best suited to use PPP
The interviewees were asked “Which type of project do you feel is best suited to use
PPP?” in Question 3. Three out of the eight responses were mentioned twice by the
interviewees, these included “Government lacks funding” and “Project dependent” which
were mentioned by the Hong Kong interviewees and “Large projects” mentioned by the
Australian interviewees. In many jurisdictions which first started to adopt PPP, private
financing was a major incentive for governments to adopt PPP, such as the United
Kingdom and the Victoria state of Australia. Therefore there has been a common
association that PPP projects are about financing.
An example, showing that Hong Kong does not need private sector financing can be
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
184
shown by the recent Hong Kong Zhuhai Macau bridge project where the governments of
these three jurisdictions have agreed to undertake the project costs without private sector
input. The HKSAR government alone has agreed to cover approximately 50% of the
costs, approximately HK$15.3 billion (South China Morning Post, 2008).
The Hong Kong interviewees also mentioned that the suitability criteria of projects to be
procured by PPP would be unique depending on the project. The Australian interviewees
mentioned that large projects would be suitable for the PPP model. Similarly, Price (2002)
suggested that for some types of projects, especially those that are large or complex, a
joint venture between the public and private sectors may prove advantageous.
6.4.2.4 Key performance indicators in PPP projects
Only one response was mentioned more than once at twice by the interviewees for
Question 4 “What do you feel are the key performance indicators in a PPP project?” This
was “Project dependant” which was mentioned by interviewees from both jurisdictions.
Six other responses were given by the interviewees for this question.
6.4.2.5 Critical success factors leading to successful PPP projects
For the final question, interviewees were asked “In general, what do you think are the
critical success factors leading to successful PPP projects?” This question received the
most number of responses probably indicating that there are many critical success factors
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
185
that could lead to successful PPP projects. But amongst these responses only four were
mentioned more than once by the interviewees, these included “Clear project objectives”
which was mentioned by the Hong Kong interviewees only and “Transparent process”,
“Project dependent” and “Market need” which were all mentioned by interviewees from
both jurisdictions.
Zhang (2006) mentioned in his study that the public client often does not have clear
objectives and priorities in infrastructure development through PPP. This often impairs
the project development process. The client should clearly define its objectives and
establish their relative importance and make sure the private sector shares these
objectives. The probability of successful project delivery increases dramatically when
both sectors have a common vision of the project to be developed. In the Partnerships
Victoria Policy (2000), it mentions that where there is private sector involvement in
major public infrastructure projects, the choice of contractors should be through a
rigorous and transparent system of public tendering.
Similar to the responses for Questions 3 and 4, the interviewees also mentioned that the
critical success factors for PPP projects would be dependent on the project due to their
uniqueness. Lastly, Partnerships Victoria (2001) also mentioned that a key characteristic
of Partnership Victoria projects (i.e. PPP projects conducted under the Partnership
Victoria’s supervision) includes market appetite. This implies that the project creates a
genuine business opportunity which is likely to attract a sufficient number of private
parties and create an effective and competitive bidding process.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
186
6.4.3 Section 6.4 summary
This section has presented the findings of seven interviews conducted by experienced
researchers in the field of PPP from Hong Kong and Australia. The interviewees were
asked to answer five questions related to the implementation of PPP. It was found that
both groups of interviewees had conducted case studies and research in the field of PPP
locally and internationally.
When considering the differences between traditionally procured projects and PPP
projects, both groups of interviewees agreed that “Different risk profiles” and “Private
sector more innovative / efficient” were the main differences. Other major differences
between the two approaches mentioned by the Hong Kong interviewees included “PPP is
a partnership arrangement” and “PPP projects have high tendering / transaction costs”.
The types of project best suited to use PPP were not the same according to the two groups
of researchers.
The Hong Kong interviewees recommended that “Government lacks funding” and
“Project dependent” are suitable criteria for PPP projects, whereas, the Australian
researchers believed that “Large projects” would be more ideal.
Amongst the key performance indicators highlighted by the interviewees “Project
dependant” was the only response given by both groups of interviewees.
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
187
From the large number of critical success factors suggested “Transparent process”,
“Project dependent” and “Market need” were the common ones highlighted by both
groups of interviewees. Hong Kong interviewees also believed that “Clear project
objectives” would be an important critical success factor.
6.5 Chapter 6 Summary
The findings presented in this chapter have summarised the views of experienced
practitioners from the public sector, private sector and renowned researchers from Hong
Kong and Australia.
It was found that the public sector and researcher interviewees from both jurisdictions
had conducted research in PPP and looked at international cases. From their experiences
other governments should also adopt a similar practice. Although both jurisdictions had
conducted research in PPP, the Australian private sector had conducted many more PPP
projects than those in Hong Kong.
Many of the private sector interviewees believed that competition in the tendering
process should be reduced. Hence governments should consider what the suitable
number of bidders for a project should be.
The public sector and researcher interviewees agreed that the main difference between
PPP and traditional projects is that in a PPP project there is the added advantage of the
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
188
private sector’s efficiency/expertise/management skills involved. The researcher
interviewees also added that PPP projects and traditional projects differ in risk profiles.
On the other hand, the private sector highlighted that the main difference is that PPP can
increase the efficiency and speed of projects.
The public sector interviewees agreed that projects which are economically viable are
those suitable to be procured by PPP. Whereas the private sector believed that projects
are normally procured by PPP due to government need, but all types of projects should be
suitable.
The public sector interviewees believed that the contractor’s performance would be the
key performance indicator for PPP projects. Whereas, the private sector interviewees
believed that economic performance indicators are the most important. On the other hand,
the researcher interviewees believed that each project is dependent so the key
performance indicators would be as well.
The project objectives being well defined and a partnering spirit/commitment/trust were
the critical success factors mentioned by both the public and private sector interviewees.
The private sector interviewees also added that the project must be economically viable.
The researcher interviewees highlighted some further critical success factors including
projects having a transparent process and there being a market need (this factor is very
closely linked with the project being economically viable as mentioned by the private
sector interviewees).
Chapter 6 Different Perspectives on Procuring Public Works Projects in Hong Kong and Australia
189
Most of the public and private sector interviewees had their own organisation
guidance/practice notes. This practice is highly recommended.
The views presented in this chapter are believed to be of interest to all practitioners
involved with PPP projects. The findings also form a comparative study between the
views of PPP practitioners in Hong Kong and Australia, and draw similarities irrespective
of the differences in jurisdictions.
Chapter 7 Suitability of Procuring Large Public Works by PPP
188
CHAPTER 7
SUITABILITY OF PROCURING
LARGE PUBLIC WORKS BY PPP
7.1 Chapter 7 Introduction
7.2 Collection of Research Data
7.3 Survey Results
7.4 Chapter 7 Summary
Chapter 7 Suitability of Procuring Large Public Works by PPP
189
7.1 Chapter 7 Introduction
This chapter will specifically consider whether Public Private Partnership (PPP) should
be used to procure public works projects in Hong Kong by studying the attractive and
negative factors for adopting PPP. A questionnaire survey was conducted with industrial
practitioners in Hong Kong and Australia, and compared to findings obtained by Li (2003)
in the United Kingdom. The respondents were requested to rank the importance of
fifteen attractive factors and thirteen negative factors for adopting PPP.
7.2 Collection of Research Data
An empirical questionnaire survey was undertaken in Hong Kong and Australia from
October 2007 to December 2007 to analyse the attractive and negative factors of adopting
PPP. The target survey respondents of the questionnaire included all industrial
practitioners from the public, private and other sectors. These respondents were
requested to rate their degree of agreement against each of the identified attractive and
negative factors according to a five-point Likert scale (1 = Least Important and 5 = Most
Important). The information collected regarding the attractive and negative factors will
help to achieve objective 1 “Identify the benefits, difficulties and critical success factors
of PPP” and objective 6 “Evaluate the findings collected to determine a best practice
framework for implementing PPP in Hong Kong” of this research study.
Chapter 7 Suitability of Procuring Large Public Works by PPP
190
Target respondents were selected based on two criteria: 1) They must possess adequate
knowledge in the area of PPP; and 2) They must have hands-on experience with PPP
projects, experience in conducting PPP research or have followed very closely with the
development of PPP. Survey questionnaires were sent to 95 target respondents in Hong
Kong and 80 target respondents in Australia. It was anticipated that some of these target
respondents would have colleagues and personal connections knowledgeable in the area
of PPP to participate in this research study as well; hence some of the respondents were
dispatched five blank copies of the survey form. A total of 34 completed questionnaires
from Hong Kong and 11 from Australia were returned representing response rates of 36%
and 9%, respectively. The lower response rate in Australia was expected as the
questionnaire was administered from Hong Kong, hence geographical complications
were perceived. But as this study mainly focuses on Hong Kong, the responses received
from Australia were used for reference only, similarly so were the results from Li’s
survey (2003).
It must be noted that the number of responses in the Kendall’s concordance analysis may
not always be 34 and 11 for Hong Kong and Australia respectively, as these respondents
may not have ranked all the factors. Therefore in some cases not all responses may have
been suitable for subsequent statistical analyses.
The questionnaire respondents comprised experienced practitioners from the industry. As
shown in Figures 7.1 and 7.2 approximately half of the respondents in Hong Kong and
Australia possessed twenty-one years or above of industrial experience. Figures 7.3 and
Chapter 7 Suitability of Procuring Large Public Works by PPP
191
7.4 provide a breakdown of questionnaire respondents who have been involved with PPP
projects.
Given the few Build Operate Transfer (BOT)/PPP projects conducted in Hong Kong, it
was a surprise to find that 33% of the respondents gained previous experience. Without
doubt some of these may have had experience with local BOT projects or PPP projects
overseas, but still the experience of these respondents confirmed the quality of the
responses from the survey conducted. In addition, amongst those respondents who have
acquired experience with PPP projects, 10% had previously been involved with at least
five projects.
In Australia, many more PPP projects have been conducted so it was unsurprising to find
that approximately 90% of the respondents have participated in PPP projects before, with
two thirds of these respondents having participated with at least five PPP projects. Once
again this reassures the value and reliability of the findings.
Chapter 7 Suitability of Procuring Large Public Works by PPP
192
0
10
20
30
40
50
60
70
80
90
100
≦ 5 6 - 10 11 - 15 16 - 20 21 ≧Years
Perc
enta
ge
Figure 7.1 Histogram showing the number of years of working experience in
construction industry for the Hong Kong survey respondents
0
10
20
30
40
50
60
70
80
90
100
≦ 5 6 - 10 11 - 15 16 - 20 21 ≧Years
Perc
enta
ge
Figure 7.2 Histogram showing the number of years of working experience in
construction industry for the Australian survey respondents
Chapter 7 Suitability of Procuring Large Public Works by PPP
193
0
10
20
30
40
50
60
70
80
90
100
0 1 2 3 4 > 4
Number of PPP projects
Perc
enta
ge
Figure 7.3 Histogram showing the number of PPP projects the Hong Kong survey
respondents have been involved with
0
10
20
30
40
50
60
70
80
90
100
0 1 2 3 4 > 4
Number of PPP projects
Perc
enta
ge
Figure 7.4 Histogram showing the number of PPP projects the Australian survey
respondents have been involved with
Chapter 7 Suitability of Procuring Large Public Works by PPP
194
7.3 Survey Results
The attractive and negative factors for adopting PPP were assessed from different
perspectives of the Hong Kong, Australia and the United Kingdom (results obtained by
Li (2003) from his survey) respondent groups. The means for each administrative system
were calculated and ranked in descending order of importance as shown in Tables 7.1 and
7.2. Although a large number of differences were observed between the findings of the
three jurisdictions. This result is logical as each jurisdiction will differ in practice,
culture, geographical location, experience, tradition, politically, economically, socially
etc. Hence it is of interest to compare these differences.
7.3.1 Ranking of attractive factors for adopting PPP
Fifteen attractive factors for adopting PPP were rated by the respondents (Table 7.1).
The findings showed that the top three attractive factors ranked in Hong Kong were:
(1) Provide an integrated solution (for public infrastructure / services);
(2) Facilitate creative and innovative approaches; and
(3) Solve the problem of public sector budget restraint.
The first and second attractive factors ranked by Hong Kong respondents were also
ranked identically by respondents in Australia. Ranked third in Australia was “Save time
Chapter 7 Suitability of Procuring Large Public Works by PPP
195
in delivering the project”. The results show that both Hong Kong and Australia ranked
efficiency-related attractive factors more importantly. Although financial drive in general
is a major reason for adopting PPP, these respondents did not rank it as the top attractive
factor.
Since Hong Kong has enjoyed abundant financial reserve in hand and budget surplus over
the past few years, these have allowed Hong Kong to pay for their public works projects
upfront. The government officials generally did not see the need to borrow money when
they could provide the cash cheaper. Hence efficiency was a more important attractive
factor that could really induce Hong Kong to adopt PPP.
Similarly in Australia, although financial reasons may have previously been the reason
for adopting PPP this is no longer the case. The Victoria State in Australia first utilised
PPP in order to deliver PPP projects using the private sectors’ money, but as the financial
situation has improved and more experience has been gained, the Australians have
realised other benefits of adopting PPP rather than for financial reasons alone.
On the contrary, in the United Kingdom economic related factors were ranked much
higher in year 2003. The top attractive factor ranked in the United Kingdom was
“Transfer risk to the private partner”. Ranked second was the same attractive factor that
came third in Hong Kong. And ranked third was “Non recourse or limited recourse to
public funding”. Similar to Australia’s Victoria State, the United Kingdom also
Chapter 7 Suitability of Procuring Large Public Works by PPP
196
introduced PPP initially due to financial reasons. But the situation today may also no
longer be the same. The results from Li’s (2003) study were obtained five years before
those presented in this study, hence certain changes in the adoption of PPP and the
attitude of practitioners are anticipated. Therefore as mentioned before the results in Li’s
(2003) study can only be used as a reference.
The first attractive factor ranked in Hong Kong “Provide an integrated solution (for
public infrastructure/services)” was also positioned first in the ranking for Australia. The
rankings have demonstrated that this attractive factor was regarded as equally important
to them irrespective of location.
PPP is an integrated solution in that a private consortium is responsible for all the
functions of design, building, financing, operation and maintenance. This bundling can
allow the partners to take advantage of a number of efficiencies and increase economies
of scale and scope (European Commission Directorate, 2003). For instance, the
contractor’s detailed knowledge of the project design and the materials utilised allows it
to develop a tailored maintenance plan over the project life that anticipates and addresses
needs as they occur, thereby reducing the risk that issues will go unnoticed or unattended
and then deteriorate into much more costly problems. In the United Kingdom, this factor
was ranked eighth showing a medium level of importance only.
Chapter 7 Suitability of Procuring Large Public Works by PPP
197
The second attractive factor ranked by respondents from Hong Kong and Australia was
“Facilitate creative and innovative approaches”. In the United Kingdom, Li (2003) found
that this attractive factor was rated seventh place amongst fifteen attractive factors for
PPP. This observation manifests that Hong Kong and Australia has a much larger urge
for having creativity and innovation in PPP projects compared to the United Kingdom. In
the United Kingdom there has been a tendency for the local government to deliver
packages of projects which are very similar, such as for schools. The creativity
difference between these projects is often minimal. Nevertheless, practitioners in Hong
Kong have expressed in public the need and importance for creativity and innovation in
PPP projects (Kwan, 2005; Ho, 2005).
The third attractive factor rated by respondents from Hong Kong “Solve the problem of
public sector budget restraint”, was also positioned highly at second place in the ranking
of respondents from the United Kingdom. Therefore, both administrative systems
perceived this attractive factor as highly important for launching PPP projects.
The financing of public sector projects has been recognised as one of the key initial
driving forces for implementing PPP schemes internationally. Many experienced
practitioners in PPP believe that PPP brings about many other attractions besides
financing, and that financial motivations should not be taken as the sole reason for
adopting PPP. However, financial reasons are frequently the initial attractive factors for
administrative systems adopting PPP. This financial attractive factor is undoubtedly very
appealing for governments across the world especially when public money is to be spent
Chapter 7 Suitability of Procuring Large Public Works by PPP
198
amongst competing needs. Therefore, it is not surprising that both groups of respondents
have rated this attractive factor highly, but with a subtle difference in emphasis.
Contrastingly, the Australian respondents ranked this factor thirteenth amongst the fifteen
attractive factors. This factor could imply that Australia currently does not face any
major restraints in public sector budget. But the views of more respondents from
Australia should be sought before confirming this conclusion as there were only eleven
respondents from the survey conducted in Australia.
The mean values for the attractive factors as rated by Hong Kong respondents ranged
from 2.94 to 3.79. This observation has reflected that the variation in their responses are
relatively small, only 0.85 for Hong Kong. In Australia and the United Kingdom the
means ranged from 2.36 to 4.45 and 1.82 to 3.98 respectively. The corresponding
differences in means were 2.09 and 2.16 respectively. The differences in means were
shown to be much higher for the survey conducted in Australia and the United Kingdom
compared to Hong Kong. This finding shows that the Hong Kong respondents rated the
fifteen attractive factors much more consistently, whereas in Australia and the United
Kingdom the respondents showed a much larger variation.
As the respondents were asked to rate the 15 attractive factors according to a Likert scale
from 1 to 5 (1 = Least Important and 5 = Most Important), a value above “3” would
represent that the attractive factor is of importance. Amongst the attractive factors only
Chapter 7 Suitability of Procuring Large Public Works by PPP
199
one was ranked below “3” in the Hong Kong rank. This attractive factor was
“Technology transfer to local enterprise” which scored “2.94” and was also ranked
bottom in Hong Kong. This is probably because the immediate results of this attractive
factor could not be seen and therefore the other fourteen attractive factors were relatively
more favourable. In Australia and the United Kingdom (Li, 2003) this attractive factor
was rated “3.18” and “1.82” respectively, showing that the first set of respondents
disagreed but the latter set of respondent agreed with those respondents from Hong Kong.
The other fourteen attractive factors in the Hong Kong rank were rated a score between
“3” and “4”.
In addition, on top of those factors the respondents were asked to rate, they were also
given the opportunity to add others which would be of importance, but they did not do so.
Chapter 7 Suitability of Procuring Large Public Works by PPP
200
Table 7.1 Mean scores and rankings for the attractive factors of PPP Attractive Factors
Hong Kong Australia
United Kingdom
(Li, 2003)
N Mean Rank N Mean Rank N Mean Rank
a. Solve the problem of public sector budget restraint 34 3.65 3 11 2.73 13 61 3.86 2
b. Provide an integrated solution (for public infrastructure / services) 33 3.79 1 11 4.45 1 61 3.05 8
c. Reduce public money tied up in capital investment 33 3.48 6 11 2.36 15 61 3.58 4
d. Cap the final service costs 34 3.26 10 11 3.55 6 61 3.56 5
e. Facilitate creative and innovative approaches 34 3.74 2 11 4.36 2 61 3.36 7
f. Reduce the total project cost 33 3.09 14 11 3.45 7 61 2.97 10
g. Save time in delivering the project 34 3.21 13 11 4.18 3 61 2.75 12
h. Transfer risk to the private partner 34 3.65 4 11 3.36 9 61 3.98 1
i. Reduce public sector administration costs 33 3.39 8 11 2.82 12 61 2.53 14
j. Benefit to local economic development 34 3.56 5 11 3.18 11 61 2.62 13
k. Improve buildability 33 3.24 11 11 3.73 5 61 3.03 9
l. Improve maintainability 34 3.32 9 11 4.18 4 61 3.36 6
m. Technology transfer to local enterprise 34 2.94 15 11 3.18 10 61 1.82 15
n. Non recourse or limited recourse to public funding 34 3.21 12 11 2.64 14 61 3.61 3
o. Accelerate project development 34 3.47 7 11 3.36 8 61 2.95 11
N = Number of survey respondents
Chapter 7 Suitability of Procuring Large Public Works by PPP
201
7.3.2 Ranking of negative factors for adopting PPP
Thirteen negative factors for adopting PPP were rated by the survey respondents (Table
7.2). The top three negative factors ranked by Hong Kong respondents included:
(1) Lengthy delays because of political debate;
(2) Lengthy delays in negotiation; and
(3) Very few schemes have actually reached the contract stage (aborted before contract).
In Hong Kong, public works projects are often delayed and complicated by the need for
public consultation; hence it is not surprising that “Lengthy delays because of political
debate” was the highest negative factor ranked by the Hong Kong respondents. This
problem is well known for causing projects to be held back.
For example, the West Kowloon Cultural District project has been cited as a typical
example in Hong Kong where political interference has caused the project to be on hold
for many years (Chan et al., 2007a). Initially there was much political debate within the
Legislative Council as to whether this project should proceed as a PPP, especially
whether the whole project with an estimated cost of US$25 billion (So, 2007) should be
handled by one single consortium instead of half a dozen number of consortia each
sharing the pie. The local government was also alleged to be unclear of the long-term
policy and objectives for this cultural development project, causing much criticism from
the general public. In Australia and the United Kingdom (Li, 2003) this factor was
Chapter 7 Suitability of Procuring Large Public Works by PPP
202
ranked of mediocre importance only at seventh and sixth position respectively, showing
that they do not face the similar problem that Hong Kong does.
Ranked second by respondents in Hong Kong and the United Kingdom (Li, 2003) was
“Lengthy delays in negotiation”. Australia also ranked this factor relatively high at
fourth place. This finding has shown that “Lengthy delays in negotiation” are typical for
PPP projects irrespective of geographical locations. Due to the size and complexity of
PPP projects the procurement process has been know to be lengthy. This can be said to
be a typical feature of PPP projects, therefore only projects that are of appropriate value
and worthiness should consider PPP.
The third negative factor as ranked by Hong Kong respondents was “Very few schemes
have actually reached the contract stage (aborted before contract)”. The high ranking of
this factor coincides with the previous argument about political debate in Hong Kong. As
a result some projects had to be aborted due to political disagreement. This negative
factor was ranked last in Australia and Li’s (2003) survey. The experience of the
Australians and the British in conducting PPP projects is much more plentiful, in that the
respondents did not believe that few schemes would reach the contract stage. Without
doubt they are much more experienced and hence more confident in launching PPP
projects.
Chapter 7 Suitability of Procuring Large Public Works by PPP
203
Another observation manifested that “Less employment positions” and “Reduce the
project accountability” were both ranked within the bottom three of the rankings for all
three jurisdictions. The respondents shared the same views on the negative factors they
believed to be of less threat. The low ranking of “Less employment positions” has shown
that employment has not been affected irrespective of how projects are procured. The
main purpose of introducing PPP projects is not to “Reduce the project accountability”;
hence it was logical that all respondents perceived that this negative factor was less
significant. Therefore these two negative factors were thus common for PPP projects
irrespective of the geographical differences.
For the negative factors rated by respondents in Hong Kong the mean values ranged from
2.79 to 3.82. The variation in responses was 1.03. On the other hand, in Australia and
the United Kingdom it was found that the mean values obtained ranged from 1.36 to 3.45
and 1.71 to 3.86 respectively. The variations in responses were 2.09 for Australia and
2.15 for the United Kingdom. Both variations were higher than that for Hong Kong. It
was also found that in general these negative factors were rated higher by Hong Kong
respondents. It can thus be interpreted that the Australian and British respondents found
that these negative factors were less of a challenge. This finding is logical as discussed
previously Australia and the United Kingdom are much more experienced in delivering
PPP projects compared to Hong Kong.
Similarly to the rating of the attractive factors, the respondents were also asked to rate the
thirteen negative factors according to a Likert scale from 1 - 5 (1 = Least Important and 5
Chapter 7 Suitability of Procuring Large Public Works by PPP
204
= Most Important), therefore a value above “3” would represent that the negative factor is
of importance. The results show that in Hong Kong there were two negative factors
below a score of “3”. On the other hand in Australia and the United Kingdom there were
ten and eleven respectively below “3”. Again this consolidates the fact that the
Australians and British are much more confident at conducting PPP projects, hence they
are less conservative. The two negative factors ranked below “3” for Hong Kong were
the ones discussed previously that were ranked low by all three sets of respondents.
These negative factors were “Less employment positions” and “Reduce the project
accountability”, which both scored only 2.79.
In addition, on top of those factors the respondents were asked to rate, they were also
given the opportunity to add others which would be of importance, but they did not do so.
Chapter 7 Suitability of Procuring Large Public Works by PPP
205
Table 7.2 Mean scores and rankings for the negative factors of PPP
Negative Factors
Hong Kong Australia The United Kingdom
(Li, 2003)
N Mean Rank N Mean Rank N Mean Rank
a. Reduce the project accountability 34 2.79 12 11 2.00 11 61 1.90 11
b. High risk relying on private sector 34 3.09 10 11 2.27 8 61 2.22 10
c. Very few schemes have actually reached the contract stage (aborted before contract) 34 3.41 3 11 1.36 13 61 1.71 13
d. Lengthy delays because of political debate 34 3.82 1 11 2.55 7 61 2.48 6
e. Higher charge to the direct users 34 3.26 9 11 2.18 10 61 2.33 8
f. Less employment positions 34 2.79 13 11 1.64 12 61 1.81 12
g. High participation costs 34 3.35 5 11 3.27 2 61 3.53 3
h. High project costs 34 3.03 11 11 2.18 9 61 2.43 7
i. A great deal of management time spent in contract transaction 34 3.29 6 11 2.55 5 61 3.86 1
j. Lack of experience and appropriate skills 33 3.27 8 11 3.45 1 61 2.78 5
k. Confusion over government objectives and evaluation criteria 34 3.41 4 11 3.00 3 61 2.81 4
l. Excessive restrictions on participation 34 3.29 7 11 2.55 6 61 2.32 9
m. Lengthy delays in negotiation 33 3.45 2 11 2.91 4 61 3.68 2
*N = Number of survey respondents
Chapter 7 Suitability of Procuring Large Public Works by PPP
206
7.3.3 Agreement of the survey respondents
As shown in Table 7.3, the Kendall’s coefficient of concordance (W) for the rankings of
attractive factors was 0.071 and 0.325 for Hong Kong and Australia respectively. The
computed W’s were significant with p = 0.008 and 0.000 respectively. As the number of
attributes considered were above seven, as mentioned previously the Chi-square value
would be referred to rather than the W value. According to the degree of freedom, the
critical value of Chi-square was 23.680 for both groups (Hong Kong and Australia) the
computed Chi-square values were all above the critical value of Chi-square (29.907 and
50.076 respectively). Therefore the assessment by the respondents within each group on
their rankings of attractive factors is proved to be consistent. This finding ensures that
the completed questionnaires were valid for further analysis.
Table 7.3 Results of Kendall’s concordance analysis for the attractive factors of PPP
Hong Kong Australia
Number of survey respondents 30 11
Kendall's coefficient of concordance (W) 0.071 0.325
Chi-square value 29.907 50.076
Critical value of Chi-square 23.680 23.680
Degree of freedom (df) 14 14
Asymptotic significance 0.008 0.000
Note: Only 30 out of 34 responses from Hong Kong were suitable for subsequent
Chapter 7 Suitability of Procuring Large Public Works by PPP
207
statistical analyses.
Table 7.4 shows the Kendall’s concordance analysis for the negative factors of PPP. The
respective W for Hong Kong and Australia was 0.094 and 0.323. The number of
attributes were also above seven hence the Chi-square value was referred to. The critical
value of Chi-square was 21.030 for both groups. The computed Chi-square values were
both higher at 35.968 and 42.591 for Hong Kong and Australia respectively. Hence the
assessment by the respondents within each group on their rankings of negative factors is
proved to be consistent. And this finding also ensures that the completed questionnaires
were valid for further analysis.
Table 7.4 Results of Kendall’s concordance analysis for the negative factors of PPP
Hong Kong Australia
Number of survey respondents 32 11
Kendall's coefficient of concordance (W) 0.094 0.323
Chi-square value 35.968 42.591
Critical value of Chi-square 21.030 21.030
Degree of freedom (df) 12 12
Asymptotic significance 0.000 0.000
Note: Only 32 out of 34 responses from Hong Kong were suitable for subsequent
statistical analyses.
Chapter 7 Suitability of Procuring Large Public Works by PPP
208
7.3.4 The suitability of adopting PPP
With the identification of attractive and negative factors of PPP, these could be identified
as checklists for assessing the suitability/feasibility of using PPP. If the attractive factors
are prevailing in a given project scenario, the use of PPP will be more positive.
Conversely, if the negative factors are dominant PPP might be considered as unsuitable.
Taking the recent Kai Tak cruise terminal project as an example, the fifteen attractive
factors and thirteen negative factors were used as checklists to assess the suitability of
adopting PPP. The Kai Tak site in Hong Kong is the exact location that the old airport
had been for 73 years (Encyclopedia.com, 2009). With the construction of the new,
larger and more advanced airport at Chep Lap Kok on Lantau Island of Hong Kong, the
Kai Tak airport was replaced in 1998. Since the Kai Tak site has been vacant, there has
been on-going debate on how this valuable city centered piece of land could be utilised.
Obviously, in a populated city like Hong Kong, residential development is the foremost
attraction to the private sector developers. But due to previous criticisms from the
general public in projects such as the Cyberport, the local government has been keen to
avoid the interpretation that the public and private sectors show collusion. The Cyberport
project is a technological park on Hong Kong Island developed by a single developer on
condition that they were given the adjacent property rights. The developer concerned
Chapter 7 Suitability of Procuring Large Public Works by PPP
209
made unbelievably high profits from the selling of these properties. Unfortunately, less
attention has been given to the Cyberport project (Tsang, 2008).
The local government will be spending HK$7.2 billion to design and build the Kai Tak
cruise terminal. The facilities will be leased to a private operator whilst the local
government retains ownership of the site and terminal. The first berth is anticipated to be
in 2013 (Cheung et al., 2008). Although it has been confirmed that this project will be
delivered by more traditional methods, it’s suitability to adopt PPP is still analysed
according to the checklist of attractive and negative factors presented in this chapter.
Table 7.5 shows a checklist of the attractive and negative factors which can be recognised
from this project. The results show that nine out of the fifteen attractive factors were
observed for the Kai Tak cruise terminal project. This represents 60% of the attractive
factors which include:
b. Provide an integrated solution (for public infrastructure / services);
d. Cap the final service costs;
e. Facilitate creative and innovative approaches;
h. Transfer risk to the private partner;
i. Reduce public sector administration costs;
j. Benefit to local economic development;
k. Improve buildability;
l. Improve maintainability;
Chapter 7 Suitability of Procuring Large Public Works by PPP
210
m. Technology transfer to local enterprise; and
On the other hand, nine amongst the thirteen negative factors were observed for this
project representing 69%, these include:
b. High risk relying on private sector;
d. Lengthy delays because of political debate;
e. Higher charge to the direct users;
g. High participation costs;
h. High project costs;
i. A great deal of management time spent in contract transaction;
k. Confusion over government objectives and evaluation criteria;
l. Excessive restrictions on participation; and
m. Lengthy delays in negotiation.
In this case, percentage wise the results show that the negative factors of PPP are more
dominant than the attractive factors of PPP. Hence, the use of traditional procurement
methods could be regarded as more suitable than PPP for the Kai Tak cruise terminal
project. This analysis was conducted according to the author’s own perception of the
project only to demonstrate how the checklist could be used. The accuracy of this current
assessment needs further refinement before it can be relied on. For examples, further
study should be carried out to establish the relative weighting of each factor. The
Chapter 7 Suitability of Procuring Large Public Works by PPP
211
intensity of each factor may be different, this will in turn effect whether the attractive or
negative factors are more dominant. Hence it is important that these are identified before
the checklist is used in real life.
Chapter 7 Suitability of Procuring Large Public Works by PPP
212
Table 7.5 Checklist of attractive and negative factors for the Kai Tak cruise terminal project
Attractive Factors Negative Factors a. Solve the problem of public sector budget restraint a. Reduce the project accountability b. Provide an integrated solution (for public infrastructure / services)
b. High risk relying on private sector
c. Reduce public money tied up in capital investment
c. Very few schemes have actually reached the contract stage (aborted before contract)
d. Cap the final service costs d. Lengthy delays because of political debate e. Facilitate creative and innovative approaches e. Higher charge to the direct users f. Reduce the total project cost f. Less employment positions g. Save time in delivering the project g. High participation costs h. Transfer risk to the private partner h. High project costs i. Reduce public sector administration costs i. A great deal of management time spent in contract transaction j. Benefit to local economic development j. Lack of experience and appropriate skills k. Improve buildability k. Confusion over government objectives and evaluation criteria l. Improve maintainability l. Excessive restrictions on participation m. Technology transfer to local enterprise m. Lengthy delays in negotiation n. Non recourse or limited recourse to public funding o. Accelerate project development
Total count 9 Total count 9 Total % 60 Total % 69
Chapter 7 Suitability of Procuring Large Public Works by PPP
213
7.4 Chapter 7 Summary
This chapter presents the findings of an empirical questionnaire survey undertaken in
Hong Kong, Australia and the United Kingdom to study the attractive and negative
factors of conducting PPP projects. The survey respondents were asked to rate fifteen
attractive factors and thirteen negative factors. The results gained from these three
administrative regions were analysed and compared.
The results found that the top three attractive factors in Hong Kong were (1) Provide an
integrated solution (for public infrastructure / services); (2) Facilitate creative and
innovative approaches; and (3) Solve the problem of public sector budget restraint.
These could be interpreted as situations where the use of PPP would be suitable. Similar
results were found in the survey conducted in Australia. Efficiency related factors
appeared to be more attractive to the respondents from Hong Kong and Australia,
whereas in the United Kingdom economic related factors were rated higher. The finding
for Hong Kong coincides with the fact that the local government has been enjoying a
budget surplus in recent years, and has therefore not been pressured for delivering public
projects with their own financial reserves.
The top three negative factors ranked by the respondents from Hong Kong were: (1)
Lengthy delays because of political debate; (2) Lengthy delays in negotiation; and (3)
Very few schemes have actually reached the contract stage (aborted before contract).
Chapter 7 Suitability of Procuring Large Public Works by PPP
214
These could be interpreted as situations where the use of PPP would be less desirable.
The top negative factor was ranked of mediocre importance by the Australians and
British, showing that they do not face the same concerns as Hong Kong. In Hong Kong
this negative factor has been shown to be a problem as demonstrated by the West
Kowloon Cultural District project which was delayed mainly due to political debate. The
second negative factor ranked in Hong Kong was also ranked high by the Australians and
British. This negative factor was therefore seen to be important irrespective of the
geographical differences and could be considered a negative factor specifically for PPP
projects. The third negative factor was ranked bottom by the Australians and British
showing a high level of controversy to the ranking in Hong Kong. This factor appears to
be more of a concern to the Hong Kong respondents. Some delayed projects as discussed
previously are causes towards the low confidence experienced. Whereas in Australia and
the United Kingdom, they are much more experienced at conducting PPP projects and
hence more confident with this type of procurement.
Chapter 8 Implementing Public Private Partnership Projects
215
CHAPTER 8
IMPLEMENTING PUBLIC PRIVATE
PARTNERSHIP PROJECTS
8.1 Chapter 8 Introduction
8.2 Reasons for Implementing PPP Projects
8.3 Factors Contributing to Successful PPP Projects
8.4 Enhancing Value for Money in PPP Projects
8.5 Chapter 8 Summary
Chapter 8 Implementing Public Private Partnership Projects
216
8.1 Chapter 8 Introduction
This chapter studies the reasons, success factors and value for money measures behind
Public Private Partnership (PPP) projects. The findings discussed were obtained from the
same questionnaire survey as described in Chapter 7.
8.2 Reasons for Implementing PPP Projects
This section presents the findings of a study to investigate the reasons for implementing
PPP projects. The same questionnaire survey described in Chapter 7 was used to obtain
data. The survey respondents were asked to rate the importance of nine identified reasons
for implementing PPP projects.
The reasons for implementing PPP projects were assessed from different perspectives of
the Hong Kong, Australia and the United Kingdom (results obtained by Li (2003) from
his survey) respondent groups. The means for each administrative system were
calculated and ranked in descending order of importance as shown in Table 8.1.
Chapter 8 Implementing Public Private Partnership Projects
217
Table 8.1 Mean scores and rankings of the reasons for implementing PPP projects
Reasons
Hong Kong Australia
United Kingdom
(Li, 2003)
N Mean Rank N Mean Rank N Mean Rank
a. Economic development pressure demanding more facilities 33 3.48 2 11 3.64 2 61 3.34 2
b. Political pressure 33 2.79 9 11 2.45 8 61 3.24 4
c. Social pressure of poor public facilities 33 2.88 8 11 3.09 5 61 3.12 5
d. Private incentive 32 3.56 1 11 3.09 4 61 2.57 9
e. Shortage of government funding 33 3.24 6 11 2.64 7 61 3.9 1
f. Inefficiency because of public monopoly and lack of competition 33 3.33 4 11 3.09 3 61 2.98 6
g. High quality of service required 33 3.42 3 11 3.91 1 61 2.7 7
h. Avoid public investment restriction 33 2.97 7 11 2.18 9 61 3.31 3
i. Lack of business and profit generating skill in the public sector 32 3.31 5 11 2.82 6 61 2.62 8
* N = Number of survey respondents
Chapter 8 Implementing Public Private Partnership Projects
218
8.2.1 Agreement of the survey respondents
As shown in Table 8.2, the Kendall’s coefficient of concordance (W) for the rankings of
reasons for implementing PPP projects was 0.076 and 0.239 for Hong Kong and Australia
respectively. The computed W’s for both were significant with p = 0.000. As the number
of attributes considered were above seven, as mentioned previously the Chi-square value
would be referred to rather than the W value. According to the degree of freedom, the
critical value of Chi-square was 15.510 for both groups (Hong Kong and Australia) the
computed Chi-square values were all above the critical value of Chi-square (18.943 and
21.042 respectively). Therefore the assessment by the respondents within each group on
their rankings of reasons for implementing PPP projects is proved to be consistent. This
finding ensures that the completed questionnaires were valid for further analysis.
Table 8.2 Results of Kendall’s concordance analysis of the reasons for implementing
PPP projects
Hong Kong Australia
Number of survey respondents 31 11
Kendall's coefficient of concordance (W) 0.076 0.239
Chi-square value 18.943 21.042
Critical value of Chi-square 15.510 15.510
Degree of freedom (df) 8 8
Asymptotic significance 0.015 0.007
Note: Only 31 out of 34 responses from Hong Kong were suitable for subsequent
statistical analyses.
Chapter 8 Implementing Public Private Partnership Projects
219
8.2.2 Ranking of the reasons for implementing PPP projects
As in Li’s questionnaire, a total of nine reasons for implementing PPP projects were rated
by the respondents. The top three reasons ranked in Hong Kong included:
(1) Private incentive;
(2) Economic development pressure demanding more facilities; and
(3) High quality of service required.
The top reason for implementing PPP projects ranked by respondents from Hong Kong
was “Private incentive”. Obviously practitioners round the world can foresee the
advantages of involving the private sector into conducting public works projects. The
private sector can add value to these projects in many ways such as financially, via
expertise, innovation, risk sharing and above all motivation. This finding has indicated
that the Hong Kong respondents felt that the main reason for implementing public works
projects by PPP is to acquire the added value from the private sector. In Australia and the
United Kingdom this reason for implementing PPP projects was ranked lower at fourth
and ninth place respectively, indicating that those respondents did not feel so strongly to
involve the private sector for their added value.
Ranked second by respondents in Hong Kong, Australia and the United Kingdom was
“Economic development pressure demanding more facilities”. The similar ranking
pattern across the three survey groups represents that the importance of this reason for
implementing PPP projects is applicable irrespective of geographical differences. Hence
Chapter 8 Implementing Public Private Partnership Projects
220
all survey respondents felt that PPP projects are implemented due to economic pressure to
provide more public facilities. The similar ranking pattern could also be a reflection of
the real life situation that the survey respondents have observed. In Hong Kong
particularly there has been a growing phase of rapid infrastructure development, which
the government has opted to use the PPP scheme. These projects include the Shatin to
Central rail link and the Kwun Tong rail extension. The new metro line will consist of
nine stations. Construction will start in 2010 and the two phases of the line will be
completed by 2015 and 2019 (Information Services Department, 2008b).
The third reason for implementing PPP projects ranked by respondents from Hong Kong
was “High quality of service required”. Being an international city, maintaining high
quality in services is important. This feeling was also reflected by the survey respondents,
as they felt that this is also a reason for implementing PPP projects. In Australia and the
United Kingdom this reason for implementing PPP projects was ranked first and seventh
respectively. The findings show that the Australians felt similarly but the British ranked
this reason for implementing PPP projects much lower. Although so, the survey with the
British respondents was conducted a few years ago, hence it is anticipated that with the
increasing projects due to be carried out before the Olympics in 2012, the respondents
might have a different view if this survey was conducted today.
In Australia, the respondents ranked “Inefficiency because of public monopoly and lack
of competition” third. Due to the size, complexity, challenges and long concession period
of PPP projects, they tend to be limited to be conducted by only those very large private
Chapter 8 Implementing Public Private Partnership Projects
221
sector companies. These companies will normally possess sufficient finance, expertise
and skills to implement PPP projects. Therefore for those who are not involved with the
PPP process they may feel that public monopoly and lack of competition exists. This
occurrence is often partially true but then only those capable parties will possess the
power to participate with PPP projects.
Ranked first by British respondents was “Shortage of government funding”. One of the
main reasons for the rise of PPP/Private Finance Initiative (PFI) projects in the United
Kingdom was due to financial resources from the private sector. The PPP/PFI method
was first adopted at a time when the British government was struggling to provide for
public facilities and services (Zhang, 2001). By involving the private sector the
government was able to continue delivering public infrastructure. As a result a heavy
emphasis on finance has always been associated to PPP/PFI projects especially in the
early days of implementation. Along with other benefits as a result of involving the
private sector, finance is often not the only element considered when delivering public
projects these days though.
Third in the United Kingdom rank was “Avoid public investment restriction”. Similar to
the reason discussed previously, this reason holds a strong emphasis on the financial
element of the project. Again it must be considered that the survey conducted with
British respondents was carried out a few years ago. It is likely that when the British
government were still in a tight budgetary condition they would also be more likely to
enforce more budgetary restrictions before approving projects. Hence it is unsurprising
Chapter 8 Implementing Public Private Partnership Projects
222
for this reason to be ranked highly by the British respondents.
The mean values of the reasons for implementing PPP projects as rated by Hong Kong
respondents ranged from 2.79 to 3.56. This observation has reflected that the variation in
their responses are relatively small, only 0.77 for Hong Kong. In Australia and the
United Kingdom the means ranged from 2.18 to 3.91 and 2.57 to 3.90 respectively. The
corresponding differences in means were 1.73 and 1.33 respectively. The differences in
means were much higher for the survey conducted in Australia and the United Kingdom
compared to Hong Kong.
As the respondents were asked to rate the nine reasons for implementing PPP projects
according to a Likert scale from 1 to 5 (1 = Least Important and 5 = Most Important), a
value above “3” would represent that the reason for implementing PPP projects is of
importance. Amongst the reasons for implementing PPP projects only three were ranked
below “3” in the Hong Kong rank. These reasons for implementing PPP projects were
“Political pressure”, “Social pressure of poor public facilities” and “Avoid public
investment restriction” which scored 2.79, 2.88 and 2.97 respectively.
For Australia and the United Kingdom, each had four reasons for implementing PPP
projects rated below “3”. In Australia, two of these were the same as those for Hong
Kong (“Political pressure” and “Avoid public investment restriction” with scores of 2.45
and 2.18 respectively). The other two in Australia were “Shortage of government
funding” and “Lack of business and profit generating skill in the public sector” which
Chapter 8 Implementing Public Private Partnership Projects
223
scored 2.64 and 2.82 respectively. On the other hand in the United Kingdom none were
the same as those in Hong Kong but one was the same as Australia (“Lack of business
and profit generating skill in the public sector” which scored 2.62). The other three
reasons in the United Kingdom were “Private incentive”, “Inefficiency because of public
monopoly and lack of competition” and “High quality of service required” which scored
2.57, 2.98 and 2.7 respectively.
The reason for implementing PPP projects “Political pressure” was rated low by
respondents in both Hong Kong and Australia. Hood and McGravey (2002) claimed that
the PPP development would remain a major political issue. Relatively speaking, Hong
Kong and Australia have less history of PPP implementation compared to the United
Kingdom. Also, they faced less political pressure when the concept was first introduced,
as the practice has been well documented in other developed countries (such as the
United Kingdom) and the political influence of trade unions is minimal. Hence this
reason for implementing PPP projects was not rated highly.
Also rated lowly by respondents from Hong Kong and Australia was “Avoid public
investment restriction”. Again this reason for implementing PPP projects was not rated
highly as both groups of survey respondents did not believe that the public were under
heavy investment restrictions.
Rated low by only the Hong Kong respondents was “Social pressure of poor public
facilities”. The Hong Kong respondents did not feel that the government has been under
Chapter 8 Implementing Public Private Partnership Projects
224
pressure from the society. Hence they rated this reason for implementing PPP projects
lowly. This finding could imply that the respondents felt happy towards the current
standard of public facilities in Hong Kong.
Rated lowly by the Australian respondents only was “Shortage of government funding”.
Although financial drive may have once been the main reason for involving private sector
participation, this is not the case anymore. In Australia, the state governments have
noticed the benefits associated with implementing PPP projects and have developed a
more revolutionary process. The state governments are capable of delivering these
services themselves but instead they choose to involve the private sector to achieve added
value from the private sector for particular public projects.
Rated lowly by the Australian and British respondents was “Lack of business and profit
generating skill in the public sector”, again the Australians and the British have a much
longer history in implementing PPP projects hence their skills in this area are much more
advanced. As a result the public sector has acquired sufficient experience and
competency to deliver these projects well. Therefore the respondents felt that
incapability of the public sector to deliver public projects was not the case.
The British respondents rated “Private incentive” lowly. This contradicts with the finding
achieved from the Hong Kong respondents. The public sector of the United Kingdom is
already well experienced at conducting PPP projects, but they realise their job is to deal
with the administrative procedures rather than act as the developer.
Chapter 8 Implementing Public Private Partnership Projects
225
Also, rated lowly in the United Kingdom survey was “Inefficiency because of public
monopoly and lack of competition” and “High quality of service required”. Again the
experience of the public sector implies that these can be achieved without involving the
private sector.
In addition, on top of those factors the respondents were asked to rate, they were also
given the opportunity to add others which would be of importance, but they did not do so.
8.2.3 Section 8.2 Summary
The findings have shown that in general those reasons ranked high by respondents from
Hong Kong and Australia focused on improving the overall performance of public
projects whereas those that were rated high by the British respondents focused on the
financial aspect of the projects. Ranked in the top three by Hong Kong respondents was
“Private incentive”; “Economic development pressure demanding more facilities”; and
“High quality of service required”. In Australia and the United Kingdom both groups of
respondents also ranked their second reason the same as Hong Kong. In addition, the
Australians also ranked the third reason in Hong Kong first; and “Inefficiency because of
public monopoly and lack of competition” third. In the United Kingdom the first and
third reasons ranked by the respondents was “Shortage of government funding” and
“Avoid public investment restriction” respectively.
The reason “Private incentive” was attractive due to the added value which could be
Chapter 8 Implementing Public Private Partnership Projects
226
applied to public works projects by the private sector. One of the main reasons to adopt
PPP is that the public works project can benefit from the private sector’s expertise,
innovation, motivation and experience. Similar for many governments around the world
“Economic development pressure demanding more facilities” is common. Even though
governments such as Hong Kong are capable to finance their own projects, there are also
other areas in society where they need to support. So by using money from the private
sector, governments can utilise their resources much more effectively. In international
cities particularly, “High quality of service required” to maintain their status and
competition is common. The size and complexity of PPP projects often limit only certain
large private sector parties therefore “Inefficiency because of public monopoly and lack
of competition” is often seen. Many governments first started to implement PPP projects
due to “Shortage of government funding”. Similarly, when the government is under tight
budget controls implementing PPP projects could also “Avoid public investment
restriction”.
Chapter 8 Implementing Public Private Partnership Projects
227
8.3 Factors Contributing to Successful PPP Projects
This section presents the findings of a study to investigate the factors contributing to
successful PPP projects. The same questionnaire survey was used to obtain data. The
survey respondents were asked to rate eighteen factors which contribute to delivering
successful PPP projects.
The factors that contribute to the success of PPP projects were assessed from different
perspectives of the Hong Kong, Australia and the United Kingdom (results obtained by Li
(2003) from his survey) respondent groups. The means for each administrative system
were calculated and ranked in descending order of importance as shown in Table 8.3.
Chapter 8 Implementing Public Private Partnership Projects
228
Table 8.3 Mean scores and rankings for the factors that contribute to the success of PPP projects
Success Factors
Hong Kong Australia
United Kingdom (Li, 2003)
N Mean Rank N Mean Rank N Mean Rank a. Stable macro-economic condition 34 3.85 4 11 4.18 12 61 3.19 15 b. Favourable legal framework 34 4.06 1 11 4.27 7 61 3.63 9 c. Sound economic policy 34 3.74 7 11 4.09 13 61 3.19 13 d. Available financial market 34 3.71 8 11 4.18 11 61 4.04 3 e. Multi-benefit objectives 34 3.50 16 10 4.20 10 61 3.19 14 f. Appropriate risk allocation and risk sharing 34 3.85 5 11 4.64 2 61 4.05 2 g. Commitment and responsibility of public and private sectors 34 3.97 2 11 4.91 1 61 3.98 4 h. Strong and good private consortium 34 3.91 3 11 4.64 3 61 4.11 1 i. Good governance 34 3.68 10 11 4.45 4 61 3.72 8 j. Project technical feasibility 34 3.56 15 11 4.36 5 61 3.79 6 k. Shared authority between public and private sectors 34 3.41 18 10 3.70 16 61 2.98 17 l. Political support 34 3.76 6 11 4.27 6 61 3.56 11 m. Social support 34 3.44 17 11 3.36 17 61 2.81 18 n. Well organised and committed public agency 34 3.65 12 11 4.27 8 61 3.74 7 o. Competitive procurement process (enough potential bidders in the process) 34 3.68 9 11 4.27 9 61 3.37 12 p. Transparency procurement process (process is made open and public) 33 3.67 11 11 4.09 14 61 3.6 10 q. Government involvement by providing guarantee 34 3.62 14 10 2.40 18 61 3.16 16 r. Thorough and realistic assessment of the cost and benefits 34 3.65 13 11 4.00 15 61 3.95 5 * N = Number of survey respondents
Chapter 8 Implementing Public Private Partnership Projects
229
8.3.1 Agreement of the survey respondents
As shown in Table 8.4, W for the rankings of factors that contribute to the success of PPP
projects was 0.061 and 0.270 for Hong Kong and Australia respectively. The computed
W’s were significant with p = 0.008 and 0.004 respectively. Again as the number of
attributes considered were above seven, as mentioned previously the Chi-square value
would be referred to rather than the W value. According to the degree of freedom, the
critical value of Chi-square was 27.590 for both groups (Hong Kong and Australia), the
computed Chi-square values were all above the critical value of Chi-square (34.045 and
36.757 respectively). Therefore the assessment by the respondents within each group on
their rankings of success factors is proved to be consistent. This finding ensures that the
completed questionnaires were valid for further analysis.
Table 8.4 Results of Kendall’s concordance analysis for the factors that contribute to
the success of PPP projects
Hong Kong Australia
Number of survey respondents 33 8
Kendall's coefficient of concordance (W) 0.061 0.270
Chi-square value 34.045 36.757
Critical value of Chi-square 27.590 27.590
Degree of freedom (df) 17 17
Asymptotic significance 0.008 0.004
Note: Only 33 out of 34 responses from Hong Kong and 8 out of 11 responses from
Australia were suitable for subsequent statistical analyses.
Chapter 8 Implementing Public Private Partnership Projects
230
8.3.2 Ranking of factors that contribute to the success of PPP projects
Eighteen success factors for adopting PPP were rated by the respondents. Figure 8.1
illustrates the relationship of the top five success factors ranked in Hong Kong with their
ranking positions in Australia and the United Kingdom. These success factors included:
(1) Favourable legal framework;
(2) Commitment and responsibility of public and private sectors;
(3) Strong and good private consortium;
(4) Stable macro-economic condition; and
(5) Appropriate risk allocation and risk sharing.
The top success factor ranked by respondents from Hong Kong was “Favourable legal
framework”. On the contrary respondents from Australia and the United Kingdom
ranked this success factor of medium importance only, at seventh and ninth position
respectively. This finding has implied that the Australian and British respondents were
not particularly concerned about their existing legal framework, which is already well
established to handle PPP projects.
On the contrary, respondents in Hong Kong felt that the legal framework is the most
important success factor. As mentioned by the National Treasury PPP Unit of South
Africa (2007), an independent, fair and efficient legal framework is a key factor for
successful PPP project implementation. Sufficient legal resources at reasonable costs
should be available to deal with the amount of legal structuring and documentation
Chapter 8 Implementing Public Private Partnership Projects
231
required. A transparent and stable legal framework would help to make the contracts and
agreements bankable. An adequate dispute resolution system would help to ensure
stability in the PPP arrangements. Appropriate governing rules, regulations and reference
manuals related to PPP have been well established in some developed countries (e.g.
United Kingdom, Australia, Canada, South Africa, etc.) to facilitate the effective
application of PPP procurement approach.
The second success factor ranked by Hong Kong respondents was “Commitment and
responsibility of public and private sectors”. This success factor was also ranked
importantly by the Australians and British at first and fourth place respectively. This
success factor was ranked high by all respondent groups irrespective of geographical
locations. To secure the success of PPP projects, both the public and private sectors
should bring their complementary skills and commit their best resources to achieve a
good relationship (National Audit Office, 2001).
Ranked third by respondents in Hong Kong and Australia was “Strong and good private
consortium”. Respondents from the United Kingdom felt even stronger on the
importance of this success factor and ranked it top. This finding again has shown that
this success factor is seen to be highly important to the success of PPP projects
irrespective of geographical locations. The government in contracting out the PPP
projects should ensure that the parties in the private sector consortium are sufficiently
competent and financially capable of taking up the projects. This suggests that private
companies should explore other participants' strengths and weaknesses and, where
Chapter 8 Implementing Public Private Partnership Projects
232
appropriate, join together to form consortia capable of synergising and exploiting their
individual strengths. Good relationship among partners is also critical because they all
bear relevant risks and benefits from the co-operation (Abdul-Rashid et al., 2006; Birnie,
1999; Corbett and Smith, 2006; Jefferies et al., 2002; Kanter, 1999; Tam, et al. 1994;
Tiong, 1996; Zhang, 2005a).
The fourth success factor ranked by respondents from Hong Kong was “Stable macro-
economic condition”. On the contrary respondents from Australia and the United
Kingdom ranked this success factor relatively low amongst the eighteen success factors
rated. In these countries this success factor was ranked only twelve and fifteenth
respectively. This success factor was therefore seen as quite important in Hong Kong but
rather unimportant in Australia and the United Kingdom.
In a stable macro-economic environment the market is more predictable, hence lowering
risks such as interest rate, exchange rate, employment rate, inflation rate, etc. It is very
important to reduce risks and enable a reasonable investment return for private investors,
especially in the emerging PPP market like Hong Kong. For projects where the major
source of revenue to the private sector is generated from direct tariffs levied on users,
there are revenue risks that can go beyond the control of the private sector like, for
example, future usage level and permitted tariff charges.
There may also be unforeseen risks during the course of the project life. To ensure
project economic viability, the government may consider some forms of government
Chapter 8 Implementing Public Private Partnership Projects
233
guarantees; joint investment funding or supplemental periodic service payments to allow
the private sector to cover the project costs and earn reasonable profits and investment
returns. At the same time, the government should take due consideration of the private
sector’s profitability requirements in order to have stable arrangements in PPP projects.
Alternative sources of income and financing like property development opportunities
along the railway can be sought to bridge the funding gap for private investors (Abdul-
Rashid et al., 2006; Corbett and Smith, 2006; Li et al., 2005c; Nijkamp et al., 2002; Qiao
et al., 2001; Tam et al., 1994; Tiong, 1996; Zhang, 2005a).
The fifth success factor ranked by Hong Kong respondents was “Appropriate risk
allocation and risk sharing”. Respondents from Australia and the United Kingdom both
ranked this success factor second, showing again that irrespective of geographical
differences all groups of respondents ranked this success factor importantly. Although so
the findings showed that the respondents from Hong Kong ranked this success factor
slightly below the others. This could be due to the fact the Hong Kong has had
experience with different procurement systems that entail different risk allocation models,
thereby making this success factor relatively less critical in terms of its contribution to
project success.
A core principle in PPP arrangement is the allocation of risk to the party best able to
manage and control it (Efficiency Unit, 2003a). Logically, the government would prefer
to transfer risks associated with asset procurement and service delivery to the private
sector participants, who are generally more efficient and experienced in managing them.
Chapter 8 Implementing Public Private Partnership Projects
234
But the government should be reasonable to take up risks that are beyond the control of
private sector participants. In all cases, the government should ensure there are measures
in place to manage the risk exposure rather than leaving it open to the private sector.
Likewise before committing to the projects, the private sector participants should fully
understand the risks involved and should be prudent in pricing and managing the risks
appropriately (Grant, 1996; Qiao et al., 2001; Zhang, 2005a).
The results also found that the success factors “Shared authority between public and
private sectors” and “Social support” were ranked in the bottom three by all groups of
respondents. These success factors were therefore seen to be least important compared to
the others. Although no explanation can be provided for why these success factors were
ranked particularly lower, it can be assumed that the other success factors were seen to be
more important. This perception was shown to be true for all survey locations.
The mean values for the success factors as rated by Hong Kong respondents ranged from
3.41 to 4.06. This observation has reflected that the variation in their responses are
relatively small, only 0.65 for Hong Kong. In Australia and the United Kingdom the
means ranged from 2.40 to 4.91 and 2.81 to 4.11 respectively. The corresponding
differences in means were 2.51 and 1.30 respectively. The differences in means were
shown to be much higher for the survey conducted in Australia and the United Kingdom
compared to Hong Kong. This finding shows that the Hong Kong respondents rated the
eighteen success factors much more similarly, whereas in Australia and the United
Kingdom the respondents showed a much larger variation.
Chapter 8 Implementing Public Private Partnership Projects
235
As the respondents were asked to rate the eighteen success factors according to a Likert
scale from 1 to 5 (1 = Least Important and 5 = Most Important), a value above “3” would
represent that the success factor is of importance. Amongst the success factors none were
ranked below “3” in the Hong Kong rank. In Australia and the United Kingdom only one
and two success factors respectively were ranked below a score of “3”. Therefore, all
three groups of respondents concurred that the identified factors were important.
In addition, on top of those factors the respondents were asked to rate, they were also
given the opportunity to add others which would be of importance, but they did not do so.
Chapter 8 Implementing Public Private Partnership Projects
236
Figure 8.1 Rank relationship between Hong Kong, Australia and the United Kingdom for success factors of PPP
Top 5 rank for success factors of PPP in Hong Kong
(1) Favourable legal framework
(2) Commitment and responsibility of public and private sectors
(3) Strong and good private consortium
(4) Stable macro-economic condition
(5) Appropriate risk allocation and risk sharing
The United Kingdom
(9)
(4)
(1)
(15)
(2)
Australia
(7)
(1)
(3)
(12)
(2)
Chapter 8 Implementing Public Private Partnership Projects
237
8.3.3 Section 8.3 summary
This section has analysed the perceptions of respondents from Hong Kong, Australia and
the United Kingdom on the importance of eighteen factors contributing to successful
delivery of PPP projects. The ranking in Hong Kong showed that the top five success
factors included: (1) Favourable legal framework; (2) Commitment and responsibility of
public and private sectors; (3) Strong and good private consortium; (4) Stable macro-
economic condition; and (5) Appropriate risk allocation and risk sharing.
The top success factor ranked by Hong Kong respondents was ranked with medium
importance by respondents from the other two groups; implying that their legal
frameworks are already well developed to cater for PPP projects hence they are less
concerned on the existing system.
The second, third and fifth success factors were ranked highly by all three groups of
respondents, indicating that these success factors were applicable to delivering successful
PPP projects irrespective of their geographical locations.
The fourth success factor ranked by Hong Kong respondents was ranked lowly by the
other groups of respondents. In Australia and the United Kingdom there is a well
established stable macro-economic environment hence the market is much more
predictable. Hong Kong on the other hand has experienced dramatic changes since the
British to Chinese handover in 1997, hence they are still adjusting to the changes and the
Chapter 8 Implementing Public Private Partnership Projects
238
market is therefore not as stable. As a result a stable macro-economic condition was
rated much higher by the Hong Kong respondents. In general, all three groups of
respondents concurred that the identified factors were important.
8.4 Enhancing Value for Money in Public Private Partnership
Projects
This section presents the findings of a study to investigate the measures that enhance
Value for Money (VFM) in PPP projects. The same questionnaire survey was used to
obtain data. The survey respondents were asked to rate the importance of eighteen VFM
measures in PPP projects.
The VFM measures in PPP were assessed from different perspectives of the Hong Kong,
Australia and the United Kingdom (results obtained by Li (2003) from his survey)
respondent groups. The means for each administrative system were calculated and
ranked in descending order of importance as shown in Table 8.5.
Chapter 8 Implementing Public Private Partnership Projects
239
Table 8.5 Mean scores and rankings for the VFM measures in PPP projects
VFM Measures
Hong Kong Australia
United Kingdom (Li, 2003)
N Mean Rank N Mean Rank N Mean Rank a. Competitive tender 34 3.91 3 11 4.27 6 61 3.5 6 b. Efficient risk allocation (allocating the risk to the party best able to manage it) 33 4.18 1 11 4.55 2 61 4.02 1 c. Risk transfer (transferring a substantial amount of risk from the public to the private) 34 3.59 8 11 2.73 17 61 3.57 5 d. Output based specification 34 3.91 2 11 4.27 5 61 3.91 2 e. Long-term nature of contracts 34 3.65 7 11 4.18 7 61 3.78 3 f. Improved and additional facilities to the public sector 34 3.35 12 11 4.00 11 61 3.16 13 g. Private management skill 34 3.82 4 11 4.27 4 61 3.41 7 h. Private sector technical innovation 33 3.82 5 10 4.50 3 61 3.28 9 i. Optimal use of asset/facility and project efficiency 34 3.68 6 10 4.70 1 61 3.31 8 j. Early project service delivery 34 3.35 11 11 4.00 10 61 3.72 4 k. Low project life cycle cost 34 3.47 10 11 4.00 9 61 3.24 11 l. Low shadow tariffs/tolls 34 2.82 18 10 3.30 13 61 2.49 17 m. Level of tangible and intangible benefits to the Users 34 3.00 16 11 4.00 8 61 2.83 15 n. Environmental consideration 34 2.97 17 11 2.73 16 61 2.38 18 o. Profitability to the private sector 34 3.18 13 10 3.00 15 61 2.84 14 p. "Off the public sector balance sheet" treatment 34 3.15 14 11 2.36 18 61 3.23 12 q. Reduction in disputes, claims and litigation 34 3.09 15 11 3.18 14 61 2.81 16 r. Nature of financial innovation 34 3.56 9 11 3.73 12 61 3.25 10
* N = Number of survey respondents
Chapter 8 Implementing Public Private Partnership Projects
240
8.4.1 Agreement of the survey respondents
As shown in Table 8.6, W for the rankings of VFM measures was 0.199 and 0.459 for
Hong Kong and Australia respectively. The computed W’s for both were significant with
p = 0.000. Again as the number of attributes considered were above seven, as mentioned
previously the Chi-square value would be referred to rather than the W value. According
to the degree of freedom, the critical value of Chi-square was 27.590 for both groups
(Hong Kong and Australia) the computed Chi-square values were all above the critical
value of Chi-square (108.189 and 54.567 respectively). Therefore the assessment by the
respondents within each group on their rankings of VFM measures is proved to be
consistent. This finding ensures that the completed questionnaires were valid for further
analysis.
Table 8.6 Results of Kendall’s concordance analysis for the VFM measures in PPP
projects
Hong Kong Australia
Number of survey respondents 32 7
Kendall's coefficient of concordance (W) 0.199 0.459
Chi-square value 108.189 54.567
Critical value of Chi-square 27.590 27.590
Degree of freedom (df) 17 17
Asymptotic significance 0.000 0.000
Note: Only 32 out of 34 responses from Hong Kong and 7 out of 11 responses from
Chapter 8 Implementing Public Private Partnership Projects
241
Australia were suitable for subsequent statistical analyses.
8.4.2 Ranking of Value for Money measures in PPP
Eighteen VFM measures in PPP were rated by the respondents. Figure 8.2 illustrates the
relationship of the top five VFM measures ranked in Hong Kong with their ranking
positions in Australia and the United Kingdom. These VFM measures included:
(1) Efficient risk allocation (allocating the risk to the party best able to manage it);
(2) Output based specification;
(3) Competitive tender;
(4) Private management skill; and
(5) Private sector technical innovation.
The top VFM measure ranked by the Hong Kong respondents was “Efficient risk
allocation (allocating the risk to the party best able to manage it)”. This VFM measure
was also ranked top by the Australians and highly at second place by the British, showing
that its importance in PPP projects is applicable irrespective of geographical locations.
It is essential for the public client and the private bidders to evaluate all of the potential
risks throughout the whole project life. Public and private sector bodies must place
particular attention on the procurement process while negotiating contracts for PPP to
ensure a fair risk allocation between them. Systematic risk management allows early
detection of risks and encourages the PPP stakeholders to identify, analyse, quantify, and
Chapter 8 Implementing Public Private Partnership Projects
242
respond to the risks, as well as take measures to introduce risk mitigation policies
(Akbiyikli and Eaton, 2004). A fundamental principle is that risks associated with the
implementation and delivery of services should be allocated to the party best able to
manage the risk in a cost effective manner.
Second in the Hong Kong and Australia rank was “Output based specification”. This
VFM measure was also ranked high by the British at fifth. Besides the top VFM measure
ranked by Hong Kong discussed previously, this was the only one also ranked highly by
all three administrative regions, indicating again that this VFM measure is applicable to
PPP projects irrespective of geographical differences.
Clear specifications can be used to quantify the resources required for a project. When
project specifications are more difficult to define the costs that it may incur are also hard
to quantify and control. Therefore clearly defined output based specifications can help
the government to monitor the private sector’s performance. The private party can also
feel more confident to achieve targets and keep control of the project flow in order to
enhance their profit margins. Output based specifications can also help the government
to use the public sector comparator more effectively in quantifying whether VFM is
reached by procuring projects via PPP. Some may feel that output based specifications
define too much of the project to allow for private sector innovation, but for example a
two lane tunnel can still leave plenty of room for added value from the private sector.
The Hong Kong respondents ranked “Competitive tender” third. In Australia and the
Chapter 8 Implementing Public Private Partnership Projects
243
United Kingdom this VFM measure was ranked with medium importance only, both at
sixth position. This VFM measure was ranked high in Hong Kong reflecting the
respondents’ views of the actual situation of procuring projects.
Hong Kong has only a limited number of contractors who are able to handle large public
works projects. Therefore it is often the same groups of contractors who are successful at
winning these bids. For those slightly smaller local companies they are often unable to
compete with the larger local companies. For international companies based in Hong
Kong they may not always wish to spend their resources in Hong Kong. Hence a
revolving situation has been formed that there are often few bids received from the
private sector. As a result these projects tend to be awarded to the same groups of people.
Therefore an evolving situation is that the fewer competitors in the tendering process the
more difficult it is to achieve VFM in PPP projects.
In a more competitive bidding environment the private sectors will try all measures to
improve their designs in every aspect. In particular in terms of VFM as one of the main
reasons that the public sector opt for PPP is to achieve VFM in public works projects.
This would therefore be a key reason to choose a particular private party for the
government. In a bidding environment that has few competitors the private sector does
not need to try so hard to win the contracts, hence VFM may not always be achieved.
Ranked fourth in Hong Kong and Australia was “Private management skill”. This VFM
measure was ranked slightly lower by the British at seventh position. The British are
Chapter 8 Implementing Public Private Partnership Projects
244
more experienced in conducting PPP projects hence many of the private sector companies
are already equipped with the necessary skills to handle PPP projects. On the other hand
in Hong Kong particularly many private companies are not experienced with handling
PPP projects and are therefore not equipped with the necessary management skills. The
capability of the private sector can determine the successfulness of the PPP project. The
success of a PPP project is often associated with its degree of VFM that can be achieved.
The fifth VFM measure in Hong Kong was “Private sector technical innovation”. This
was ranked slightly higher by the Australians but lower by the British at third and ninth
position respectively. This VFM measure is similar to “Private management skill”, in that
it relies on the capability of the private party. Obviously the ability of the private party
will determine how successful the PPP project can become in terms of VFM. Then again
VFM is the main incentive for governments around the world to involve the private
sector in to procuring public works projects.
The mean values for the VFM measures as rated by Hong Kong respondents ranged from
2.82 to 4.18. This observation has reflected that the variation in their responses are
relatively small, only 1.36 for Hong Kong. In Australia and the United Kingdom the
means ranged from 2.36 to 4.70 and 2.38 to 4.02 respectively. The corresponding
differences in means were 2.34 and 1.64 respectively. The differences in means were
slightly higher for the survey conducted in Australia and the United Kingdom compared
to Hong Kong. This finding shows that the Hong Kong respondents rated the eighteen
VFM measures much more similarly, whereas in Australia and the United Kingdom the
Chapter 8 Implementing Public Private Partnership Projects
245
respondents showed a slightly larger variation.
As the respondents were asked to rate the eighteen VFM measures according to a Likert
scale from 1 to 5 (1 = Least Important and 5 = Most Important), a value above “3” would
represent that the VFM measure is of importance. Amongst the VFM measures only two
were ranked below “3” in the Hong Kong rank. These VFM measures were “Low
shadow tariffs/tolls” and “Environmental consideration” which scored 2.82 and 2.97
respectively. In Australia and the United Kingdom three and five VFM measures were
rated below “3” respectively. Similar to Hong Kong, the other respondent groups also
rated “Environmental consideration” below a score of “3” with scores of 2.73 and 2.38
respectively. This finding showed that environment related issues showed the least effect
towards enhancing VFM according to all groups of survey respondents.
In addition, on top of those factors the respondents were asked to rate, they were also
given the opportunity to add others which would be of importance, but they did not do so.
Chapter 8 Implementing Public Private Partnership Projects
246
Figure 8.2 Rank relationship between Hong Kong, Australia and the United Kingdom for VFM measures of PPP
Top 5 rank for VFM measures of PPP in Hong Kong
(1) Efficient risk allocation (Allocating the risk to the party best able to manage it)
(2) Output based specification
(3) Competitive tender
(4) Private management skill
(5) Private sector technical innovation
The United Kingdom
(1)
(2)
(6)
(7)
(9)
Australia
(2)
(5)
(6)
(4)
(3)
Chapter 8 Implementing Public Private Partnership Projects
247
8.4.3 Section 8.4 summary
This section has discussed the VFM measures rated by survey respondents from Hong
Kong, Australia and the United Kingdom. The results showed that there were two VFM
measures that were ranked highly by all groups of survey respondents.
The first of these which was ranked top in Hong Kong was “Efficient risk allocation
(allocating the risk to the party best able to manage it)”. Appropriate risk allocation so
that risks are assigned to the party best able to manage it, is believed to reduce the
problems encountered in a project. As a result VFM is enhanced due to fewer risks
occurring in the project life.
The second VFM measure ranked highly by all was “Output based specification”. A
clearly defined output based specification enables the milestones and activities in a
project to be much more predictable compared to one without hence the effect towards
VFM is larger.
Ranked thirdly in Hong Kong was “Competitive tender”. This measure can create VFM
when it exists. The more competition in the tendering process, the more the private
sector will try to offer a better package overall for the public sector. In Hong Kong
unfortunately there is limited competition between those companies that can handle PPP
projects; hence the respondents felt that this VFM measure is relatively more important.
Chapter 8 Implementing Public Private Partnership Projects
248
Ranked fourth and fifth in Hong Kong was “Private management skill” and “Private
sector technical innovation”. Both of these VFM measures relate to the ability of the
private sector. Obviously the better the private sector’s ability the more chance there is
for them to enhance VFM. In Hong Kong the skill of the private sector in conducting
PPP projects may not be as experienced as the Australia and the United Kingdom, hence
the respondents felt strongly towards these measures.
8.5 Chapter 8 Summary
This chapter has presented the findings from a questionnaire survey looking at the
reasons for implementing PPP projects, the success factors of PPP projects and the VFM
measures of PPP projects.
The findings showed that the top reason ranked by the survey respondents in Hong Kong
was “Private incentive”. Ranked second by all three groups of survey respondents was
“Economic development pressure demanding more facilities”. Third in Hong Kong and
first in Australia was “High quality of service required”. The reason “Inefficiency
because of public monopoly and lack of competition” was ranked third by the Australian
respondents. And finally ranked first and third by the British respondents was “Shortage
of government funding” and “Avoid public investment restriction”. The rankings showed
that in general those reasons rated highly in the United Kingdom focused on financial
elements whereas those rated highly in Hong Kong and Australia were more related to the
Chapter 8 Implementing Public Private Partnership Projects
249
overall performance of improving public projects.
Amongst the top five success factors ranked by Hong Kong respondents, three were also
ranked highly by the Australians and British. These success factors included:
“Commitment and responsibility of public and private sectors”; “Strong and good private
consortium”; and “Appropriate risk allocation and risk sharing”. These success factors
were therefore found to be important for contributing to successful PPP projects
irrespective of geographical locations. Ranked top in Hong Kong but only with medium
importance in the other surveyed jurisdictions was “Favourable legal framework”. Also,
ranked within the top five by Hong Kong respondents was “Stable macro-economic
condition”, but this success factor was ranked lowly by the Australians and British.
The top five VFM measures ranked by the respondents from Hong Kong included (1)
Efficient risk allocation (allocating the risk to the party best able to manage it); (2) Output
based specification; (3) Competitive tender; (4) Private management skill; and (5) Private
sector technical innovation. The first and second of these VFM measures were also
found to be ranked high by the respondents from Australia and the United Kingdom,
indicating that these were true irrespective of geographical differences. When the risks
are handled well less pitfalls are experienced and as a result VFM is more achievable.
Hence an efficient risk allocation is vital in determining whether VFM can be achieved in
PPP projects. A clear output based specification can enable a more obvious project
design and concept hence minimising the possibility of delivering the wrong product for
the user. Therefore this measure is also important in determining whether VFM has been
Chapter 8 Implementing Public Private Partnership Projects
250
achieved for a PPP venture.
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
251
CHAPTER 9
A BEST PRACTICE FRAMEWORK FOR
IMPLEMENTING PPP PROJECTS IN HONG KONG
9.1 Chapter 9 Introduction
9.2 The PPP Process
9.3 Incorporating the Research Findings into the PPP Process
9.4 Validation of the Framework
9.5 Chapter 9 Summary
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
252
9.1 Chapter 9 Introduction
This chapter presents a best practice framework for implementing Public Private
Partnership (PPP) projects in Hong Kong. Based on the process for conducting PPP
projects presented by the Efficiency Unit of the Hong Kong Special Administrative
Region (HKSAR) government, the findings achieved from this research study suggest
measures to improve the process at each step. The findings drawn from the literature
review, case study analysis, interviews and questionnaire survey are triangulated to
enhance the exiting practice of implementing PPP projects in Hong Kong. By using this
framework both the public and private sectors can deliver better PPP projects.
9.2 The PPP Process
As this research study aims to develop a best practice framework for implementing PPP
projects in Hong Kong, it would be logical to work on the existing governmental
framework. Although the Efficiency Unit of the HKSAR government is not involved
with conducting PPP projects, as mentioned in previous chapters their involvement in
PPP research for Hong Kong within the local government has been inevitable. Hence this
study chose to adopt their process as the baseline for conducting PPP projects in Hong
Kong.
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
253
Figure 9.1 looks at the steps involved in the PPP process as proposed by the Efficiency
Unit (Efficiency Unit, 2008b). A total of 8 steps are defined for this process. The first
step is “Mobilisation and development of a business case”. Within this step there are a
further eight activities that should occur, these include: 1) Conduct needs analysis, market
testing and PPP feasibility study; 2) Establish a project steering committee and designate
a contract manager; 3) Establish whether a site is available; 4) Establish what
facilities/services are required; 5) Prepare a draft Statement of Requirements; 6) Consider
whether to accept proposals for enhanced or other additional commercial
facilities/services on the site; 7) Assess risk; and 8) Prepare public sector comparator and
seek policy endorsement.
The second step is “Funding” which involves submitting a bid via the policy bureau for
funds through the resource allocation exercise process.
The third step is “Technical assessments, consultation and land requirements”. It
involves three activities including: 1) Conduct appropriate technical assessments and
socio-economic studies; 2) Seek necessary authorities’ agreement on land use; and 3)
Conduct consultations with stakeholders, policy committee and legislative council panel.
Step 4 is the “Expression of interest exercise” where an expression of interest exercise is
initiated.
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
254
Step 5 looks at the “Policy and funding approvals”. Two activities are involved including:
1) Consult and seek approvals of public works subcommittee of the legislative council;
and 2) finance committee of the legislative council.
Step 6 is the “Procurement and selection” involving seven activities including: 1) Instruct
department of justice on drafting of procurement documents/contract; 2) Finalise
procurement documents and seek approval from central tender board; 3) Establish bid
evaluation committee; 4) Issue request for proposal and conduct briefings/site inspections;
5) Evaluate proposals; 6) Negotiate with bidders and select from best and final offer; and
7) Award contract.
Step 7 is the “Service commencement”. There are four activities for this step including: 1)
Commence construction; 2) Commissioning of facility; 3) Commence service delivery;
and 4) Establish and maintain close relationship with the consortium.
And finally step 8 “Payment and contract management” wraps up the PPP process. Six
activities are involved including: 1) Monitor performance regularly / Make payment for
the facilities/services provided; 2) Defer or reduce payment; 3) Institute investigations
and issue warning / Initiate dispute resolution procedures; 4) Step-in; 5) Conduct joint
inspection towards the end of the contract; and 6) Hand over facilities at the end of the
contract.
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
255
Figure 9.1 The process for implementing PPP projects in Hong Kong (adapted from
Efficiency Unit, 2008b)
Step 1 Mobilisation and development of a business case 1.1 Conduct needs analysis, market testing and PPP feasibility study 1.2 Establish a project steering committee and designate a contract manager 1.3 Establish whether a site is available 1.4 Establish what facilities/services are required 1.5 Prepare a draft Statement of Requirements 1.6 Consider whether to accept proposals for enhanced or other additional
commercial facilities/services on the site 1.7 Assess risk 1.8 Prepare public sector comparator and seek policy endorsement
Step 2 Funding 2.1 Submit a bid via the policy bureau for funds through the resource allocation
exercise process
Step 3 Technical assessments, consultation and land requirements 3.1 Conduct appropriate technical assessments and socio-economic studies 3.2 Seek necessary authorities’ agreement on land use 3.3 Conduct consultations with stakeholders, policy committee and legislative
council panel
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
256
Step 5 Policy and funding approvals 5.1 Consult and seek approvals of public works subcommittee of the legislative
council and finance committee of the legislative council 5.2 Determine detailed commercial arrangements 5.3 Seek draft land grant conditions
Step 4 Expression of interest exercise 4.1 Initiate an expression of interest exercise
Step 8 Payment and contract management 8.1 Monitor performance regularly / Make payment for the facilities/services
provided 8.2 Defer or reduce payment 8.3 Institute investigations and issue warning / Initiate dispute resolution
procedures 8.4 Step-in 8.5 Conduct joint inspection towards the end of the contract 8.6 Hand over facilities at the end of the contract
Step 7 Service commencement 7.1 Commence construction 7.2 Commissioning of facility 7.3 Commence service delivery 7.4 Establish and maintain close relationship with the consortium
Step 6 Procurement and selection 6.1 Instruct department of justice on drafting of procurement documents/contract 6.2 Finalise procurement documents and seek approval from central tender board 6.3 Establish bid evaluation committee 6.4 Issue request for proposal and conduct briefings/site inspections 6.5 Evaluate proposals 6.6 Negotiate with bidders and select from best and final offer 6.7 Award contract
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
257
9.3 Incorporating the Research Findings into the PPP Process
The existing PPP process described in Section 9.2 of this chapter demonstrates “What”
needs to be done in order to implement a PPP project in Hong Kong. But it does not
explain “How” these activities can be achieved. By incorporating the “What” and “How”,
a best practice framework for implementing PPP projects in Hong Kong can be derived.
The “How” part of the framework can be formed from the research findings obtained
from both the international and local literature review, case studies, interviews and
questionnaire survey. These results were further triangulated for validation purposes. For
each step of the process, users are shown “How” to implement PPP projects by a list of
the “Dos” and “Don’ts”. Tables 9.1 to 9.8 show the “Dos” and “Don’ts” for each step of
the PPP process.
For example, Table 1 demonstrates that there are thirty “Dos” and “Don’ts” for step 1 of
the process “Mobilisation and development of a business case”. The first “Dos” item for
step 1 is to “Prepare a public sector comparator” and the first “Don’ts” item is to “Choose
PPP without thorough investigation” (Section 6.2.2.2). These items are listed within the
table under no specific order. Similarly the same applies for the other tables.
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
258
Table 9.1 Guideline for conducting step 1 “Mobilisation and development of a
business case”
No. Dos Don’ts Reference 1 Prepare a public sector
comparator Choose PPP without thorough investigation
Section 6.2.2.2
2 Ensure an economically viable project
Choose projects that are uneconomical
Section 6.2.2.5
3 Streamline the process Spend long durations during mobilization
Section 4.4.1.4
4 Consider to use PPP when improved services / products can be achieved
Use PPP when improved services / products cannot be achieved
Section 3.4
5 Ensure appropriate risk sharing / allocation
Intend to transfer large proportions of risk to a single party
Section 8.3.2
6 Keep to a timeline Ignore timeframe Section 4.3.4 7 Provide an integrated
solution Have unclear objectives Section 7.3.1
8 Facilitate creative and innovative approaches
Limit the opportunity for the private party to show innovation and creativity
Section 7.3.1
9 Solve the problem of public sector budget restraint
Consider PPP for financial reasons only
Section 7.3.1
10 Minimise political debate Involve in political debate Section 7.3.2 11 Continuous training Employ inexperienced or
unskilful employees Section 6.3.3
12 Public sector to show commitment
Government to be indecisive on procurement method
Section 4.3.4
13 Government to have clear objectives and evaluation criteria
Government to have unclear objectives and evaluation criteria
Section 4.3.4
14 Gain interest of general public
Lack of communication with general public
Section 5.4.2
15 Consider complex projects so that private sector can maximise their ability
Define project scope and design fully
Section 6.4.2.3
16 Avoid legislation obstacles Challenge legislation system Section 4.2 17 Ensure an attractive financial
market Force projects that have no market
Section 3.7
18 Avoid lengthy delays Tolerate delays Section 7.3.2 19 Ensure transparent and
process Lack of transparency in the process
Section 6.2.2.5
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
259
20 Government champion from high level or treasury departments
Lack of government support Section 6.2.2.5
21 Positive media Bad relationship with media Section 6.3.2.7
22 Ensure a stable macro-economic condition
Proceed under unstable economic conditions
Section 8.3.2
23 Ensure project technically feasible
Expect projects to work without thorough investigation on the technical feasibility
Section 8.3
24 Thorough and realistic assessment of the cost and benefits
Leave assessment of the cost and benefits to later stages
Section 8.3
25 Ensure partnering spirit / commitment / trust
Reluctance to work with partners
Section 6.2.2.5
26 Ensure there is a market need Consider projects with no market
Section 6.4.2.5
27 Consider projects with large operation element
Consider projects that do not involve operation
Section 6.2.2.3
28 Ensure there is government need
Consider projects that the government do not need
Section 6.3.2.3
29 Consider projects of large scale
Consider small scale projects Section 6.4.2.3
30 Ensure better value for money can be demonstrated
Consider projects that are not value for money
Section 6.2.2.5
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
260
Table 9.2 Guideline for conducting step 2 “Funding”
No. Dos Don’ts Reference 1 Solve the problem of public
sector budget restraint Focus on private financing only
Section 7.3.1
2 Allocate the risks appropriately Allocate all financial risks to the private sector
Section 8.3.2
3 Avoid political debate Intensify political debates Section 7.3.2 4 Rely on private parties that are
financially incapable Rely on private financing solely
Section 3.4
5 Avoid delays in negotiation Spend long durations over negotiation
Section 7.3.2
6 Ensure an efficient and mature financial market exists
Assume an efficient and mature financial market is readily available
Section 3.7
7 Conduct a thorough and realistic assessment of the costs and benefits
Avoid continuous assessment analysis
Section 8.3
8 Ensure commitment and responsibility of all parties
Lack commitment and responsibility
Section 8.3.2
9 Ensure an economically viable project
Choose projects that are uneconomical
Section 6.2.2.5
10 Avoid public investment restriction
Conduct PPP projects for financial reasons only
Section 8.2.2
11 Opt for PPP to provide funding Let funding be the sole reason for PPP
Section 3.4
12 Demonstrate appropriate risk allocation and sharing
Inappropriate risk allocation and sharing
Section 8.3.2
13 Demonstrate value for money Ignore value for money Section 6.2.2.5
14 Ensure partnership arrangement
Think of self privileges only Section 6.4.2.2
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
261
Table 9.3 Guideline for conducting step 3 “Technical assessments, consultation and
land requirements”
No. Dos Don’ts Reference 1 Ensure that improved services
and products can be delivered Lack of interest to show improvement
Section 3.4
2 Appropriate risk sharing Inefficient risk allocation Section 8.3.2 3 Ensure that the party best able
to manage the risk is assigned Transfer all risks to the private sector
Section 8.4.2
4 Provide integrated solution Consider short term goals only Section 7.3.1 5 Facilitate creative and
innovative approaches Minimise opportunities for private efficiency and innovation
Section 7.3.1
6 Ensure experience and appropriate skills
Inexperienced employees Section 5.4.2
7 Gain support and interest from general public
Block out the general public Section 5.4.2
8 Conduct complex projects so that private sector’s expertise could be utilised
Conduct over challenging projects
Section 6.4.2.3
9 Avoid lengthy delays and negotiation
Spend long durations during negotiation
Section 7.3.2
10 Good governance Lack of government governance
Section 8.3
11 Ensure transparent process Lack public consultation Section 6.2.2.5
12 Ensure that project is technically feasible
Aim to achieve technically infeasible aspects
Section 8.3
13 Conduct thorough and realistic assessment of the cost and benefits
Leave assessment of cost and benefits to later stage
Section 8.3
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
262
Table 9.4 Guideline for conducting step 4 “Expression of interest exercise”
No. Dos Don’ts Reference 1 Demonstrate appropriate risk
sharing Hide details of risk allocation arrangement
Section 8.3.2
2 Keep to a timetable Delay the process Section 7.3.2 3 Facilitate creative and
innovative approaches Limit private sector’s chance to show creativity and innovation
Section 7.3.1
4 Government show support towards project
Government appear to be indecisive
Section 6.2.2.5
5 Have clear government objectives and evaluation criteria
Government lack objectives and evaluation criteria
Section 4.3.4
6 Good private sector capability Poor private sector capability Section 8.3.2 7 Government to commit to
projects Government indecisive on procurement method
Section 4.3.4
8 Gain support and interest from general public
Lack of support and interest from general public
Section 5.4.2
9 Speed up negotiation process Spend long durations during negotiation
Section 4.4.1.4
10 Minimise private sector expenditure
Expect private sector to have clear conceptual plans at this stage
Section 5.3.2
11 Partnering spirit/commitment/trust
Consider self privileges only Section 6.2.2.5
12 Ensure transparent process Block out the general public Section 6.2.2.5
13 Ensure there is a market need Propose projects with no market
Section 6.4.2.5
14 Ensure an economically viable project
Choose projects that are uneconomical
Section 6.2.2.5
15 Have well defined project objectives
Have unclear project objectives
Section 6.2.2.5
16 Propose projects that are technically feasible
Propose projects that cannot be achieved technically
Section 3.4
17 Ensure stable macro-economic condition
Pursue projects under unstable macro-economic condition
Section 8.3.2
18 Ensure efficient and mature financial market exists
Pursue projects under inefficient and immature financial market
Section 3.7
19 Close connection with media Negative media Section 6.3.2.7
20 Ensure a favourable legal framework
Pursue projects under unfavourable legal framework
Section 8.3.2
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
263
21 Ensure a stable political and social environment exists
Pursue projects under unstable political and social environment
Section 3.7
22 Ensure government need Propose projects that the government does not need
Section 6.3.2.3
23 Propose large projects Propose small projects Section 6.4.2.3
Table 9.5 Guideline for conducting step 5 “Policy and funding approvals”
No. Dos Don’ts Reference 1 Keep to a timetable Delays during negotiation /
political debate Section 7.3.2
2 Ensure a stable social and political environment
Pursue projects under unstable and political environment
Section 3.7
3 Ensure a clear legal framework Pursue projects under an unclear legal framework
Section 8.3.2
4 Ensure good governance Poor governance Section 8.3 5 Ensure transparent process Block out the general public Section
6.2.2.5 6 Gain government support and
have champion from high level or treasury department
Lack of government support Section 6.2.2.5
7 Ensure stable macro-economic condition
Pursue projects under unstable macro-economic condition
Section 8.3.2
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
264
Table 9.6 Guideline for conducting step 6 “Procurement and selection”
No. Dos Don’ts Reference 1 Ensure a fair risk allocation
mechanism Allocate large proportion of risk to a single party
Section 5.4.4
2 Allocate risks to the party best able to manage them
Allocate all the risks to the private sector
Section 8.4.2
3 Streamline the process Waste time during administrative procedures
Section 4.4.1.4
4 Provide an integrated solution Have unclear objectives Section 7.3.1 5 Keep to a timetable Delays during negotiation /
political debate Section 7.3.2
6 Ensure a stable social and political environment
Pursue projects under unstable and political environment
Section 3.7
7 Ensure a clear legal framework Pursue projects under an unclear legal framework
Section 8.3.2
8 Ensure good governance Poor governance Section 8.3 9 Ensure transparent process Block out the general public Section
6.2.2.5 10 Gain government support and
have champion from high level or treasury department
Lack of government support Section 6.2.2.5
11 Ensure stable macro-economic condition
Pursue projects under unstable macro-economic condition
Section 8.3.2
12 Minimise political debate Encourage political debate Section 7.3.2 13 Government commitment Scheme aborted before contract Section 4.3.4 14 Compensation to losing bidder High participation costs Section 5.3.2 15 Select strong and good private
consortium Select incapable private consortium
Section 8.3.2
16 Gain general public support and interest
Lack consultation with general public
Section 5.4.2
17 Clear government objectives and evaluation criteria
Unclear government objectives and evaluation criteria
Section 4.3.4
18 Ensure positive media Negative media Section 6.3.2.7
19 Ensure partnering spirit / commitment / trust
Lack partnering spirit / commitment / trust
Section 6.2.2.5
20 Ensure rigorous tendering process
Fixing contracts too quickly Section 6.4.2.5
21 Low tendering / transaction costs
High tendering / transaction costs
Section 6.4.2.2
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
265
Table 9.7 Guideline for conducting step 7 “Service commencement”
No. Dos Don’ts Reference 1 Keep to the contract milestones Neglect the target milestones Section 3.7 2 Continuously introduce
appropriate talents or resources Conduct minimal requirements Section
6.3.2.1 3 Continuous training Be reluctant to develop
personnel Section 6.3.3
4 Communicate with general public
Stop communicating with general public
Section 5.4.2
5 Ensure transparent process Hide project details Section 6.2.2.5
6 Charge reasonable fees for facilities/services
Overpriced fees for facilities/services
Section 4.3.2
7 Ensure financial market Stop searching for markets Section 3.7 8 Ensure a stable and macro
economic condition Ignore surrounding macro economic condition
Section 8.3.2
9 Show good governance Government avoid responsibility
Section 8.3
10 Government to step in if necessary
Government to intrude on activities
Section 5.44
11 Create close links with media Allow the media to gain a bad perception
Section 6.3.2.7
12 Commitment of all parties Lack commitment Section 8.3.213 Partnership arrangement Consider self privileges only Section
6.4.2.2 14 Government to give private
sector free hand to maximise their ability
Prevent private sector to maximise their potential
Section 3.7
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
266
Table 9.8 Guideline for conducting step 8 “Payment and contract management”
No. Dos Don’ts Reference 1 Check that appropriate services
and products are delivered Deliver services and products of lower quality then specified in contract
Section 3.4
2 Show a partnership arrangement
Blame partners for unsatisfactory performance
Section 6.4.2.2
3 Encourage interest of the general public
Prevent transparency Section 5.4.2
4 Government to step in if necessary
Government to interfere without appropriate reason
Section 5.44
5 Ensure a stable macroeconomic condition
Ignore the surrounding macro economic condition
Section 8.3.2
6 Ensure stable political and social environment
Ignore changes to political and social environment
Section 3.7
7 Conduct thorough and realistic assessment of the cost and benefits
Avoid continuous assessment analysis to minimise work load
Section 8.3
8 Ensure efficient and mature financial market
Stop creating economic opportunities
Section 3.7
9 Ensure an economically viable project
Choose projects that are uneconomical
Section 6.2.2.5
10 Ensure continuous market need Search for new markets Section 6.4.2.5
11 Ensure compliance with contract terms
Breach contract terms Section 3.7
12 Assessed by performance Assessed solely be economic return
Section 3.2.2
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
267
9.4 Validation of the Framework
Validation is an important process to ensure the quality of the research outcomes. This is
normally undertaken as the final stage of the research works. This section presents the
findings of the validation for the best practice framework developed.
9.4.1 Design of the validation questionnaire survey
In order to validate the best practice framework developed from this research study, a
questionnaire survey was conducted. This survey was based on a similar validation
process conducted by Yeung (2007). In his study, a questionnaire survey was adopted to
validate the quality of the “Partnering Performance Index” model which was developed.
Six aspects regarding the model were assessed. These included the areas: appropriateness,
objectivity, replicability, practicability, reliability and suitability. In the questionnaire
survey conducted to validate the best practice framework, the respondents were also
asked to rate these six aspects.
The survey respondents were first presented with the purpose of the questionnaire, some
background information, instructions for the exercise, the process for implementing PPP
projects in Hong Kong according to the Efficiency Unit’s (of the HKSAR government)
model, and also the best practice framework developed from this research study. At the
end of the exercise, the respondents were asked to rate their extent of satisfaction for each
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
268
of the six validation aspects according to a scoring scale from 1 to 5, where 1 represented
“poor” and 5 represented “excellent”. The template for this questionnaire survey has
been included in Appendix 2.
9.4.2 Respondents of the survey
There were three main criteria for selecting the survey respondents for this validation
process. Firstly, the respondents needed to be working closely with PPP, either with
hands-on experience or in research. Secondly, the respondents needed to have a good
amount of knowledge in the situation of conducting PPP projects in Hong Kong. Lastly,
the survey respondents must not have contributed to the development of the best practice
framework in this research study. According to these criteria, participants that attended
the recent CIB TG72 symposium titled “Revamping PPPs’ Symposium” which was held
in Hong Kong on 28 February 2009 were targeted as survey respondents. A total of nine
responses were collected and their details have been shown in Table 9.9.
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
269
Table 9.9 Details of the survey respondents for the validation process
No. Position Type of Organisation Sector Experience
1 Professor
University Research Active researcher
2 President
Project advisers Public and Private Hands-on experience with conducting PPP projects.
3 Professional Consultant University (Law) Research Active researcher and adviser for the Efficiency Unit of the HKSAR government.
4 General Manager Project advisers Private Hands-on experience with conducting PPP projects in Mainland China.
5 Manager Transportation provider Private Hands-on experience with conducting PPP projects in Hong Kong and Mainland China.
6 Researcher
University Research Active researcher
7 Lecturer
University Research Active researcher
8 Legal Adviser Transportation provider Private Hands-on experience with conducting PPP projects in Hong Kong and Mainland China.
9 General Manager Transport authority Public Hands-on experience with conducting PPP projects in Hong Kong.
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
270
9.4.3 Results of the validation
Table 9.10 shows the results obtained from the validation questionnaire survey, which
was conducted with the respondents mentioned in the previous section. The respondents
were asked to rate six aspects of the framework according to a Likert scale of 1 to 5. A
score above “3” would represent satisfactory performance for that aspect. The results
showed that all aspects were rated above “3”. The aspect rated highest was “Degree of
appropriateness” at 3.78. Rated the lowest by respondents was the “Degree of
replicability” at 3.33. Therefore it can be construed that the newly developed best
practice framework was validated to be appropriate, objective, replicable, reliable, and
suitable for delivering PPP projects in Hong Kong.
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
271
Table 9.10 Results of the validation questionnaire survey
Validation Aspect Respondent Mean
1 2 3 4 5 6 7 8 9
1. Degree of appropriateness 4 4 5 4 4 4 2 4 3 3.78
2. Degree of objectivity 4 4 5 3 3 3 3 4 4 3.67
3. Degree of replicability 4 4 4 3 3 2 2 4 4 3.33
4. Degree of practicality 4 4 4 4 4 3 2 4 3 3.56
5. Overall reliability 4 4 4 2 4 3 3 4 3 3.44
6. Overall suitability for PPP projects in Hong Kong 3 4 4 4 4 3 3 4 4 3.67
Chapter 9 A Best Practice Framework for Implementing PPP Projects in Hong Kong
272
9.5 Chapter 9 Summary
Using the findings collected throughout this research study, this chapter has demonstrated
“How” each step of the PPP process proposed by the Efficiency Unit (2008b) could be
conducted based on the findings of this research. As a result a best practice framework
for implementing PPP projects in Hong Kong has been delivered. The presented
framework will enable practitioners in Hong Kong from both the public and private
sectors to effectively utilise the PPP model. Also, given the clearer understanding it is
anticipated to encourage more PPP projects in Hong Kong.
Chapter 10 Conclusions and Recommendations
273
CHAPTER 10
CONCLUSIONS AND RECOMMENDATIONS
10.1 Chapter 10 Introduction
10.2 Review of the Project Objectives
10.3 Major Findings
10.4 Value and Significance of the Research
10.5 Limitations of the Research
10.6 Recommendations for Future Research
10.7 Chapter 10 Summary
Chapter 10 Conclusions and Recommendations
274
10.1 Chapter 10 Introduction
This chapter concludes the research study. Firstly, the project objectives and the methods
used to achieve them are reviewed. The major findings from this study are analysed and
triangulated according to the data collection methods adopted. Similarities and
differences between these findings are further discussed. Following, the value and
significance of this research are once again revisited. Limitations of this study are also
highlighted and finally recommendations are made for future research.
10.2 Review of the Project Objectives
This research study aimed to develop a best practice framework for implementing Public
Private Partnerships (PPP) in Hong Kong by looking at international experiences. In
order to achieve the aim, six objectives were identified for this research:
(a) Identify the benefits, difficulties and critical success factors of PPP.
(b) Measure the effectiveness of PPP against other procurement methods.
(c) Identify representative case studies from other countries for analysis to identify
their approach to success/failure.
(d) Identify previous projects in Hong Kong that utilised a similar approach to PPP
and to analyse their implementation successfulness.
Chapter 10 Conclusions and Recommendations
275
(e) Investigate the best conditions in terms of project nature, project complexity,
project types and project scales under which the use of PPP is the most
appropriate.
(f) Evaluate the findings collected to determine a best practice framework for
implementing PPP in Hong Kong.
The objectives were achieved by information collected from a comprehensive literature
review, case studies, interviews and a questionnaire survey (as described in Chapter 2).
Table 10.1 illustrates the tools used to achieve these objectives.
Chapter 10 Conclusions and Recommendations
276
Table 10.1 Tools used to achieve the research objectives
Data collection tools Objective 1 2 3 4 5 6
Identify the benefits,
difficulties and critical
success factors of PPP
Measure the effectiveness
of PPP against other
procurement methods
Identify representative case studies from other
countries for analysis to
identify their approach to
success/failure
Identify previous
projects in Hong Kong
that utilised a similar
approach to PPP and to
analyse their implementation successfulness
Investigate the best
conditions in terms of
project nature, project
complexity, project types and project scales under
which the use of PPP is the
most appropriate
Evaluate the findings
collected to determine a best practice
framework for implementing PPP in Hong
Kong
Literature review Case study Interview Questionnaire survey
Chapter 10 Conclusions and Recommendations
277
10.3 Major Findings
10.3.1 Benefits, difficulties and critical success factors of PPP
10.3.1.1 Benefits/attractive factors of PPP
A summary of the attractive factors were summarised from international literature and
presented in Section 3.4 of Chapter 3. Financial benefits of PPP projects are often
regarded by governments as an attractive factor. In many jurisdictions that first started to
adopt PPP projects this was often seen to be the main driver. For example, the United
Kingdom and the Victoria state of Australia were also amongst those to introduce PPP
projects due to financial difficulties to provide for public works projects.
Obviously, private financing is attractive to the public sector for a number of other
reasons. Firstly the government’s pressure to provide for public services can be reduced
by introducing private sector financing. For governments that have no financial worries,
they still often welcome private financing so that they can utilize their own resources for
other means such as for medical and education services. Although some may argue that
the government can borrow more cheaply than the private sector, by reducing the
government’s borrowing will in turn increase their credit ratings. Often PPP projects tend
to be large scaled projects which are complex and costly to deliver, without introducing
private financing these projects may not be possible. For some jurisdictions they may
also be interested to deliver these projects to increase their image, tourism and
Chapter 10 Conclusions and Recommendations
278
international status.
Cost certainty is also something that has been demonstrated by the private sector to be
more achievable. The public sector on the other hand are not trained businessmen hence
tend to be less capable than the private sector at the economics of projects. In addition,
for public works projects to be delivered by PPP, more business opportunities can be
introduced for the private sector. In PPP projects the extent of private sector participation
tends to be much more compared to traditional projects.
Improved services and products were also found to be attractive factors of PPP from the
literature search. Private sector can introduce more efficiency, skills, technology,
expertise, innovation, long term maintenance and knowledge to the project so that better
public services are provided. The public sector is not trained for these types of jobs
whereas the private sector is hence they tend to perform better. The public sector on the
other hand is trained to deal with administration and by delivering public works by PPP
the public sector can focus on their job duties.
Appropriate risk sharing in PPP projects is a very popular topic amongst literature. A
large emphasis of the arrangement is based on the risk allocation element. Some previous
projects have also had bad experiences with dealing with inappropriate risk allocation for
example the Cross City Tunnel in Sydney. Under a PPP arrangement the public sector
can pass a large proportion of the risks to the private sector. Whereas, in a traditional
approach often the risks handled by the consortium are limited only to the design and
Chapter 10 Conclusions and Recommendations
279
construction of the project. In PPP projects the risks can extend to operation,
maintenance, revenue, market risks etc. Although this may be advantageous to the public
sector to some extent, the party best able to manage the risk should be assigned.
PPP projects tend to show time certainty. The private sector is involved for financial
returns. The faster a project is delivered the faster they start to collect their revenue.
Hence, often PPP projects tend to be delivered on-time or even earlier than expected.
Chapter 7 presented the findings from an empirical questionnaire survey. The results
found that the top three attractive factors in Hong Kong were efficiency related. The first
attractive factor identified was “Provide an integrated solution (for public infrastructure /
services)”. This may also be considered an attractive factor for traditional projects but in
PPP projects there is a larger emphasis on the overall package as the private sector are
involved in a larger extent.
The second attractive factor rated was “Facilitate creative and innovative approaches”.
As mentioned previously the public sector is not trained in this way, instead their job is to
perform administrative duties. Hence, the private sector tends to be better in this area.
Another factor identified was “Solve the problem of public sector budget restraint”.
Although, Hong Kong is financially capable to provide for its own public services and
facilities there were still some respondents that rated this factor highly, probably due to
the Hong Kong’s large infrastructure plan in the coming years. The first and second
attractive factors were rated the same in Australia.
Chapter 10 Conclusions and Recommendations
280
The third attractive factor was rated second in the United Kingdom. Rated third in
Australia was “Save time in delivering the project”. And rated first and third in the
United Kingdom was “Transfer risk to the private partner” and “Non recourse or limited
recourse to public funding” respectively.
From the case studies conducted in Hong Kong, it was found that PPP was no longer
solely about drawing finance from the private sector. Advantages such as the private
sector’s added efficiency, skills, innovation, expertise, and risk sharing can also be
achieved. In addition, the cases also showed that recent projects incorporating the
experiences from overseas delivered successful projects, hence future projects should also
learn from good practices of others.
10.3.1.2 Difficulties/negative factors of PPP
A summary of the negative factors of PPP were also found from international literature.
These findings have been presented in Section 3.5 of Chapter 3. Problems in the bidding
process are often discussed for PPP projects. These include the high participation costs,
the lengthy process, and the lack of competition.
Some jurisdictions such as Queensland state in Australia have started to introduce
compensation for losing bidders to encourage more competition. Although the
compensated amount may not be comparable to the actual costs spent by the bidders, still
it helps to reduce their financial losses. Hence the idea has been welcome. The process
Chapter 10 Conclusions and Recommendations
281
for procuring PPP projects also tend to be lengthy as the process is much more rigorous
than traditional methods. A main stage that public works projects need to get through is
the public sector comparator to validate whether the project should be delivered by PPP
or more traditional methods. Public sectors tend to be very careful to ensure that PPP
projects are only chosen when value for money can be introduced. The process used by
the Victoria state of Australia is particularly rigorous. Also, PPP projects tend to be large,
expensive and complex hence the procurement process tends to take longer.
Appropriate risk allocation is an advantage of PPP, but inappropriate risk allocation is
also a disadvantage. In situations where projects contain high risks or where contracts are
secured too quickly, risks tend to be easily misallocated. Also, the public sector tends to
be keen to pass as much risk as possible to the private sector, and often the private sector
are keen to take up an unhealthy proportion of the risks in order to participate. The
private sector can be risk takers and tend to be keen to take them for a chance of higher
economic benefits.
Literature also identified that lack of private sector capability can be a problem. In most
cases the private sector tends to be confident in their ability. From experience they have
also shown to perform better than the public sector. But in some situations the chosen
private sector may not be financially or technically capable to handle the project. This
could just be because they are not the correct people for the job.
The success of a project often depends on the general public’s support and interest.
Chapter 10 Conclusions and Recommendations
282
Dissatisfaction from the general public can lead projects failing. This could be due to the
high charges for a PPP facility or service. In PPP projects the private consortium often
charges the facility or service a lot more compared to if it was ran by the public sector as
they need to repay their investment costs as well as earn a profit. Whereas, this is not the
government’s concern..
Other problems identified from literature include the existing legal framework. The
current legal framework of some jurisdictions has not been designed to apply for PPP
projects. In Hong Kong for example there has been specific project legislation which is
time consuming and costly.
An unattractive financial market can also occur during the course of the concession
period which can be long periods, in Hong Kong this tends to be thirty years. The
political unstability and high interest rates are some common problems which are
common.
From the same empirical questionnaire survey presented in Chapter 7, the top three
negative factors identified in Hong Kong were also derived. The top factor identified was
“Lengthy delays because of political debate”. Many projects in Hong Kong have been
put on hold or changed from being delivered by PPP to traditional methods because of
political debate particularly within the local Legislative Council.
The second factor identified was “Lengthy delays in negotiation”, again this factor is
Chapter 10 Conclusions and Recommendations
283
partially related to the first factor identified. Also, due to some unsuccessful experiences
the local Hong Kong government has been careful to deliver projects by PPP, hence the
negotiation process of projects has tend to be lengthened to ensure that the correct
decisions are made.
The third factor identified was “Very few schemes have actually reached the contract
stage (aborted before contract)”. Again, as mentioned the local government has proposed
a number of PPP projects but due to the opposition received from the Legislative Council
and general public they have continuously reverted to more traditional methods.
The second negative factor was also rated the same in the United Kingdom. Rated first
and third in the United Kingdom included “A great deal of management time spent in
contract transaction” and “High participation costs” respectively. And, rated in the top
three in Australia include: 1) Lack of experience and appropriate skills; 2) High
participation costs; and 3) Confusion over government objectives and evaluation criteria.
Chapter 5 presented the analysis of cases in Australia. The results showed that a number
of obstacles and failings were encountered. First PPP projects took a long process, lack of
knowledge was observed, and disruption of normality was also observed. It was also
found that some complex projects were conducted. Social projects can be more
challenging than economic ones. Projects with unique features can cause more
challenges. It was found that often the private sector can lack confidence due to the
government’s poor track record in committing to projects.
Chapter 10 Conclusions and Recommendations
284
For transportation projects, inaccurate traffic forecasts can lead to a raise of tolls, general
public dissatisfaction, government limiting the users’ options etc. Also, a partnership
arrangement is essential for PPP projects. In the cases considered the public and private
parties openly criticised each other; there was no toll subsidy / compensation from the
local government, and also the toll level was not open for negotiation.
10.3.1.3 Critical success factors of PPP
Critical success factors of PPP were sourced from international literature and summarised
in Section 3.7 of Chapter 3. The findings include contract benchmarks being achieved
on-time and with good quality, although this critical success factor could also be
considered for traditional projects. Part of the reason for conducting projects by PPP is to
introduce the private sectors’ expertise to a larger extent hence it is important for the
government to give a free hand for the private sector to maximise their ability. In
situations where the project fails in anyway the government must be willing to step in if
necessary as PPP projects emphasise on a partnership arrangement.
A transparent and efficient procurement process is essential in PPP projects. In Hong
Kong for example the general public has often criticised public private collusion existing
due to certain large private parties benefiting huge profits from residential development
rights. A stable political and social environment is also important particularly in less
developed countries. An efficient and mature financial market is essential to ensure that
the project gains revenue as often concession periods span over a long period compared
Chapter 10 Conclusions and Recommendations
285
to traditionally procured projects.
Critical success factors were derived from the Australian case analysis presented in
Chapter 5. Compensation to the losing bidder was one of these. Due to the high
tendering costs competition is often limited as private parties will consider thoughtfully
that their probability of winning is very high before competing for PPP projects.
Therefore compensation for the losing bidder is attractive to increase compensation as
their financial loss will be reduced. The government should also show strong support so
that the project can be delivered successfully.
Chapter 6 presented the findings from interviews conducted with experienced PPP
practitioners from the public and private sector, as well as researchers. From the
interviews with the public sector the most common critical success factors were identified.
Well defined project objectives were mentioned according to both Hong Kong and
Australian interviewees. Obviously, this factor is also important in traditional projects
but for the complexity of PPP projects it is even more important. As mentioned
previously PPP projects emphasise a partnering arrangement hence partnering
spirit/commitment/trust was mentioned by both groups of interviewees again. Also, the
importance of an appropriate risk allocation was highlighted by Hong Kong interviewees.
And a competitive procurement process was mentioned by Australian interviewees. Due
to the size and complexity of PPP projects there are very few private parties who are
capable hence often there are very few competitors involved. More competition in the
process will increase the chance of selecting a capable consortium to handle the job.
Chapter 10 Conclusions and Recommendations
286
The private sector interviewees mentioned similar critical success factors for PPP to the
public sector interviewees. In addition, they also added that an economically viable
project (according to Hong Kong and Australian interviewees) is important. As
mentioned previously the private sector are businessmen hence economics is an important
factor for them. In Hong Kong, government support (champion) was found to be
important. In other jurisdictions there is often a specific unit to deal with PPP projects. It
is likely that this unit will fall under the treasury department. In Hong Kong on the other
hand there is no such unit hence there is a lack of leadership to drive PPP projects from
the government’s side. As shown from previous cases in Australia, positive media is
crucial for successful PPP projects. The researcher interviewees agreed that well defined
project objectives would be important. They also added that a transparent process and
market need are important.
Chapter 8 continues to present the findings from the empirical questionnaire survey. The
top five success factors for delivering PPP projects in Hong Kong were also mentioned
previously by the other sources of information collected. The findings from the
questionnaire therefore validated previous findings from other sources. These success
factors include:
(1) Favourable legal framework;
(2) Commitment and responsibility of public and private sectors;
(3) Strong and good private consortium;
(4) Stable macro-economic condition; and
(5) Appropriate risk allocation and risk sharing.
Chapter 10 Conclusions and Recommendations
287
The second success factor was ranked first in Australia and fourth in the United Kingdom.
The third success factor was ranked third and first in Australia and the United Kingdom
respectively. The fifth success factor was also ranked second in both Australia and the
United Kingdom. Also ranked in Australia was “Good governance” at fourth and
“Project technical feasibility” at fifth. In the United Kingdom ranked third and fifth was
“Available financial market” and “Thorough and realistic assessment of the cost and
benefits”.
10.3.2 PPP compared to other procurement methods
As mentioned in Section 3.2 of Chapter 3 from the international literature review, there
are several differences between the PPP method and the traditional practice. The main
differences highlighted include the financial arrangement for funding the project and the
risk allocation arrangement for each party involved. It is likely that in a PPP project the
finances will be supported fully or partially by the private sector. And also in PPP
projects the public sector tends to prefer letting the private sector take a share of the risks
involved.
Chapter 4 has analysed a large cross border project where the governments responsible
were originally going to deliver it by Build Operate Transfer (BOT), but in the end
decided to finance it themselves instead. Reasons for this change were analysed and
several suggestions to encourage PPP projects have been presented (refer to section
10.3.4 of this chapter).
Chapter 10 Conclusions and Recommendations
288
Again, from the interview findings presented in Chapter 6 it was found that the public
sector interviewees observed several differences between PPP projects and traditional
projects, these include:
PPP projects tap in private sector’s efficiency/expertise/management/skills
(according to Hong Kong and Australian interviewees);
Public Sector Comparator can act as an indicator to determine the preference
between the methods (according to Hong Kong interviewees only); and
Private sector financing and finance structure of the project (according to
Australian interviewees only).
According to the private sector interviewees the implementation process of projects can
be independent but reducing the competition can minimise the private sector’s loss in
time and money. They also mentioned several differences between PPP and traditional
methods including:
Increased efficiency and speed in PPP projects (according to Hong Kong and
Australian interviewees);
Better integration in PPP projects (according to Hong Kong interviewees only);
Better value for money in PPP projects (according to Hong Kong interviewees
only);
PPP projects accessed by performance (according to Hong Kong interviewees
only);
Larger projects (according to Australian interviewees only);
Different risk profiles (according to Australian interviewees only); and
Chapter 10 Conclusions and Recommendations
289
Rigorous tendering process (according to Australian interviewees only).
In addition, the researchers identified several differences between the two approaches as
well including:
Different risk profiles (according to Hong Kong and Australian interviewees);
Private sector more innovative / efficient in PPP projects (according to Hong
Kong and Australian interviewees);
PPP is a partnership arrangement (according to Hong Kong interviewees only);
and
PPP projects have high tendering / transaction costs (according to Hong Kong
interviewees only).
10.3.3 Representative case studies from Australia
Chapter 4 has presented and analysed two highly profiled PPP projects in Australia.
These are the Southbank Education and Training Precinct (SETP) in Brisbane and the
Cross City Tunnel (CCT) in Sydney. SEPT is the Queensland state’s first PPP project
hence it has been in the public eye from the very beginning. The CCT has been a project
highly profiled in the media and criticised by the general public. From the analysis of the
SETP and CCT projects the failures observed have been reported in Section 10.3.1.2 of
this chapter. Besides these failures, a number of success factors were also observed in the
SETP project and reported in Section 10.3.1.3 of this chapter. Similarly the advantages
and best criteria for PPP have been given in Sections 10.3.1.1 and 10.3.5. These cases
Chapter 10 Conclusions and Recommendations
290
were identified from the literature review and during the discussion with interviewees.
Chapter 4 also describes the function of Partnerships Victoria in Victoria state of
Australia. The unit has produced some of the best guidelines and materials for
conducting PPP projects. Also, a database of projects conducted by their unit is available
on the public domain.
From the interviews with the public sector in Chapter 6, it was found that the
interviewees had all referred to international cases for lessons learnt. Also, they were
keen to build up their knowledge on the PPP experience in other jurisdictions. The
interviews with the private sector showed that all had previous PPP experience
internationally. Similarly the researchers had also conducted cases studies and research
on an international scale.
10.3.4 PPP experiences in Hong Kong
Four highly profiled projects in Hong Kong were analysed in Chapter 4. These included
the Cross Harbour Tunnel (CHT) which is also the first BOT project in Hong Kong to be
conducted, and also the only PPP style project to be returned into the local government’s
hands in Hong Kong. The second case studied was the Western Harbour Crossing
(WHC). This project has been one of the less fortunate BOT projects in Hong Kong, due
to the frequent criticism from the general public, media and legislative councilors
concerning its high tolls. The Asia World Expo (AWE) is a more recent PPP project
Chapter 10 Conclusions and Recommendations
291
which has been subsidised heavily by the local government to encourage more PPP
projects. And finally the West Kowloon Cultural District (WKCD) project which was
originally going to be procured by PPP, but a recent decision left the government paying
for it themselves. From the analyses of these studies it was found that the local
government could encourage more and proper PPP projects by integrating the lessons
learnt internationally with their own experiences. These cases were identified from the
literature review and during the discussion with interviewees.
A non-PPP project was also considered in Chapter 4. The Hong Kong – Zhuahai –
Macau bridge was originally proposed to be delivered by the BOT model. But recently
the three governments responsible have come to an agreement that they would finance the
project themselves instead. Several reasons were highlighted for this sudden change.
These reasons led to a list of conditions that would be necessary in future to encourage
more PPP style projects including:
Attract the private sector by an economically viable project;
Speed up the process of tendering and negotiation in PPP projects;
Adopt legal experts to advise on the contracts;
Ensure that toll prices are kept at acceptable levels to the general public
throughout the concessionary period;
Transparent process to avoid public perception of collusion between business
and the government; and
PPP should be adopted for reasons besides financial.
Chapter 10 Conclusions and Recommendations
292
Findings from Chapter 6 showed that the private sector interviewees tended to have
experience in projects both locally and overseas. Practitioners in Hong Kong may not
have the necessary talents to conduct PPP projects due to the minimal PPP project
experience in Hong Kong. Therefore, gaining overseas experience or importing expertise
has been a solution. Instead Hong Kong should consider training their own people both
in the public and private sector to involve in PPP projects.
The public and private sector interviewees all felt keen towards PPP reference materials.
Some of the public sector interviewees in Hong Kong even had their own resources
available. On the other hand the private sector interviewees tended to refer to reference
materials provided by others.
10.3.5 Best conditions for using PPP
The interview findings in Chapter 6 showed that projects best suited for PPP according to
the public sector interviewees include ones that are economically viable (according to
Hong Kong and Australian interviewees) and ones with scope for innovation (according
to Australian interviewees only). Often the success of a project is measured by the
economics, especially for the private sector. Therefore, with adequate profit margins
from the PPP project all parties are normally kept happy. PPP projects tap in private
sector’s expertise, so where projects have more room for innovation, the private sector’s
ability can be maximised.
Chapter 10 Conclusions and Recommendations
293
According to the private sector all sorts of projects are suited for PPP, but their motives
for conducting PPP projects include:
Government need (according to Hong Kong and Australian interviewees);
Private sector expertise (according to Hong Kong interviewees only);
Value for money (according to Hong Kong interviewees only);
Private sector efficiency (according to Hong Kong interviewees only); and
Risk transfer (according to Australian interviewees only)
The researchers in Hong Kong added that each project should be considered
independently but it is likely that PPP is adopted when the government lacks funding for
providing public works projects. According to the Australian researchers large projects
are more suitable for PPP.
Also presented in Chapter 8 are the findings for the reasons to adopt PPP projects. The
results showed that in general Hong Kong focuses on improving the overall performance
of public projects. Ranked highly in Hong Kong, Australia and the United Kingdom was
“Economic development pressure demanding more facilities”, again this reason is related
to the project’s economics Ranked highly in Hong Kong and Australia was “High quality
of service required”. Ranked in Hong Kong only was “Private incentive” also related to
economics. And ranked in either Australia or the United Kingdom alone include
“Shortage of government funding”, “Inefficiency because of public monopoly and lack of
competition” and “Avoid public investment restriction”. As mentioned previously Hong
Kong is not short of financial reserve but both Australia and the United Kingdom started
Chapter 10 Conclusions and Recommendations
294
to use PPP because they were unable to provide for the necessary public facilities and
services. The competition issue has once again been confirmed to be important. Often
there are many governmental procedures for finances to be secured but with the
introduction of private financing many of these can be avoided.
The criteria for PPP projects were discussed in Chapter 5 from the Australian case
analysis results. It was found that PPP should be adopted when the project shows value
for money. Project risks should always be allocated to the party best able to handle them.
A risk sharing mechanism should be adopted in projects of high risk nature. A regular fee
payment from the government instead of the private sector bearing the revenue risk could
be considered
10.3.6 Recommendations for Developing a Best Practice Framework for Public
Private Partnerships in Hong Kong
Drawing from the findings derived, a best practice framework for implementing PPP
projects in Hong Kong has been presented in Chapter 9. Obviously, it is difficult to unify
all types of projects hence this framework acts as a general guideline only. This
framework incorporates the findings achieved from the literature review, case studies,
interviews and questionnaire survey throughout the research study. The findings were
then applied to an existing PPP process identified by the Efficiency Unit (2008b) of the
Hong Kong Special Administrative Region (HKSAR) government. This process contains
eight key steps for implementing PPP projects including:
Chapter 10 Conclusions and Recommendations
295
(1) Mobilisation and development of a business case;
(2) Funding;
(3) Technical assessments, consultation and land requirements;
(4) Expression of interest exercise;
(5) Policy and funding approvals;
(6) Procurement and selection;
(7) Service commencement; and
(8) Payment and contract management.
From the findings of this research study, users adopting the process for PPP projects in
Hong Kong are shown the “Dos” and “Don’ts” at each step. Lastly, this framework was
validated by a questionnaire survey conducted with PPP practitioners. The respondents
were asked to rate six factors relating to the performance of the framework. These factors
included: appropriateness; objectivity; replicability; practicability; reliability and
suitability.
10.4 Value and Significance of the Research
This research study has introduced a best practice framework for PPP in Hong Kong
which has never been introduced previously by others. The framework does not intend to
introduce new alternatives but instead builds on existing practices so that users can more
easily adapt to the improvement. Development is made to the current process of
implementing PPP projects. Up to present, practitioners in Hong Kong are only told
Chapter 10 Conclusions and Recommendations
296
“what” they should be doing, but have not been shown “how” they can achieve these
goals. This framework has been developed using both international and local experiences
so that the lessons learnt from overseas can be incorporated to fit in with the distinct local
situation.
The findings are believed to be useful for all practitioners who are either considering or
currently involved with PPP projects. Practitioners involved with existing projects can
better understand how to conduct them so that they can be carried out more efficiently.
For those practitioners considering adopting or participating with PPP projects can be
given more confidence to take action. As a result more development is encouraged.
Opportunities are also broadened for the private sector improving the overall financial
climate. With Hong Kong’s current proposed infrastructure plan more procurement
alternatives should be sought. Projects should be delivered by the method that it is most
suitable for.
This framework therefore provides an alternative to traditional methods. The public
sector is better informed hence in future can consider which types of projects are most
appropriate to be delivered by PPP. Also, both the public and private sector will be more
aware of each others’ motives which are important for projects to succeed.
Besides the obvious practical uses of this best practice framework, the findings from this
study have also contributed to the body knowledge in PPP. The recent developments of
Chapter 10 Conclusions and Recommendations
297
PPP in Hong Kong have been reviewed, highlighting areas that require further works for
researchers. Information has also been gathered from countries that are leading in the
area of PPP, which has helped to broaden knowledge in this field. In addition, the
development of this best practice framework has presented a methodology that could be
used for research studies even in other fields and industries.
10.5 Limitations of the Research
Several limitations were noticed whilst conducting this research study, these include:
A larger number of questionnaire responses would have increased the
credibility of the results from the survey analysis. In Australia particularly, data
collection was found to be more difficult due to geographic distances.
The questionnaire results obtained from Hong Kong and Australia were
compared to those findings obtained by Li (2003) in England. The analysis
would have been more valuable if the data collected in England was more up to
date.
The interview findings from Hong Kong and Australia were more difficult to
compare due to the different level of understanding in the topic of PPP.
Although all interviewees were involved with PPP in some way, it was found
that the Hong Kong interviewees were in general less knowledgeable on the
topic compared to the Australian interviewees.
The results would have been more representative if more case studies could
have been conducted, but due to time limitation this was not possible.
Chapter 10 Conclusions and Recommendations
298
The attractive and negative factors were used as a checklist for identifying
suitable PPP projects, but the accuracy needs improvement as the relative
weighting of the factors has not been identified.
Currently the best practice framework has been designed for general PPP
projects only.
10.6 Recommendations for Future Research
Some recommendations for further research work are also proposed:
From the findings achieved in this research study it would be interesting to
apply the theory to potential real life PPP projects. These projects could be
monitored throughout their project life and compared with projects that did not
follow the best practice framework proposed in this study. The differences
could be recorded and analysed for further improvement. Also, with the
development of this framework it would be interesting to see it put to trial by
encouraging the Hong Kong government to adopt the suggestions. This
message could be delivered to them via local conferences and presentations.
The questionnaire survey adopted for this research study could be repeated in
other jurisdictions to enable an international comparison with the results
obtained from the Hong Kong respondents.
The relative weighting of the attractive and negative factors should be
identified, so that the checklist for identifying suitable PPP projects could
provide a more accurate assessment.
Chapter 10 Conclusions and Recommendations
299
The best practice framework presented should be further refined for different
projects according to their size, type, government’s political and budgetary
strength, time etc. currently it is for general projects only.
10.7 Chapter 10 Summary
This research study has formed a solid basis for practitioners in Hong Kong to improve
on the current PPP model adopted. By doing so, a win-win situation will be created
between both the public and private sectors. As a result the construction industry and the
general public at large will benefit.
References
300
REFERENCES
References
301
AAP General News Wire (2006a). War of Words Erupts again Between Lemma and
Tunnel Boss. AAP General News Wire, 4 August 2006.
AAP General News Wire (2006b). Cross City not viable, higher prices not the answer.
AAP General News Wire, 26 August 2006.
AAP General News Wire (2006c). Lane Cove Tunnel Road Changes May Be As Bad As
Cross City. AAP General News Wire, 21 August 2006.
AAP General News Wire (2006d). Motorists have right to be angry over toll inequities.
AAP General News Wire, 20 September 2006.
AAP General News Wire (2006e). Cross City Boss says Lemma Fails to Show
Leadership. AAP General News Wire, 4 August 2006.
AAP General News Wire (2006f). Tunnel Operators Seek Millions in Compensation for
Changes. AAP General News Wire, 26 August 2006.
Abdul-Rashid, A. A., Puteri, S. J. K., Ahmed, U. A. and Mastura, J. (2006). Public
private partnerships (PPP) in housing development: the experience of IJM
Malaysia in Hyderabad, India. Accelerating Excellence in the Built Environment,
2 – 4 October 2006, Birmingham, United Kingdom.
Ahadzi, M. and Bowles, G.. (2004). Public-Private Partnerships and Contract
Negotiations: An Empirical Study. Construction Management and Economics,
22(9), 967-978.
Akbiyikli, R. and Eaton, D. (2004). Risk management in PFI procurement: A holistic
approach. Proceedings of the 20th Annual Association of Researchers in
Construction Management (ARCOM) Conference, Heriot-Watt University,
Edinburgh, United Kingdom, 1-3 September 2004, 1269-1279.
References
302
Akintoye, A. (2007). Developments in the UK Public Private Partnerships: Lessons for
the New PPP Ventures (Keynote Paper). Proceedings of the 2007 International
Conference on Concession Public / Infrastructural Projects (ICCPIP), Dalian
University of Technology, China, 24 – 26 August 2007.
Akintoye, A., Beck, M. and Hardcastle, C. (2003). Public-Private Partnerships:
managing Beijing Municipal Commission of Development and Reform.
Proceedings of International Forum on Infrastructure Marketization,
http://www.bjpc.gov.cn/zt/sheshi (accessed on 18 March 2008).
Akintoye, A., Beck, M., Hardcastle, C., Chinyio, E. and Asenova, D. (2001). The
financial structure of Private Finance Initiative projects. Proceedings of the 17th
ARCOM Annual Conference, Salford University, Manchester, United Kingdom,
1361 - 1369.
Al-Sharif, F. and Kaka, A. (2004). PFI/PPP topic coverage in construction journals.
Proceedings of the 20th Annual ARCOM Conference, 1-3 September 2004, Heriot
Watt University, United Kingdom, 1, 711-719.
Apple Daily (2008). 明智決定謝絕財團免加價冇王管 (Chinese version only). English
translation: Wise Decision to Prevent Consortia from Raising Tolls. Apple Daily,
6 August 2008, Hong Kong.
Asia World Expo (2008a). Photo Gallery, http://www.asiaworld-expo.com/NewsRoom
/PhotoVenue.aspx?lang=en-US&category=Exterior (accessed on 16 November
2008).
AsiaWorld Expo (2008b). www.asiaworld-expo.com (accessed on 11 November 2008).
References
303
Asian Development Bank (2009). Application of Public Private Partnerships in Urban
Rail Based Transportation Project, Component C: PPP Manual, TA4724-PRC, 12
March 2009.
Askar, M.M. and Gab-Allah, A.A. (2002). Problems Facing Parties Involved in Build,
Operate, and Transport Projects in Egypt. Journal of Management. in Engineering,
18, 4, 173-178.
Aziz, A.M.A. (2007). A Survey of the Payment Mechanisms for Transportation DBFO
Projects in British Columbia. Construction Management and Economics, 25(5),
529-543.
Berg, S.V., Pollitt, M.G. and Tsuji, M. (2002). Private Initiatives in Infrastructure.
Edward Elgar, Cheltenham, United Kingdom.
Birnie, J. (1999). Private Finance Initiative (PFI) – UK construction industry response.
Journal of Construction Procurement, 5(1), 5-14.
Borzel, T.A. and Risse, T. (2005). Public Private Partnerships: Effective and Legitimate
Tools of Transnational Governance? Edited by Grande, E. and Pauly, L. Complex
Sovereignty: Reconstituting Political Authority in the Twenty-First Century,
University of Toronto Press.
Boussabaine, A. (2007). Cost planning of PFI and PPP building projects, Taylor and
Francis.
Bouygues-Asia (2008). www.bouyguesasia.com (accessed on 11 November 2008).
Bovaird, T. (2004). Public–Private Partnerships: from Contested Concepts to Prevalent
Practice. International Review of Administrative Sciences, 70(2), 199-215.
References
304
British Columbia (1999). Public Private Partnership – A Guide for Local Government
Ministry of Municipal Affairs, British Columbia Government.
Carrillo, P., Robinson, H., Foale, P., Anumba, C., Bouchlaghem, D. (2007). Participation,
Barriers and Opportunities in PFI: The United Kingdom Experience. Journal of
Management in Engineering, ASCE, 24(3), 138-145, July 2008.
Chan, A. P. C., Sidwell, T., Kajewski, S., Lam, P. T. I., Chan, D.W.M. and Cheung, E.
(2007a). From BOT to PPP - A Hong Kong Example. Proceedings of the 2007
International Conference on Concession Public / Infrastructural Projects
(ICCPIP), Dalian University of Technology, China, 24 – 26 August 2007, 9:010-
018.
Chan, A.P.C., Lam, P.T.I., Chan, D.W.M. and Cheung, E. (2008). A Mechanism for Risk
Sharing in PPP Projects – The Sydney Cross City Tunnel Case Study. Surveying
and Built Environment (Journal of the Hong Kong Institute of Surveyors), 19, 1,
December 2008.
Chan, D.W.M., and Kumaraswamy, M.M. (1996). An evaluation of construction time
performance in the building industry. Building and Environment, 31(6), 569-578.
Chan, D.W.M., Chan, A.P.C. and Lam, P.T.I. (2006). A feasibility study of the
implementation of public private partnership (PPP) in Hong Kong. Proceedings of
the CIB W89 International Conference on Building Education and Research,
April 10-13, 2006 (under Sub-theme 2.6 - Procurement Management).
Chege, L.W. (2001). Private Financing of Construction Projects and Procurement
Systems: An Integrated Approach. Proceedings of the CIB World Building
Congress, April 2001, Wellington, New Zealand.
References
305
Chen, B. (2008). Bridge set for early finish on new deal. The Standard, 4 August 2008,
Hong Kong.
Chen, B. and Lee, D. (2008). Bridging the Divide. The Standard, 6 August 2008, Hong
Kong.
Cheung, G., Eng, D. and Ng J. (2008). Government to splash out HK$7.2 billion on
cruise terminal, South China Morning Post, 1 October 2008.
Chow, L.K. (2005). Incorporating Fuzzy Membership Functions and Gap Analysis
Concept into Performance Evaluation of Engineering Consultants – Hong Kong
Study, Unpublished PhD thesis, Department of Civil Engineering, The University
of Hong Kong, Hong Kong Special Administration Region, 225 pages.
Civic Exchange, APCO Asia Limited and Hawker Britton (2005). Getting PPP Right:
Using West Kowloon Cultural District as a Case Study, Hong Kong.
Clifton, C. and Duffield, C.F. (2006). Improved PFI/PPP Service Outcomes through the
Integration of Alliance Principles. International Journal of Project Management,
24(7), 573-586.
Cobb, J.M. (2005). Financing Bangkok’s Mass Transit, IDC TransGate.
http://www.idcworld.com/bangkok.htm (accessed on 23 May 2007).
Corbett, P. and Smith, R. (2006). An analysis of the success of the Private Finance
Initiative as the Government's preferred procurement route. Proceedings of the
Accelerating Excellence in the Built Environment Conference, Birmingham,
United Kingdom, 2 – 4 October 2006.
Cratchley, D. and Jean, P. (2006a). Govt May Compensate Lane Cove Tunnel Operators,
AAP General News Wire, 28 August 2006.
References
306
Cratchley, D. and Jean, P. (2006b). State Government May Compensate Lane Cove
Tunnel Owners, AAP General News Wire, 28 August 2006.
Cross City Tunnel Proprietary Limited (2007). http://www.crosscity.com.au (accessed on
30 May 2007).
Dainty, A.R.J., Bagilhole, B.M. and Neale, R.H. (2000). Computer aided analysis of
qualitative data in construction management research. Building Research and
Information, 84, 4, 226 – 233.
Denzin, N.K. and Lincoln, Y.S. (2005). Handbook of Qualitative Research, Second
Edition, Sage Publications Inc.
Department of Education, Training and the Arts (2008). South Bank Education and
Training Precinct – Ariel Photographs October 2007, Queensland Government,
Australia,http://www.southbank.edu.au/site/epicentre/downloads/October2007Aer
ialPhotographs.pdf (accessed on 16 November 2008).
Dhaene, G. (2008). PPP initiatives and the HR crisis in the health sector. Proceedings of
the Global Health Workforce Alliance Conference, March 2008, Kampala,
Uganda.
Drew, J. (2005). Public Private Partnerships – Opportunities and Challenges.
Proceedings of the Conference on Public Private Partnerships – Opportunities
and Challenges, 22 February 2005, Hong Kong.
Eaton, D., Akbiyukli, R. and Dickinson, M. (2006). An evaluation of the stimulants and
impediments to innovation within PFI/PPP projects. Construction Innovation. 6,
63-77.
References
307
Efficiency Unit (2002). Project 2002- Enhancing the Quality of Education in Glasgow
City Schools by Public Private Partnership, Hong Kong Special Administrative
Region Government, Hong Kong.
Efficiency Unit (2003a). Serving the community by using the private sector - An
introductory guide to public private partnerships (PPPs), Hong Kong Special
Administrative Region Government, Hong Kong.
Efficiency Unit (2003b). Case Summary: University College London Hospital (UCLH)
Redevelopment – Improving the Standard of Healthcare by Public Private
Partnership,
http://www.eu.gov.hk/english/psi/psi_case/files/glasgow_city_schools.pdf
(accessed on 11 November 2008), The Hong Kong Special Administrative Region
Government, Hong Kong.
Efficiency Unit (2008a). Overview,
http://www.eu.gov.hk/english/psi/psi_ppp/psi_ppp_over/psi_ppp_over.html.
(accessed on 5 June 2008), Hong Kong Special Administrative Region
Government, Hong Kong.
Efficiency Unit (2008b). Serving the Community By Using the Private Sector - An
Introductory Guide to Public Private Partnerships (PPPs) (Second Edition),
March 2008, The Hong Kong Special Administrative Region Government, Hong
Kong.
Efficiency Unit (2008c). List of Case Studies,
http://www.eu.gov.hk/english/case/case.html (accessed on 28 July 2008), The
Hong Kong Special Administrative Region Government, Hong Kong.
References
308
Efficiency Unit (2008d). Serving the Community Through Successful Project Delivery,
May 2008, The Hong Kong Special Administrative Region Government, Hong
Kong.
Efficiency Unit (2008e). Policy and Practical Guides to PSI, Outsourcing and PPPs,
http://www.eu.gov.hk/english/psi/psi_guides/psi_guides_ppgpop/psi_guides_ppgp
op.html (accessed on 17 September 2008), The Hong Kong Special
Administrative Region Government. Hong Kong.
Efficiency Unit. (2001). Serving the Community by Using the Private Sector, Hong Kong
Special Administrative Region Government, Hong Kong.
Efficiency Unit. (2007). Serving the Community By Using the Private Sector Policy and
Practice (Second Edition), January 2007, Hong Kong Special Administrative
Region Government, Hong Kong.
El-Gohary, N.M., Osman, H. and El-Diraby, T.E. (2006). Stakeholder management for
public private partnerships, International Journal of Project Management, 24(7),
595-604.
Encyclopedia.com (2009). A Brief History of Hong Kong’s Kai Tak Airport,
http://www.encyclopedia.com/doc/1P2-18198579.html (accessed on 17 March
2009).
English, L.M. and Guthrie, J. (2003). Driving privately financed projects in Australia:
what makes them tick, Accounting, Auditing and Accountability Journal, 16(3),
493 – 511.
References
309
Entwistle, T. and Martin, S. (2005). From Competition to Collaboration in Public Service
Delivery: A New Agenda for Research. Public Administration, 83(1), 233–242.
Environment, Transport and Works Bureau (2004). Reference Guide on Selection
of Procurement Approach and Project Delivery Techniques, Technical Circular,
No. 32/2004.
Environment, Transport and Works Bureau (2004). Reference Guide on Selection of
Procurement Approach and Project Delivery Techniques, Technical Circular
(Works) No. 32/2004, October 2004, Hong Kong Special Administrative Region
Government, Hong Kong.
Ernst and Young (2005). Australian PPP Survey – Issues Facing the Australian PPP
Market, November 2005.
European Commission Directorate (2003). Guidelines for Successful Public-Private
Partnerships – Version 1, Directorate-General Regional Policy, European
Commission, February 2003.
Farrah, T. (2007). Brumby wins battle to keep EastLink costs secret. The Age, February
14, 2007. http://www.theage.com.au/news/national/brumby-wins-battle-to-keep-
eastlink-costs-secret/2007/02/13/1171128974031.html (accessed on 15 May 2007).
Fellows, R., and Liu, A. (1997). Research Methods for Construction. Blackwell Science
Limited, Oxford, United Kingdom.
Field K. (2006a). Childish Act Shows NSW Not Open For Business, AAP General News
Wire, 10 October 2006.
Field, K. (2006b). Sydney's Cross City Tunnel Operators to Pursue Toll Cheats, AAP
General News Wire, 20 September 2006.
References
310
Forum Sara (2008). Western Harbour Crossing Tunnel,
http://site.sara.free.fr/photos/HKG-West_Kowloon_Highway-001-
Western_Harbour_Crossing_Tunnel-JRL.jpg (accessed on 16 November 2008).
Gentry, B.S. and Fernandez, L.O. (1997). Evolving public-private partnerships: general
themes and urban water examples. Proceedings of the OECD Workshop on
Globalization and the Environment: Perspectives from OECD and Dynamic Non-
Member Economies, Paris, 13 – 14 November 1997, 19-25.
Ghobadian, A., Gallear, D., O'Regan, N., and Howard, V. (2004). Future of the Public
Private Partnership, Public Private Partnerships: Policy and Experience, Palgrave
Macmillian, Chippenham, 271-302.
Grimsey, D. and Lewis, M.K. (2004). Public private partnerships: The worldwide
revolution in infrastructure provision and project finance, Edward Elgar,
Cheltenham, The United Kingdom.
Grimsey, D. and Lewis, M.K. (2005). Are Public Private Partnerships value for money?
Evaluating alternative approaches and comparing academic and practitioner views.
Accounting Forum, 29(4), 345 – 378.
Grimsey, D. and Lewis, M.K.. (2002). Evaluating the Risks of Public Private
Partnerships for Infrastructure Projects. International Journal of Project
Management, 20(2), 107-118.
Gunnigan, L. and Eaton, D. (2006). Addressing the challenges that are emerging in the
continued increase in PPP use in the Republic of Ireland. Proceedings of the CIB
W89 International Conference on Building Education and Research, CIB, 10 – 13
April 2006, Hong Kong.
References
311
Heald, D. (2003). Value for money tests and accounting treatment in PFI schemes.
Accounting. Auditing and Accountability Journal, 16, 3, 342-371.
HM Treasury (2003). PFI: Meeting the Investment Challenge, July 2003, United
Kingdom.
Ho, R.C.T. (2005). How Can We Capitalize on the Concept of PPP? Proceedings of the
Conference on Public Private Partnerships – Opportunities and Challenges,
Hong Kong, 22 February 2005.
Hodge, G.A. (2004). The risky business of public private partnerships. Australian
Journal of Public Administration, 63(4), 37 – 49.
Home Affairs Bureau (2008). A Cultural Hub in the Making - West Kowloon Cultural
District, the Hong Kong Special Administrative Region Government,
http://www.hab.gov.hk/wkcd/pe/eng/doc/cultural_hub_in_the_making_ppt_e.pdf
(accessed on 16 November 2008).
Hong Kong Engineer (2006). PPP Stakes Claim for Hong Kong as an Exhibition and
Entertainment Hub. The Journal of the Hong Kong Institution of Engineers, 7-9.
Hong Kong Special Administrative Region Government (2008). Press Release of
the 11th Plenary of the Hong Kong/Guangdong Co-operation Joint Conference, 5
August 2008, Hong Kong.
Hong Kong Special Administrative Region Government (2008).
http://www.eu.gov.hk/english/psi/psi_ppp/psi_ppp_cases/files/uclh_redevelopmen
t.pdf (accessed on 12 March 2008), The Hong Kong Special Administrative
Region Government, Hong Kong.
References
312
Hood, J. and McGravey, N. (2002). Managing the Risk of Public-Private Partnerships in
Scottish Local Government, Policy Studies, 23(1): 21-35.
Howes, R. and Robinson, H. (2005). Infrastructure for the Built Environment: Global
Procurement Strategies (First edition), Oxford: Butterworth-Heinemann.
Hughes, W., Hillebrandt, P., Lingard, H. and Greenwood, D. (2001). The impact of
market and supply configurations on the costs of tendering in the construction
industry. Proceedings of the CIB World Building Congress, April 2001.
Hung, W.T. (2008). Hong Kong-Zhuhai-Macau Bridge – Transport and Environmental
Concerns.
http://www.chamber.org.hk/streaming/ppt/4_HKZMB_wthung.files/frame.htm
(accessed on 13 August 2008).
Information Services Department (2008a). Pact reached on funding Pearl River bridge,
Hong Kong Special Administrative Region Government, Hong Kong, 5 August
2008.
http://www.news.gov.hk/en/category/infrastructureandlogistics/080805/print/0808
05en06002.htm (accessed on12 August 2008).
Information Services Department (2008b). Shatin-Central link construction set for 2010,
Hong Kong Special Administrative Region Government, Hong Kong.
http://www.news.gov.hk/en/category/infrastructureandlogistics/080311/html/0803
11en06003.htm (accessed 1on 2 March 2008).
Infranews (2006). Australian PPPs Ride the Storm.
http://www.nzcid.org.nz/downloads/Australian%20PPPs%20ride%20the%20stor
m%20-%20Infranews%20Aug%2006.pdf (accessed on 10 September 2008).
References
313
Infrastructure Implementation Group (2005). Review of Future Provision of Motorways
in NSW. New South Wales Government, Australia.
Ingall, P. (1997). London Underground's Connect Project, The Institution of Electrical
Engineers,
http://ieeexplore.ieee.org/iel4/5456/14721/00668019.pdf?arnumber=668019 (1
May 2007).
Jean, P. (2006). Cronulla Riot, Tunnel Were my Toughest Days: Lemma. AAP General
News Wire, 3 August 2006.
Jefferies, M. (2006). Critical success factors of public private sector partnerships a case
study of the Sydney SuperDome. Engineering, Construction and Architectural
Management, 13(5), 451-462.
Jefferies, M., Gameson, R. and Rowlinson, S. (2002). Critical success factors of the
BOOT procurement system: reflections from the Stadium Australia case study.
Engineering Construction and Architectural Management, 9(4), 352 - 361.
Jin, X.H. and Doloi, H. (2008). Interpreting risk allocation mechanism in public - private
partnership projects: an empirical study in a transaction cost economics
perspective . Construction Management and Economics, 26, 707–721.
Kanakoudis, V., Papotis, A., Sanopoulos, A., Gkoutzios, V. (2007). Crucial parameters
for PPP projects successful planning and implementation. Edited by Schrenk, M.,
Popovich, V.V., Benedikt, J. REAL CORP 007 Proceedings, Vienna, 20-23 May
2007, 167 – 184.
Kanter, R. M. (1999). From spare change to real change. Harvard Business Review,
77(2), 122-32.
References
314
Ke, Y.J., Wang, S.Q., Chan, A.P.C. and Cheung, E. (2008). Research Trend of Public
Private Partnership (PPP) in Construction Journals. Journal of Construction
Engineering and Management, ASCE, Under review.
Khang, D.G. (1998). Hopewell’s Bangkok Elevated Transport System (BETS), School of
Management, AIT, Bangkok, Thailand.
Koppenjan, J. F. M. (2005). The formation of public-private partnerships: lessons from
nine transport infrastructure projects in the Netherlands, Public Administration,
83(1), 135-157.
Kowloon Motor Bus 30X/230X (2008). Cross Harbour Tunnel,
http://i40.photobucket.com/albums/e234/AVD1-LJ7006/HongKong-
CrossHarbourTunnel.jpg (accessed on 16 November 2008).
Kwan, J. (2005). Public Private Partnerships: Public Private Dialogue. Proceedings of
the Conference on Public Private Partnerships - Opportunities and Challenges,
22 February 2005, Hong Kong.
Kwok, W. (2009). Timeline,
http://jmsc.hku.hk/jmsc6030/bridgestory/dossier/timeline/index.html# (accessed
on 17 March 2009).
Lam, A. (2008). Cross-delta bridge given green light Funding arrangements agreed
between three governments. South China Morning Post, 29 February 2008.
Lam, A. and Chan, Q. (2008). Role in Bridge Plan Ends. South China Morning Post, 9
August 2008, Hong Kong.
Lam, A. and Lai, C. (2008). Beijing Cash Puts Bridge a Step Closer. South China
Morning Post, 6 August 2008, Hong Kong.
References
315
Lam, K. C., Wang, D., Lee, P. T. K. and Tsang, Y. T. (2007). Modelling Risk Allocation
Decision in Construction Contracts. International Journal of Project
Management, 25(5), 485-493.
Legislative Council (2008). Hong Kong – Zhuhai – Macao Bridge, Hong Kong
Boundary Crossing Facilities and the Link Road in Hong Kong, LC Paper No.
CB(1)1317/07-08(04), 25 April 2008, Legislative Council Panel on Transport,
Hong Kong Special Administrative Region Government, Hong Kong,
http://www.thb.gov.hk/eng/whatsnew/transport/2008/200804252.pdf (accessed on
27 August 2008).
Leiringer, R. (2006). Technological Innovation in PPPs: Incentives. Oppourtunities and
Actions. Construction Management and Economics, 24, 301-308. March 2006.
Leong A. (2008). A Sustainable West Kowloon Cultural District. Ming Poa Daily News, 2
June 2008.
Levy, S.M. (1996). Build Operate Transfer, John Wiley and Sons, New York.
Li, B. (2003). Risk management of construction public private partnership projects,
Ph.D Thesis, Glasgow Caledonian University, United Kingdom.
Li, B., Akintoye, A., Edwards, P. J. and Hardcastle, C. (2005b). Perceptions of positive
and negative factors attractive factors influencing the attractiveness of PPP/PFI
procurement for construction projects in the U.K. Engineering, Construction and
Architectural Management, 12(2), 125-148.
Li, B., Akintoye, A., Edwards, P.J. and Hardcastle, C. (2004). Risk treatment preferences
for PPP/PFI construction projects in the UK. Proceedings: ARCOM Conference,
Heriot Watt University, 1-3 September 2004, 2, 1259-1268.
References
316
Li, B., Akintoye, A., Edwards, P.J. and Hardcastle, C. (2005a). The allocation of risk in
PPP/PFI construction projects in the UK. International Journal of Project
Management, 23 (1), January, 25-35.
Li, B., Akintoye, A., Edwards, P.J. and Hardcastle, C. (2005c). Critical success factors
for PPP/PFI projects in the UK construction industry. Construction Management
and Economics, 23, 459-471.
Liu, Y.W., Zhao, G.F. and Wang, S.Q. (2007). Case Study VI – The National Stadium
BOT Project For Beijing 2008 Olympic Games, Public Private Partnership in
Infrastructure Development: Case Studies From Asia and Europe, EU – Asia
Network of Competence Enhancement on Public Private Partnerships in
Infrastructure Development, August 2007.
Mak, C.K., and Mo, S. (2005). Some Aspects of the PPP Approach to Transport
Infrastructure Development in Hong Kong. Proceedings of the Conference on
Public Private Partnerships – Opportunities and Challenges, Hong Kong, 22
February 2005.
Mak, C.W. (2008). 港 珠 澳 大 橋 中 央 注 資 70 億 助 三 地 興 建 踢 走 財 團 降 收
費 (Chinese version only). English Translation: The Chinese Central Government
Invests RMB7 billion in the Hong Kong – Zhuhai – Macau Bridge to Lower Toll
Fees, Apple Daily, 6 August 2008, Hong Kong.
Maltby, P. (2003). Has the PFI grown up? Public Finance, London, August 2003.
Merna, T. and Owen, N. (1998). Understanding the Private Finance Initiative: The New
Dynamics of Project Finance, Hong Kong: Asia Law and Practice Publishing
References
317
Limited, Hong Kong.
Ming Pao Newspaper (2008a). 融資方案突變中央出資 22億 (Chinese version only)
English Translation: Sudden Change in Financing Model, Chinese Central
Government Pays RMB2.2 billion, Ming Poa Newspaper, 6 August 2008, Hong
Kong.
Ming Pao Newspaper (2008b). 中央出資 港珠澳橋後年上馬港出 67億 收費料可減至
200 元下 (Chinese version only). English Translation: Chinese Central
Government Invests in Hong Kong – Zhuhai – Macau Bridge, Project
Commences in Two Years, Hong Kong Invests RMB6.7 billion, Ming Poa
Newspaper, 6 August 2008, Hong Kong.
Mok, C.S. (2005). Privately Financed Infrastructure Projects, MSc Thesis, The
University of Hong Kong, Hong Kong.
Mustafa, A. (1999). Public-Private Partnership: An alternative institutional model for
implementing the Private Finance Initiative in the provision of transport
infrastructure. Journal of Project Finance, 5(2), 64-79.
National Audit Office (2001). Managing the Relationship to Secure a Successful
Partnership in PFI Projects, HC375, National Audit Office, United Kingdom, 29
November 2001.
National Audit Office (2008). Background to Private Finance.
http://www.nao.org.uk/practice_areas/private_finance/background.htm (accessed
on 13 June 2008).
References
318
National Treasury PPP Unit of South Africa (2007). Public Private Partnership Manual,
http://www.treasury.gov.za/organisation/ppp/default.htm (accessed on 15 June
2007).
New South Wales Government (2006). Working with Government - Guidelines for
Privately Financed Projects, December 2006.
Ng, A. and Loosemore, M. (2007). Risk allocation in the private provision of public
infrastructure. International Journal of Project Management, 25(1): 66-76.
Ng, S.T. and Wong, Y.M.W. (2006). Adopting non-privately funded public-private
partnerships in maintenance projects a case study in Hong Kong. Engineering,
Construction and Architectural Management, 13(2), 186-200.
Ng, T. (2008). Govt to have more say in deciding bridge toll. China Daily Hong Kong
Edition, 6 August 2008, Hong Kong.
Nijkamp, P, Van der Burch, M. and Vindigni G. (2002). A Comparative Institutional
Evaluation of Public Private Partnerships in Dutch Urban Land-use and
Revitalization Projects. Urban Studies, 39(10), 1865–80.
Nisar, T.M. (2007). Value for money drivers in public private partnership schemes.
International Journal of Public Sector Management, 20(2) 147-156.
Nishimatsu. (2006). Nishimatsu and PFI, Nishimatsu Construction Company Limited –
Hong Kong Branch.
Oriental Newspaper (2008). 花開堪折不去折直待無花空折枝 (Chinese version only).
English Translation: Opportunity Taken Too Late, Oriental Newspaper, 6 August
References
319
2008, Hong Kong.
Partnerships UK (2008). Partnerships UK. www.partnershipsuk.org.uk (accessed on 25
June 2008).
Partnerships Victoria (2000). Partnerships Victoria Policy. Department of Treasury and
Finance, Victoria State Government, Australia.
Partnerships Victoria (2001). Practitioner’s Guide, June 2001. Department of Treasury
and Finance, Victoria State Government, Australia.
Partnerships Victoria (2008a). Projects, Department of Treasury and Finance, Victoria
State Government, Australia,
http://www.partnerships.vic.gov.au/CA25708500035EB6/WebProjects?OpenView
(accessed on 24 July 2008).
Partnerships Victoria (2008b). Policy and Guidelines, Department of Treasury and
Finance, Victoria State Government, Australia,
http://www.partnerships.vic.gov.au/CA25708500035EB6/0/C0005AB6099597C2
CA2570F50006F3AA?OpenDocument (accessed on 24 July 2008).
Partnerships Victoria (2008c). Standard Commercial Principles, April 2008, Department
of Treasury and Finance, Victoria State Government, Australia.
Partnerships Victoria (2008d). Partnerships Victoria. http://www.partnerships.vic.gov.au
(accessed on 25 June 2008).
Price, W. (2002). Innovation in Public Finance. Public Works Management and Policy, 7,
1, 63-78.
Project Finance (2007). Skies not the limit. Project Finance, April 2007.
References
320
Qiao, L., Wang, S.Q., Tiong, R.L.K. and Chan, T.S. (2001). Framework for critical
success factors of BOT projects in China. Journal of Project Finance, 7(1), 53–61.
Qiu, Q. (2008). Pact Inked of Funding Pearl River Delta Bridge, China Daily Hong
Kong Edition, 6 August 2008, People’s Republic of China.
Queensland Government (2008a). Southbank EPI Centre,
http://www.southbank.tafe.net/site/epicentre/ (accessed on 28 March 2008).
Queensland Government (2008b). Business Case Development,
http://www.dip.qld.gov.au/docs/library/pdf/ppp/ppp_guide_bus_case_dev.pdf
(accessed on 29 July 2008).
Raiden, A.B., Dainty, A.R.J. and Neale, R.H. (2008). Understanding employee
resourcing in construction organizations. Construction Management and
Economics, 26, 11, 1133 – 1143.
Roads Traffic Authority (2003). Cross City Tunnel: Summary of contracts, Roads and
Traffic Authority of New South Wales Government, Australia.
Roads Traffic Authority (2007).
http://www.rta.nsw.gov.au/constructionmaintenance/majorconstructionprojectssyd
ney/crosscitytunnel/index.html (accessed on 30 May 2007).
Sapte, W. (1997). Project Finance: The Guide to Financing Build Operate Transfer
Projects – Uses in PPP. Euromoney, Hong Kong.
Satpathy, I. and Das, B. (2007). Sustainable strategy and policy making module on
infrastructure development via PPP mechanisms: a perspective for application in
India. Proceedings of the 2007 International Conference on Concession Public /
Infrastructural Projects (ICCPIP), Dalian University of Technology, Dalian,
References
321
China, 24 – 26 August 2007.
Sharma S. (2007). Exploring best practices in public–private partnership (PPP) in e-
Government through select Asian case studies. The International Information &
Library Review, 39(3-4), 203-210.
Shen, L.Y. and Wu, Y.Z. (2005). Risk concession model for BOT contract projects.
Journal of Construction Engineering and Management, ASCE, 131, 2, 211-220.
Shen, L.Y., Platten, A. and Deng X. P. (2006). Role of Public Private Partnerships to
Manage Risks in Public Sector Projects in Hong Kong. International Journal of
Project Management, 24(7), 587-594.
Siegel, S. and Castellan, N. J. (1988). Nonparametric Statistics for the Behavioral
Sciences, McGraw-Hill Inc.
Singh, L.B. and Kalidindi, S.N. (2006). Traffic Revenue Risk Management Through
Annuity Model of PPP Road Projects in India. International Journal of Project
Management, 24(7), 605-613.
Sing Tao Daily (2008) Tate’s Cairn Toll Rise Shows Need to Review the Build Operate
Transfer System. Sing Tao Daily, 16 September 2008.
So, K.K.L., Chung, K.L. and Cheung, M.M.S. (2007). Public Private Partnership in
infrastructure development in Hong Kong - past and future trend. Proceedings of
the 5th International Conference on Construction Project Management / 2nd
International Conference on Construction Engineering and Management, March
1-2, 2007.
References
322
So, U. (2009). West Kowloon hub empowered to cover costs. The Standard, 11
September 2007,
http://www.thestandard.com.hk/news_print.asp?art_id=53223&sid=15309731
(accessed on 17 March 2009).
South China Morning Post (2008). Now we Need Action on the Arts Hub Project,
19 June 2008.
Sun, Y., Fang, D.P., Wang, S.Q., Dai, M.D. and Lv, X.Q. (2008). Safety Risk
Identification and Assessment for Beijing Olympic Venues Construction. Journal
of Management in Engineering, 24(1): 40-47.
Tam, A. (2006). PPP Stakes Claim for Hong Kong as an Exhibition and Entertainment
Hub. The Journal of the Hong Kong Institution of Engineers, 7-9.
Tam, C.M. (1999). Build-operate-transfer model for infrastructure developments in Asia:
reasons for successes and failures. International Journal of Project Management,
17, 6, 377 – 382.
Tam, C.M., Li, W.Y. and Chan, A.P.C. (1994). BOT applications in the power industry of
South East Asia: a case study in China. In: East Meets West. Procurement
Systems Symposium CIB W92 Proceedings Publication, 175, 315 - 322.
The Hong Kong Polytechnic University (2009). Newspapers,
http://www.lib.polyu.edu.hk/newspapers (accessed on 19 March 2009).
Thomas, A.V., Kalidindi, S.N. and Ananthanarayanan, K. (2003). Risk perception
analysis of BOT road project participants in India. Construction Management
References
323
and Economics, 21(4): 393-407.
Thomas, A.V., Kalidindi, S.N. and Ganesh, L.S. (2006). Modeling and assessment of
critical risks in BOT road projects. Construction Management and Economics,
24(4): 407-424.
Tieman, R. (2003). A revolution in public procurement: UK’s private finance initiative.
Finance Times, London, 24 November 2003, 4.
Tiong, R. L. K. (1996). CSFs in competitive tendering and negotiation model for BOT
projects. Journal of Construction Engineering Management, 122(3), 205-211.
Townsend, I. (2004). Springborg envisions united conservative party, AM ABC Radio,
13 November 2004, http://www.abc.net.au/am/content/2004/s1242839.htm
(accessed on 28 March 2008).
Taffman (2008). Altair with Three Roads,
http://www.flickr.com/photos/30246562@N05/2994666472/ (accessed on 17
November 2008).
Transport and Housing Bureau (2008a). Hong Kong – Zhuhai – Macao Bridge, Hong
Kong Special Administrative Region Government, 7 March 2008,
http://www.thb.gov.hk/eng/policy/transport/issues/cbt_3.htm (accessed 12 August
2008).
Transport and Housing Bureau (2008b). Consensus reached on financing of HK-Zhuhai-
Macao bridge, Hong Kong Special Administrative Region Government, 28
February 2008,
http://www.thb.gov.hk/eng/psp/pressreleases/transport/land/2008/200802291.htm
References
324
(accessed on 12 August 2008).
Transport and Housing Bureau (2008c). 運輸及房屋局局長談港珠澳大橋(答問部
分) (Chinese version only). English Translation: Secretary of Transport and
Housing Bureau Speaks of the Hong Kong – Zhuhai – Macau Bridge (Questions
and Answers), Hong Kong Special Administrative Region Government, Hong
Kong, 28 February 2008,
http://www.thb.gov.hk/tc/psp/pressreleases/transport/land/2008/200802293.htm
(accessed on 12 August 2008).
Tsang, J.C. (2008). Fallacies about Cyberport, CB(1)814/04-05(01)
http://www.legco.gov.hk/yr04-05/english/panels/itb/papers/itb0202cb1-814-1e.pdf
(accessed on 17 November 2008).
United Nations Economic Commission for Europe (2004). Governance in Public Private
Partnerships for Infrastructure Development, Geneva.
Van der Kamp, J. (2008). New Funding Proposal Made for Zhuhai Bridge. South China
Morning Post, 1 August 2008, Hong Kong.
Walker, C. and Smith, A. (1995). Privatized Infrastructure: the BOT Approach, Thomas
Telford, London.
Walker, C., Mulcahy, J., Smith, A., Lam, P.T.I., and Cochrane, R. (1995). Privatized
Infrastructure, Thomas Telford, London.
Wibowo, A. and Kochendörfer, B. (2005). Financial risk analysis of project finance in
Indonesian toll roads. Journal of Construction Engineering and Management,
References
325
131(9): 963-972.
Wong, A. (2005). ICAC to take role in public private deals. The Standard, 31 October
2005, http://www.thestandard.com.hk/news_print.asp?art_id=4529&sid=5255280
(accessed on 20 August 2008)
Wong, A. (2007). Lessons Learned from Implementing Infrastructure PPPs – A View
from Singapore. Seminar jointly organized by the Department of Civil
Engineering of The University of Hong Kong and Civil Division of The Hong
Kong Institution of Engineers, June 13, 2007.
World Bank (2008). Private Participation in Infrastructure Database,
http://ppi.worldbank.org (accessed on 15 June 2008).
Wu E. (2008). HK$21.6b Approved to Bankroll Arts Hub. South China Morning Post, 5
July 2008.
Xenidis, Y. and Angelides, D. (2005). The financial risks in build-operate-transfer
projects. Construction Management and Economics, 23(3), 431-441.
Yahoo (2008). Yahoo Finance,
http://au.finance.yahoo.com/currency/convert?amt=1&from=CNY&to=USD&sub
mit=Convert (accessed on 24 November 2008)
Yescombe, E.R. (2008). Public Private Partnerships – Principles of Policy and Finance,
Elsevier, Great Britain.
Yeung, F.Y. (2007). Developing aPartnering Performance Index (PPI) for Construction
Projects – A Fuzzy Set Theory Approach, PhD Thesis, The Hong Kong
References
326
Polytechnic University, Hong Kong.
Zhang, X. and AbouRisk, S.S. (2006). Relational concession in infrastructure
development through public-private partnerships. Proceedings of the CIB W89
International Conference on Building Education and Research, CIB, Hong Kong,
10 – 13 April 2006.
Zhang, X.Q. (2001). Procurement of Privately Financed Infrastructure Projects, Ph.D
Thesis, The University of Hong Kong, Hong Kong Special Administrative Region.
Zhang, X.Q. (2005a). Critical Success factors for Public–Private Partnerships in
Infrastructure Development. Journal of Construction Engineering and
Management, 131(1), 3-14.
Zhang, X.Q. (2005b). Paving the Way for Public–Private Partnerships in Infrastructure
Development. Journal of Construction Engineering and Management, ASCE,
131, 1, 71 - 80.
Zhang, X.Q. (2006). Factor Analysis of Public Clients’ Best-Value Objective in Public–
Privately Partnered Infrastructure Projects. Journal of Construction Engineering
and Management, ASCE, 132, 9, 956-965.
Appendices
327
APPENDICES
Appendix 1 Questionnaire Survey Template for Research Study
Appendix 2 Questionnaire Survey Template for Validation Process
Appendices
328
Appendix 1 Questionnaire Survey Template for Research Study
1. Your position in the organization: 2. Name of your organization: 3. Your Country of Origin: 4. Please select your primary role below:
Public sector Private sector Other Central government Financier Please specify: Local government D&B contractor Public enterprise Designer only
Contractor only Consultant / advisor Operator (facility manager) Supplier Subcontractor
5. How many years of industrial experience do you have? 5 years or below 6 – 10 years 11 – 15 years 16 – 20 years 21 years or above 6. How many PPP projects have you been involved in? None (please move on to Part B) 1 2 3 4 above 4 7. Which of the following PPP projects have you been involved with (you may tick more than one box)?
Hospital Transportation Water & Sanitary Power & Energy IT & Communication Housing & Office Defence & Naval Police & Prison School & Education Others (please specify)
B. Features of PPP Projects Please rate the following statements based on a Likert scale from 1 – 5, where 1 represents the “Least Important”; 5 represents the “Most Important”; and select “N/A”’ if you are uncertain in rating a particular statement. 1. Please rate the attractive factors for adopting PPP instead of traditional
procurement
1 2 3 4 5 N/A
a) Solve the problem of public sector budget restraint b) Provide an integrated solution (for public infrastructure / services) c) Reduce public money tied up in capital investment d) Cap the final service costs e) Facilitate creative and innovative approaches f) Reduce the total project cost g) Save time in delivering the project h) Transfer risk to the private partner i) Reduce public sector administration costs j) Benefit to local economic development k) Improve buildability l) Improve maintainability m) Technology transfer to local enterprise n) Non recourse or limited recourse to public funding o) Accelerate project development p) Others (please specify)
Developing a Best Practice Framework for Implementing Public Private Partnerships (PPP)
A. About the Respondent
Appendices
329
Please rate the following statements based on a Likert scale from 1 – 5, where 1 represents the “Least Important”; 5 represents the “Most Important”; and select “N/A”’ if you are uncertain in rating a particular statement. 2. Please rate the negative factors for adopting PPP arrangements 1 2 3 4 5 N/
A a) Reduce the project accountability b) High risk relying on private sector c) Very few schemes have actually reached the contract stage (aborted before contract) d) Lengthy delays because of political debate e) Higher charge to the direct users f) Less employment positions g) High participation costs h) High project costs i) A great deal of management time spent in contract transaction j) Lack of experience and appropriate skills k) Confusion over government objectives and evaluation criteria l) Excessive restrictions on participation m) Lengthy delays in negotiation n) Others (please specify) 3. Please rate the privileges / attractions for private sector involvement in PPP
projects
1 2 3 4 5 N/A
a) Government sponsorship b) Government assistance in financing c) Government guarantee d) Tax exemption or reduction e) Incentive of new market penetration f) Others (please specify) 4. Please rate the driving forces leading to the adoption of PPP
1 2 3 4 5 N/A
a) Economic development pressure of demanding more facilities b) Political pressure c) Social pressure of poor public facilities d) Private incentive e) Shortage of government funding f) Inefficiency because of public monopoly and lack of competition g) High quality of service required h) Avoid public investment restriction i) Lack of business and profit generating skill in the public sector j) Others (please specify) 5. Please rate the measures that enhance the achievement of Value for Money in
PPP projects
1 2 3 4 5 N/A
a) Competitive tender b) Efficient risk allocation (allocating the risk to the party best able to manage it) c) Risk transfer (transferring a substantial amount of risk from the public to the private) d) Output based specification e) Long-term nature of contracts f) Improved and additional facilities to the public sector g) Private management skill h) Private sector technical innovation i) Optimal use of asset/facility and project efficiency j) Early project service delivery k) Low project life cycle cost l) Low shadow tariffs/tolls m) Level of tangible and intangible benefits to the Users n) Environmental consideration o) Profitability to the private sector p) “Off the public sector balance sheet” treatment q) Reduction in disputes, claims and litigation r) Nature of financial innovation s) Others (please specify)
Appendices
330
Please rate the following statements based on a Likert scale from 1 – 5, where 1 represents the “Least Important”; 5 represents the “Most Important”; and select “N/A”’ if you are uncertain in rating a particular statement.
6. Please rate the factors that contribute to the success of PPP projects
1 2 3 4 5 N/A
a) Stable macro-economic condition b) Favourable legal framework c) Sound economic policy d) Available financial market e) Multi-benefit objectives f) Appropriate risk allocation and risk sharing g) Commitment and responsibility of public and private sectors h) Strong and good private consortium i) Good governance j) Project technical feasibility k) Shared authority between public and private sectors l) Political support m) Social support n) Well organised and committed public agency o) Competitive procurement process (enough potential bidders in the process) p) Transparency procurement process (process is made open and public) q) Government involvement by providing guarantee r) Thorough and realistic assessment of the cost and benefits s) Others (please specify)
C. Other Suggestions and Comments on Implementing PPP Projects
End of the questionnaire Thank you for your valuable contribution
Acknowledgement This questionnaire was adapted from Dr. Bing Li and Prof. Akintola Akintoye with their permission to compare PPP practices between different jurisdictions. Returning Questionnaire Kindly return the completed questionnaire by: (a) post to Miss Esther Cheung (Research Associate), Freepost No.58, Department of Building and Real Estate, The Hong Kong Polytechnic University, Hung Hom, Kowloon, Hong Kong; or (b) fax to (852) 2764-5131; or (c) e-mail at [email protected] Further Information If you are interested in assisting our further research work / receiving a summary of our research work, please provide your e-mail address: _____
Appendices
331
Appendix 2 Questionnaire Survey Template for Validation Process
Validation Scoring Sheet
- A Best Practice Framework for Implementing PPP in Hong Kong Purpose of the questionnaire To validate that the best practice framework for implementing PPP in Hong Kong is comprehensive, objective, reliable and practical. Background This framework was developed as part of the deliverables of a PhD research study conducted at the Queensland University of Technology in Australia by Ms. Esther Cheung. Instructions This document contains of 5 pages (1 page of background and instructions and 4 pages explaining the best practice framework). At the end of this document you are kindly requested to rate six validation aspects by simply selecting the appropriate boxes. Information of Respondent Your position in the organization: Name of your organization: Please state your primary role (i.e. public/private/other):
Your kind assistance in completing this questionnaire is very much appreciated. Please kindly return the completed form to Ms. Esther Cheung either by email: [email protected] or by fax: 852 2764 5131 on or before 31 March 2009.
Thank you in advance for your kind contribution.
Ms. Esther Cheung
17 March 2009
The Best Practice Framework for Implementing PPP in Hong Kong
According to the Efficiency Unit’s (of the Hong Kong Special Administrative Region (HKSAR) Government) process for implementing PPP projects in Hong Kong there are a total of eight steps (Figure 1). This process demonstrates “What” needs to be done in order to implement a PPP project in Hong Kong. But it does not explain “How” these activities can be achieved. By incorporating the “What” and “How”, a best practice framework for implementing PPP projects in Hong Kong has been derived. For each step of the process, users are shown “How” to implement PPP projects by a list of the “Dos” and “Don’ts”. Tables 1 to 8 show the “Dos” and “Don’ts” for each step of the PPP process.
Appendices
332
Figure 1 The process for implementing PPP projects in Hong Kong (adapted from the Efficiency Unit of the HKSARG)
Step 1 Mobilisation and development of a business case 1.1 Conduct needs analysis, market testing and PPP feasibility study 1.2 Establish a project steering committee and designate a contract manager 1.3 Establish whether a site is available 1.4 Establish what facilities/services are required 1.5 Prepare a draft Statement of Requirements 1.6 Consider whether to accept proposals for enhanced or other additional commercial facilities/services on the site 1.7 Assess risk 1.8 Prepare public sector comparator and seek policy endorsement
Step 2 Funding 2.1 Submit a bid via the policy bureau for funds through the resource allocation exercise process
Step 3 Technical assessments, consultation and land requirements 3.1 Conduct appropriate technical assessments and socio-economic studies 3.2 Seek necessary authorities’ agreement on land use 3.3 Conduct consultations with stakeholders, policy committee and legislative council panel
Step 4 Expression of interest exercise 4.1 Initiate an expression of interest exercise
Step 5 Policy and funding approvals 5.1 Consult and seek approvals of public works subcommittee of the legislative council and finance committee of the legislative
council 5.2 Determine detailed commercial arrangements 5.3 Seek draft land grant conditions
Step 6 Procurement and selection 6.1 Instruct department of justice on drafting of procurement documents/contract 6.2 Finalise procurement documents and seek approval from central tender board 6.3 Establish bid evaluation committee 6.4 Issue request for proposal and conduct briefings/site inspections 6.5 Evaluate proposals 6.6 Negotiate with bidders and select from best and final offer 6.7 Award contract
Step 7 Service commencement 7.1 Commence construction 7.2 Commissioning of facility 7.3 Commence service delivery 7.4 Establish and maintain close relationship with the consortium
Step 8 Payment and contract management 8.1 Monitor performance regularly / Make payment for the facilities/services provided 8.2 Defer or reduce payment 8.3 Institute investigations and issue warning / Initiate dispute resolution procedures 8.4 Step-in 8.5 Conduct joint inspection towards the end of the contract 8.6 Hand over facilities at the end of the contract
Appendices
333
Table 1 Guideline for conducting step 1 “Mobilisation and development of a business case”
Table 2 Guideline for conducting step 2 “Funding”
No. Dos Don’ts 1 Solve the problem of public sector budget restraint Focus on private financing only 2 Allocate the risks appropriately Allocate all financial risks to the private sector 3 Avoid political debate Intensify political debates 4 Rely on private parties that are financially incapable Rely on private financing solely 5 Avoid delays in negotiation Spend long durations over negotiation 6 Ensure an efficient and mature financial market exists Assume an efficient and mature financial market is readily
available 7 Conduct a thorough and realistic assessment of the costs and
benefits Avoid continuous assessment analysis
8 Ensure commitment and responsibility of all parties Lack commitment and responsibility 9 Ensure an economically viable project Choose projects that are uneconomical 10 Avoid public investment restriction Conduct PPP projects for financial reasons only 11 Opt for PPP to provide funding Let funding be the sole reason for PPP 12 Demonstrate appropriate risk allocation and sharing Inappropriate risk allocation and sharing 13 Demonstrate value for money Ignore value for money 14 Ensure partnership arrangement Think of self privileges only
No. Dos Don’ts 1 Prepare a public sector comparator Choose PPP without thorough investigation 2 Ensure an economically viable project Choose projects that are uneconomical 3 Streamline the process Spend long durations during mobilization 4 Consider to use PPP when improved services / products can
be achieved Use PPP when improved services / products cannot be achieved
5 Ensure appropriate risk sharing / allocation Intend to transfer large proportions of risk to a single party 6 Keep to a timeline Ignore timeframe 7 Provide an integrated solution Have unclear objectives 8 Facilitate creative and innovative approaches Limit the opportunity for the private party to show innovation
and creativity 9 Solve the problem of public sector budget restraint Consider PPP for financial reasons only 10 Minimise political debate Involve in political debate 11 Continuous training Employ inexperienced or unskilful employees 12 Public sector to show commitment Government to be indecisive on procurement method 13 Government to have clear objectives and evaluation criteria Government to have unclear objectives and evaluation criteria 14 Gain interest of general public Lack of communication with general public 15 Consider complex projects so that private sector can
maximise their ability Define project scope and design fully
16 Avoid legislation obstacles Challenge legislation system 17 Ensure an attractive financial market Force projects that have no market 18 Avoid lengthy delays Tolerate delays 19 Ensure transparent and process Lack of transparency in the process 20 Government champion from high level or treasury
departments Lack of government support
21 Positive media Bad relationship with media 22 Ensure a stable macro-economic condition Proceed under unstable economic conditions 23 Ensure project technically feasible Expect projects to work without thorough investigation on the
technical feasibility 24 Thorough and realistic assessment of the cost and benefits Leave assessment of the cost and benefits to later stages 25 Ensure partnering spirit / commitment / trust Reluctance to work with partners 26 Ensure there is a market need Consider projects with no market 27 Consider projects with large operation element Consider projects that do not involve operation 28 Ensure there is government need Consider projects that the government do not need 29 Consider projects of large scale Consider small scale projects 30 Ensure better value for money can be demonstrated Consider projects that are not value for money
Appendices
334
Table 3 Guideline for conducting step 3 “Technical assessments, consultation and land requirements”
No. Dos Don’ts 1 Ensure that improved services and products can be delivered Lack of interest to show improvement 2 Appropriate risk sharing Inefficient risk allocation 3 Ensure that the party best able to manage the risk is assigned Transfer all risks to the private sector 4 Provide integrated solution Consider short term goals only 5 Facilitate creative and innovative approaches Minimise opportunities for private efficiency and innovation 6 Ensure experience and appropriate skills Inexperienced employees 7 Gain support and interest from general public Block out the general public 8 Conduct complex projects so that private sector’s expertise
could be utilised Conduct over challenging projects
9 Avoid lengthy delays and negotiation Spend long durations during negotiation 10 Good governance Lack of government governance 11 Ensure transparent process Lack public consultation 12 Ensure that project is technically feasible Aim to achieve technically infeasible aspects 13 Conduct thorough and realistic assessment of the cost and
benefits Leave assessment of cost and benefits to later stage
Table 4 Guideline for conducting step 4 “Expression of interest exercise”
No. Dos Don’ts 1 Demonstrate appropriate risk sharing Hide details of risk allocation arrangement 2 Keep to a timetable Delay the process 3 Facilitate creative and innovative approaches Limit private sector’s chance to show creativity and
innovation 4 Government show support towards project Government appear to be indecisive 5 Have clear government objectives and evaluation criteria Government lack objectives and evaluation criteria 6 Good private sector capability Poor private sector capability 7 Government to commit to projects Government indecisive on procurement method 8 Gain support and interest from general public Lack of support and interest from general public 9 Speed up negotiation process Spend long durations during negotiation 10 Minimise private sector expenditure Expect private sector to have clear conceptual plans at this
stage 11 Partnering spirit/commitment/trust Consider self privileges only 12 Ensure transparent process Block out the general public 13 Ensure there is a market need Propose projects with no market 14 Ensure an economically viable project Choose projects that are uneconomical 15 Have well defined project objectives Have unclear project objectives 16 Propose projects that are technically feasible Propose projects that cannot be achieved technically 17 Ensure stable macro-economic condition Pursue projects under unstable macro-economic condition 18 Ensure efficient and mature financial market exists Pursue projects under inefficient and immature financial
market 19 Close connection with media Negative media 20 Ensure a favourable legal framework Pursue projects under unfavourable legal framework 21 Ensure a stable political and social environment exists Pursue projects under unstable political and social
environment 22 Ensure government need Propose projects that the government does not need 23 Propose large projects Propose small projects
Table 5 Guideline for conducting step 5 “Policy and funding approvals”
No. Dos Don’ts 1 Keep to a timetable Delays during negotiation / political debate 2 Ensure a stable social and political environment Pursue projects under unstable and political environment 3 Ensure a clear legal framework Pursue projects under an unclear legal framework 4 Ensure good governance Poor governance 5 Ensure transparent process Block out the general public 6 Gain government support and have champion from high level
or treasury department Lack of government support
7 Ensure stable macro-economic condition Pursue projects under unstable macro-economic condition
Appendices
335
Table 6 Guideline for conducting step 6 “Procurement and selection”
No. Dos Don’ts 1 Ensure a fair risk allocation mechanism Allocate large proportion of risk to a single party 2 Allocate risks to the party best able to manage them Allocate all the risks to the private sector 3 Streamline the process Waste time during administrative procedures 4 Provide an integrated solution Have unclear objectives 5 Keep to a timetable Delays during negotiation / political debate 6 Ensure a stable social and political environment Pursue projects under unstable and political environment 7 Ensure a clear legal framework Pursue projects under an unclear legal framework 8 Ensure good governance Poor governance 9 Ensure transparent process Block out the general public 10 Gain government support and have champion from high level
or treasury department Lack of government support
11 Ensure stable macro-economic condition Pursue projects under unstable macro-economic condition 12 Minimise political debate Encourage political debate 13 Government commitment Scheme aborted before contract 14 Compensation to losing bidder High participation costs 15 Select strong and good private consortium Select incapable private consortium 16 Gain general public support and interest Lack consultation with general public 17 Clear government objectives and evaluation criteria Unclear government objectives and evaluation criteria 18 Ensure positive media Negative media 19 Ensure partnering spirit / commitment / trust Lack partnering spirit / commitment / trust 20 Ensure rigorous tendering process Fixing contracts too quickly 21 Low tendering / transaction costs High tendering / transaction costs
Table 7 Guideline for conducting step 7 “Service commencement”
No. Dos Don’ts 1 Keep to the contract milestones Neglect the target milestones 2 Continuously introduce appropriate talents or resources Conduct minimal requirements 3 Continuous training Be reluctant to develop personnel 4 Communicate with general public Stop communicating with general public 5 Ensure transparent process Hide project details 6 Charge reasonable fees for facilities/services Overpriced fees for facilities/services 7 Ensure financial market Stop searching for markets 8 Ensure a stable and macro economic condition Ignore surrounding macro economic condition 9 Show good governance Government avoid responsibility 10 Government to step in if necessary Government to intrude on activities 11 Create close links with media Allow the media to gain a bad perception 12 Commitment of all parties Lack commitment 13 Partnership arrangement Consider self privileges only 14 Government to give private sector free hand to maximise their
ability Prevent private sector to maximise their potential
Table 8 Guideline for conducting step 8 “Payment and contract management”
No. Dos Don’ts 1 Check that appropriate services and products are delivered Deliver services and products of lower quality then specified
in contract 2 Show a partnership arrangement Blame partners for unsatisfactory performance 3 Encourage interest of the general public Prevent transparency 4 Government to step in if necessary Government to interfere without appropriate reason 5 Ensure a stable macroeconomic condition Ignore the surrounding macro economic condition 6 Ensure stable political and social environment Ignore changes to political and social environment 7 Conduct thorough and realistic assessment of the cost and
benefits Avoid continuous assessment analysis to minimise work load
8 Ensure efficient and mature financial market Stop creating economic opportunities 9 Ensure an economically viable project Choose projects that are uneconomical 10 Ensure continuous market need Search for new markets 11 Ensure compliance with contract terms Breach contract terms 12 Assessed by performance Assessed solely be economic return
Appendices
336
Questionnaire Please select the relative score for each validation aspect below to represent the extent of satisfaction (1 represents “poor” and 5 represents “excellent”).
Validation Aspects
Scoring Scale Poor Excellent
1 2 3 4 5 1. Degree of appropriateness 2. Degree of objectivity 3. Degree of replicability 4. Degree of practicality 5. Overall reliability 6. Overall suitability for PPP projects in Hong Kong