a presentation to the sport portfolio committee 5 …
TRANSCRIPT
Copyright Mangaung Local Municipality 2007
MANGAUNG 2010 UPDATEMANGAUNG 2010 UPDATE
A PRESENTATION TO THE A PRESENTATION TO THE SPORT PORTFOLIO COMMITTEE SPORT PORTFOLIO COMMITTEE 5 JULY 20085 JULY 2008
GEORGE MOHLAKOANA (PR. ENG)CEO MANGAUNG 2010
Copyright Mangaung Local Municipality 2007
PRESENTATION OVERVIEWPRESENTATION OVERVIEW• Matches to be hosted by Mangaung• Host City Agreement compliance update• Mangaung 2010 business plan financial allocation • Stadium facilities • Operational planning• Accommodation, Hospitality and Tourism • 2010 Marketing and communication • Volunteer programme• Safety and Security • Disaster Management, Emergency and Health services• ICT• Involvement of local businesses• Legacy projects• Challenges
Copyright Mangaung Local Municipality 2007
MANGAUNG MATCH SCHEDULE
Mangaung match schedule
A. Mangaung is Host City for 2 FIFA events
• FIFA Confederations Cup 2009 – 14 June 2009 to 28 June 2009– Host venue for semi final
• 2010 FIFA World CupTM
– 11 June 2010 to 11 July 2010– Host venue to second round (6 games)
Copyright Mangaung Local Municipality 2007
PROGRESS TO DATEHost City compliance report 28 July 2008
Good
Fast tracking needed
High risk
Copyright Mangaung Local Municipality 2007
HCA COMPLIANCE STATUSHCA COMPLIANCE STATUS• Outstanding FIFA requirements
– Advertising agreement (Clean stadium period)– Rights Protection Programme enforcement strategy– Exclusion zone and advertising space
• Areas that fall outside local government competency – Safety and security– Public transportation– Health and disaster management services
• LOC venue offices to be identified
Copyright Mangaung Local Municipality 2007
PROGRESS TO DATEBusiness Plan projects
DORA ALLOCATION 2008/2009 2009/2010 2010/2011
2010 Operating grant• Capacity building of 2010 Office• Training venues• Signages• Fan Parks• Overlay
0 R49.8 m R17.8 m
R183.551 m
R3.347 m
R204.698 m
Transport projects• ITS• Airport link feasibility study• Intermodal transport• Selbourne pedestrianisation• Parfitt avenue• Nelson Mandela upgrading• Transport operational plan
R242.617 mR5 mR5 m
R145 mR12 mR60 mR10 mR3 m
R82.168 m
Free State stadium R117.8 m R3.563 m
Total R363.417 m R135.531 m
Copyright Mangaung Local Municipality 2007
DORA EFFECT ON BUSINESS PLANDORA EFFECT ON BUSINESS PLAN• Very positive effect on projects commitment
– National : R894 m– Provincial : R64 m– City : R84 m
• Shortfall = R1.600 b – R1.042 b = R558 m
• Shortfall for the following projects.– Training venues (R200 million) – Hoffman Square (R31 million)– ICT (R168 million)– Safety and security (R24 million)– Waste Management (R10 million)
Copyright Mangaung Local Municipality 2007
PROGRESS TO DATEUpgrading of Free State stadium
FREE STATE STADIUMFREE STATE STADIUM
Copyright Mangaung Local Municipality 2007
PROJECT OVERVIEWPROJECT OVERVIEW• Upgrade main western pavilion • Increase seating capacity from 38 000 to 46 000• Accommodate FIFA/LOC spatial requirements for
change rooms, referee rooms, doping, etc• Accommodate spatial requirements for VIP and VVIP
requirements• Accommodate Media / Press • Upgrade of existing flood lights to 2000 lux• Upgrade public address system
Copyright Mangaung Local Municipality 2007
CONSTRUCTION TEAMCONSTRUCTION TEAM• The Joint Venture (RMIP) made up as follows:
– Ruwacon (Pty) Ltd– Meyker Re-teng Construction (Pty) Ltd– Ikaneng Developments– Promania 128 CC
• The JV is Free State based with about 60% black ownership
• Committed to using Local Labour, Local SMME’s and Mangaung EPWP learnership programme.
PROFILE OF LABOURPROFILE OF LABOUR LABOUR ON SITE: JULY 2008
CONTRACTOR
WORK FORCE TOTALKEY LOCAL LOCAL DISABLED DISABLED KEY LOCAL LOCAL DISABLED DISABLED
PERS. MEN WOMEN MEN WOMEN PERS. MEN WOMEN MEN WOMEN
Contracts Manager 1 3 4Site Agent 1 6 7Technicians 2 2 4Foreman 8 4 12Semi-skilled 12 12Operators 3 11 14Storeman 2 3 5Clerk 2 2Watchman 4 4General Workers 189 1 23 120 2 335
000
TOTAL 15 205 3 0 0 50 124 2 0 0 399
RMIP JVMAIN CONTR.
SUB CONTRACTORSMAIN CONTRACTOR
PERSPECTIVESPERSPECTIVES
PERSPECTIVESPERSPECTIVES
PERSPECTIVESPERSPECTIVES
PERSPECTIVESPERSPECTIVES
PERSPECTIVESPERSPECTIVES
Copyright Mangaung Local Municipality 2007
CONSTRUCTION PROGRESSCONSTRUCTION PROGRESS• Key dates
– Started 1 Sept 2007– Completion date 30 Aug 2008
• 400 jobs created (83% local) • Sub contractors appointed in consultation with MLM• Out of 8 available learners, 4 have been appointed.
The other 4 are fully committed on MLM projects• Extra 109 workers have been identified and registered
to participate in a SETA Learnership programme
Copyright Mangaung Local Municipality 2007
CONSTRUCTION PROGRESSCONSTRUCTION PROGRESS……
• 55% of the work complete (v/s Plan of 70%).• Delays due to
– Unknown services (14 days) – Illegal strike action (21 days)– Use of stadium for soccer matches (5 days)– Use of stadium for rugby– Performance of the Contractor
Copyright Mangaung Local Municipality 2007
RECOVERY PLANRECOVERY PLAN• Extra 1 fixed Crane and two mobile cranes • Additional set of shuttering for more welding • Additional working hours during week days
– But time off on pay Fridays and Saturdays • 50% working on Saturdays • Additional site team and supervisors • Night work for precast units• Regular motivational talks with the workforce by
a professional motivational speaker
Copyright Mangaung Local Municipality 2007
FURTHER OPPORTUNITY AREASFURTHER OPPORTUNITY AREAS• Work longer hours – including pay weekends• Working over weekends with full teams• Employ more qualified and experienced
personnel • Review construction planning and methodology
to limit time lost due to “learning curves”• Approach specialist contractors for
management and process support – were required (e.g. raking beams work)
• Contractor raised COSTS as shortcoming
Copyright Mangaung Local Municipality 2007
CURRENT DISPUTESCURRENT DISPUTES• Two disputes
– Payment period of 7 days v/s 21 days– Claim for extension of time
• Based on 65 days claim– Mangang offered revised completion of 30
September 2008 (20 days), with extra R1.5 m– Contractor rejected the offer – Parties currently in discussion, failing which will go
ahead with adjudication
Copyright Mangaung Local Municipality 2007
REALISTIC COMPLETION DATEREALISTIC COMPLETION DATE• Based on recovery plan, work has been
accelerated• Professional team believes
– Actual completion will be end Oct 08, beginning Nov 08
– Hiring specialist for Raking beams may speed up work more, Contractor against it due to costs
• Stadium will be completed before FIFA deadline
• Good decision by Mangaung to allow 4 months safety margin
FREE STATE RUGBY ISSUESFREE STATE RUGBY ISSUES……• MLM is stadium owner, FSRU is stadium
operator• Parties signed 20 years lease agreement, with
option to renew for another 20 years. Effective since December 2001
• Review of lease agreement essential due to capital investment
• Negotiations in progress, but not going smoothly
FREE STATE RUGBY ISSUESFREE STATE RUGBY ISSUES• Construction agreement with FSRU in place
– Allow for use of stadium during construction– Consideration of FSRU envisaged financial losses
• Financial losses estimated by FSRU as R20 m• To date received following claims
– Office accommodation – R250 000. Approved– Suite rental – R1 400 000. Rejected– Seasoned tickets – R1 600 000. Rejected– Main stand ticket – R1 400 000. Rejected– Test match ticket sales – R2 600 000. Rejected– Vodacom naming rights – R1 000 000. Vodacom to
suspend clause, but limited to exclusive use period
Copyright Mangaung Local Municipality 2007
PROGRESS TO DATEUpgrading of Training Venues
BOTSHABELO SEISA RAMABODU
Copyright Mangaung Local Municipality 2007
OPERATIONAL PLANNING
TRANSPORT PLAN
PUBLIC TRANSPORT ROUTES
RACECOURSE PARK & RIDE
NORTHRIDGE MALL, PARK & RIDE
UOFS
PARK & WALK
CUT PARK & WALK
WINDMILL CASINO PARK & RIDE
BLOEMFONTEIN AIRPORT
ACCOMODATION NODES
50-250 beds
<50 beds
<50 beds
50-250 beds
250-500 beds
250-500 beds500-1000 beds
500-1000 beds
>1000 beds
MilestonesProject TitleStart date
Finish date
Budget Year to date progress
Pedestrianizationof Elizabeth Street
Jan 07 Oct 07 R1.8 m Project completed
Pedestrianizationof SelbourneAvenue
Jan 08 Aug08 R6 m Construction about 80% complete.
SelbournePedestrian route
Jul 08 Nov 09 R12 m •Detail design to be completed Oct 2008;•Start construction 14 Jan 2009;•Complete construction 10 Nov 2009
Intermodal Public Transport Facility
Oct 07 Apr 10 R239 m •Detail planning and design completed.•Design concept accepted by NDoT. •Construction to start Jan 2009.•Complete construction May 2010
2010 Transport Operational Planning
Nov 07 Jun 10 R3 m •Initial plan done, busy with revision•Operational team needs to be appointed soon
TRANSPORT PROJECTSTRANSPORT PROJECTS
MilestonesProject TitleStart date
Finish date
Budget Year to date progress
Airport Link Oct 08 Jan 10 R113.56 m
•Detail design (conducted by SANRAL) to be completed 31 Aug 2008•MLM Council to approve financial contribution
ITS N/A N/A R5 m •No details providedNelson Mandela Drive Upgrading
Jun 08 Nov 09 R20 m •Detail design to be done - Oct 2008•Start construction - Jan 2009•Expected completion – Apr 2010
Parfitt Avenue Upgrading
Jun 08 Apr 10 R78.8 m •Detail design to be done – Sept 2008•Start construction – Mar 2009•Expected completion – Apr 2010
IRPTN N/A N/A N/A Awaiting in principle approval of project and approval to carry on with Operational Plan by MLM Council.
Mangaung Activity Corridor: Phase 1Dr Belcher
Aug 07 Aug 08 R11.05 m Construction about 96% complete.
Mangaung Activity Corridor: Phase 2Chief Moroka Crescent
Mar 08 Apr 09 R13.75 Construction about 25% complete.
Copyright Mangaung Local Municipality 2007
TRANSPORT PLAN PRIORITIESTRANSPORT PLAN PRIORITIES• Expedite implementation• Key world cup points• The use of Kimberlely airport to provide additional
capacity• The use of larger aircrafts during the event • The use of Tempe airport• Collaboration between Mangaung, Lesotho, Kimberly,
Welkom, • Increasing capacity of metered taxis by a factor of at
least 5• The role of the taxi industry• Establishment of a transport delivery team
Copyright Mangaung Local Municipality 2007
OTHER SERVICESOTHER SERVICESWater services • Business plan submitted to DWAF, no response• Detailed operational planning in progress
Roads• Detailed plans are being prepared to address
the following – Road patching– Road Sweeping– Road Marking
Copyright Mangaung Local Municipality 2007
OTHER SERVICESOTHER SERVICESSolid Waste • Detailed plans are being prepared to address
the following – Waste collection at stadium, etc– Waste recycling– Waste containers– Hours of operations– Waste management vehicles
Copyright Mangaung Local Municipality 2007
ACCOMMODATION
Copyright Mangaung Local Municipality 2007
ACCOMMODATIONACCOMMODATION• Need at least 20 000 beds for expected 40 000
spectators• Mangaung establishments - 10 884 beds • Satellite establishments - 19 000• Total accommodation - 30 000
• MATCH contracted 654 rooms v/s required 1050 for non hotel
• Challenges– Grading– Willingness to contract
Copyright Mangaung Local Municipality 2007
VOLUNTEERSVOLUNTEERS• Registration Access Venues
– Youth Centres– Public Libraries– Umsobomvu Youth Fund offices– Mobile trucks from Umsobomvu to access remote
areas• Number of Volunteers needed for FCC is 856
– LOC – 538– Mangaung – 318
• Training from Jan 09 by SETA
Copyright Mangaung Local Municipality 2007
SAFETY AND SECURITY
Copyright Mangaung Local Municipality 2007
SAFETY AND SECURITYSAFETY AND SECURITY• Working with SAPS for a local safety and security• The plan covers:
– Remote search area – Central University of Technology (CUT) site
– Concentric rings of security zones around the stadium, which covers
• Access control• Traffic free zones• Traffic warning zones
– Halfway emergency centres– Airport security– Ports of entry security (Lesotho border)– Personnel and equipment requirements for the
FCC and the FWC
Copyright Mangaung Local Municipality 2007
SAFETY AND SECURITYSAFETY AND SECURITY• City focussing on the following services
– City security– Accommodation security– Events security– Tourist attraction security– Practice venues security– Stadium security– Street security– Rights Protection Programme enforcement
Copyright Mangaung Local Municipality 2007
EMERGENCY SERVICES
Copyright Mangaung Local Municipality 2007
EMERGENCY SERVICESEMERGENCY SERVICES• Conduct fire safety inspections of all hotels,
stadiums, Fan Park and public viewing areas• Internal Disaster Management Forum
established • Development of scenario planning strategy
done– Anticipated injuries – Clear understanding of location of equipment,
isolation points (e.g. hydrants, etc)– Handling of hazardous materials
Copyright Mangaung Local Municipality 2007
CHALLENGES TO BE MANAGED BY MANGAUNG
Copyright Mangaung Local Municipality 2007
CHALLENGES TO BE MANAGEDCHALLENGES TO BE MANAGED• Institutional arrangements
– Implementation of committed projects• PTIS projects• Held a meeting with DG NDoT for intervention strategy on 4 Aug 08
– Interface between 3 spheres of government– International relations
• Outstanding business plan financial allocation – Training venues – ICT related projects
• Stadium upgrade– Delays– Disputes– Lease agreement
Copyright Mangaung Local Municipality 2007
“Ke Nako.
Celebrate Africa's Humanity”